building information centre - Universiti Teknologi Malaysia
-
Upload
khangminh22 -
Category
Documents
-
view
2 -
download
0
Transcript of building information centre - Universiti Teknologi Malaysia
DECLARATION OF THESIS / UNDERGRADUATE PROJECT PAPER AND COPYRIGHT
Author’s full name : NUR SYAIMASYAZA BT. MANSOR
Date of birth : 12 JANUARI 1987
Title : NOTICE AS CONDITION PRECEDENT TO CLAIM _
LIQUIDATED DAMAGES _
Academic Session : 2010/2011 _
I declare that this thesis is classified as:
I acknowledged that Universiti Teknologi Malaysia reserves the right as follows:
1. The thesis is the property of Universiti Teknologi Malaysia.
2. The Library of Universiti Teknologi Malaysia has the right to make copies for the
purpose of research only.
3. The Library has the right to make copies of the thesis for academic exchange.
Certified by:
SIGNATURE SIGNATURE OF SUPERVISOR
870112-02-5026 Assoc Prof. Dr. Rosli Abdul Rashid
(NEW IC NO. / PASSPORT NO.) NAME OF SUPERVISOR
Date: JULY 2011 Date : JULY 2011
NOTES : * If the thesis is CONFIDENTAL or RESTRICTED, please attach with the letter from
the organization with period and reasons for confidentiality or restriction.
UNIVERSITI TEKNOLOGI MALAYSIA
CONFIDENTIAL (Contains confidential information under the Official Secret
Act 1972)*
RESTRICTED (Contains restricted information as specified by the
organization where research was done)*
OPEN ACCESS I agree that my thesis to be published as online open access
(full text)
√
PSZ 19:16 (Pind. 1/07)
NOTICE AS CONDITION PRECEDENT TO CLAIM LIQUIDATED
ASCERTAINED DAMAGES (LAD)
NUR SYAIMASYAZA BT. MANSOR
A thesis submitted in fulfilment of the
requirements for the award of the degree of
Master in Science of Construction Contract Management.
Faculty of Built Environment
Universiti Teknologi Malaysia
July 2011
ii
DECLARATION
I declare that this thesis entitled “Notice as Condition Precedent to Claim Liquidated
Ascertained Damages (LAD)” is the result of my own research except as cited in the
references. The thesis has not been accepted for any degree and is not concurrently
submitted in candidature of any other degree.
Signature : ....................................................
Name : ....................................................
Date : ....................................................
NUR SYAIMASYAZA BT. MANSOR
iv
ACKNOWLEDGEMENT
With high gratitude to Allah S.W.T. who gave me the ideas and physical
strength in preparing this master project.
In preparing this master project, I was fortunate as I was supported and aided
by many individuals. First and foremost the special thank goes to my supervisor,
Assoc Prof. Dr. Rosli Abdul Rashid for his guidance and advice in order to complete
this master‟s project.
A special thanks to all the lecturers in Master of Science in Construction
Contract Management, for their patience and kind advice during the process of
completing this master project.
I am also thankful to my parents for their helpfulness and encouragement
while preparing this master project.
Lastly, I would like to thank my classmates for their great support, opinion
and willingness to share their knowledge towards the completion of my research.
.
v
ABSTRACT
Most forms of building contract include a clause entitling the employer to a specified
amount of damages, referred to as liquidated and ascertained damages (LAD) if the
contractor is late in constructing a project. This clause sets out the procedure and
condition that need to be followed by the employer. Some provision for example in
clause 40.1 PWD 203A (Rev. 2007) require the employer to issue notice of intention
before claiming LAD. The purpose of the issuance of notice is to inform the
contractor about the payment or deduction. However, does the issuance of notice is
condition precedent to the said claim? Some provision does not specifically expressly
state the requirement to issue notice. So, there is an argument that section 56(3) of
Contract Act is effective as an implied term to the contract. Based on the respective
situations, question arises whether the employer‟s entitlement to liquidated damages
is waived if he fails to issue the said notice. This study is carried out to determine
whether notice is condition precedent to claim liquidated damages and the legal
impact of notice provision for liquidated damages claim. The study was carried out
mainly through documentary analysis of law journals. It was found that when the
provision expressly state that notice is condition precedent, the failure to comply
with notice provision might jeopardize the employer‟s claim. However, the
employer‟s claim is not totally rejected because based on prevention principle, the
contractor who caused the delay, cannot benefit from its wrong act. When the
provision did not expressly state that notice is a condition precedent, it can be
condition precedent by implication. The argument that section 56(3) is an implied
term to the contract was wrong because section 56(3) is only applicable when the
contract becomes voidable.
vi
ABSTRAK
Kebanyakan borang kontrak pembinaan mengandungi klausa bagi membolehkan
majikan menuntut ganti rugi jika kontraktor tidak menyiapkan kerja pada tarikh siap
yang ditetapkan yang dikenali sebagai Ganti Rugi Tertentu dan Ganti Rugi
Ditetapkan. Klausa ini mengandungi prosedur dan syarat yang perlu diikuti oleh
pihak yang berkontrak. Terdapat sesetengah klausa yang menyatakan bahawa
majikan perlu mengeluarkan notis niat sebelum memohon ganti rugi seperti yang
dinyatakan di dalam klause 40.1 JKR 203A (Sem. 2007). Tujuan pengeluaran notis
adalah untuk memaklumkan kepada kontraktor mengenai pembayaran atau
pemotongan yang akan berlaku. Namun, adakah pengeluaran notis menjadi syarat
yang perlu dipenuhi sebelum membuat tuntutan tersebut? Sesetengah klausa tidak
menyatakan keperluan untuk mengeluarkan notis niat sebelum menuntut ganti rugi.
Oleh itu, terdapat pendapat mengatakan seksyen 56(3) Akta Kontrak 1950 akan
bertindak sebagai syarat tersirat kepada kontrak mereka. Berdasarkan situasi yang
dinyatakan di atas, persoalan timbul sama ada hak majikan terhadap ganti rugi akan
terjejas jika dia gagal mengelurkan notis. Kajian dijalankan untuk mengetahui sama
ada notis menjadi syarat sebelum menuntut ganti rugi dan kesan peruntukan notis
tersebut dari sudut undang-undang. Kajian telah dijalankan dengan menjalankan
analisis dokumentari jurnal undang-undang. Hasil kajian mendapati apabila klausa
menyatakan notis menjadi syarat sebelum memohon ganti rugi, kegagalan untuk
mematuhi syarat tersebut akan menjejaskan hak majikan terhadap ganti rugi tersebut.
Namun, majikan masih layak untuk menerima pampasan kerana berdasarkan prinsip
pengelakan, kontraktor tidak boleh mendapat keuntungan daripada kesalahannya
sendiri. Pendapat yang menyatakan seksyen 56(3) adalah syarat tersirat kepada
kontrak adalah salah kerana seksyen 56(3) hanya boleh terpakai apabila kontrak
tersebut menjadi kontrak yang boleh dielakkan.
vii
TABLE OF CONTENT
CHAPTER TITLE PAGE
DECLARATION ii
DEDICATION iii
ACKNOWLEDGMENTS iv
ABSTRACT v
ABSTRAK vi
TABLE OF CONTENT vii
LIST OF CASES xi
LIST OF ABBREVIATIONS xiii
LIST OF FIGURE xiv
1 INTRODUCTION 1
1.1 Background of the Study 1
1.2 Problem Statement 7
1.3 Previous Studies 8
1.4 Objective of the Study 9
1.5 Scope of the Study 10
1.6 Significance of the Study 10
1.7 Research Methodology 11
1.7.1 Identifying the Research Issue 11
1.7.2 Literature Review 12
1.7.3 Data Collection 12
1.7.4 Research Analysis 13
1.7.5 Conclusion and Recommendation 13
viii
1.8 Organization of the Thesis 15
2 LIQUIDATED AND ASCERTAINED DAMAGES (LAD) 17
2.1 Introduction 17
2.2 Definition of LAD 17
2.3 Issues Concerned on LAD 18
2.3.1 Liquidated damages vs. Penalty clause 19
2.3.2 The Requirement to Prove Loss 22
2.3.3 The Validity of LAD if the Architect/Engineer fails
to grant a timely extension of time 24
2.3.4 Can a Party Challenge the Validity of a Liquidated
Damages Sum after the Contract has been signed? 25
2.3.5 Provisional Liquidated Ascertained Damages 26
2.4 Principle element of enforceable liquidated damages 26
2.5 Benefits of imposing liquidated damages 30
2.6 Conclusion 32
3 PROVISION OF LIQUIDATED DAMAGES 34
3.1 Introduction 34
3.2 Contractual Procedure to claim LAD 35
3.2.1 Establish the Default of the Contractor 35
3.2.2 Establish the Existence and Validity of the
Liquidated Damages Clause 36
3.2.3 Determine if Employer has Waived his Rights 37
3.2.4 Determine Whether the Relevant Certificates/Notices
Have Been Issued 38
3.2.5 Employer Recovers the Liquidated Damages 39
3.3 Liquidated Damages Provision in Various Standard Forms 39
3.3.1 JKR 203A (Rev. 2007) 40
3.3.2 PAM 2006 Forms (With and Without Quantities)
Editions 40
ix
3.3.3 IEM.ME 1/94 Form 41
3.3.4 JCT 98 Standard Forms Contracts 41
3.4 Principle of Contract 43
3.4.1 Express Terms 43
3.4.2 Implied Terms 44
3.4.2.1 Terms implied by statute 44
3.5 Notices as Condition Precedent 45
3.5.1 Definition of „notice‟ 46
3.5.2 The Purpose of Notice 47
3.5.3 Definition of „condition precedence‟ 48
3.5.4 Court Interpretation of „condition precedence‟ 49
3.5 Conclusion 54
4 THE STATUS AND IMPLICATION OF NOTICE
PROVISION 55
4.1 Introduction 55
4.2 Case Analysis 56
4.2.1 Notice as Condition Precedent 56
4.2.2 Notice Not Expressly Stated as Condition
Precedent 60
4.2.3 No Notice Provision 64
4.2.4 Validity of notice 73
4.3 Conclusion 78
5 CONCLUSION AND RECOMMENDATION 79
5.1 Introduction 79
5.2 Summary of Research Findings 79
5.3 Research‟s Constraints 81
5.4 Suggestions for Further Research 81
5.5 Conclusion 82
REFERENCES 83
BIBLIOGRAPHY 88
x
LIST OF CASES
CASES PAGE
A.Bell & Son (Paddington) Ltd v CBF Residential Care &
Housing Association [1990] 46 BLR 102....................................................4,60
Alfred McAlpine Capital Projects Ltd v. Tilebox Ltd
(2005) EWHC 281 (TCC)…………………………………………...………27
Bethlehem Steel Corporation v. City of Chicago
(1965) 234 F.Supp. 726……………………………………………………..27
Brammal and Ogden Ltd v. Sheffield City Council
[1983] 29 BLR 73………………………………………………………...…36
Brisdale Resources Sdn Bhd v. Law Kim [2004] 6 MLJ 76…………………………68
Bovis Lend Lease Ltd v. Braehead Glasgow Ltd
[2000] All ER (D) 633………………………………………………..47,54,75
Bunge Corporation v. Tradax Export S.A. [1981] 1 W.L.R. 711…………..……60,63
CJ Sims Ltd v. Shaftesbury PLC [1991] 60 BLR 94…………...……………………49
Clydebank Engineering and Shipbuilding Company Limited v. Don
Jose Ramos Ysquierdo-y-Castaneda and Others [1905] AC 6…………..21,28
Dunlop Tyre v. New Garage [1915] AC 60…………………………………...…19,32
Gaymark Investments Pty Ltd v. Walter Construction Group Ltd [1999]
NTSC 143…………………………………………………………………...58
Hadley v Baxendale (1854) 9 EX 341..........................................................................1
Hariram a/l Jayaram & Ors v. Sentul Raya Sdn Bhd
[2003] 1 MLJ 22…………………………………………………………….66
Holloway Holdings Ltd v Archway Business Centre Ltd
19 August 1991, unreported..............................................................................4
xi
Jarvis Brent Ltd v. Rowlinson Construction Ltd [1990] 6 Const LJ 292............7,63,74
J.F. Finnegan Ltd v. Community Housing Association Ltd
[1995] 65 BLR 103...............................................................................62,63,73
Linggi Plantations Ltd v Jagatheesan [1972] 1 MLJ 89.......................................21,32
London Borough of Merton v. Stanley Hugh Leach [1985] 32 BLR 51…………….52
Lord Elphinstone v. Monkland Iron and Coal Company [1886]
11 App. Cas 332..............................................................................................21
Mardale Pipes Plus Ltd v Malaysian International Trading Corp
(Japan) Sdn Bhd [2009] 5 MLJ 691............................................................6,71
Multiplex Construction v Honeywell [2007] 1 BLR 195……………………………47
Osceola County, FI v. Bumble Bee Construction (1985) 479 So.2d 310………...…27
Peak Construction (Liverpool) Ltd v. McKinney Foundations
Ltd (1970) 1 BLR 114………………………………………………...24,33,57
Philips v. Attorney General of Hong Kong (1993) 61 BLR 41………………25,31,33
Pym v, Campbell [1856] 6 E & B 370………………………………………………49
Robinson v Harman (1848) 1 EXCH 850.....................................................................2
Sakinas Sdn Bhd v. Siew Yik Hau & Anor [2002] 5 MLJ 497……………...6,23,32,64
Selva Kumar a/l Murugiah v Thiagarajah a/l Retnasamy [1995]
1 MLJ 817………………………………………………………………..23,32
SS Maniam v. State of Perak [1957] MLJ 75……………………………………...3,21
Tai Kim Yew & Ors v. Sentul Raya Sdn Bhd [2004] 4 MLJ 227……………………69
Temloc v Errill Properties (1987) 39 BLR 30…………………………………...24,33
Token Construction Co Ltd v. Charlton Estates Ltd (1973) 1 BLR 48………...…...38
Tool Metal Manufacturing Co. Ltd v. Tungsten Electric Co. Ltd
[1955] 2 All ER 657…………………………………………………………37
Tunjang Wawasan Sdn. Bhd. v TNB Generation Bhd [2007] MLJU 362....................6
Wearne Brothers (M) Ltd v Jackson [1966] 2 MLJ 155…………………………….22
Wise v. United States (1919) 249 U.S. 361………………………………………….27
WW Gear Construction Ltd v. McGee Group Ltd. [2010]
EWHC 1460 TCC………………………………………………………..50,54
xii
LIST OF ABBREVIATION
All ER - All England Law Report
BLR - Building Law Report
CIDB - Construction Industry Development Board
EWHC - High Court of England and Wales
EXCH - Law Reports: Court of Exchequer
FIDIC - Federation Internatonale des Ingenieurs-Conseils
IEM - The Institute of Engineers, Malaysia
LAD - Liquidated and Ascertained Damages
MLJ - Malayan Law Journal
MLJU - Malayan Law Journal Unreported
PAM - Pertubuhan Arkitek Malaysia
PWD - Public Work Department
JCT - Joint Contracts Tribunal
CHAPTER 1
INTRODUCTION
1.1 Background of the Study
A contract is an agreement between two or more parties which creates
obligations to do or not do the specific things that are the subject of that agreement
and it is enforceable by law.1 If one of the parties failed to perform his part of the
obligation or he does it not according to the contract, he is considered to be in breach
of the contract.2 It now gives the other party the right to claim for damages for the
breach. Damages are normally assessed when breach occurs, and are designed to be
compensatory in nature.3 Two principles important for assessment of damages are
the principles of remoteness derived from the famous case of Hadley v Baxendale4 in
which Baron Alderson said:
1 Section 2 of Contracts Act 1950
2 Beatson J. (2002). Anson‟s Law of Contract. (28th ed.). United States: Oxford University Press.
p.172 3 Molloy J. B., (2001). Liquidated Damages – Some General Principles. HKIS Newsletter, 4 May p.1
4 (1854) 9 EX 341
2
"Where two parties have made a contract which one of them has broken, the
damages which the other party ought to receive in respect of such breach of
contract should be such as may fairly and reasonably be considered either
arising naturally, i.e. according to the usual course of things, from such
breach of contract itself, or such as may reasonably be supposed to have
been in the contemplation of both parties, at the time they made the contract,
as the probable result of the breach of it".5
The measures of damages are derived from the equally old case of Robinson v
Harman6 where it was stated:
"The rule of common law is that where a party sustains a loss by reason of a
breach of contract, he is, so far as money can do it, to be placed in the same
situation, with respect to damages, as if the contract had been performed".7
Damages calculated from these principles are normally assessed after the
breach occurs and are known as general or unliquidated damages. However, such
approach is difficult to assess and usually the contracting parties like certainty.8 This
lead party to include within their contracts remedies for most common breaches
which are known as liquidated damages.
Liquidated damages or usually known as liquidated and ascertained damages
(LAD) arise where the parties to a contract agree from the start the amount of
damages that one party will pay to the other in the event of a specified breach of
contract.9 In England, the imposition of the word “ascertained” is aim to put a
distinction between “liquidated damages” with “penalty” where this word will lend
5 Molloy J. B., (2001). Liquidated Damages – Some General Principles. HKIS Newsletter, 4 May p.1
6 (1848) 1 EXCH 850
7 Molloy J. B., (2001). Liquidated Damages – Some General Principles. HKIS Newsletter, 4 May p.1
8 Ibid.
9 Murdoch J. (2009). Being Late Can Have Damaging Effects. The Estates Gazette. ProQuest Direct.
3
more weight to the argument that the liquidated damages is a genuine and ascertained
pre-estimate of the Employer‟s loss. However in Malaysia, there is no such
distinction between liquidated damages and penalty.10
Most forms of building contract include a clause entitling the client to a
specified amount of damages, referred to as “Liquidated Damages” or “Liquidated
and Ascertained Damages” (LAD) if the Contractor is late in handing over the
building.11
LAD replaces the client‟s common law right to damages for late
completion with a contractual right to a pre-determined sum for the period of delay.12
These clauses are favoured by employers because they alleviate the need to prove an
actual loss. However, this did not apply in Malaysia, because the client still need to
prove the actual damages suffered pursuant to section 75 of the Contract Act 1950.13
The imposition of LAD is also purport to provide for a negotiated and fair method of
allowing for the possibility of a delay in completion of the project, which provides
adequate compensation for the purchaser/owner, while ensuring that the contractor is
not too heavily penalized for the delay.14
One of the issues that can be discussed is regarding the issuance of notice of
intention before claiming liquidated damages. If the contract clearly stated that the
employer should issue notice of intention to claim liquidated damages, does it
invalidate the employer‟s right to deduct payment if he fail to issue them? Does the
issuance of certificate of non-completion is enough to entitle the employer to claim
LAD? For example in section 40 P.W.D. Form 203A (Rev. 2007):
10
SS Maniam v. State of Perak [1957] MLJ 75 11
Clause 40.1 PWD 203A (Rev. 2007), Clause 22.1 PAM 2006, Clause 26.2 CIDB (2000 Edition) 12
Turner B., 2011. Liquidated damages clauses in construction contracts. [online] Available at:
http://www.boyesturner.com/news-article.html?id=66 [Accessed 22 January 2011]. 13
Lim C. F. (1993). Enforcement of Liquidated Damages- To Prove Actual Loss?. The Malayan Law
Journal Articles. Vol 1, 1-9. Lexis Nexis Business Solution. 14
PM Professional Resources (2010). Construction Claim and Dispute Resolution. [online] Available
at: http://www.pm-pro.com.my/ [Accessed 20 October 2010].
4
If the Contractor fails to complete the Works by the Date for Completion or
within any extended time granted pursuant to clause 43 (Delay and Extension
of Time), the S.O. shall issue a Certificate of Non-completion to the
Contractor. Prior to the issuance of the Certificate of Non-completion, the
S.O. shall issue a notice to the Contractor informing the Contractor the
intention of the Government to impose Liquidated and Ascertained Damages
to the Contractor if the Contractor fails to complete the Works by the Date
for Completion or within any extended time granted.
The clause stated that prior to the issuance of the Certificate of Non-
completion the Superintending Officer shall issue a notice to the contractor
informing the intention of the government to impose Liquidated and Ascertained
Damages. However, does the issuance of notice is considered “condition precedent”
or just information. If it is considered as condition precedent, does it waive the
employer‟s right to claim liquidated damages if the employer fail issue the notice?
In A.Bell & Son (Paddington) Ltd v CBF Residential Care & Housing
Association15
Judge John Newey QC state that the certificate of failure to complete
and a written requirement of payment or allowance under the middle part of clause
24.2.1 (JCT 98) were conditions precedent to the making of deductions on account of
liquidated damages. In Holloway Holdings Ltd v Archway Business Centre Ltd16
a
similar clause in IFC 84 was considered and it was again held that for the employer
to be able to deduct liquidated damages there must both be a certificate from the
Architect and a written request to the contractor from the employer.17
On another issue, for example in PWD 203A (Rev. 10/83), it did not mention
the requirement to give written notice of intention to claim liquidated damages.
Below is the example of the clause:
15
[1990] 46 BLR 102 16
19 August 1991, unreported 17
Chappell D. (2007). The JCT Design and Build Contract 2005. (3rd
ed.). Oxford:Wiley-Blackwell.
5
Clause 40 Damages for Non-completion (PWD 203A (Rev. 10/83))
If the Contractor fails to complete the Works by the “Date for Completion”
stated in the Appendix or within any extended time under Clause 43 hereof
and the S.O. certifies in writing that in his opinion the same ought reasonably
so to have been completed the Contractor shall pay or allow the Government
a sum calculated at the rate stated in the Appendix as Liquidated and
Ascertained Damages for the period during which the said Works shall so
remain and have remained incomplete and the S.O. may deduct such
damages from any monies due to the Contractor. The certificate issued under
this Condition shall be referred to as the “Certificate of Non-completion”.
The clause entitled the employer to claim for damages for late completion of
the project. From the clause above, there is no requirement for the employer to issue
notice of intention to claim liquidated damages. If such situation occurs, can the
contractor argue that the employer must issue notice as mention under section 56(3)
of the Contract Act? Does section 56(3) of the Contract Act is an implied term to
contract between parties?
In Section 56 (3) of Contract Act 1950 states:
If, in case of a contract voidable on account of the
promisor‟s failure to perform his promise at the time
agreed, the promisee accepts performance of the promise at
any time other than that agreed, the promisee cannot claim
compensation for any loss occasioned by the non-
performance of the promise at the time agreed, unless, at
the time of the acceptance, he gives notice to the promisor
of his intention to do so.
6
From section 56(3) of the Act, it briefly explain that when a party to the
contract cannot perform his promise within the stipulated time, the innocent party
may either terminate the contract or to treat it as still subsisting. If the innocent party
choose to treat the contract as still subsisting, either expressly or by conduct, the
contract will continue to exist but the time cease to be of the essence and becomes at
large. Consequently, the innocent party will lose their right to claim liquidated
damages under the contract. The time can be revived to be of the essence if the
innocent party serve a notice to the defaulting party before the time lapse. The notice
include the intention of the innocent party to claim compensation due to the breach
and setting a new date of completion. The issue here is whether the absence of a
clause in the contract such as in PWD 203A (Rev. 10/83) requiring the employer to
issued notice, does section 56(3) of the Contract Act 1950 serves as an implied terms
and the failure to follow them can waive the employer‟s right to liquidated damages.
In Sakinas Sdn Bhd v. Siew Yik Hau & Anor18
Abdul Aziz held that section
56(3) did not apply and that it was not necessary to give notice before a right to
impose LAD charges arose under a LAD clause. The court in Tunjang Wawasan Sdn.
Bhd. v TNB Generation Bhd19
also held the same decision that where there is a
liquidated damages clause section 56(3) does not apply.
However in Mardale Pipes Plus Ltd v Malaysian International Trading Corp
(Japan) Sdn Bhd (ExxonMobil Exploration and Production Malaysia Inc, third
party)20
the defendant argue that the requirement to give notice of intention to claim
liquidated damages as stated in section 56(3) of the Contract Act on the ground of the
Act did not apply where there was an LAD clause in the contract. The court held that
the failure to issue notice by the defendant had invalidate their right to claim LAD. In
fact the LAD clause could only be invoked when a notice under section 56(3) of the
Act had been properly given by the defendant.
18
[2002] 5 MLJ 497 19
[2007] MLJU 362 20
[2009] 5 MLJ 691
7
In Jarvis Brent Ltd v. Rowlinson Construction Ltd21
a contractor challenge
recovery of liquidated damages on grounds that the document actually received from
the employer is not the notice of liquidated damages required under the contract.22
So, what constitutes a notice? Since the clause did not specify what information
should be included in the notice, there is argument regarding the issue.
1.2 Problem Statement
Although most of the standard form contain provision for liquidated damages,
but the procedure and language in the clause is not similar. For example clause 40
(Damages for Non-completion) in PWD 203A (Rev. 10/83), there is no requirement
to issue notice by the employer before claiming liquidated damages. While in clause
22.1 PAM 2006 only state that the employer need to inform the contractor in writing
of the deduction of LAD. Although there is no requirement to issue notice in the
contract, contractor argue that notice should be given before claiming liquidated
damages pursuant to section 56(3) of Contract Act 1950 which states that at the time
of the acceptance of late delivery, the innocent party need to issue notice to state
their intention to claim damages. Question arises whether section 56(3) of Contract
Act is an implied term and shall be followed by the contracting parties.
In the new version of PWD standard form of contract, government had made
an amendment in clause 40 of PWD 203A (Rev. 2007) provides clearly express
notice requirement in the clause. It states that the employer prior to the issuance of
Certificate of Non-completion must issue notice of intention to claim liquidated
damages to inform the contractor about the payment or deduction. However, the
clause did not expressly state that notice is condition precedent to the said claim. It is
21
[1990] 6 Const LJ 292 22
Ndekugri I. and Rycroft M. (2000). The JCT 05 Standard Building Contract Law and
Administration. (2nd
ed.) Oxford: Elsevier.
8
not clear whether notice is deem as condition precedent before claiming liquidated
damages.
The foregoing discussion brings us to several pertinent questions:
1) The status of notice if it is stated as condition precedent in the LAD
provision?
2) If the provision stated the requirement to issue notice before claiming
liquidated damages but without expressly stated as condition precedent,
does it considered as condition precedent?
3) If the contract contains no express provision for notice of intention to
claim liquidated damages, is it possible to impose general act into the
contract in order to make notice as condition precedent?
4) What information should be included in the notice?
1.3 Previous Studies
There is several research studies had been carried out concerning liquidated
damages. Yong (2006) has done studies on “Liquidated and Ascertained Damages
(LAD) and Requirement of Mitigation”. The objectives were to determine the
requirement of mitigation and the extent of the employer‟s duty to mitigate his losses
when enforcing his right under the liquidated damages clause. From the research, it
was found that an employer‟s requirements to mitigate the losses is silent in standard
forms of contract, but despite that, the employer is bound to comply with the
requirements of mitigation in enforcing LAD by taking all reasonable steps or action
in accordance with principles of mitigation.
9
Chia (2009) had tried to identify the enforceability of the liquidated damages
provision in construction contract. The finding from the research found that the party
suffered losses will need to prove when claiming for compensation and required to
mitigate the losses before claim for damages. But there is an exceptions to contract of
sale and purchase under the Housing Developers Regulation 1989. This contract also
exempts the party from the need to issue notice of intention when claiming for
damages.
Mohamad Noor (2008) studied on the legal status of the practice of
provisional liquidated damaged (PLD) and identified the reasons and the effect of
imposing PLD on contractors. It was found that the contractual provisions must be
strictly adhered by the government in order to secure their right to liquidated
damages. Furthermore, in Malaysia the provisions are subject to the statutory
provisions under the Act.
1.4 Objective of the Study
The objective of study is to ascertain whether:
1) The issuance of notice is a condition precedence
2) If so, how it arise
Contract Act; or
Common Law
3) The implication of notice provision
10
1.5 Scope of the Study
The approach adopted in this research is case law based. There are no
limitations as for the court cases referred to in this study in terms of type of projects
as long as the case is related to “liquidated ascertained damages” and “notice to
claim LAD”. Types of contract involved include construction contracts (between
employer and main contractor, and between main contractor and subcontractor) and
contracts of sales of goods and land. The standard forms of contract that will be
referred to are:
a) Public Works Department (P.W.D) Form 203A (Rev. 10/83) & (Rev. 2007)
b) Pertubuhan Arkitek Malaysia (PAM) (2nd Edition, 2006)
c) Construction Industry Development Board (CIDB) Standard Form of
Contract for Building Works (2000 Edition)
d) The Institution of Engineers, Malaysia (IEM.ME 1/94 Form)
e) Joint Contracts Tribunal (JCT) Standard building contract guide (SBC/G),
(1998) & (2005b).
1.6 Significance of the Study
Poor understanding of the requirement of notification or the lack of notice has
led to disputes and disagreement amongst the various parties in construction contract.
The purpose of this study is to give an insight into the issues regarding the notice as
condition precedent to claim liquidated damages and the court reaction and its
decision concerning the issue. It is hoped that the findings of this study will assist the
players in the construction industry to understand the significance of the liquidated
damages clause in their contract, plus understand the requirement to issue notice of
11
intention to claim liquidated damages and put their best effort to avoid disputes
involving those issues.
1.7 Research Methodology
Research process and method of approach is vital as guidelines in preparing
the research so that the research could be done in an organized way to achieve the
research objective. Basically, this research process comprise of five major stages,
which involve identifying the research issue, literature review, data collection,
research analysis, conclusion and recommendation.
Stage 1 – Development of Proposal
1.7.1 Identifying the Research Issue
The initial stage involves the identification area of issues as well as
formulating the research objective. First, the overview of the concept of this
topic will be done through the initial literature review. The study issue arises
from intensive reading of books, journals and articles which can be attained
from the UTM library, Building Construction Information Centre (BCIC)
and Resource Centre of Alam Bina (RC). Once research objective has been
formulated, the scope and limitations for the research will be determined as
well as the research title.
12
1.7.2 Literature Review
Collection of various documentation and literature regarding the study
field is of most important in achieving the research objectives. Data will be
collected mainly through documentary analysis. All collected data and
information will be recorded systematically. Data will be collected mainly
from Malayan Law Journal, Singapore Law Report, Building Law Report,
Construction Law Report and other law journals. Data is collected by
browsing through the LexisNexis legal database. Important and relevant
cases will be collected and used for the analysis at the later stage. In
addition, secondary data from books, article reports, seminar papers,
newspapers and articles from the internet, is also useful for this research. All
the relevant books will be obtained from the Universiti Teknologi Malaysia
library and other public libraries.
Stage 2 – Data & Information Collection
1.7.3 Data Collection
At this stage, all the collected data, information, ideas, opinions and
comments will be arranged and recorded systematically. Important and
relevant cases is collected and use for the analysis at the later stage.
13
Stage 3 – Analysis
1.7.4 Research Analysis
The fourth stage of research is analysis phase. It involves data
analysis, interpretation and data arrangement. Once the previous related
court cases are collected, reviewing and clarifying all the facts of the cases
will be conducted. The focus will be on the issue of this research. After
identifying issues in each case, a thorough discussion and comparison will
be done in order to achieve objectives of this study.
1.7.5 Conclusion and Recommendation
In this final stage, discussions will be done based on the findings from
the previous stage to fulfil the aims or objective of this research and reach a
conclusion. Recommendations for further research will be made as a
suggestion for future researcher.
14
STAGE 2: DATA & INFORMATION COLLECTION
STAGE 4: CONCLUSION
STAGE 3: RESEARCH ANALYSIS
STAGE 1: DEVELOPMENT OF PROPOSAL
DATA AND INFORMATION COLLECTION 1. BREACH OF CONTRACT, DAMAGES
2. LIQUIDATED AND ASCERTAINED
DAMAGES (LAD)
3. NOTICE OF INTENTION TO CLAIM LAD
4. LEGAL ISSUES IN RELATION TO NOTICE
RESOURCES: 1. Books, Journals, Statutory, and cases.
2. UTM library electronic database: Lexis-Nexis
Legal Database eg. Malayan Law Journal, Appeal
Cases Report, All England Report, Building Law
Report
DETERMINATION OF
RESEARCH TITLE
SCOPE AND
LIMITATIONS
RESEARCH
OBJECTIVES
ISSUE OF THE
RESEARCH
RESEARCH METHODOLOGY 1. LITERATURE REVIEW
2. DATA AND INFORMATION
COLLECTION
3. RESEARCH ANALYSIS
CONCLUSION
OBJECTIVE:
TO ASCERTAIN WHETHER NOTICE IS CONDITION
PRECEDENT BEFORE CLAIMING LIQUIDATED DAMAGES
Figure 1.1 Research Flow Chart
15
1.8 Organization of the Thesis
1.8.1 Chapter 1: Introduction
The first chapter is an introduction to the research topic and covered a few
subtopics. The first subtopic is background of the study, followed by problem
statement which stated the issues that will be discuss in the study. Then, the next
subtopic covered on the previous research on the similar topic; objectives of the
research which stated the aims of the study; scope of the research; significance of the
study and finally the research methodology that to be used during the process of
research.
1.8.2 Chapter 2: Liquidated and Ascertained Damages (LAD)
Briefly, this chapter will covered on definition of liquidated damages, issues
concerned on LAD which include liquidated vs. penalty clause; the requirement to
prove loss; the validity of LAD if the Architect/Engineer fails to grant a timely
extension of time; can a party challenge the validity of a liquidated damages sum
after the contract has been signed; and provisional liquidated ascertained damages.
16
1.8.3 Chapter 3: Provision of Liquidated Damages
This chapter discuss on contractual procedure to claim liquidated damages. It
is divided into five subtopics ie. Establish the default of the contractor; establish the
existence and validity of the liquidated damages clause; determine if employer has
waived his rights; determine whether the relevant certificates/notices have been
issued; and employer recovers the liquidated damages. After that, the topic expend to
discuss on liquidated damages provision in various standard forms for example in
JKR 203A (Rev. 2007), PAM 2006, CIDB 2000 and etc; definition and purpose of
notice; definition and court interpretation of condition precedent.
1.8.4 Chapter 4: The Status and Implication of Notice Provision
This chapter is essential part of the research. Here, case law on condition
precedent and notice requirement before claiming liquidated damages shall be
analysed and the result discuss in a logical qualitative analysis. The task is to
ascertain the status of notice provision in liquidated damages clause; whether it is
condition precedent upon claiming liquidated damages.
1.8.5 Chapter 5: Conclusion and Recommendations
This chapter is the final part of the whole report and is a conclusion chapter. Briefly,
this chapter will give a detail summary of the research finding to a logical conclusion
of the previous chapter, highlight the problem encountered during the course of the
research and give recommendation on improving the subject area.
CHAPTER 2
LIQUIDATED AND ASCERTAINED DAMAGES (LAD)
2.1 Introduction
This chapter discusses briefly the principles of liquidated damages and its
attributes. It will be dealt with under five headings: (1) definition of LAD, (2) issues
concerned on LAD, (3) principle element of enforceable liquidated damages, (4)
benefits of imposing liquidated damages, and (5) conclusion.
2.2 Definition of LAD
Liquidated damages are variously defined. Glazov (2009) define liquidated
damages as an amount of money that contracting parties agree on as the amount of
damages one of them can recover if the party breaches the contract. For an example,
the amount of damages can be charge for per day of delay or per week.
18
Liquidated damages means a fixed and agreed sum as opposed to
unliquidated damages which is a sum which is neither fixed nor agreed, but must be
proved in court, arbitration or adjudication.23
It is a means of making the sanction for
breach explicit within a contract.
Eggleston (1997) defines liquidated damages as „a genuine pre-estimate of
the loss likely to be suffered or a lesser sum they can rightly be termed liquidated
damages.‟
2.3 Issues Concerned on LAD
Liquidated damages are always an emotive topic for both contractors and
employers alike.24
Many critics of liquidated damages provisions correctly assert that
these provisions foster finger-pointing between the parties and result in an
unnecessarily antagonistic relationship between the owner and contractor from day
one of the project.25
Apart from the issue of issuing notice of intention to claim
liquidated damages, there seems a lot of gray area concerned on the implementation
of LAD. Other issues concerned on LAD are discusses as follows.
23
Chappel D., Powell-Smith V. & Sims J. (2004). Building Contract Claims. (4th
ed.). Oxford:
Blackwell Publishing Ltd. pp 42 24
Molloy J. B., (2001). Liquidated Damages – Some General Principles. HKIS Newsletter. 25
Viscarello K. (2006) The Use of Liquidated Damages Clauses in Construction Contracts. [online]
Available at: http://www.sheehan.com/publications/good-company-newsletter/The-Use-of-
Liquidated-Damages-Clauses-in-Construction-Contracts.aspx [Accessed 20 October 2010].
19
2.3.1 Liquidated damages vs. Penalty clause
Many construction industry participants mistakenly consider a liquidated
damages provision to be a penalty clause because it often functions as an incentive
for the contractor to complete the project on time.26
Penalties, like fines or
forfeitures, may be imposed only by the courts or by other representatives of the
government, after due process of law.27
Powell-Smith (1989) defines penalty as a
sums of money inserted in a contract which is extravagant and unconscionable, the
purpose being to coerce a party to performance. Most modern forms of contract
eschew the use of „penalty‟ in favour of „liquidated damages‟, but the term is often to
be found in correspondence, site minutes and occasionally in forms of contract
drafted by construction professionals.28
It is important to note that the effect of a
penalty clause is that it is invalid and the sum is irrevocable in contrast to a bona fide
liquidated damages clause.29
The distinction between liquidated damages and penalty are defined in case
Dunlop Tyre v. New Garage.30
In this case, the clause in question was a standard
form, imposed on all of Dunlop‟s customers, that required the payment of £5 by way
of “liquidated damages” if the customer did any one of the acts of tampering with
marks on the goods; selling at under list price; supplying to persons blacklisted by
Dunlop; or exporting without Dunlop‟s consent. Lord Dunedin ruled that:
26
Friedlander M. C. (2001). Contractor Marketing- Penalty Clauses. [online] Available at:
http://www.schiffhardin.com [Accessed 23 January 2011]. 27
Ibid. 28
Chappel D., Powell-Smith V. & Sims J. (2004). Building Contract Claims. (4th
ed.). Oxford:
Blackwell Publishing Ltd. pp 44 29
Harban Singh (2002). Engineering and Construction Contracts Management Commencement and
Administration. Malaysia: LexisNexis Business Solution. 30
[1915] AC 60
20
„The distinction between penalties and liquidated and ascertained damages
depends on the intention of the parties to be gathered from the whole of the
contract. If the intention is to secure performance of the contract by the
imposition of a penalty or a fine, then the sum is a penalty; but if, on the other
hand, the intention is to assess the damages for breaches of contract, it is
liquidated and ascertained damages.‟
The principles enunciated by Lord Dunedin in Dunlop case can be
summarized as follows:
1) It will be held to be a penalty if the sum stipulated for is extravagant and
unconscionable in amount in comparison with the greatest loss that could
conceivably be proved to have followed from the breach. The essence of a
penalty is a payment of money stipulated as in terrorem of the offending
party whilst the essence of liquidated damages is genuine covenanted pre-
estimate of damage.31
2) Though the parties to a contract who use the words penalty or liquidated
damages may prima facie be supposed to mean what they say, yet the
expression used is not conclusive.32
3) The question whether a sum stipulated is a penalty or liquidated damages
is a question of construction to be decided upon the terms and inherent
circumstances of each particular contract, judged of as the time of the
making of the contract, not as at the time of the breach.33
4) It is no obstacle to the sum stipulated being a genuine pre-estimate of
damage that the consequences of the breach are such as to make precise
pre-estimation almost an impossibility.34
31
Lim C. F. (1993). Enforcement of Liquidated Damages- To Prove Actual Loss?. The Malayan Law
Journal Articles. Vol 1, 1-9. Lexis Nexis Business Solution. 32
Ibid. 33
Ibid. 34
Ibid.
21
Apart from the Dunlop case, there are few cases had laid down some
principle or approach taken in distinguishing the matter. For example Lord Watson in
Lord Elphinstone v. Monkland Iron and Coal Company35
held that there is a
presumption that it is a penalty when, „a single lump sum is made payable by way of
compensation, on the occurrence of one or more or all of several events, some of
which may occasion serious and others but trifling damage.‟ On the other hand, Lord
Halsbury in Clydebank Engineering and Shipbuilding Company Limited v. Don Jose
Ramos Ysquierdo-y-Castaneda and Others36
explained that it will be held to be a
penalty if the sum stipulated for is extravagant and unconscionable in amount in
comparison with the greatest loss that could conceivably be proven to have followed
form the breach.
In Malaysia, the existence of statutory provision37
said to cut the most
troublesome knot in the common law doctrine of damages namely, the distinction
between a penalty clause and a provision for liquidated and ascertained damages.38
It
was held in Maniam v The State of Perak39
and in Linggi Plantations Ltd v
Jagatheesan40
, there is no difference between penalty and liquidated damages. The
Privy Council in Linggi Plantations held that the intention of s 75 is to cut through
the rather technical rules of English law relating to the liquidated damages and
penalties and to apply in substance the equitable rule to all cases whether the sum
provided in the contract was in substance a penalty or a genuine pre-estimate of the
damages likely to be suffered. The equitable rule is that the court will only grant a
sum which is reasonable as representing the plaintiff s actual loss.41
35
[1886] 11 App. Cas 332 36
[1905] AC 6 37
Section 75 of Contract Act 1950 38
Lim C. F. (1993). Enforcement of Liquidated Damages- To Prove Actual Loss?. The Malayan Law
Journal Articles. Vol 1, 1-9. Lexis Nexis Business Solution. 39
[1957] 1 MLJ 75. 40
[1972] 1 MLJ 89. 41
Lim C. F. (1993). Enforcement of Liquidated Damages- To Prove Actual Loss?. The Malayan Law
Journal Articles. Vol 1, 1-9. Lexis Nexis Business Solution.
22
Lal (2008) concluded that there will be a good arguable challenge to a
specified sum stated to be liquidated damages where the payer can prove on the
balance of probabilities that the stated sum had the dominant purpose of acting as a
deterrent; and the payer can prove on the balance of probabilities that the sum was
not a genuine pre-estimate of loss, because there was a substantial discrepancy
between the stated sum and the actual claim for damages.
2.3.2 The Requirement to Prove Loss
In theory, a liquidated damages clause is an unenforceable penalty when the
actual damages are markedly less than the stipulated contractual damages.42
In
practice, however, courts will enforce a liquidated damages clause if it provides a
reasonable forecast of the losses expected to result from a breach.43
With the
distinction between liquidated damages and penalty now well settled in Malaysia, it
means that an injured party must now prove his actual loss when claim for
compensation notwithstanding the liquidated damages clause in his contract.44
The Malaysian legal position is governed by section 75 of the Contract Act
1950 which stated that the amount provided for liquidated damages will only be
enforced in favour of the innocent party if it can be shown that this amount was a
genuine pre-estimate of the damages likely to flow from the specified breach.45
The
true intention of section 75 was observed by Abdul Aziz J in Wearne Brothers (M)
42
Coldwell D., Burchett-Williams A. & Celeste M. (2010). Liquidated Damages. Franchise Law
Journal [e-journal] 29 (4) Available through: ProQuest Database [Accessed on 25 Mei 2011] 43
Ibid. 44
Lim, G. and Kasim, K. (2002). Sakinas Sdn Bhd V Siew Yik Hau & Anor (2002) 5 MLJ 498: One
Step Forward, Two Steps Back? The Malayan Law Journal Articles. Vol 3, Lexis Nexis Business
Solutions. 45
Lim C. F. (1993). Enforcement of Liquidated Damages- To Prove Actual Loss?. The Malayan Law
Journal Articles. Vol 1, 1-9. Lexis Nexis Business Solution.
23
Ltd v Jackson46
who held that: The plaintiff must prove the damages they have
suffered unless the sum named is a genuine pre-estimate. Sinnadurai (1979)
commented that the cases seem to suggest that the plaintiff cannot recover simpliciter
the sum fixed in the contract, whether as a penalty or liquidated damages. The
plaintiff is required to prove the actual damages he has suffered.47
The failure to
proof of any actual loss might jeopardize their claim for liquidated damages.
In Selva Kumar a/l Murugiah v Thiagarajah a/l Retnasamy48
the court has
laid out the principle regarding the requirement to prove actual loss suffer. This case
concerned the disputes between medical practitioners and was decided in the context
of a sale of a medical practice. It must be note that this case was heard in Federal
Court, which is the highest court in Malaysia. Therefore, this principle is binding to
all other courts. However, there is some evidence that it is not applied by the courts
in a construction context.49
In Sakinas Sdn Bhd v. Siew Yik Hau & Anor50
, the breach by the developer to
hand over vacant possession on stipulated time had caused them to pay liquidated
damages to the respondents (buyers) as stipulated in the Sale and Purchase
Agreement. The court held that late completion was a species of breach which „no
known measure of damages was employable‟ and thus the court would have to
decide the fair amount to be paid as „reasonable compensation‟. These two different
contradiction decisions thus left the issue whether actual losses need to be proved
prior to LAD being granted in a gray position. 51
46
[1966] 2 MLJ 155 47
Lim C. F. (1993). Enforcement of Liquidated Damages- To Prove Actual Loss?. The Malayan Law
Journal Articles. Vol 1, 1-9. Lexis Nexis Business Solution. 48
[1995] 1 MLJ 817 49
Chia M. L. (2009). The Enforceability of Liquidated and Ascertained Damages in Construction
Contract. Master. University Teknologi Malaysia. 50
[2002] 5 MLJ 498 51
Chia M. L. (2009). The Enforceability of Liquidated and Ascertained Damages in Construction
Contract. Master. University Teknologi Malaysia.
24
2.3.3 The Validity of LAD if the Architect/Engineer fails to grant a timely
extension of time.
Most forms of contract set down very rigid time limits for the contractor to
serve notice of a claim for an extension of time but few are so strict on the time
within which the contract administrator must act.52
A question often asked is if the
contract administrator does not grant an extension of time in a timely manner does
this invalidate the liquidated damages provisions.53
The answer to this is much to the
contractor's disappointment. In the case of Temloc v Errill Properties54
(a case
concerning the JCT form of contract) the court held that:
"Even if the provision of clause 25.3.3 [requirement for the architect to
review extension of time within 12 weeks of practical completion] is
applicable, it is directory only as to time and is not something which would
invalidate the calculation and payment of liquidated damages. The whole
right of recovery of liquidated damages under clause 24 does not depend on
whether the architect, over whom the contractor has no control, has given his
certificate by the stipulated day".
However, in Peak Construction (Liverpool) Ltd v. McKinney Foundations
Ltd55
, Lord Justice Salmon held that if the failure to complete on time is due to the
fault of both the employer and the contractor, in his view, the clause does not bite.
He further commented that there is no way that the employer can insist on
compliance with a condition if it is partly his own fault that it cannot be fulfilled. In
any event, it is clear that, even if clause 23 had provided for an extension of time on
account of the delay caused by the contractor, the failure in this case of the architect
to extend the time would be fatal to the claim for liquidated damages. Accordingly,
as the architect has not made „by writing under his hand such an extension of time‟,
52
Molloy J. B., (2001). Liquidated Damages – Some General Principles. HKIS Newsletter. 53
Ibid. 54
(1987) 39 BLR 30 55
(1970) 1 BLR 114
25
there is no date under the contract from which the defendants‟ liability to pay
liquidated damages for delay could be measured. And therefore none can be
recovered.
2.3.4 Can a Party Challenge the Validity of a Liquidated Damages Sum after the
Contract has been signed?
In English law and also the legal position in Singapore, it is always open to
the contractor to challenge that the agreed sum is a penalty.56
Whilst in the case of
Philips v. Attorney General of Hong Kong57
, the court emphasizes that the fact that
the parties were able to agree beforehand the damages recoverable for a breach of
contract was to the advantage of both parties since they should be able to estimate
with a reasonable degree of certainty the extent of their liability and the risks which
they run, it is nonetheless clear that the parties to a contract can challenge terms, if
for example, they are contrary to the law either in Statute – Control of Exemption
Clauses Ordinance or in this case at common law where for example liquidated
damages are a penalty.58
56
Lim C. F. (1993). Enforcement of Liquidated Damages- To Prove Actual Loss?. The Malayan Law
Journal Articles. Vol 1, 1-9. Lexis Nexis Business Solution. pp. 1. 57
(1993) 61 BLR 41 58
Molloy J. B., (2001). Liquidated Damages – Some General Principles. HKIS Newsletter.
26
2.3.5 Provisional Liquidated Ascertained Damages
In Malaysia, there is a practice by some of the contract administrators who
are found to impose provisional liquidated damages (PLD) without complying with
the specified contractual procedures.59
The act of deducting liquidated damages
provisionally means that the contract administrator deducts liquidated damages
without complied with the contract procedure to issue the official Certificate of Non-
completion. The prevailing local practice of deducting liquidated damages
„provisionally‟ is found to be illegal and should be discontinues.60
It may amount to a
repudiation of the contract by the employer which may entitle the contractor to
determine the contract.61
2.4 Principle element of enforceable liquidated damages
The basic essence of liquidated damages is that they represent a genuine pre-
assessment of the likely loss that will flow from the breach of contract in question.62
This follows from the general principle that the aim of damages is to place the
innocent party in the position he would have occupied had the contract been
performed without breach.63
59
Mohamad Noor S. B. (2008). Provisional Liquidated Damages (PLD). Master. University
Teknologi Malaysia. 60
Harban Singh (2002). Engineering and Construction Contracts Management Commencement and
Administration. Malaysia: LexisNexis Business Solution. pp533 61
Ibid. 62
Ndekugri I. and Rycroft M. (2000). The JCT 05 Standard Building Contract Law and
Administration. (2nd
ed.) Oxford: Elsevier. pp 280 63
Ibid.
27
The US courts apply a three-pronged test in order to determine the
enforceability of the LAD clause.64
1) The intent test, which essentially assesses whether the parties intended to
liquidated damages in advance of the parties‟ act and works.65
2) The difficulty test, which places great weight on the ascertainment of the
contractual damages regarding the degree of uncertainty involved in the
estimate. The greater the degree of difficulty in calculating the likely
future damages accurately, the more valid the LAD clause becomes in the
eyes of the court and vice versa.66
3) The reasonable test, which assesses LAD amount in view of the actual
damages suffered due to the breach. Should the court construe the
proposed damages as significantly greater than actual damages, then the
LAD provision generally is determined to be a penalty and ruled invalid.67
Tuuli, Baiden and Badu (2007) have identified the similarities between
English law and the US system regarding LADs and penalties, albeit some
differences as well. The intent test of the US system is similar to Jackson J‟s
observation68
of the primary test of genuine pre-estimate being an objective one. The
reasonableness tests in the two systems are essentially the same.69
64
Tuuli M.M., Baiden B.K. & Badu E. (2007). Assessment and Enforcement of Liquidated Damages
in Construction Contracts in Ghana. Structural Survey [e-journal] 25 (3/4) Available through:
Emerald database [Accessed 25 Mei 2011]. 65
Bethlehem Steel Corporation v. City of Chicago (1965) 234 F.Supp. 726, the court denied
Bethlehem‟s claim for $52,000.00 liquidated damages withheld by the defendant together with certain
items of interest. The court in determining this case had made consideration of the argument in Wise v.
United States which state that the courts will endeavor, by a construction of the agreement which the
parties have made, to ascertain what their intention was when they inserted such a stipulation sum for
remedies for breach of contract. 66
Osceola County, FI v. Bumble Bee Construction (1985) 479 So.2d 310 67
Wise v. United States (1919) 249 U.S. 361 68
Alfred McAlpine Capital Projects Ltd v. Tilebox Ltd (2005) EWHC 281 (TCC), Jackson J stated that
although many authorities use the phrase “genuine pre-estimate”, the test does not turn upon the
genuineness or honesty of the parties who made the pre-estimate. The test is primarily an objective
one, even though the court has some regard to the thought processes of the parties at the time of
contracting. 69
Tuuli M.M., Baiden B.K. & Badu E. (2007). Assessment and Enforcement of Liquidated Damages
in Construction Contracts in Ghana. Structural Survey [e-journal] 25 (3/4) Available through:
Emerald database [Accessed 25 Mei 2011].
28
Evidence of the difficulty tests also apply in UK which is drawn from the case
Clydebank Engineering and Shipbuilding Company Limited v. Don Jose Ramos
Ysquierdo-y-Castaneda and Others.70
In this case, Halsbury LC dismissed the claim
that the likely damages were extremely difficult to quantify and he expressed the
view that the LAD clause served a useful purpose, precisely because the true amount
of damages was uncertain and difficult to assess.
Glazov (2009) identified five principal elements of enforceable liquidated
damages and stated that these elements vary from state to state and country to
country.
1) Actual damages must be difficult to quantify
2) The amount must be liquidated (i.e., agreed on and set in advance)
Liquidated means that the contract must set the amount of damages that
the party will receive, or pay, if the other party breaches a specific promise
in the contract.
3) The amount must be reasonable
There is no exact percentage in determining whether a stipulated amount is
reasonable or not. The court will generally look to whether the presumed
loss was a reasonable estimate of potential loss at the time the clause was
agreed to.71
If so, the court will analyze whether the liquidated damages
sum is grossly and unreasonably disproportionate by examining the actual
damages.72
70
[1905] AC 6 71
Viscarello K. (2006) The Use of Liquidated Damages Clauses in Construction Contracts. [online]
Available at: http://www.sheehan.com/publications/good-company-newsletter/The-Use-of-
Liquidated-Damages-Clauses-in-Construction-Contracts.aspx [Accessed 20 October 2010]. 72
Ibid.
29
4) They must be compensation, not a penalty
The contract must focus on compensating for the party who did not breach
the contract, not punishing the party who breached the contract. If a judge
think the amount set for liquidated damages are really a penalty imposed
on the party who breach the contract, or coercive device for deterring a
potential breach, then the judge will not enforce the liquidated damages.
5) They must be exclusive (i.e., the only remedy available)
The liquidated damages must be the innocent party exclusive remedy. If
the contract provides the innocent party with an alternate way to measure
their damages, chances for the liquidated damages will be enforce is very
slim.
On the other hand, Harban Singh (2002) also listed some elements for a
successful claim for liquidated damages. For a successful imposition of liquidated
damages, it is incumbent on the employer to comply with the applicable pre-
condition, a typical list of which includes:
1) There must be included in the contract an express clause enabling the
deduction of the liquidated damages;
2) The liquidated damages clause included in the contract is valid and
enforceable;
3) The details of the liquidated damages, eg rate for the section/sections
of work covered, etc, are clearly filled in the contract;
4) All specified contractual procedures have been strictly complied with;
5) There is a definite date fixed contractually from which the damages
can run;
6) The employer has not waived the right to deduct the liquidated
damages.
30
2.5 Benefits of imposing liquidated damages
The function of LAD is to act as an inducement to „due performance of
particular contractual obligations, or to regulate beforehand in an agreed and certain
manner the rights of the parties‟.73
The imposition of LAD clause will give many
advantages. Some of the advantages are contracting parties have the certainty of
knowing in advance what the financial cost of delay is and how that risk is
allocated.74
The non-defaulting party benefits from making a recovery of damages
without the difficulty and expense of proving actual loss.75
Traditionally, the employer were having a hard time to claim damages
because the only remedy is to claim unliquidated damages which there have the
burden to prove their claim. This process involves time-consuming and costly
litigation which involves the professionals‟ fees and costs (e.g. lawyers, consultants,
expert witnesses, travel, document production and copying). As many people know,
litigation is generally recognised as being expensive and lengthy.76
To avoid this
difficulty, the LAD clause will come in handy. Fixing the damages payable for delay
beforehand may removes the uncertainty, cost and risk of suing at common law for
damages caused by the breach of contract.77
By having LAD clause, the contracting
parties can reduce the legal costs with recovery of compensation made under the
contract.78
Consequently, contractual obligations are reinforced to deter breach and
commercial tension is created for performance and/or timely delivery.79
73
Adriaanse J. (2005) Construction Contract Law – The Essential. Basingstoke: Palgrave Macmillan.
pp. 152 74
Turner & Townsend (2009). Liquidated Damages Contract Risk Management. [online] Available
at: www.turnerandtownsend.com/Liquidated_Damages_oeN9s.pdf.file [Accessed 22 January 2011]. 75
Ibid. 76
Chappel D., Powell-Smith V. & Sims J. (2004). Building Contract Claims. (4th
ed.). Oxford:
Blackwell Publishing Ltd. pp 42 77
Adriaanse J. (2005) Construction Contract Law – The Essential. Basingstoke: Palgrave Macmillan.
pp. 152 78
Turner & Townsend (2009). Liquidated Damages Contract Risk Management. [online] Available
at: www.turnerandtownsend.com/Liquidated_Damages_oeN9s.pdf.file [Accessed 22 January 2011]. 79
Ibid.
31
Basically the LAD clause not only advantages the employer but also gives
advantage to contractor. It is common use to provide advance warning to the
contractor of the financial consequences of failing to achieve practical completion by
the stipulated date.80
The liquidated damages provisions enable the contractor to
know in advance the extent of his potential liability for which he can make adequate
provisions, as to the amount and the limit involved.81
In a tender situation, it makes
fixing the contract price more certain, since the contractor can price the level of
LADs into his tender bid.82
Besides, the contractor can appreciate the financial
implications of completing, plan to complete on time or price the risk of delay.83
Contractors know from the outset how much “exposure” they have if they finish the
work late and use this information to prepare their schedules, deploy their forces, and
schedule the timing and sequence of subcontractor‟s work.84
Also, if the project is behind schedule, the contractor can make a commercial
decision to whether it would be preferable to hand the building over late and to pay
the LADs or to devote more resources to the project to bring it back on time.85
Contractors and sub-contractors benefit from the knowledge that any breach will
result in a set cost to it and often liability is capped once a certain level of liquidated
damages are reached.86
Additionally, should the Liquidated and Ascertained
Damages fail the common law default position would likely only allow the employer
to recover unliquidated damages, which are effectively „capped‟ to level of the
Liquidated and Ascertained Damages, since after all they were suppose represent a
genuine pre-estimate of the employer‟s loss.87
80
Murdoch J. (2009). Being Late Can Have Damaging Effects. The Estates Gazette. ProQuest Direct. 81
Philips Hong Kong Ltd v. Attorney General of Hong Kong [1993] 61 BLR 41 82
Turner B., 2011. Liquidated damages clauses in construction contracts. [online] Available at:
http://www.boyesturner.com/news-article.html?id=66 [Accessed 22 January 2011]. 83
Turner & Townsend (2009). Liquidated Damages Contract Risk Management. [online] Available
at: www.turnerandtownsend.com/Liquidated_Damages_oeN9s.pdf.file [Accessed 22 January 2011]. 84
Glazov J. (2009). Liquidated Damages in Construction Contracts- Enforcing Liquidated Damages.
[online] Available at: http://www.constructionlawtoday.com/ [Accessed 20 Oktober 2010]. 85
Turner B., 2011. Liquidated damages clauses in construction contracts. [online] Available at:
http://www.boyesturner.com/news-article.html?id=66 [Accessed 22 January 2011]. 86
Hawkswell Kilvington (2003). Liquidated Damages. [online] Available at:
http://www.thkp.co.uk/media/bulletins-new/Liquidated%20Damages%20%20HK.pdf [Accessed 24
Mei 2011]. 87
Always Associates (2004). Drafting for Liquidated and Ascertained Damages- Avoiding Pitfalls.
[online] Available at: http://www.alway-associates.co.uk/ [Accessed 24 Mei 2011].
32
In the Malaysian context, at the moment, the advantages of the inclusion of
such provision appear to lean more toward the contractor‟s favour88
especially in the
light of the Federal Court‟s decision in Selva Kumar a/l Murugiah v. Thiagarajah a/l
Retnasamy.89
Nevertheless, taken as a whole, the positive attributes for the inclusion
of such provisions, prima facie, outweigh the drawbacks.90
2.6 Conclusion
Liquidated damages are a fixed and agreed sum agreed by contracting parties
as the amount of damages to be paid in the event of a breach of contract.
There are many critics on the implementation of liquidated damages. Some of the
issues raised is the liquidated damages provision to be a penalty clause. Principles
laid in Dunlop Tyre v. New Garage.91
held that the court will deem the clause as
penalty if it can be prove that the sum stipulated for is extravagant and
unconscionable in amount in comparison with the actual loss. However, in Malaysia,
as in Linggi Plantations Ltd v Jagatheesan92
there is no difference between penalty
and liquidated damages. The innocent party must prove his actual loss
notwithstanding the liquidated damages clause in the contract. This principle was
held in case Selva Kumar a/l Murugiah v Thiagarajah a/l Retnasamy93
but it has
been contradicted by the decision made in the case of Sakinas Sdn Bhd v. Siew Yik
Hau & Anor.94
88
Harban Singh (2002). Engineering and Construction Contracts Management Commencement and
Administration. Malaysia: LexisNexis Business Solution pp.517 89
[1995] 2 MLJ 817, the purpose of LAD clause is to avoid the difficulty in proving the loss suffers
by the employer. However, in view of section 75 of the Contract Act 1950, provides that the court
must determine in every case, what is the reasonable compensation, whether or not actual damages or
loss is proved to have been caused thereby. 90
Harban Singh (2002). Engineering and Construction Contracts Management Commencement and
Administration. Malaysia: LexisNexis Business Solution pp.517 91
[1915] AC 60. 92
[1972] 1 MLJ 89. 93
[1995] 1 MLJ 817 94
[2002] 5 MLJ 498
33
The issue on validity of LAD if the Architect/Engineer fails to grant a timely
extension of time has been held to be valid in case Temloc v Errill Properties95
,
however in Peak Construction (Liverpool) Ltd v. McKinney Foundations Ltd96
, the
court held that the failure of the Architect to grant timely extension of time would be
fatal to the liquidated damages claim. In the case Philips v. Attorney General of
Hong Kong97
, it was held that the contractor can challenge the agreed sum is a
penalty even after the contract has been signed. On the other hand, the research
shown that the practice of deducting liquidated damages provisionally is found to be
illegal and may entitle the contractor to determine the contract.
Some principle elements of enforceable liquidated damages are the actual
damages are difficult to quantify; the amount must be reasonable; they must be
compensation; and etc. The use of liquidated damages can benefit both employer and
contractor. For employer, it will release the burden to prove loss in the event of
delay, while, for contractor, it provide advance warning to the contractor of the
financial consequences of failing to achieve practical completion by the stipulated
date.
95
[1987] 39 BLR 30 96
[1970] 1 BLR 114 97
[1993] 61 BLR 41
CHAPTER 3
PROVISION OF LIQUIDATED DAMAGES
3.1 Introduction
For the employer to seek recovery of the liquidated damages it is necessary
for him and his contract administrator to follow the detailed procedure as laid down
in the particular contract being implemented.98
Construction contract, however, are
rarely simple so it is necessary in every case to analyse the wording of the particular
conditions of contract to see what conditions precedent they impose and when they
permit damages to be deducted.99
This chapter will generally discuss on the
procedure to claim liquidated damages, the provision of liquidated damages in
various standard forms, definition and purpose of notice, definition of condition
precedent and court interpretation of its meaning.
98
Harban Singh (2002). Engineering and Construction Contracts Management Commencement and
Administration. Malaysia: LexisNexis Business Solution. pp.530 99
Eggleston B. (1997). Liquidated Damages and Extensions of Time in Construction Contracts.
Oxford: Blackwell Science.
35
3.2 Contractual Procedure to claim LAD
3.2.1 Establish the Default of the Contractor
Harban Singh (2002) state that the event that triggers the whole process for
the recovery of liquidated damages is the failure of the contractor to complete on
time. Therefore, it is a necessary pre-requisite for the contract administrator to
establish that100
:
All extensions of time for which the contractor is entitled under the contract
have been properly evaluated and issued to the contractor;
The contractor, based on the available facts and prevailing circumstances, is
not entitled at the material time to further extensions of times;
The contractor has failed to complete the works by either:
a) The original date for completion, ie in the event that he is not entitled
to any extension of time at all; or
b) The revised date for completion fixed by the contract administrator, ie
in the situation where the contractor is entitled to extension of time.
100
Harban Singh (2002). Engineering and Construction Contracts Management Commencement and
Administration. Malaysia: LexisNexis Business Solution. pp.530
36
3.2.2 Establish the Existence and Validity of the Liquidated Damages Clause
Once the hurdle of establishing breach of contract by the contractor in failing
to complete on time has been surmounted, the contract administrator must next verify
substantive issues such as101
:
The existence of an express provision in the contract pertaining to liquidated
damages;
The validity and enforceability of the said clause; and
Miscellaneous issues such as:
a) The proper filling in of the details pertaining to the liquidated
damages;
b) The existence of a definite date from which the liquidated damages
can run.
Some common grounds for challenging the validity and enforceability of
liquidated damages clause are for example the contractual provision on liquidated
damages being a penalty clause102
and that provision are being uncertain or
inconsistent103
.
101
Harban Singh (2002). Engineering and Construction Contracts Management Commencement and
Administration. Malaysia: LexisNexis Business Solution. pp.532 102
See Chapter 2 pp.19 103
Brammal and Ogden Ltd v. Sheffield City Council [1983] 29 BLR 73, liquidated damages were
expressed at the rate of £20 per week for each uncompleted dwelling, but the Appendix gave only one
date for completion and the works covered not only dwellings but also communal areas. It was held
that, in the absence of provisions for sectional completion, liquidated damages could not be claimed.
The LAD clause was held to be unenforceable because of lack of uncertainty and inconsistency.
37
3.2.3 Determine if Employer Has Waived His Rights
Eggleston (1997) stated that waiver occurs when one party expressly or
implicitly, indicates to the other his intention to forgo certain rights under a contract
and it is effective in law when the other party changes their position in reliance on
the waiver. In Tool Metal Manufacturing Co. Ltd v. Tungsten Electric Co. Ltd104
,
Lord Justice Denning held that:
„if the defendant, as he did, led the plaintiffs to believe that he would not
insist on the stipulation as to time and that if they carried out the work he
would accept it, and they did it, he could not afterwards set up the stipulation
as to time against them. Whether it be called waiver or forbearance on his
part, or an agreed variation or substituted performance, does not matter.‟
If the employer agrees to relinquish his right to liquidated damages either
expressly (by a written letter, oral representation) or impliedly105
(by inaction in
enforcing the right) the contractor is relieved of his liability accordingly.106
Therefore, for a successful claim of liquidated damages, the employer must make
sure he did not made some representations or given assurances to the contractor or
led him to believe that he would not insist on the stipulations liquidated damages.
104
[1955] 2 All ER 657 105
Centerre Trust Co. v. Continental Insurance Co. , the owner was found to have waived his right to
liquidated damages by making final payment rather than retaining funds to offset accruing liquidated
damages. The owner would have been within his right to withhold all remaining contract balances to
recover the accruing liquidated damages if he had not made final payment to the contractor. 106
Harban Singh (2002). Engineering and Construction Contracts Management Commencement and
Administration. Malaysia: LexisNexis Business Solution. pp.532
38
3.2.4 Determine Whether the Relevant Certificates/Notices Have Been Issued
Most of liquidated damages provision contains some requirement to be fulfil
before any claim can be made. Usually, the issuance of Certificate of Non-
completion is condition precedent to the said claim. Some standard forms require the
employer to issue notice of intention to claim liquidated damages which operate as a
forewarning to the contractor of the likely deductions from the amount due.
The importance of the said pre-conditions cannot be underestimated as
reflected in the judgment of Token Construction Co Ltd v. Charlton Estates Ltd107
where it was held, inter alia, that failure to comply with the conditions precedent
would render the deduction of liquidated damages unlawful and the contractor would
be able to sue for their return.108
Hence, the prevailing local practice of deducting liquidated damages
„provisionally‟ (before the issue of the official Certificate of Non-completion) or
impose provisional liquidated damages (PLD) without complying with the specified
procedures in the contract can jeopardize the employer‟s right to liquidated damages
and is prima facie illegal. This act should be discontinued because it can amount to a
repudiation of the contract by the employer which may entitle the contractor to
determine the contract, provided the corresponding ground for determination is
expressly included in the contract, for example Clause 26.1 (i) PAM 1998 Forms
(With and Without Quantities) Editions.109
107
(1973) 1 BLR 48 108
Harban Singh (2002). Engineering and Construction Contracts Management Commencement and
Administration. Malaysia: LexisNexis Business Solution. pp533 109
Ibid.
39
3.2.5 Employer Recovers the Liquidated Damages
All standard forms of conditions of contract make it clear that the recovery of
the liquidated damages is undertaken not by the contract administrator but by the
employer.110
It must be noted that the contract administrator is only act as the
employer representative and he did not have any rights to claim liquidated damages
from the contractor. The contract administrator is responsible merely in advising the
employer of this contractual right, the amount of the entitlement, the contractual
formula and the mode of affecting the same.111
Harban Singh (2002) stated that, by issuing the Certificate of Non-completion
and copying the same to the employer, the contract administrator to a large extent
fulfils the said advisory role, leaving the employer therefore to decide as to whether
to exercise his right of recovery and if so, as to the appropriate timing.
3.3 Liquidated Damages Provision in Various Standard Forms
Most standard form of contracts use in construction industry contains
provision for damages in the event of non-completion by the contractor. This
provision covers the procedure and requirement that need to be fulfilled before
claiming the liquidated damages. Some of the requirements are identified as
condition precedent. The example of the provision of this clause in various standard
forms will be discussed below.
110
Harban Singh (2002). Engineering and Construction Contracts Management Commencement and
Administration. Malaysia: LexisNexis Business Solution. pp.534 111
Ibid.
40
3.3.1 JKR 203A (Rev. 2007)
In JKR 203A (Rev. 2007) issuance of notice to the contractor informing the
deduction of money for liquidated damages is make condition precedent as stated in
Clause 40.1 Damages for Non-completion.
40.1 If the Contractor fails to complete the Works by the Date for Completion or
within any extended time granted pursuant to clause 43 (Delay and Extension of
Time), the S.O. shall issue a Certificate of Non-completion to the Contractor. Prior
to the issuance of the Certificate of Non-completion, the S.O. shall issue a notice to
the Contractor informing the Contractor the intention of the Government to impose
Liquidated and Ascertained Damages to the Contractor if the Contractor fails to
complete the Works by the Date for Completion or within any extended time granted.
3.3.2 PAM 2006 Forms (With and Without Quantities) Editions
In PAM 2006 Forms giving of notice is not expressly stated in Clause 22.1
Damages for Non-completion.
22.1 If the Contractor fails to complete the Works by the Completion Date, and the
Architect is of the opinion that the same ought reasonably so to have been completed,
the Architect shall issue a Certificate of Non-completion. Upon the issuance of the
Certificate of Non-completion, the Contractor shall pay or allow to the Employer a
sum calculated at the rate stated in the Appendix as Liquidated Damages for the
period from the Completion Date to the date of Practical Completion. The Employer
may recover such sum as a debt or may deduct such sum from any monies due or to
become due to the Contractor under the Contract or the Employer may recover such
41
sum form the Performance Bond. The Employer shall inform the Contractor in
writing of such deduction or such debt due from the Contractor.
3.3.3 IEM.ME 1/94 Form
In IEM.ME 1/94 Form Clause 31.4 deals with damages for non-completion.
Similar with JKR and PAM Form, this clause state clearly that the employer is
required to issue notice of his intention to claim a reduction for liquidated damages.
If the contractor fails to complete the works within the Time for Completion, the
employer shall be entitled to a reduction in the Contract Price unless it can be
reasonably concluded from the circumstances that the employer will suffer no loss.
The Employer shall within a reasonable time give the contractor notice of his
intention to claim a reduction. The reduction shall be the percentage per day in the
Appendix of that part of the Contract Price which is attributable to such part of the
works as cannot in consequence of the failure be put to the intended use. The
reduction shall be computed for each day between the Time for Completion and the
actual date of completion.
3.3.4 JCT 98 Standard Forms Contracts
This is an example of United Kingdom standard form of contract regarding
clause for liquidated damages. Clause 24 did not expressly stated that the employer
shall issue notice of intention before deducting. The wording in the clause did not
expressly stated the requirement to issue notice. It only stated that the employer shall
42
informed the contractor in writing that he may require payment of liquidated and
ascertained damages.
24.1 If the Contractor fails to complete the Works by the Completion Date then the
Architect shall issue a certificate to that effect....
24.2 Provided:
- The Architect has issued a certificate under clause 24.1; and
- The Employer has informed the Contractor in writing before the date of
the final Certificate that he may require payment of, or may withhold or
deduct, liquidated and ascertained damages
Almost all the local conditions of contract make the issue of the Certificate of
Non-completion (CNC) by the contract administrator a condition precedent to the
recovery of the liquidated damages by the employer, e.g. Clause 26.1 CIDB Form
(2000 Edition), Clause 22.1 PAM 1998 Forms (With and Without Quantities)
Editions, Clause 40 JKR Form 203 and 203A and IEM.CE 1/89 Form, etc.112
Some
conditions of contract for example JKR 203A (Rev. 2007)113
, PAM 2006 Forms114
,
IEM.ME 1/94115
, and JCT 98116
stipulate a further pre-condition being the giving of a
written notice by the employer of his intention to deduct damages.
112
Harban Singh (2002). Engineering and Construction Contracts Management Commencement and
Administration. Malaysia: LexisNexis Business Solution. pp.533 113
Clause 40 114
Clause 22.1 115
Clause 31.4 116
Clause 24
43
3.4 Principle of Contract
Principle of contract relates to doctrine of laissez-faire which reflects the
importance of freedom of contract.117
This doctrine promotes the ideas that since
parties are the best judges of their own interests; they should be free to make
contracts on any terms they choose – on the assumption that nobody would choose
unfavourable terms.118
Once this choice is made, the job of the courts is simply to act
as an umpire, holding the parties to their promises; it is not the courts‟ role to ask
whether the bargain made was a fair one.119
The terms of the contract can be divided
into two categories which are express terms and implied terms.
3.4.1 Express Terms
In essence, express terms are terms that have been formally asserted or
expressed.120
Vincent Powel-Smith in An Engineering Contract Dictionary describes
express terms as:
Terms which are actually recorded in a written contract or which are
expressed and agreed openly at the time the contract was made. An express
term will prevail over any term which would otherwise be implied on the
same subject matter.
117
Elliot C. and Quinn F. (2007) Contract Law. 6th
edition. Edinburgh: Pearson Education Limited.
pp.3 118
Ibid. 119
Ibid. 120
Harban K.S. (2002) Engineering and Construction Contracts Management Law and Principles.
Singapore: Lexis Nexis pp.144
44
3.4.2 Implied Terms
The law may imply into a contract a terms which the parties have not
themselves inserted which is called implied terms. Implied terms can be defines as
follows121
:
A term which will be implied (eg from statute or custom) where it is
necessary to carry out the presumed intention of the parties to a contract and
is so obvious that the parties must have intended it to apply. Such term will
not override an express term.
The implied terms may be divided into four groups: terms implied in fact;
terms implied in statute; terms implied by custom; and terms implied by trade usage.
However for this research study, the discussion will be focus on terms implied by
law.
3.4.2.1 Terms implied by statute
These are terms which the law dictates must be present in certain types of
contract, in some cases, regardless of whether or not the parties want them. For
example in this research study, the issue is whether section 56(3) of the Contract Act
1950 can be identified as an implied terms to the contract. Harban (2002) identified
three common statutes which provide that certain terms are to be implied into
particular contracts are:
121
Harban K.S. (2002) Engineering and Construction Contracts Management Law and Principles.
Singapore: Lexis Nexis pp.145
45
The Sale of Goods Act 1957;
The Hire Purchase Act 1967; and
The National Land Code 1965.
The general principles are that an implied term must122
:
1) not contradict any express term of the contract
2) be reasonable and equitable
3) be necessary to give business efficacy to the contract, such that the contract
cannot be effective without it
4) so obvious that it goes without saying, and
5) be capable of being clearly expressed.
3.5 Notices as Condition Precedent
Standard forms of contract often contain conditions precedent to the
deduction of liquidated damages (e.g. Clause 31.4 of IEM.ME 1/94).123
These work
principally to the benefit of the contractor in forewarning him of likely deductions
from amounts due, but they are also of benefit to the employer in drawing attention
to this entitlement to damages.124
122
Gillhams Solicitors (2005). Contracts & Disputes: Importance of Implied Terms. [online]
Available through: http://www.gillhams.com/articles/141.cfm [Accessed on 1 June 2011] 123
Eggleston B. (1997). Liquidated Damages and Extensions of Time in Construction Contracts.
Oxford: Blackwell Science. pp.196 124
Ibid.
46
It is common to find that provision for liquidated damages contain condition
precedent to be fulfilled. Usually, there are three stated condition precedent in
liquidated damages clause125
:
1) The contractor shall fail to complete on time;126
2) The architect shall issue a certificate to that effect (e.g. certificate of non-
completion);127
3) The employer shall give written notice of his intention to deduct damages.128
3.5.1 Definition of ‘notice’
Notice is defined as the information given of some act done, or the
interpellation by which some act is required to be done.129
It serves as a medium of
communication between the contracting parties seeking to make its recipient aware
of a fact or thing, as required by law or contract.130
It is use to state of awareness of a
fact or thing.131
There are several types of notice including public notice (or legal
notice), actual notice, constructive notice, and implied notice.132
125
Eggleston B. (1997). Liquidated Damages and Extensions of Time in Construction Contracts.
Oxford: Blackwell Science. pp.196 126
Clause 40.1 of JKR 203A (Rev. 2007) 127
Clause 40.1 of JKR 203A (Rev. 2007) 128
Clause 31.4 of IEM.ME 1/94 Form 129
Lectric Law Library (2011). Notice. [online] Available at: http://www.lectlaw.com/def2/n075.htm
[Accessed on 17 Jun 2011]. 130
YourDictionary.com (2011). Notice Law Definition. [online] Available at:
http://law.yourdictionary.com/notice [Accessed on 17 Jun 2011]. 131
Ibid. 132
Wikipedia (2011). Notice. [online] Available at: http://en.wikipedia.org/wiki/Notice [Accessed on
17 Jun 2011].
47
In this research study, notice is refer to as the notification by the employer to
the contractor of his intention to deduct the liquidated damages as per stated in the
contract.
3.5.2 The Purpose of Notice
In order to understand the importance of issuing notice, we can refer to case
Multiplex Construction v Honeywell133
. In this case Jackson J stressed the importance
of giving notice of delay:
„Contractual terms requiring a contractor to give prompt notice of delay
serve a valuable purpose; such notice enables matters to be investigated
while they are still current. Furthermore, such notice sometimes gives the
employer the opportunity to withdraw instructions when the financial
consequences become apparent.‟
The purpose of giving notice of intention to deduct liquidated damages is to
let the contractor know beforehand that their payment is going to be deducted for
compensation of late completion. Furthermore, the contractor can review the notices
received and if the correct number or form of notices have not been served properly,
then the contractor can challenge the validity of notice and the amount of liquidated
damages stated.134
Dyson J. in Bovis Lend Lease Ltd v. Braehead Glasgow Ltd135
held that the rationale for the requirement of notice stated in the provision of
liquidated damages is simply to avoid unexplained deductions from interim
payments. The employer should not be permitted to make a deduction for liquidated
damages without making clear to the contractor that that is what he is doing.
133
[2007] 1 BLR 195 134
Barton Legal (2007). Liquidated Damages – A Three Stage Process. [online] Available at:
http://www.bartonlegal.com/commercialServices.asp?Id=69&menu=7 [Accessed 28 Jun 2011]. 135
[2000] All ER (D) 633
48
3.5.3 Definition of ‘condition precedence’
A condition may be defined as a statement of fact, or a promise, which forms
an essential term of the contract.136
If the statement of fact proves untrue, or the
promise is not fulfilled, the breach may be treated as a repudiation which discharges
the innocent party from further performance of the contract.137
While, condition precedent can be defined as an event or state of affairs that
is required before something else will occur. A condition is precedent if it provides
that the contract or a term or condition within a contract will not be binding until a
specified event occurs.138
One party has to perform a condition before the other‟s
promise to perform arises.139
Before the occurrence of the specified condition/event,
there is no duty on either party to render the principal performance promised by
him/her under the agreement or relevant part thereof.140
136
Beatson, J. (2002). Anson‟s Law of Contract. (28th ed.). United States: Oxford University Press.
pp.135 137
Ibid. 138
Osborne D. (2006). Effect of Conditions Precedent on Building Contracts. Journal of Building
Appraisal. Vol 2, 188-192, Palgrave Macmillan Ltd. 139
Adriaanse J. (2005) Construction Contract Law – The Essential. Basingstoke: Palgrave Macmillan.
pp.52 140
Osborne D. (2006). Effect of Conditions Precedent on Building Contracts. Journal of Building
Appraisal. Vol 2, 188-192, Palgrave Macmillan Ltd.
49
3.5.4 Court Interpretation of ‘condition precedence’
The case Pym v, Campbell141
is an early example of the importance of a
condition precedent in law.142
Mr Pym who invented a “crushing, washing and
amalgamating machine” had entered into negotiations with Mr Campbell to sell a
one eight share of the machine‟s patent. Mr Campbell agreed to purchase the one
eight share with the proviso that the machine was to be approved by a third party
engineer. The agreement was drawn and signed by both parties. However the
requirement of the engineer‟s approval was not included in the written agreement.
Plus, the third party engineer refused to give his approval. Therefore, Campbell
refused to pay and was subsequently sued by Pym. The court held that the approval
of the engineer was a condition precedent to the contract and the court found in
favour of Campbell.
A more recent case on condition precedent can be found in case CJ Sims Ltd
v. Shaftesbury PLC143
. In this case Sims started construction work on a project after
receiving a letter of intent from Shaftesbury but before an actual contract was signed
between the parties. Work carried on and negotiations continued but no contract was
ever entered into. The letter stated:
„in the unlikely event of the contract not proceeding, CJ Sims will be
reimbursed their reasonable costs which have been and will be incurred and
costs for which they are liable including those of their sub-contractors and
suppliers, such costs to include loss of profit and contribution to overheads,
all which must be substantiated in full to the reasonable satisfaction of our
quantity surveyor.‟
141
[1856] 6 E & B 370 142
Donohoe S. (2011). The WW Gear Case, Conditions Precedent and Construction Contracts.
Structural Survey [online] 29 (2) Available through: Emerald Database [Accessed on 17 Jun 2011]. 143
[1991] 60 BLR 94
50
No agreement was ever reached and Sims claimed £1,090,038 plus value
added tax (VAT) as their reasonable costs of carrying out the work. It was held that
the letter of intent created a condition precedent so that the claimants were not
entitled to make a claim until they had substantiated their claim to the reasonable
satisfaction of the defendant‟s quantity surveyor. The result was that until the
condition was satisfied (the quantity surveyor certified the amount owed), no
payment was due to the contractor.144
The judge held that the requirement for the
quantity surveyor to substantiate the claims was a condition precedent that Sims had
to comply with before making their claim.145
Some guidelines as to how judges interpret condition precedent in a contract
were laid down by the judgement in WW Gear Construction Ltd v. McGee Group
Ltd.146
WW Gear (the employer) entered into a contract with McGee (contractor) for
substructure works for a hotel using an amended JCT Trade Contract Terms (TC/C)
2002 edition with Amendment No 1:2003 together with further bespoke
amendments. The contract contained a number of conditions precedent. The relevant
conditions of the amended JCT Trade Contract are set out below:
4.21 If the Trade Contractor makes written application to the Construction
Manager stating that he has incurred or is likely to incur direct loss and/or
expense [. . .] because the regular progress of the Works has been or is likely
to be materially affected [. . .] then the Construction Manager from time to
time [. . .] shall ascertain the amount of such loss and/or expense which has
been or is being incurred by the Trade Contractor; provided always that:
4.21.1 The Trade Contractor‟s application shall be made as soon as and in
any event not later than two months after it has become, or should have
become apparent to him that the regular progress of the Works [. . .] has
144
Adriaanse J. (2005) Construction Contract Law – The Essential. Basingstoke: Palgrave Macmillan.
pp.53 145
Donohoe S. (2011). The WW Gear Case, Conditions Precedent and Construction Contracts.
Structural Survey [online] 29 (2) Available through: Emerald Database [Accessed on 17 Jun 2011]. 146
[2010] EWHC 1460 TCC
51
been or was likely to be affected [. . .] and such application shall be formally
made in writing and fully documented and costed in detail, and it shall be a
condition precedent to the Trade Contractor’s entitlement [. . .] that the
Trade Contractor has complied fully with all of the requirements of this
clause.
The contractor submitted applications for payment every month. However in
his 18th
application for payment, there was a claim for loss and/ or expense for
approximately £1.5 million. The employer refused to pay the claim and the matter
was referred to adjudication. The decision found in favour of the contractor despite
the presence of an alleged condition precedent outlining a procedure to be followed
in the event of a claim. The adjudicator stated that the alleged condition precedent
had no effect and could be ignored.
Not satisfied with the adjudicator decision, the case was brought to
Technology and Construction Court (TCC) where Mr Justice Akenhead had to
consider a few questions regarding the condition precedent:
1) Was there an effective condition precedent in the Trade Contract between
WW Gear and McGee?
2) If there was a condition precedent, how ought it to be construed?
3) Was the condition precedent reasonable?
4) Was the condition precedent enforceable?
1) Was there an effective condition precedent in the Trade Contract between
WW Gear and McGee?
The judge in determining the issue of whether a condition precedent is
effective or not said that it depends on the form that it takes the condition
precedent‟s relationship to the contract as a whole and the general principles
52
of the Law of Contract. The use of the word “if” in clause 4.21 provided a
trigger to the procedure for ascertainment of loss and/or expense.147
The use
of the words “provided always that” was important. The judge held that this
type or wording was often the strongest sign that the parties intend there to be
a condition precedent.148
2) If there was a condition precedent, how ought it to be construed?
Counsel for the contractor argued that there was a body of case law
which said that the condition precedent ought to be construed strictly.149
Counsel for the contractor further argued that there had been an error in
drafting and therefore if construed strictly the clause became meaningless and
therefore the contractor was not prevented from claiming loss and/or
expense.150
The judge confirmed that conditions precedent was to be
construed strictly but not so strictly as to make them unenforceable where the
intention of the parties was clear.151
3) Was the condition precedent reasonable?
The judge held that the requirements of the condition precedent were
neither onerous nor difficult to comply with.152
The judge felt that the two
month time limit was not unduly onerous and noted that the words “has been
or was likely to be affected” contained in clause 4.21 gave a certain amount
of flexibility to the contractor in the submission of claims.153
The judge felt
147
London Borough of Merton v. Stanley Hugh Leach [1985] 32 BLR 51 148
Donohoe S. (2011). The WW Gear Case, Conditions Precedent and Construction Contracts.
Structural Survey [online] 29 (2) Available through: Emerald Database [Accessed on 17 Jun 2011]. 149
Ibid. 150
Ibid. 151
Ibid. 152
Ibid. 153
Ibid.
53
that the wording of condition precedent in this particular contract was
reasonable.
4) Was the condition precedent enforceable?
The answer to the question above was “yes” however the judge held
that in the absence of express words the contractor still had the right to pursue
a common law claim against WW Gear.154
The judgement in this case had laid down some criteria that will determine
the enforceability of condition precedent in the contract. First, it was held that if the
wording of a condition is clear, the judges will not interfere with the expressed
intention of the parties. Second, the judges will only make the condition enforceable
if the condition is reasonable. If the condition precedent is found to be onerous, it is
more likely that the judge will decide that the condition precedent is unenforceable.
154
Donohoe S. (2011). The WW Gear Case, Conditions Precedent and Construction Contracts.
Structural Survey [online] 29 (2) Available through: Emerald Database [Accessed on 17 Jun 2011].
54
3.6 Conclusion
Most standard form of contract use in construction contains liquidated
damages provision in the event of delay of practical completion by the contractor.
The wording in the provision stated that the employer shall issue notice of intention
to claim LAD to the contractor. In Bovis Lend Lease Ltd v. Braehead Glasgow
Ltd155
, it was held that the purpose of issuing notice is to avoid unexplained
deductions from interim payments. However, most of the provision did not expressly
state that the notice is condition precedent to the said claim. In WW Gear
Construction Ltd v. McGee Group Ltd156
the court held that the type or wording is
the strongest sign that the parties intend there to be a condition precedent. The use of
the word “if” and “provided always that” provided a trigger to the procedure for
ascertainment of loss and/or expense. Plus, the court confirmed that the condition
precedent was to be construed strictly but not so strictly as to make them
unenforceable where the intention of the parties was clear.
155
[2000] All ER (D) 633 156
[2010] EWHC 1460 TCC
CHAPTER 4
THE STATUS AND IMPLICATION OF NOTICE PROVISION
4.1 Introduction
As discuss in previous chapter, most standard form of contract contain
liquidated ascertained damages provision and most importantly it stated that the
employer shall issue notice before claiming liquidated damages. Even so, not every
provision spells out the same requirement. Some standard forms of contract do not
specifically state the requirement to issue notice to claim liquidated damages. This
can be found in Clause 40 PWD 203A (Rev. 10/83), Clause 26.2 CIDB Form (2000
Edition) and Clause 22.1 PAM 2006. While in a new version of PWD form, there is a
requirement from the employer to issue notice of intention to the contractor before
claiming LAD. This can be found in clause 40.1 PWD 203A (Rev. 2007).
Consequently, this chapter focus on analyzing the issues for this study in relation to
different case laws whereby, it will determine whether the objectives of the study
could be achieved.
56
4.2 Case Analysis
This chapter focus on discussing to ascertain whether notice is condition
precedent to claim LAD. The discussion will be divided into four parts;
1) The status of notice if it is stated as condition precedent in the LAD
provision
2) If the provision stated the requirement to issue notice before claiming
liquidated damages but without expressly stated as condition precedent,
does it considered as condition precedent?
3) If the contract contains no express provision for notice of intention to
claim liquidated damages, is it possible to impose general act into the
contract in order to make notice as condition precedent?
4) What information should be included in the notice?
4.2.1 Issue 1 – Notice as Condition Precedent
The status of notice if it is stated as condition precedent in the LAD provision.
Condition precedent occurs most commonly in construction contracts157
and
it is not limited in LAD provision. For example in clause 23.1(a) of PAM 2006 states
that the giving of notice of intention to claim extension of time shall be a condition
precedent to the said claim. While, clause 24.1(a) of PAM 2006 states that notice is a
condition precedent to contractor‟s entitlement to loss and/or expense. So, if the
provision expressly states that notice is condition precedent to the entitlement of the
157
Osborne D. (2006). Effect of Conditions Precedent on Building Contracts. Journal of Building
Appraisal. Vol 2, 188-192, Palgrave Macmillan Ltd.
57
claim, does failure to comply with notice provision will cause the party lose his right
to the said claim? Osborne (2006) stated that in such cases, the extension of time
clause provides that the issuance of notice of intention is condition precedent before
claiming extension of time, failure to comply with the condition precedent in such a
case would appear to remove the contractor‟s entitlement to an extension of time.
However, it is not right to deny one‟s right to claim his right although he did
not comply with the notice provision. Under certain circumstances, the innocent
party may be entitled to additional time or compensation even if it fails to abide by
contract notice provisions. This common law principle is the exceptions to notice
requirement known as Prevention Principle. The prevention principle comes from a
generally stated legal principle that a party cannot benefit from its own wrong.158
Sometimes known as „Peak‟ principle, the principle was first applied in the
case of Peak Construction (Liverpool) v McKinney Foundations159
where Peak
Construction (Liverpool) Ltd („Peak‟), the head contractor, contracted with the
employer, Liverpool Corporation („the corporation‟) for the construction by Peak of
a multi-storey block of flats. McKinney Foundation Ltd („McKinney‟) was the
nominated subcontractor responsible to design and construct the foundation piles. By
clause 22 of the head contract, time was to be considered of the essence on the part
of Peak who becomes liable to pay the corporation liquidated damages if the work
was not completed on time. By clause 23 of the head contract, the architect was
entitled to extend time as to him may seem reasonable” by reason (inter alia) of any
variations to the works or other “unavoidable circumstances”.
158
Winser C. (2007). The Prevention Principle After Multiplex v Honeywell. [online] Available
through: http://www.crownofficechambers.com/downloads/174.pdf [Accessed on 1 June 2011]. 159
(1990) 1 BLR 111
58
In early October 1964 it was discovered that a grave fault existed in one of
the building‟s perimeter piles and the work stopped. The parties agreed to submit the
problem to an expert. The expert reported to the parties in late May 1965. The
following day Peak wrote to the corporation asking for an instruction to carry out the
work recommended by the expert. Peak heard nothing and so wrote to the
corporation in late June. The expert‟s recommendations were finally approved by the
corporation on 30 July 1965. The remedial work was commenced by Peak on 12
August 1965 and completed in early November 1965 – some 58 weeks after the
works had been suspended. As a result of the delay, the corporation sought liquidated
damages from Peak. Peak, in turn, sought liquidated damages for that entire period
from McKinney.
The Court of Appeal held that Peak was not entitled to recover liquidated
damages from McKinney as the corporation not entitled to recover those liquidated
damages from Peak. The reason for this decision was because the court found that at
least part of the delay had been caused by the corporation itself.
In Gaymark Investments Pty Ltd v. Walter Construction Group Ltd160
employer is prevented from levying liquidated damages since the delay is caused by
his own act of prevention even though the contractor failed to submit a written notice
which under the terms of the contract was a condition precedent to the right to an
extension of time. The employer, Gaymark Investments entered into a contract with
the contractor, Walter Construction for the construction of a hotel, retail and office
complex in Darwin, Australia. Delays occurred to the progress of the works,
including a 77 days delay for which the employer was responsible. The contract
provided that the contractor should give a notice within 14 days of the cause of any
delay event, followed up by particulars of its claim for extension of time within 21
days, failing which the employer's agent would have no power to allow an extension
of time. Walter had failed to comply with these requirements.
160
[1999] NTSC 143, Supreme Court of the Northern Territories
59
As a result, the employer took liquidated damages for the period of his own
delay.161
The matter went to arbitration where the arbitrator held that the delays
caused by the employer were acts of prevention making the time for completion at
large and removing the employer‟s right to take liquidated damages.162
The employer
appeal and the case were brought to the Supreme Court. The court held that the
prevention principle did indeed present a formidable barrier to Gaymark's claim for
liquidated damages based on delays of its own making. The court agreed with the
arbitrator's reasoning that the contract failed to provide for a situation in which
Gaymark caused actual delays and Walter failed to comply with the notice
provisions. With those observations the Supreme Court refused to overturn the
decision of the arbitrator.
The findings from the above cases show that although there is condition
precedent requirement, under common law, a party cannot benefits from its wrong
act. Therefore, if the LAD clause expressly stated that the issuance of notice of
intention is condition precedent to the said claim, contractually, failure to issue the
notice may risk the employer‟s entitlement to LAD. However, the delay is not cause
by the employer‟s act of prevention and totally cause by contractor‟s fault. So, is it
fair to deny employer‟s right to LAD if he fail to issue notice as per contract? It must
be noted that the purpose of issuance of notice is to inform the contractor of the
possibility of deduction of LAD because of delay. However, although notice is not
been issued, the contractor should already aware that the project is delay since he is
the one responsible to construct the project. Plus, when there is delay, the contractor
should already expect the deduction of liquidated damages.
161
Molloy J. B. (2001). Notice Provisions – A Change in Attitude?. HKIS Newsletter. 162
Ibid.
60
4.2.2 Issue 2 – Notice Not Expressly Stated as Condition Precedent
If the provision stated the requirement to issue notice before claiming liquidated
damages but without expressly stated as condition precedent, does it considered
as condition precedent?
In determining whether the said requirement is condition precedent or not, the
approach of the courts is to determine the expressed intention of the parties from the
terms of the agreement itself. For example in Bunge Corporation v. Tradax Export
S.A.163
, a case concerned a contract for the sale of soya bean meal, the sellers were
required, by 30 June 1975, to load the goods on board chip at a single United States
Gulf port to be nominated by them. The contract further provided that the buyers
should give to the sellers „at least 15 consecutive days‟ notice of probable readiness
of vessel and of the approximate quantity required to be loaded. The buyers did not
give that notice until 17 June, by which time less than 15 days of the loading period
remained. The sellers declared the buyers in default and claimed damages for
repudiation of the contract on the ground that the term as to notice was a condition.
The House of Lords held that the term, though not expressly stated in the contract to
be a condition, was one by implication, so that its breach entitled the sellers to treat
themselves as discharged.
In A.Bell & Son (Paddington) Ltd v. CBF Residential Care & Housing
Association164
the contract used was JCT 80 Private Edition with Quantities. A date
for possession of the site was given as 28 May 1985 with a date for completion of 28
February 1986. The contractor was granted extension of time and, when he failed to
complete by the extended date, the architect issued a certificate of non-completion
and the employer gave written notice of his intention to deduct liquidated damages.
The architect granted further extension of time and the employer deducted damages
from this later date to the eventual date of practical completion. The question arise
163
[1981] 1 W.L.R. 711 164
[1990] 46 BLR 102
61
whether the architect have to issue fresh certificates of completion after every grant
of extension in a delay period, and does the employer have to issue fresh written
notices of intention to deduct?
The contractor argued that liquidated damages should not have been deducted
as the procedures required by JCT 80 had not been properly complied with since the
non-completion certificate was not re-issued to reflect the revised dates for
completion in addition with no fresh written notice of intention to deduct from
employer. There is no express word stating that notice is condition precedent to
claim liquidated damages.
Judge John Newey stated:
„there can be no doubt that a certificate of failure to complete given under
clause 24.1 (JCT 98) and a written requirement of payment or allowance
under the middle part of clause 24.2.1 were conditions precedent to the
making of deductions on account of liquidated damages or recovery of them
under the latter part of clause 24.2.1.‟
The court further stated that:
„Construing clause 24.1 strictly and in accordance with its plain and
ordinary meaning, it demands the issue of a certificate when a contractor had
not completed by "the completion date" ...... I think that when a new
completion date is fixed, if the contractor has not completed by it, a
certificate to that effect must be issued, and it is irrelevant whether a
certificate has been issued in relation to an earlier, now superseded
completion date.
62
Construing clause 24.2.1 in a similar manner to clause 24.1, since the giving
of a notice is made subject to the issue of a certificate of non-completion, if
the certificate is superseded, then logically the notice should fall with it. .....
If a new completion date is fixed, any notice given by the employer before it is
at an end.‟
From the judgement in this case, it was held that the issuance of notice of
intention to claim liquidated damages is by implication a condition precedent and
must be comply by the employer. In the event that a fresh certificate of non-
completion had been issued, a fresh notice should follow since the previous notice
has been superseded by the new certificate of non-completion.
In J.F. Finnegan Ltd v. Community Housing Association Ltd165
, Peter Gibson
LJ held that the employer‟s written requirement was a condition precedent to the
deduction of liquidated damages.166
In this case, the employer and the contractor
entered into a written contract in the JCT 80 for the construction of 18 flats in a 7
storey block with associated and site development works at 46-47 Coram Street,
London WC1. The completion date was 15 months after the date for possession of
the site. The issue in this case was whether notice is condition precedent and what
information must such requirement in writing give?
The provision in the contract was as follow:
24.2.1 Subject to the issue of a certificate under clause 24.1 the Contractor
shall, as the Employer may require in writing not later than the date of the
Final Certificate, pay or allow to the Employer the whole or such part as may
be specified in writing by the Employer of a sum calculated at the rate stated
165
[1995] 65 BLR 103 166
Chappel D., Powell-Smith V. & Sims J. (2004). Building Contract Claims. (4th
ed.). Oxford:
Blackwell Publishing Ltd. pp 224
63
in the Appendix as liquidated and ascertained damages for the period
between the Completion Date and the date of Practical Completion and the
Employer may deduct the same from any monies due or to become due to the
Contractor under this Contract (including any balance stated as due to the
Contractor in the Final Certificate) or the Employer may recover the same
from the Contractor as a debt.
The provision did not expressly state that notice should be issued before
claiming liquidated damages. The requirement in writing means no more and no less
than was the employer intention with regard to liquidated damages.167
The language
of the clause makes clear that the entitlement of the employer to deduct or recover
liquidated damages is dependent on the employer indicating by such requirement.168
From the language of the clause, there are only two matters which must be contained
in the written requirement. First, whether the employer is claiming a payment or a
deduction in respect of liquidated damages and second, what sum is being deducted,
the whole or only part of the sum for the liquidated damages.169
The judge went on
stating that the notice should indicate at least the basic details which are being relied
upon to justify the deduction including the period of overrun and the figure for
deduction which is claimed.170
Based on the judgement of the cases discuss above, shows that where there is
notice requirement in liquidated damages provision, although it is not stated as
condition precedent, but it can be by implication condition precedent to claim
liquidated damages. This decision was supported in case Bunge Corporation v.
Tradax Export S.A.171
. Important to note that, when interpreting the meaning of a
contractual term, the judges will try to discover what the parties appeared to intend
the contract to mean and the intention of the parties. From the cases, it was held that
the language of the clause makes clear that the entitlement of the employer to deduct
167
Jarvis Brent Ltd v. Rowlinson Construction Ltd [1990] 6 Const LJ 292 168
J.F. Finnegan Ltd v. Community Housing Association Ltd [1995] 65 BLR 103 169
Ibid. 170
Ibid. 171
[1981] 1 W.L.R. 711
64
or recover liquidated damages is dependent on the employer indicating by such
requirement.
4.2.3 Issue 3 – No Notice Provision
If the contract contains no express provision for notice of intention to claim
liquidated damages, is it possible to impose general act into the contract in
order to make notice as condition precedent?
In Malaysia, when there is no requirement to issue notice in the contract,
some contractor will argue that the employer is not entitle to liquidated damages
without issuing notice pursuant to section 56(3) of Contract Act 1950. Does section
56(3) of Contract Act 1950 is an implied term for the issuance of the notice?
First, the analysis will be done by referring to Malaysian cases regarding this
issue. In Sakinas Sdn Bhd v. Siew Yik Hau & Anor172
, the respondents entered into an
agreement („SPA‟) to purchase an apartment from the developer. Vacant possession
of the apartment should have been given on 13 December 1997. There was a failure
on the part of the appellant to hand over vacant possession of the apartment and to
complete the common facilities in time. The respondents brought an action in the
magistrate‟s court to claim damages for the delay. The respondents applied for
summary judgment and succeeded. The appellant appealed. The appellant argue that
the respondent is not entitled for the liquidated damages since at the time the
respondents received vacant possession on 15 September 1998, they had accepted
performance of the appellant‟s promise at a time other than the agreed date of
delivery of vacant possession. Since the respondents did not give to the appellant
172
[2002] 5 MLJ 497
65
notice of their intention to claim compensation for late delivery on 15 September
1998 pursuant to s 56(3) of the Contracts Act 1950, the appellant argued that the
respondents could not claim compensation now.
Abdul Aziz J interpreted s 56(3) of the Contracts Act 1950 as follow:
In my opinion, the words „at any time other than that agreed‟ do not refer to
the act of accepting performance of the promise, but refer to the performance
of the promise itself. The words „If ... the promisee accepts performance of
the promise at any time other than that agreed‟ do not mean that
performance has been delayed but is now completed and the promisee now,
at a time later than the agreed time, accepts the performance. If that were so,
and the promisee now gives notice of intention to claim compensation, the
notice cannot be of any practical use to the promisor, except to enable him to
know in advance that there will be a claim against him and he had better get
ready with the money to pay his lawyers, and the promisee, if the promisee
should succeed, which I do not think is the intended purpose of the notice.
The phrase really means, in my opinion, the promisee accepting, meaning
agreeing, that the promisor who has been in breach as to time may perform
his promise at some other time, which has to be a time later than the time of
the promisee‟s so agreeing. At the time of the promisee‟s so agreeing, the
performance has not been completed yet. The promisee says, „It‟s all right.
Although the contract is now voidable because of your delay, I will not void
it. You may complete it later, on such and such a date‟. At the time that he
says so, the promisee, if he wants to claim compensation for the delay, must
give notice of his intention to claim compensation, otherwise the promisor is
entitled to assume that he will not be liable to any compensation. The notice
is important as it will enable him to come to a commercial decision whether it
is viable for him to go on performing if he is going to have to pay
compensation.
66
The judge concluded that s 56(3) does not apply to the respondents unless
when the contract became voidable on 13 December 1997, or soon after that, they
indicated to the appellants that it was acceptable to them if the appellants fulfilled
their promise at some other time. However, it must be noted that s 56(3) only
applicable if the contract is voidable. The circumstances that contract is voidable is
when the contract formed is influence by coercion173
, undue influence174
, fraud175
and misrepresentation.176
In this case, the act of failure to give notice of intention to
claim liquidated damages did not amount to voidable contract but only a breach.
Therefore, the respondents still entitled liquidated damages although notice has not
been issued.
In Hariram a/l Jayaram & Ors v. Sentul Raya Sdn Bhd177
, the plaintiffs
agreed to purchase condominium units from the defendant (the developer). The
agreements were in accordance with Schedule „H‟ to the Housing Developers
(Control and Licensing) Regulations 1989 („the Housing Regulations‟) which were
in turn made under the Housing Developers (Control and Licensing) Act 1966 („the
Housing Act‟). The defendant failed to hand over vacant possession within the
stipulated time and the plaintiff claim RM 1,592,074.89 as liquidated damages. There
were two issues raised by the defendant:
(i) whether s 56(3) of the Contracts Act 1950 („the Contracts Act‟) would
operate to exclude a claim for liquidated ascertained damages by reason
of the failure on the part of the plaintiffs to give the relevant notices to the
defendant of their intentions to claim liquidated ascertained damages at
the time of acceptance of later performance;
(ii) whether the terms of the sale and purchase agreements can be said to
operate to entitle the plaintiffs to liquidated ascertained damages in any
173
Section 15 of Contract Act 1950 174
Section 16 of Contract Act 1950 175
Section 17 of Contract Act 1950 176
Section 18 of Contract Act 1950 177
[2003] 1 MLJ 22
67
event despite the provisions of s 56(3) of the Contracts Act as to the
requirement of the relevant notices.
There was an express term in clause 24(2) of the sale and purchase
agreements, that if the defendants failed to complete the common facilities within 36
months, the defendant shall pay immediately to the plaintiffs liquidated damages to
be calculated from day to day at the rate of 10% pa of the last 20% of the purchase
price. Abdul Malik Ishak J held that one must not purport to go around the Housing
Act and the Housing Regulations so as to remove the protection accorded to the
plaintiffs as house-buyers by importing s 56(3) of the Contracts Act. It would
certainly be erroneous in the extreme to burden the plaintiffs as purchasers with the
requirement of s 56(3) of the Contracts Act when the Housing Act and the Housing
Regulations do not impose such a burden. Any attempt to impose such a burden will
taint and remove the very protection which the Housing Act under which the
Housing Regulations were made was enacted for. Plus the presence of the words
„shall pay immediately‟ in the LAD clause has given a purposive interpretation,
meaning automatically attracting the invocation of the LAD without the need to issue
a notice at the time of acceptance of late delivery.
The judge further explained that the Contracts Act 1950 is a piece of
legislation of a general nature setting out the general law governing contracts
between the parties, in general, whereas, the Housing Act was enacted to „provide for
the control and licensing of the business of housing development in West Malaysia
and for matters connected therewith‟. In short, it is a piece of specific legislation
governing the sale of houses by a licensed developer. The plaintiffs‟ claims for
liquidated ascertained damages were not based on the general contract but rather on
the standard sale and purchase agreements as set out in accordance with Schedule
„H‟ to the Housing Regulations which were made under the Housing Act.
68
The judge in this case also referred to the decision in Sakinas and referred to
Abdul Aziz J interpretation of s 56(3). From the interpretation, Abdul Malik Ishak J
commented that Sakinas case laid down the principle that the notice is to be given
when the promise expressly affirms the contract. However, the judge failed to
identify that the s 56(3) is only applicable when the contract is voidable. Although
the decision to allow the purchaser to claim liquidated damages without issuing
notice is a correct decision, but the judge could make the argument stronger and
certain if he recognize this fact.
In other different case, Brisdale Resources Sdn Bhd v. Law Kim178
, the
respondent, being the plaintiff in the sessions court proceedings, had succeeded in
obtaining a summary judgment against the appellant (the defendant in the said
proceedings) for liquidated damages for late delivery of vacant possession. Displease
with the judgment, Brisdale appeal to the court and the one of the issues raised were
whether the plaintiff needs to give notice of his intention to claim for damages for
delivery.
Faiza Tamby Chik J held that:
It is true that the sale and purchase agreement is a „contract‟, however it was
made in accordance with Schedule H of the Housing Developers (Control
and Licensing) Act 1966 for accommodation units. As there is a specific Act
pertaining to the area of law to it, the Contracts Act 1950, which is a general
Act, is therefore not applicable in the instant case. The said sale and
purchase agreement was drafted in accordance with „Schedule H‟ of the
Housing Developers (Control and Licensing) Act 1966 for accommodation
type and it is a statutory contract which cannot be „contracted out‟, unless
with the consent of the Controller of Housing or Government. The intention is
to protect purchasers such as the plaintiff from the defendant who has a more
178
[2004] 6 MLJ 76
69
bargaining power and who unilaterally takes advantage of interpreting the
plaintiff‟s conduct as a waiver and who could refuse to pay compensation
even though in breach of the agreement.
The judge further added that there is no provision in the said sale and
purchase agreement which requires the plaintiff to give the said notice. If the
defendant required notice to be given by the plaintiff as soon as the defendant
breached the time in handing over vacant possession, then the defendant should
provide for the same as an important term in the sale and purchase agreement by
applying to the authorities for approval to add the terms pertaining to the notice.
Basically, Faiza Tamby Chik J also did not acknowledge that s 56(3) of
Contract Act 1950 is applicable to a voidable contract. The judge went on explaining
application of general act with specific act by commenting that s 56(3) of Contract
Act 1950 was applicable in general for all types of contract, while „Schedule H‟ of
the Housing Developers (Control and Licensing) Act 1966 is specific to sale and
purchase agreement.
The case of Tai Kim Yew & Ors v. Sentul Raya Sdn Bhd179
is quite similar to
the above cases. The 15 plaintiffs, who are purchasers of apartments (condominium
units) in a condominium in Kuala Lumpur known as Sang Suria Condominium,
claim for delay in the delivery of vacant possession against the defendant company, a
property developer from whom they had purchased the condominium units. The
defendant however, refused to acknowledge the plaintiffs‟ claim invoking s 56(3)
Contracts Act 1950 that plaintiff must give notice of his intention to claim LAD.
Mohd Hishamudin J made judgment in favour of the plaintiff and held that:
179
[2004] 4 MLJ 227
70
In my judgment, I am in agreement with the learned counsel for the plaintiffs
that the right of the plaintiffs to LAD is solely governed by cll 22(2) and 24(2)
of the sale and purchase agreement entered into between each of the
plaintiffs and the defendant and the Housing Developers Regulations (as well
as the ousing Developers Act); and that s 56(3) of the Contracts Act 1950 has
no relevance. The presence of the words „shall pay immediately‟ in both the
clauses is very significant in the interpretation of both the clauses; and what
the phrase means is that the right to be paid LAD is automatic once there was
a delay by the developer to hand over possession or to complete the common
facilities. The developer/defendant must pay the LAD to the purchaser at
once, without further ado, once there was a delay. If the right to be paid is
automatic, it follows then that there was no obligation on the part of the
purchasers/plaintiffs to give any notice to the defendant. The phrase „shall
pay immediately‟ would be meaningless if the defendant‟s argument that
notice was required were to be accepted.
All the four cases discuss above involved the sale of property and the
purchaser claim liquidated damages without issuing notice pursuant to their contract.
However, the developer did not satisfied and contended that notice should be given
before claiming liquidated damages pursuant to s 56(3) of Contract Act 1950. All
cases decided on favour of the purchaser but the judges failed to acknowledge that s
56(3) is only applicable when the contract is voidable contract. Plus, the contract was
in accordance with Schedule H of the Housing Developers (Control and Licensing)
Act 1966 which is drafted to protect purchaser‟s right. So, in the four cases, notice is
not condition precedent and the purchaser need not to issue notice before claiming
liquidated damages.
71
In Mardale Pipes Plus Ltd v. Malaysian International Trading Corp (Japan)
Sdn Bhd180
, the plaintiff was awarded the contract to supply duplex stainless steel
piping materials to the defendant. It was an express term in the letter of award that
time was of the essence of the contract, especially as the goods were intended for
delivery to ExxonMobil Exploration and Production Malaysia Inc. There was also a
provision for the imposition of liquidated damages for such delay in delivery.
The time stipulated for delivery of GOODS in the LETTER OF AWARD shall
be of essence. SUPPLIER agree to effect delivery of GOODS on or before the
stipulated delivery schedule. If for any reason, delivery shall be delayed,
SUPPLIER to notify MITCO JAPAN immediately in writing, giving reason(s)
for such delay. For late delivery of GOODS, liquidated damage (LD) of 1% a
week or part thereof of slippage from the agreed delivery period/date
stipulated up to the maximum of 10% of contract value shall be imposed.
The defendant refused to pay the sum amounted €255,267.26 (shipments of
goods between 2004 and 2006) on the grounds, inter alia, that LAD was occasioned
by the plaintiff‟s failure to ensure timely readiness of the delivery of the goods,
which sum was substantially the same as that imposed by ExxonMobil. The plaintiff
applied for summary judgment and managed to get €22,923.23 instead of the whole
sum. Dissatisfied, the plaintiff applied to High Court. The plaintiff relied on s 56(3)
of the Contracts Act 1950 („the Act‟) and submitted that since the defendant had
chosen to accept a late delivery where time was of the essence of the contract and
had not given notice at the time of acceptance of his intention to claim damages for
late delivery, it was not entitled to LAD.
This case was decided in favour of the plaintiff. Mary Lim JC explained that
in most commercial contracts, it would be agreed between the parties that time was
of essence. As such, non-performance by the due dates allowed the innocent party to
180
[2009] 5 MLJ 691
72
treat the contract as voidable, that is, to reject late delivery. Despite time being of the
essence of this contract, no notice was given by the defendant at the material time of
acceptance of the goods, of its intention to claim for damages for delivery at dates
other than those stipulated in the orders. Therefore, the issue of damages for late
delivery did not arise. The judge further stated that the LAD clause could only be
invoked when a notice under s 56(3) of the Act had been properly given by the
defendant.
However, the judge in this case was wrong. As discuss in the earlier cases, s
56(3) of the Contract Act 1950 is only applicable for voidable contract, but the
failure to issue notice did not amount to voidable contract but only a breach.
Therefore, in the first place, s 56(3) is not appropriate to be used as an argument by
the plaintiff.
Generally, the findings from the cases stated above show that for those
contracts which involve sale and purchase agreement under the Housing Developers
(Control and Licensing) Act 1966, notice of intention before claiming for damages is
not a condition precedent. The argument that section 56(3) of the Contract Act 1950
must comply in their contract has been prove to be wrong. Plus, the buyers are
protected under Housing Act and the Housing Regulations. Any attempt to impose
section 56(3) will remove the very protection which the Housing Act under which
the Housing Regulations were made was enacted for.
73
4.2.4 Issue 4 – Validity of Notice
What information should be included in the notice?
Many provision regarding liquidated damages in various standard form only
stated that the employer need to give written notice of intention to deduct liquidated
damages. Not many provisions give detail of information that should be included in
the notice. Thus, it gives rise to the contractor to challenge the sufficiency of
information in the notice and claim that the document sent did not meet the
requirement of notice as per contract.
In J.F. Finnegan Ltd v. Community Housing Association Ltd181
, one of the
issues raised is regarding what information must be include in the notice. The
Employer contends that it had to require the Contractor to pay or allow LADs and, if
only part is claimed, to specify what part of the total sum of LADs the Contractor
was to pay or allow; the period of overrun or any other details need not be contained
in the written requirement. The Contractor contends that it must specify three
matters: (i) that the Employer was requiring payment or allowance of LADs; (ii) that
the payment or allowance was of the whole or part of the LADs and if a part, what
part; and (iii) the period in respect of which the deduction was being made. The
judge held that:
“From the language of clause 24.2.1 I consider that there are only two
matters which must be contained in the written requirement. One is whether
the Employer is claiming a payment or a deduction in respect of LADs. The
other is whether the requirement relates to the whole or a part (and, if so,
what part) of the sum for the LADs. I stress the words "the sum" because it is
181
[1995] 65 BLR 103
74
quite clear, in my view, from the language of clause 24.2.1 that what is
required is a statement of the sum in respect of LADs.”
A contractor may challenge recovery of liquidated damages on grounds that
the document actually received from the employer is not the notice of liquidated
damages required under the contract.182
In Jarvis Brent Ltd v. Rowlinson
Construction Ltd183
, the claimant (Jarvis) carried out work as main contractors for
Rowlinson on the terms of the JCT 80. After a Non-completion Certificate had been
issued, the employer sent to Jarvis a letter enclosing a cheque and a letter sent to
Rowlinson by the Quantity Surveyor. The cheque was in the amount due under an
Interim Certificate reduced by an amount stated by the Quantity Surveyor in his letter
to be recoverable as liquidated damages. For subsequent Interim Certificates,
Rowlinson only sent cheques which reflected deductions for liquidated damages. The
claimant argued that a written requirement was a condition precedent to the
deduction of liquidated damages and the letter accompanied by the cheque did not
constitute such a requirement. The judge held that:
„...that there was no condition precedent that the employer‟s requirement had
to be in writing. What was essential was that the contractor should be in no
doubt that the employer was exercising its power under 24.2 in reliance on
the architect‟s certificate given under 24.1 and deducting specific sums from
monies otherwise due under the contract.‟
Judge Fox-Andrews held, in a judgment which was conflicting with Bell
case:
182
Ndekugri I. and Rycroft M. (2000). The JCT 05 Standard Building Contract Law and
Administration. (2nd
ed.) Oxford: Elsevier. pp.315 183
[1990] 6 Const LJ 292
75
1) The employer‟s letter was an adequate request in writing as it got the message
across to the contractor;184
2) In any event:
a) The employer‟s written request was not a condition precedent to his
right to deduct liquidated damages;185
b) The contractor by his conduct had led the employer to believe that
strict contractual rights would not be insisted upon and he was thereby
stopped from making the challenge.186
The judge emphasized that what was essential was that the contractor should
not be left in any doubt that the employer was deducting liquidated damages and in
this case the judge found that the contractor was in no such doubt.187
The judge went
on to hold that the written requirement was satisfied by a letter, written by the
quantity surveyor and forwarded to the contractor, which stated the amount which
the employer was entitled to deduct; alternatively, that the cheques issued by the
employer form which liquidated damages had been deducted constituted such written
requirements.188
Similar issue can be found in case Bovis Lend Lease Ltd v. Braehead
Glasgow Ltd.189
Bovis as contractor for Braehead Glaslow Limited were responsible
to design and construct a shopping and leisure centre at Braehead, Glaslow. Bovis
make an application for summary relief in respect of two interim applications for
payment, nos. 53 and 54. The sums claimed (excluding interest and VAT) are
respectively £2.2M and £6,645,619, ie. a total of £8,845,619 excluding VAT and
184
Eggleston B. (1997). Liquidated Damages and Extensions of Time in Construction Contracts.
Oxford: Blackwell Science. pp.199 185
Ibid. 186
Ibid. 187
Ndekugri I. and Rycroft M. (2000). The JCT 05 Standard Building Contract Law and
Administration. (2nd
ed.) Oxford: Elsevier. pp.316 188
Chappel D., Powell-Smith V. & Sims J. (2004). Building Contract Claims. (4th
ed.). Oxford:
Blackwell Publishing Ltd. pp.224 189
[2000] All ER (D) 633
76
interest. Bovis asserts that Braehead is not entitled to deduct or recover any LADs
based on some ground. One of their arguments is Braehead failed to make a
requirement in writing pursuant to clause 24.2 of the contract. Further, or
alternatively, it is not entitled to LADs in respect of the delayed completion of some
sections of the works, because it failed to issue a notice of failure to complete in
accordance with clause 24.1.
However, Braehead had sent out two letters to Bovis which serves as notice
as require in the contract. The first is dated 27 October 1999, in which Braehead said:
"CSC will make post valuation deductions for LADs . . ."
The second is dated 26 November 1999. In this letter Braehead stated:
With specific regard to liquidated damages, pending receipt and analysis of a
fully documented and substantiated application for an extension of time we
have no alternative other than to deduct damages from the contract
completion date of 31 July 1999."
The judge held that:
I find it surprising that the clause did not spell out what information the
requirement in writing had to contain.
The reality is that there are only 3 elements to a claim for LADs. The first is
the date when the Works or Section of the Works ought to have been
completed. For the purposes of a deduction of LADs, this is fixed, for the time
being at least, by the giving of a notice under clause 24.1. The second is the
77
date of practical completion of the Works or the relevant Section. The third
is the application of the amount or amounts included in the contract for
LADs to the period between the two dates just mentioned, a matter of simple
arithmetic.
The judge was satisfied that Braehead has a real prospect of succeeding in its
arguments that its letters of 27 October and 26 November were requirements in
writing within the meaning of clause 24.2.
In conclusion, the purpose of notice is to inform the contractor about the
deduction beforehand. The contractor must not be leave in doubt and questioning
about the deduction. From the cases, some of the information that should be included
in the notice is:
State the intention of claiming a payment or deduction in respect of LADs;
State whether the payment or deduction relates to the whole or a part of the
sum for the LADs;
The date when the works or section of the works ought to have been
completed;
The date of practical completion of the works or the relevant section;
The amount of payment or deduction for LADs.
78
4.3 Conclusion
For contract which consist notice as condition precedent before claiming
LAD, failure to comply the notice provision contractually will risk the employer‟s
right to LAD. However, based on prevention principle, one party cannot benefit by
its own fault. Since, the contractor is responsible for the delay of the project, the
contractor should compensate the employer since the employer had suffered losses
because of the delay even though the employer did not give notice of intention before
claiming LAD.
A contract may be subject to terms that are sanctioned by the relevant statute,
although these terms have not been expressly mentioned by the parties in their
contract. For example, the argument by some party although their contract did not
mention the requirement to issue notice but section 56(3) of Contract Act 1950 is by
implication stated that notice of intention should be issued before claiming LAD. It is
clear that section 56(3) is only applicable went the contract is voidable. The contract
becomes voidable if it involves coercion, undue influence, fraud and
misrepresentation. Therefore, when the party is in breach because they fail to issue
notice of intention before claiming LAD, the other party cannot rely on section 56(3)
because the breach is not amount to voidable contract.
79
CHAPTER 5
CONCLUSION AND RECOMMENDATION
5.1 Introduction
Briefly this chapter consists the research findings based on the literature review,
case studies, and analysis; together with research‟s constraint, some suggestions for
future studies and conclusion to the whole study. This chapter will summarize all the
findings regarding status and implication of notice of intention before claiming
liquidated damages.
5.2 Summary of Research Findings
80
The objective of this study is to determine whether notice is condition precedent
to claim liquidated damages. In summary, examination the facts and findings from
previous chapter have leads to the following findings.
Where there is notice provision expressly stated as condition precedent, the
failure to comply them contractually amount to breach of contract and could
jeopardize the party‟s claim. However, it is not necessarily that the claim is
totally rejected because based on prevention principle, one cannot benefits from
its own wrong act. So, if the employer fail to issue notice of intention before
claiming LAD as per stated in the contractor, the contractor is most probably will
have to compensate the employer based on common law. This is because the
delay is totally cause by the contractor‟s fault. So, the employer who suffered
losses should be compensated because of the delay although he fail to issue
notice.
According to Section 56(3) of the Contract Act 1950, giving of a notice is a
condition precedent to the promisee‟s right to claim damages for non-compliance
within the stipulated time. However, section 56(3) did not apply because it is
only applicable for voidable contract. Plus the sale of property agreement is
protected under the Housing Developers (Control and Licensing) Act. Therefore,
the buyers who experience late delivery of vacant possession may claim for
damages without issuing notice of intention.
When there is notice provision in the contract, although it did not expressly
stated that the issuance of notice is condition precedent to claim liquidated
damages, but by implication, the notice requirement can be held to be condition
precedent because the interpretation of the language of the clause shows that it
was the intention of the parties to make the notice a condition precedent to the
said claim.
81
Although the liquidated damages provision did not specifically state what
information should be included in the notice, the findings from the cases shows
that notice should contains the following information:
1) State the intention of claiming a payment or deduction in respect of
LADs;
2) State whether the payment or deduction relates to the whole or a part of
the sum for the LADs;
3) The date when the works or section of the works ought to have been
completed;
4) The date of practical completion of the works or the relevant section;
5) The amount of payment or deduction for LADs.
5.3 Research’s Constraints
The main constraint of this study is insufficient of time. Due to the fixes time
frame, the extent and scope of this research has been narrowed down and limited to
certain objectives. This limitation led to less cases being found to support the findings.
With more cases, claim and waiver of notice requirement time can be presented more
comprehensively.
5.4 Suggestions for Further Research
82
This research was done to determine whether notice is condition precedent to
claim liquidated damages and research done by analyzing liquidated damages provision
in various standard form use construction. There are some aspects that further study can
be conducted. Further study can be done by narrowing the scope to analyze provision of
liquidated damages but focus in one standard form use in Malaysia. Perhaps further
research may give a more comprehensive and concretive findings.
5.5 Conclusion
The imposition of liquidated damages provision is intended to give certainty of
the financial cost of delay190
and the non-defaulting party can make recovery of damages
without the difficulty and expense of proving actual loss.191
However, there are some
conditions and procedure that need to be followed in order to have a successful claim of
liquidated damages. One of the conditions is the requirement to issue notice. In
Malaysia, section 56(3) of the Contract Act 1950 was claimed to give an implied
meaning in the contract. Therefore, the issue of condition precedent arise. However,
section 56(3) of the Contract Act 1950 is only applicable for voidable contract. While
most cases, the party is only in breach because of failure to issue notice before claiming
LAD. Therefore, the reference to section 56(3) is not appropriate in the first place. In
conclusion, to ensure a successful claim for liquidated damages, ones must know and
understand the procedure and requirements that need to be fulfilled by the party.
190
Turner & Townsend (2009). Liquidated Damages Contract Risk Management. [online] Available at:
www.turnerandtownsend.com/Liquidated_Damages_oeN9s.pdf.file [Accessed 22 January 2011]. 191
Ibid.
83
REFERENCES
Adriaanse J. (2005) Construction Contract Law – The Essential. Basingstoke: Palgrave
Macmillan.
Always Associates (2004). Drafting for Liquidated and Ascertained Damages- Avoiding
Pitfalls. [online] Available at: http://www.alway-associates.co.uk/ [Accessed 24
Mei 2011].
Beatson, J. (2002). Anson‟s Law of Contract. (28th ed.). United States: Oxford
University Press.
Barton Legal (2007). Liquidated Damages – A Three Stage Process. [online] Available
at: http://www.bartonlegal.com/commercialServices.asp?Id=69&menu=7 [Accessed
28 Jun 2011].
Chappel D., Powell-Smith V. & Sims J. (2004). Building Contract Claims. (4th
ed.).
Oxford: Blackwell Publishing Ltd
Chappell D. (2007). The JCT Design and Build Contract 2005. (3rd
ed.). Oxford:Wiley-
Blackwell.
Chia M. L. (2009). The Enforceability of Liquidated and Ascertained Damages in
Construction Contract. Master. University Teknologi Malaysia.
84
Coldwell D., Burchett-Williams A. & Celeste M. (2010). Liquidated Damages.
Franchise Law Journal [e-journal] 29 (4) Available through: ProQuest Database
[Accessed on 25 Mei 2011]
Drewry C. (n.d.). The Availability and Enforceability of Liquidated Damages in
Construction Litigation. [online] Available at:
http://www.dsvlaw.com/images/publications/Liquidated%20Damages%20Clauses.p
df [Accessed 25 May 2011].
Donohoe S. (2011). The WW Gear Case, Conditions Precedent and Construction
Contracts. Structural Survey [online] 29 (2) Available through: Emerald Database
[Accessed on 17 Jun 2011].
Eggleston B. (1997). Liquidated Damages and Extensions of Time in Construction
Contracts. Oxford: Blackwell Science.
Elliot C. and Quinn F. (2007) Contract Law. 6th
edition. Edinburgh: Pearson Education
Limited.
Friedlander M. C. (2001). Contractor Marketing- Penalty Clauses. [online] Available at:
http://www.schiffhardin.com [Accessed 23 January 2011].
Glazov J. (2009). Liquidated Damages in Construction Contracts- Enforcing Liquidated
Damages. [online] Available at: http://www.constructionlawtoday.com/ [Accessed
20 Oktober 2010].
Gillhams Solicitors (2005). Contracts & Disputes: Importance of Implied Terms.
[online] Available through: http://www.gillhams.com/articles/141.cfm [Accessed on
1 June 2011]
85
Government of Malaysia (2006). Public Works Department Form 203A (Revised
2007). Malaysia : Government of Malaysia.
Harban, K. S. (2002) Engineering and Construction Contracts Management,
Commencement and Administration, Singapore: Lexis Nexis.
Harban K.S. (2002) Engineering and Construction Contracts Management Law and
Principles. Singapore: Lexis Nexis
Hawkswell Kilvington (2003). Liquidated Damages. [online] Available at:
http://www.thkp.co.uk/media/bulletins-
new/Liquidated%20Damages%20%20HK.pdf [Accessed 24 Mei 2011].
Lal H. (2009). Liquidated Damages. Construction Law Journal, 25(8), pp. 569-580.
Lectric Law Library (2011). Notice. [online] Available at:
http://www.lectlaw.com/def2/n075.htm [Accessed on 17 Jun 2011].
Lim C. F. (1993). Enforcement of Liquidated Damages- To Prove Actual Loss?. The
Malayan Law Journal Articles. Vol 1, 1-9. Lexis Nexis Business Solution.
Lim, G. and Kasim, K. (2002). Sakinas Sdn Bhd V Siew Yik Hau & Anor (2002) 5 MLJ
498: One Step Forward, Two Steps Back? The Malayan Law Journal Articles. Vol
3, Lexis Nexis Business Solutions.
Mohamad Noor S. B. (2008). Provisional Liquidated Damages (PLD). Master.
University Teknologi Malaysia.
Molloy J. B. (2001). Liquidated Damages – Some General Principles. HKIS Newsletter.
Molloy J. B. (2001). Notice Provisions – A Change in Attitude?. HKIS Newsletter.
86
Murdoch J. (2009). Being Late Can Have Damaging Effects. The Estates Gazette.
ProQuest Direct.
Ndekugri I. And Rycroft M. (2000). The JCT 05 Standard Building Contract Law and
Administration. (2nd
ed.). Oxford: Elsevier Ltd.
Osborne D. (2006). Effect of Conditions Precedent on Building Contracts. Journal of
Building Appraisal. Vol 2, 188-192, Palgrave Macmillan Ltd.
Pertubuhan Arkitek Malaysia (2006). Agreement and Conditions of PAM Contract
2006 (With Quantities). Malaysia : Pertubuhan Arkitek Malaysia.
PM Professional Resources (2010). Construction Claim and Dispute Resolution. [online]
Available at: http://www.pm-pro.com.my/ [Accessed 20 October 2010].
Powell-Smith V., Chappell D. and Simmonds D. (1989). An Engineering Contract
Dictionary. London: Legal Studies and Services (Publishing) Ltd.
Sinnadurai, V. (1979). The Law of Contract in Malaysia and Singapore: Cases and
Commentary. Kuala Lumpur: Oxford University Press.
Turner & Townsend (2009). Liquidated Damages Contract Risk Management. [online]
Available at: www.turnerandtownsend.com/Liquidated_Damages_oeN9s.pdf.file
[Accessed 22 January 2011].
Turner B., 2011. Liquidated damages clauses in construction contracts. [online]
Available at: http://www.boyesturner.com/news-article.html?id=66 [Accessed 22
January 2011].
87
Tuuli M.M., Baiden B.K. & Badu E. (2007). Assessment and Enforcement of Liquidated
Damages in Construction Contracts in Ghana. Structural Survey [e-journal] 25
(3/4) Available through: Emerald database [Accessed 25 Mei 2011].
Viscarello K. (2006) The Use of Liquidated Damages Clauses in Construction
Contracts. [online] Available at: http://www.sheehan.com/publications/good-
company-newsletter/The-Use-of-Liquidated-Damages-Clauses-in-Construction-
Contracts.aspx [Accessed 20 October 2010].
Yong M. L. (2006). Liquidated and Ascertained Damages (LAD) and Requirement of
Mitigation. Master. University Teknologi Malaysia.
YourDictionary.com (2011). Notice Law Definition. [online] Available at:
http://law.yourdictionary.com/notice [Accessed on 17 Jun 2011].
Wikipedia (2011). Notice. [online] Available at: http://en.wikipedia.org/wiki/Notice
[Accessed on 17 Jun 2011].
Winser C. (2007). The Prevention Principle After Multiplex v Honeywell. [online]
Available through: http://www.crownofficechambers.com/downloads/174.pdf
[Accessed on 1 June 2011].