Tender MSME LOAN POINT HALDWANI - Union Bank of India

1

Signature & Seal of the Contractor

(A Government of India Undertaking)

(BANK’s EMPANELLED VENDORS OF HALDWANI REGION CAN ONLY APPLY)

UNION BANK OF INDIA REGIONAL OFFICE, HALDWANI, P.B COMPLEX, NEAR

CENTRAL HOSPITAL, KALADHUNGI ROAD, KUSUM KHERA HALDWANI-263139

.

TENDER FOR COMPLETE FURNISHING ( INTERIOR, ELECTRICAL, LAN AND AC WORK)

AT

NEW PREMISES OF MSME LOAN POINT SITUATED AT FIRST FLOOR, P.B COMPLEX, NEAR CENTRAL HOSPITAL,

KALADHUNGI ROAD, KUSUMKHERA HALDWANI-263139

CLIENT

UNION BANK OF INDIA REGIONAL OFFICE, P.B COMPLEX, NEAR CENTRAL

HOSPITAL, KALADHUNGI ROAD, KUSUM KHERA HALDWANI-263139.

2


To, The Regional Manager Union Bank of India Regional Office Haldwani, P.B Complex, Near Central Hospital, Kaladhungi Road, Kusumkhera Haldwani, Distt-Nainital, Uttarakhand Subject: Interior, Electrical, LAN and AC & ATM work for Union Bank of India Branch Office at Rudarpur. ISSUE OF TENDERS FROM 03/08 /2022 TO 09 /08/2022 LAST DATE OF SUBMISSION 09/08/2022 UPTO 15.00 HOURS. TENDER OPENING DATE 09/ 08 / 2022 TIME 17.00 HOURS (TENDERS WILL BE OPENED IN PRESENCE OF CONTRACTING AGENCIES OR THEIR AUTHORISED REPRESENTATIVES) TENDERS CAN BE DOWNLOADED FROM THE BANK’S WEBSITE / PORTAL OR CAN BE COLLECTED AT THE FOLLOWING ADDRESS BY PAYING TENDER DOCUMENT FEES OF Rs. Nil . (Bank Empanelled Vendors of Haldwani Region Can Only Apply). PLACE OF TENDER COLLECTION / SUBMISSION: Union Bank of India Regional Office Haldwani, P.B Complex, Near Central Hospital, Kaladhungi Road, Kusumkhera Haldwani, Distt-Nainital, Uttarakhand.

3


NOTICE FOR INTIMATION TENDER To, M/s._______________________________ ___________________________________ ___________________________________ Dear Sir, Subject: Interior, Electrical, LAN and AC work for Union Bank of India Branch Office MSME Loan Point at Haldwani situated at First Floor, P.B Complex, Near Central Hospital, Kaladhungi Road, Kusumkhera Haldwani-263139. 1) Sealed, item rate, tenders are invited in the prescribed format from contractors empanelled with haldwani regional office for carrying out jobs for execution of Interior, Electrical, LAN and AC work for Union Bank of India at branch office MSME Loan Point situated at First Floor, P.B Complex, Near Central Hospital, Kaladhungi Road, Kusumkhera Haldwani-263139: Name of the work :- Furnishing, Electrical, AC & LAN works

of branch office situated at Haldwani. Estimate cost :- 2290000.00 (Twenty Two Lakh Ninty Thousand Only) (excluding GST). Earnest Money Deposit :- Nil Period of Completion :- 60 Days from 7th day from issue of work order. Validity of Tender :- 120 Days Defect Liability Period :- Twelve Month Tender Cost :- Nil Last Date of submission of Tender :- Up to 3.00 PM. On 09/08/2022. Date of Time of opening the tender :- 5:00 PM. On 09/08/2022. 2) The tender document can be downloaded from our bank’s website / portal or obtained from the Office of The Regional Manager, Union Bank of India, Regional Office Haldwani, , Haldwani, Uttarakhand 263139, 3) The item rates under the contract include for full, final & entire completion of all works in all respects described in contract & as shown in drawings forming part of the contract. Contractor must quote item rates for all the items of work. Tenders will be opened in the presence of contracting agencies or their authorized representatives.

4


4) The Envelope of the contractors will be opened on the due date & time of opening. 5) Tenders are to be submitted in a sealed envelope cover super scribed “Tender for Interior, Electrical, LAN and AC work for Union Bank of India Branch Office MSME Loan point at Haldwani. 6) The tenderer must use only the tender forms issued for the purpose to fill in the rates intimation of tender quoted by letter, telegram / telex will not be acceptable. 7) Tenderers are advised not to make any alternation / modification in the tender documents, item of work or in any respect whatsoever. Violation of this requirement will make the Tender Liable for rejection. 8) In case of postal delivery, the tenderer has to ensure that tender is reached before the due date and time. The bank will not be responsible for damage in the transit and delay of receipt to tender, if any or sent by a special messenger. Tender received late shall be rejected. 9) Every page of the tender documents should be signed by the person or persons submitting the tender in token of his / their having acquainted himself / themselves with the General and Special Conditions of Contract, Specifications etc., as laid down. Any tender with any of the documents not so signed will be subjected to rejection. 10) No consideration will be given to a tender received after the time stipulated above and no extension will be allowed for submission of the tender. The Union Bank of India shall not be bound to accept the lowest tender and reserves the right to accept or reject any or all the tenders without assigning any reason whatsoever. 11) This notice inviting tenders, the conditions of tender and the duly completed form of tender etc., will form part of the Agreement to be executed by the successful tenderer with the bank. The following document forming a part of tender are enclosed herewith

1. Tender Notice 2. Special Conditions 3. Letter of Offer 4. List of Approved Manufacturers for Materials 5. Bill of Quantities 6. Working Drawings

This tender notice shall form part of the contract and non-submission of tender in the above manner will render your offer liable for rejection.

FOR

UNION BANK OF INDIA REGIONAL MANAGER

5


TENDER NOTICE

Subject: Interior, Electrical, LAN and AC work for Union Bank of India Branch Office MSME Loan Point at Haldwani situated at First Floor, P.B Complex, Near Central Hospital, Kaladhungi Road, Kusumkhera Haldwani-263139. Sealed item rate tenders are invited by Union Bank of India, The Regional Head, Regional Office Haldwani, situated at P.B Complex, Near Central Hospital ,Kaladhungi Road,Kusumkhera , Haldwani, Uttarakhand -263139.

1. Tenders are invited on behalf of Regional Head, Union Bank of India, Regional Office, Haldwani , for the commissioning & completion of above work. Tenderers are advised to inspect and examine the Site and its surrounding and satisfy themselves before submitting their tenders as also to the nature of the work, the means of access to the Site etc., and any information they may require. Contractors in general shall themselves obtain all necessary information as to risk and contingencies and other circumstances which may influence or effect their tender. A tenderer shall be deemed to have full knowledge of the site whether he inspects or not and no claims for anything extra consequent upon any misunderstanding or otherwise shall be payable.

2. Submission of a tender by a tenderer implies that he has read this notice and all other

contract documents and has made himself aware of the scope and specifications of the work to be done and of conditions and rates at which execution of the work is to be carried out.

3. A tenderer should quote in figures as well as in words the rate(s) tendered. The amount

of each item should be worked out and the requisite totals given. Special care shall be taken to write rates in figures as well as in the words and the amounts in figurers only in such a way that interpolation is not possible. In case of any discrepancy the rate mentioned in the works shall be taken for evaluation purpose. In case of figures, the words, "Rs" should be written before the figures of rupees and the word "Paisa" after the decimal figure, e.g. Rs.2.16p and in case of word "Rupees" should precede and the "paisa" should be written at the end. Unless the rate is in whole rupees followed by the word "only" it should invariably be up to two places of decimal.

4. All rates should be quoted in the tender form, which shall have to be in sealed cover

which shall be super scribe with “Price bids for Interior Works of Union Bank of India, Regional Office Haldwani” and name of tenderer firm to be written on sealed cover. Tenderer shall also enclose their empanelment letter with Union Bank of India. All pages of the tender documents are to be signed and stamped by tenderer. In case of item rate tenders, only rates quoted shall be recorded. Any tender containing percentage below/above the rates quoted is liable to be rejected. However, where a tenderer voluntarily offers a rebate, this may be considered.

5. The application/Bids form shall also be available at the Bank’s Website

www.unionbankofindia.co.in and www.eprocure.gov.in . Tenders shall be received by The Chief Manager, Union Bank of India, Regional Office, Haldwani by 09 /08/2022

6


up to 3.00PM and shall be opened in the office of the Regional Head, Union Bank of India, Regional Office, Haldwani on 09/08/2022 at 5.00 P.M. in the presence of tenderers who wish to be present.

6. Contractors to submit all statutory mandatory documents before commencement of

project including labor license etc. from competent Authority as Applicable. 7. On acceptance of tender, the earnest money will be treated as part of the security

deposit which shall be deducted @ 10% of the value of work done from all payments. 8. A tenderer shall submit the tender who satisfies each and every condition laid down in

this notice, failing which, the tender may be rejected. 9. Bank further reserves to himself the right of accepting the tender whole or in part and

tenderers shall be bound to perform the same at their quoted rates. Also the quantities of items can be increased or decreased as per requirement of the Bank. However, the bank shall entertain no claim on this ground.

10. Since the work to be handed over complete in all respect with 100% workable and

functioning condition, so all material shall be F.O.R. site including all taxes like Freights, carriage etc.in respect of this contract shall be payable by the Contractor(s) and the employer will not entertain any claim whatsoever in this respect. Income-tax shall also be deducted as per statutory instructions, from all payments due to the contractor(s).

11. This notice of tender shall from part of the contract documents. 12. The validity for acceptance of the tenders by the employer shall be upto 90 days from

the date of opening of tenders. 13. All corrections and over-writings shall have to be initialed by the tenderers. Efforts to

be made to avoid overwriting. 14. The bill of quantities attached to the tender documents is only approximate & is likely

to be increased or decreased as per site conditions. 15. Incomplete and conditional tenders shall be summarily rejected.

16. Contractor(s) shall be responsible for all defects upto a period of Twelve months from

the date of virtual completion of project. 17. Bank shall not arrange/supply of any T & P, labour or material required for the

construction and completion of the work. 18. Bank shall not be responsible for any loss or damage to the contractor material or

machinery brought by him at site due to any reason or due to any act of God uring the

7


course of execution. Contractor shall be liable to make good all the damages, if any till the work is completed and handed over to the Bank Authorities.

19. Work shall have to be completed within 60 days from the 7th day from the date of issue

of order. For unnecessary delay on the part of the contractor, they will be liable for penalty @ Rs. 3000/- per day subject to maximum of 5% of awarded sum. Bank may extend the time limit in deserving cases for which request shall have to be made in writing well in time with valid reasons recommended by the Architect.

20. Running payment shall be released after verification of all running bill and final bill by

the Architects and final checking of the work done by the Premises department if required. Running payment may be permitted at discretion of the bank. Request for such payment shall not be considered if the value of work done is less than Rs. 5.00 lakh.

21. All frame work drawings for fixing & other working drawing and details shall be

supplied by the Contractor & approved by the Architect befoe starting the job and any clarification can be had from him in his office.The time allowed for the completion of work is 30 days from 7th day after the date of written order to commence the work or after the date on which the site is handed over to the contractor, which so ever is later.

22. The successful tenderer should make his own arrangement to obtain all materials

required at site including all perishable and non-perishable goods, apart from the items as per instructions from Bank/Architect.

23. Contractor shall make his own arrangement for water supply, electricity and security to

his machinery plants & workmen, in case of availability of water and electricity from work, contractor may be allowed to use the same.

24. All rates shall include the complete cleaning of site within the premises and

surrounding areas before his submission of final bill and approval from the Architect. 25. If the contractor after receipt of written notice from the Architect requiring compliance

within ten days fails to comply with such further drawings/and or architects/ instructions, the employer may employ any other person to execute any such work whatsoever that may be necessary and all cost incurred in connection with this shall be deducted and recoverable from contractors bills by the employer on the certificate from Architect as a debit.

26. All disputes arising out of work are subject to Haldwani jurisdiction only.

8


SPECIAL CONDITIONS OF CONTRACT Subject: Interior, Electrical, LAN and AC work for Union Bank of India Branch Office at Haldwani. Inspection of sites: The contractor shall visit and examine the site and satisfy as to the nature and correct dimensions of work and facilities for obtaining material and shall obtain generally his own information on all matters affecting the execution of work. No extra charge made in consequence of any misunderstanding or incorrect information on any of these points on the ground of insufficient description will be allowed. All expenses incurred by the contractors in connection with obtaining information for submitting this tender including his visit to site and efforts in compiling the tender shall be borne by the tenderer ad no claims for reimbursement thereof shall be entertained. Safety Regulations: The contractor shall take all the necessary precautions while working and to safeguard adjacent property, Bank’s property, Bank’s employees, and traffic persons Compliance to local laws: The contractor shall conform to the provisions of any Act of the Legislature relating to the work and to the Regulation of Bye Laws of any authority. He shall also obtain the permission of the Municipality or any other Authorities if required under the existing rules.

Site cleaning: All the rates quoted are inclusive of removal of rubbish / debris collected during the progress of work, rejected material and clearance of site before and after the work is completed. Not more than one truck load shall be stored that to for not more than 3 days. The contractor shall arrange to remove the same immediately. If the contractor is failing to remove the same and the expenses shall be recovered from the contractor and he will not dispute for the expenses so incurred.

Vouchers / bills: Contractor shall upon the request of the Bank furnish bills, invoices, accounts, receipts and other vouchers for all materials brought on site to prove that the material purchased are as mentioned in the specification. Contractor’s responsibility: The work will from time to time be examined by Bank’s Architect / Engineer, but such examination shall not in any way exonerate the contractor from the obligation to remedying any defects which may be observed at any stage of the work or after the same is completed.

Dismissal from work: The contractor shall upon the written request of the Bank’s Architect / Engineer immediately dismiss from the work any person employed by him thereon, who may in the opinion of the authority be incompetent or misconduct himself and such person shall not be again employed on the work, without the permission of the bank. Commencement of work: The work must be started within 3rd days upon accepting the work order and the programmer for carrying out the various jobs shall be drawn out in consultation with the Bank’s Architect / Engineer. Adequate labour force shall be provided to complete the

9


work within the specified period. Proper security aspects should be taken care of by adequate vigilance in view of the importance of the building. Default in compliance with the programmers so finalized shall entail operation of liquidated damages as stated.

Subletting the work: The contractor shall not directly or indirectly sublet the work to other party without written permission from the bank. Quantities of works are provisional: The quantities mentioned in schedule are provisional and likely to increase / decrease to any extent or may be omitted thus altering the aggregate value of the contract. No claim for loss of profit / business shall be entertained on this account Distribution of work: The Bank reserve the right to distribute the work for which quotation have been called, among more than one parties, if found necessary. No claim in this respect shall be considered and the contractor agrees to cooperate with other agencies appointed by the bank.

Third party damage: The contractor shall be responsible for all injury to persons, animals, building, building structure, any damage to road, streets, footpaths and shall rectify it at its own cost. Insurance cover: All the workers of the contractor as well as his sub-contractor must be properly covered by an Insurance Policy under Workman’s Compensation Act and Fatal Accidents Act. The contractor at his own expenses arrange to effect and maintain until the virtual completion of the contract, insurance policy in the joint name of the Bank and the contractor against this risk to be retained by the Bank until the virtual completion of the work, and indemnify the Bank from all the liabilities arising out of such events. In case of delay, contractor shall arrange to extend insurance policy till work is completed. Delay & Extension of time: All the work should be completed within the specified period in the tender. If the work is delayed due to the reasons beyond the control of the contractor, he should apply to the Bank explaining, therein the reasons for such delays, immediately and if in the opinion of Bank’s authorities, the delay is justified, the contractor shall be granted extension in time limit. Certificate of virtual completion: As soon as the work is completed, the contractor shall inform in writing such completion to the Bank’s Architect / Engineer who will inspect the work and if satisfied will issue the certificate that the work has been virtually completed and the defects liability period shall commence from the date of such certificate. Defect liability period: The defects or other faults which may appear during the defect liability period which is 12 months after the virtual completion of the work, arising in the opinion of the bank due to inferior quality of material or bad workmanship not in accordance with the contract, contractor shall make good at his own cost within a reasonable time. In case of default, Bank may employ and pay other agencies to amend and make good such defects and all expenses / damages / losses shall be recoverable by Bank or may be deducted from any money due to the contractor

10


Arrangement of work: The contractor shall organize the work in such a way that the office users or the nearby public area put to no hardships and the working of the office is not affected. The contractor shall take adequate care during the progress of work to protect the office property like stationery, furniture, etc. In case of any damage, the same shall be made good by the contractor. Contractor is agreed to work after office hours for which no extra cost shall be considered.

Stacking of material: The contractor is not to stack any of his material recklessly so as to endanger the safety of the building and cause any nuisance to the occupants and the public.

Extra charges: It must be clearly understood that all the conditions of contracts are intended to be strictly enforced and that no extra charges in respect of extra work will be allowed unless they are clearly outside the spirit and meaning of the condition and unless such work shall have been ordered in writing.

Protection of material and work: The contractor shall be responsible for storing and watching his own material and protecting the work at his own cost. The contractor and his worker will be allowed to use lift after office hours. However, no paint drums or heavy bag of cement / paint will be allowed to be taken into the lift. Any damage / spoiling of lift / floor / dado caused during such act will have to be made good by the contractor at his own expenditure. Water supply: The contractor shall make his own arrangement for water required for the work. in case the water is available and supplied by the Bank, the charges for the same shall be recovered at the rate of 1% of value of the work executed. In case water supplied by the Bank, the contractor shall make his own arrangement for the storage, pipeline from point of tape of to the required location.

Electric supply: The contractor shall make his own arrangement for providing points, wires lines, extension board wherever it is required in the premises, in and out.

Approval of samples: The contractor shall furnish well in time before work commence at his own cost, colour samples, samples of material or workmanship that may be called by Bank’s Architect / Engineer for approval. Rates quoted shall cover for such preliminary work.

Workmanship: The work involved calls for a high standard of workmanship combined with speed. All the glass panes, door handles / hinges, electric fitting, fans, furniture records, floors etc. are to be thoroughly cleaned after work is completed. Any damage to the flooring, tiles, dado, panelling or any other part of the building, etc. shall be made good at the cost of the contractor to the entire satisfaction of the Bank. Contractor shall make all arrangements for shifting of furniture / records and keeping the same in its original position after he finishes the work on daily basis. The contractor at his own cost shall provide brown paper, polythene, tarpaulin etc. for protecting furniture / fixtures, paneling, electrical, fittings, records, etc.

11


Interpretation of documents / drawing: Except where otherwise provided in the contract all questions and disputes relating to the meaning of the specifications, design drawings and instructions herein before mentioned and as to the quality of workmanship or materials used for the work or as to any other question, claim, right, matter or thing whatsoever, in any way arising out of or relating to the contract, designs, drawings specifications, estimates, instructions, orders or these conditions or otherwise concerning the works, or the execution or failure to execute the same whether arising during the progress of the work or after the completion or abandonment thereof shall be referred to the competent authority of the Bank whose decision shall be final and binding on the contractor.

Use of scaffolding: The contractor shall allow the use of scaffolding erected by them to any other agency employed by the Bank during the contract period without any payment. Provisional Item: If ordered by the Bank, contractor shall be required to carry out provisional items at the same conditions and rates as applicable for this contract.

Measurements of all concealed items: Measurements of all concealed items of work and extra item if any, shall be got recorded by the Bank’s Architect / Engineer before they are checked up.

Measurements: All measurement tapes shall be of steel and all scaffolding and ladders that may be required for taking measurements shall be supplied by the contractor.

Cleaning during the work: The rates quoted shall include cleaning of ceiling roses, electric switches, boards, window panes etc. after the repairing leaving the site neat and tidy from time to time.

Complying I.S. specification: Unless otherwise mentioned in the contract, the latest Indian Standard Code for material specifications, method of work, mode of measurements shall be followed. The payment shall be made on the basis of actual measurement of work done to be submitted along with bill Rate to exclude: The rates quoted by the contractor shall cover for work at any height in the premises for all finished items under this contract. The rate quoted shall be exclusive of all material cost, wastage, labour, loading, profit, taxes if any, scaffolding, transport, supervision, spot light arrangement and any other means to complete the job. All tax excluding in the rates so quoted. Price Fluctuation: The rates quoted by the contractor shall be firm throughout the currency of contract (including extension of time if any granted) and will not be subject to any fluctuation due to variation in the cost of material or labour

The successful tenderer if called upon to do so, shall obtain a letter from the approved trade manufacturer whose product is used, if found necessary by the Bank confirming that the manufacturer shall provide all the technical assistance and supervision during the execution of the work at all such places as directed and the contractor shall bear the expenses,

12


if any, for such supervision and technical assistance supplied by the trade manufacturer. Testing of materials: If at any point of time during the work, if Bank authorities desire to carry out the tests of certain materials, the contractor shall arrange for the same and submit the test report without any extra cost to the Bank.

The contractor shall note that they should bring to the notice of the Architect / Engineer any breakage in glass window before starting work. However, if any glass window is found to be broken during the repairing work, the same shall be replaced by the contractor at his own cost. Conditional tenders: Conditional tenders are liable to be rejected. Rates of non-tendered items: The successful tenderer is bound to carry out any item of work necessary for the completion of the job even though such items are not included in schedule of quantities. Abandonment of work: If in any case the work required to be abandoned, the contractor shall not be entitled for any claims and he will be paid as per the actual work done till that period. The Bank reserves the right to accept / reject the lower or any or all tenders in part or in whole without assigning a reason therefor. Decision of the Bank shall be final and binding on any matter connected with the work. The matter of any dispute shall be decided after mutual discussions based on the terms and conditions of this contract. However, if the matter can not be resolved then the same shall be referred to the respected, qualified person in the field agreed to both the parties and his opinion shall be binding on both the parties. However, this is precourse to any legal action in this regard. Incomplete quotation: Incomplete quotations shall be summarily rejected Payments: The contractor shall be paid by the Bank from time to time under interim payment on account of works executed and when the value of work equal to the approximate value named in the Appendix as ‘Value of work for Interim Certificate’ has been executed in accordance with this contract. When the work has been virtually completed and Bank’s Architects / Engineer has certified in writing that the work has been completed on the basis of detailed measurements and has made a final scrutiny and that there is no dispute items, rates, ad quantities, the contractor shall be entitled to the payment of the final bill in accordance with the final certificate which will be honored within the period specified in the Appendix as period of honoring final certificate. The contractor shall be paid by the Bank within the period named in Appendix (period of honoring certificate) after such certificate has been delivered to the employer by the Bank’s Architect / Engineer. Bank’s Architect / Engineer has power to withhold any certificate in the work or any part thereof are not carried out to his satisfaction or the contractor fails to show the desired progress or fails to follow the instructions given or in case of breach of this contract.

13


For water proofing works on traces, bathroom, WC, Chajja, work has to be executed through the agency specialized in waterproofing. Contractor will have to submit a guarantee of 10 years on stamp papers as per the format toe be prescribed by the Bank. Earnest Money Deposit of successful tenderer shall be treated as security deposit. The contractor should pay this amount to the Bank by DD or PO at the time of submission of tender. This amount shall be retained by the Bank till the work is virtually completed and all amounts relating thereto settled. Second part of security deposit shall be built through the retentions from interim and final bills of the contractor and the amount of retention shall be as stated in the Appendix. When the certificate of the virtual completion is issued to the contractor the security deposit in the form of EMD and 50% of retention money shall be refunded, provided that the contractor has fulfilled all the conditions of contract and further provided that the employer has no claim for forfeiture of part or whole of the said deposit. The balance 50% of the retention money built up through retention from interim and final bills will be returned to the contractor after the expiry of defect liability period, subject to deductions for any appropriations thereof required to be made by the Bank as per conditions of the contract. The contractor should note that no interest will be allowed on his security deposit. The contractor is requested to sign each page of the quotation and put rubber stamp, seal below his signature and seal the quotation in an envelope. Liquidated damages: If the contractor fails to maintain the required progress or to complete the work and clear the site or before the contract or extended date period of completion, he shall without prejudice to any other right, pay as agreed compensation amount of 1 % of contract amount per week of delay subject to maximum of 10 % of contract amount as liquidated damages. Records & measurements: Measurements shall be taken jointly by Bank’s Architect / Engineer and contractor and shall without extra charges provide assistance with appliance, labour and other things necessary for the work and measurements will be signed and dated by both the parties on completion of measurements. Safety measures: The contractor at his own cost shall provide tarpaulins on the external side of the building at the time of breaking plaster etc. to safeguard adjacent property, Bank’s property, employees, traffic, etc. The contractor shall follow all the safety measures while carrying out the work. Employer that is Bank shall not be liable for any compensation due to accident, any mishap or negligence. If there is delay in commencement of work for any reason, the employer that is Bank shall not be liable for any compensation. If at any point of time during the progress, it is observed that the contractor is not progressing the work with due diligence, care and lagging much behind the schedule or fails to gear up the work despite instructions from Bank’s Architects, the employer (Bank) reserves the right to

14


terminate the contract with 7 days notice. In such case, the contractor shall be liable to pay the employer any extra cost involved for the completion of the said work and will not obstruct any way in completing the work through other agency. After completion of entire work the contractor shall be paid for the actual work executed by him at the quoted rates after deducting any claims, damages. In case of such termination the security deposit held by the Bank will be forfeited Although the number of coats of paints / polishing / white washing are specified the contractor will have to additional coats if the surface is not to the satisfaction of the Bank’s Architect / Engineer and there shall be no extra payment on account of such coats First Aid: The contractor shall be responsible for all first aid and he shall keep the site fully equipped to meet such emergency. Supervision: The contractor is required to have on site during all working hours a competent supervisor (acceptable to Bank) who will be responsible for the conduct of worker and who has authority to receive and act on such instructions issued by the Architect / Engineer of Bank. All work shall be carried out in a workman-like manner to the entire satisfaction of the Architect / Engineers. Contractor shall follow all rules / regulations in force and should possess the license for employing labour and also follow all safety measures, labour bye law and shall be responsible for any lapse. Transfer of Tender Documents: Transfer of tender documents purchased by one intending tenderer to another is not permissible. Safety: The contractor shall carry out the entire work in a workman like manner having full regard for the safety of the men working at site. All safe practices shall be strictly adhered to by the workmen of the contractor like wearing helmets, safety belts when working at heights, gloves when handling sharp objects and reinforcement, eye shields during welding, safety shoes, etc. The contractor shall protect sides of openings in floor slabs, edges of slabs, stairs, stairwells etc. with barricades, warning signs / lights and educate all his workmen regarding following safe working practices. He shall provide first aid boxes at site. In spite of following safe methods, in case of any unfortunate accident, the contractor shall indemnify the employer against any expenses or claims towards treatment or compensation. A Daily Diary Register: A daily diary register (with cement and steel stock statement) will be kept in the Engineer’s Office or the site office. The contractor or his representative will furnish every day at 9.00 hrs. details of work for the day proceeding and the diary will be written up every day and jointly signed by the Engineer and the Contractor or their representatives in token of its correctness. Nuisance: The contractor shall not any time do cause or permit anyone to do or cause any nuisance on the site or do anything which shall cause unnecessary disturbance of inconvenience to the Employer or to the owners, tenants or occupiers of other properties near the site and to the public generally.

15


Rights, remedies and powers: I) Termination of contract due to contractor’s default. If the contractor: a. Abandon the contract.

b. At any time defaults in proceedings with the works with due diligence and continues to do so after a notice in writing of seven days from the Engineer or Project Architect or Employer, or

c. Commit default in complying with any of the terms and conditions of the contract and

does not remedy it within 3rd days after a notice in writing is given to him in that behalf of the Engineer or Project Architect or Employer.

d. Persistently disregards the instructions of the Engineer, Project Architect or contravenes any provision of the contract, or

e. Fails to remove materials from the site or to pull down and replace work after receiving from the Engineer, Project Architect notice to the effect that the said materials or works have been rejected.

f. Fails to complete the works or items of work on or before the stipulated date (s) of

completion, and does not complete them within the period specified in a notice given in writing in that behalf by the Engineer, or Project Architect of Employer, or

g. Offer or gives or agrees to give to any person in the Employer’s service or to any other

person on this behalf, any gift or consideration of any kind as an inducement or reward for doing or forbearing to do so for having done or forborne to do any act in relation to the obtaining or execution of this or any other contract for the Employer, or

h. Shall enter into a contract with the Employer in connection with which commission has

been paid or agreed to be paid by him or to his knowledge, unless the particulars of any such commission and the terms of payment thereof have previously been disclosed in writing to the Employer / Engineer, or

i. Shall obtain a contract with the Employer as a result of ring tendering or other non-

bonafide methods of competitive tendency, or j. Being an individual, or if a firm, any partner thereof, shall at any time be adjudged

insolvent or have a receiving order or order for administration of his estate made against him or shall take any proceedings for liquidation or composition (other than a voluntary liquidation fir the purpose of amalgamation or reconstruction) under any Insolvency Act for the time being in force or make any conveyance or assignment of his effects or composition or arrangement for the benefit of his creditors or support so to do, or any application be made under any Insolvency Act for the time being in force for the sequestration of his estates or if a trust deed be executed by him for benefit of his creditors, or

16


k. Being a company, shall pass a resolution or the court shall make an order for the liquidation of its affairs, or a appointed or circumstances shall arise which entitle the court or debenture holders to appoint a receiver or manager, or

l. Shall suffer an execution being levied on his goods and allow it to be continued for a

period of 21 days, or m. Assigns, transfers, sublets (engagement of labour on a piece work basis or of labour

with materials not to be incorporated in the work, shall not be deemed to be sub-letting) or attempts to assign, transfer or sub-let the entire works, or any portion thereof without the prior written approval of the employer.

I) The Bank may, without prejudice to any other right or remedy which shall have accrued or shall accrue thereafter as the Employer by written notice determine the contract either as a whole or in part. II) Upon such determination of the contract in whole or in part, the security deposit with the

Employer in respect of the contract shall stand forfeited to the Employer without in any way effecting the rights of the Employer.

III) Rights of the employer after determination of the contract due to contractor’s default. The Engineer shall on such determination have powers to:

a. Take possession of the site and any materials equipment, plant, implements stores etc. thereon, and / or

b. Carry out the incomplete work by any means at the risk and cost of the contractor. IV) On determination of the contract in full or in part, the Engineer shall determine what

amount, if any, is recoverable from the contractor for completion of the works or part of the works or in case the works or part of the works is not to be completed, the loss or damage suffered by the Employer. In determining the amount, credit shall be given to the contractor for the value of the work executed by him up to the time of cancellation or the value of contractor’s materials to be present so as to record the measurements in his presence. If the contractor fails to be present in response to the notice, the recording of measurements shall be proceeded with ex-parte and the measurements as recorded shall be binding the contractor.

V) The Bank shall have the right to use contractor’s plant, machinery and materials on the

balance work but shall not in any way be responsible for any damage or loss of the same and the contractor shall not be entitled to any compensation thereof.

The Contractor will have to liaison with various concerned authorities to obtain various N.O.C.’s at beginning of work, during the work or at completion stage, N.O.C. obtaining permanent water connection (in our case it would be from Haldwani Municipal Corporation or any other authority), necessary drawings or assistance shall be given by the Architect if found necessary actual legal charge paid in behalf of Clients for which receipt is issued against it, will be reimbursed by the Owner.

17


To, The Regional Manager, Union Bank of India, Regional Office, Haldwani, Dear Sir,

LETTER OF OFFER

Subject: Interior, Electrical, LAN and AC work for Union Bank of India Branch Office MSME Loan Point at Haldwani situated at First Floor, P.B Complex, Near Central Hospital, Kaladhungi Road, Kusumkhera Haldwani-263139. With reference to the tender regarding the above work invited by you, we have to state as under. We declare that before quoting the rates, we have visited the site and our rates are as per present site condition. As required by you, I / We are returning herewith the documents (in single) duly signed by us at each page in token of our acceptance of the provisions in the documents. We hereby offer to execute and complete the whole of the works strictly in accordance with the said conditions of contract, special conditions of contract, specifications and drawings at the rates set out against each of the items of work in the schedule of quantities. the total cost included in the above is Rs. _________ /- (Rs._________________________________________________ only). We have carefully read and clearly understood the conditions of contracts, special conditions of contract, special conditions of contract and specifications. We agree to complete the work at the rate / rates quoted by me / us in the schedule of quantities and within the specified time from the date of work order awarding the work to us. We understand the work is to be completed within scheduled time period. Our rates are firm, excluding and cover all cost, expenses, liabilities of every description and all risk of every kind to be taken in execution and handing over the work to the Bank. The VAT, Service Tax, Sales Tax (State & Central), works contract tax, octroi, duties, municipal tax, general tax and any other taxes applicable and prevailing from time to time on such item for which the same are lovable and the rates quoted by us are exclusive of the same. Thanking You, Yours faithfully, Name : Address : Tel. No. : (Fax. No.) :

18


Mobile No. : Email Id :

A FURNISHING WORKS

S. No. Description Qnty Unit Rate (Rs.) Amount

1 FALSE CEILING (Including ATM Ceiling)a. Providing and fixing GYPSUM BOARD FALSE CEILING in levels as per the detailed drawing - made up of G.I frames as specified by

Gypsum India/Saint -Gobain Gyproc and 12mm thick Gypsum board with suitable suspenders fixed to the ceiling. Ceiling section,perimeter channel of size 20X27X30 mm and 0.55 mm thick for light fittings, AC Grills, diffusers, suspenders etc. shall be standardsections supplied by Gypsum India/ Saint Gobain. Spacing of intermediate channels shall be at 1200 mm c/c and ceiling section at 457mm c/c. The work includes taping and jointing, applying primer, two or more coats of plastic emulsion paint of approved shade ICI/ASHIAN PAINTS make, making cut-out for light fixtures /fittings, etc. The Final coat shall be done with FOAM ROLLER and no brushmarks should be visible. Providing of perimeter channels / beading etc. as per drawing complete in all respects.(All measurement in sqftonly and finished surface area shall be measured)

714 sqft

b. GRID FALSE CEILING(24" x 24")24"x24" Grid False Ceiling Providing and fixing in the true horizontal level false ceiling system of Armstrong world industries. Thesuspension system shall be the Armstrong Trulock Silhouette revealed profile grid system with 15mm wide flanges incorporating a 3mmor 6mm central recess color black or white revealed Silhouette main runners and cross tees to have mitered ends with birds mouthnotches to provide mitered cruciform junctions. Main runners to be spaced at 12mm c/c fixed by using 2mm pre straightened GIWire.Main tee,rotary stitched of size 15mm x44mmx3600mm at every 1200mm c/c maximum and 1200mm cross tee of size15mmx44mm x1200mm at every 600 mm c/c maximum and 600 mm c/c cross tee of size 15 mm x 44 mm x 600 mm at every 1200mmc/c maximum and 19mmx19mmx3000 wall angle All as per the design and instructions Architects (make- Armstrong)All as per thedesign and instructions Architects. (make- Armstrong)

960 sqft

2 PARTITIONSa1 Low height Partition

Providing & fixing of LOW HEIGHT PARTITION (HT. 4'-0") made of 2"x2" alluminium tublar section framework (16 gauge) 2’0” c/cboth ways 10 mm MDF BOARD of approved make on both faces finished with 1mm thick laminate of approved shade. Till the heightof 3'-3" and 1'-3"(10mm thk.) toughened glass on top complete with teak beading, The spirit polishing teak sections of approved shadeas per drawing Complete in all respects to the complete satisfaction of the Architect.

195 sqft

a2 Full height Partition

Providing & fixing of FULL HEIGHT PARTITION up to ceiling level partly glazed, made of 2"x2" alluminium tublar section framework

(16 gauge) 2’0” c/c both ways 10 mm MDF BOARD of approved make on both faces finished with 1mm thick laminate of approved

Make and shade. minimum 8 mm thick toughened glass of approved make with etching/taping as required) on the glazed portion. The

work includes spirit polishing on woodwork and teak beading etc. Complete in all respects to the complete satisfaction of the Architect.

Including doors but excluding cost of door closers, mortise locks.

432 sqft

b SEMI GLAZED PATITIONProviding & fixing of partly glazed (12mm toughened glass of approved make as per design), made of 2"x2" alluminium tublar sectionframework ( 18 gauge) 2’0” c/c both ways 10 mm MDF BOARD of Approved Make on both faces finished with 1mm thick laminate of approved make & shade The work includes providing a 6" x 9" voucher cut out with tray, spirit polishing of shade on woodwork andsteam beach beading etc. Including doors but excluding cost of door closers mortise locks. Complete in all respects to the completesatisfaction of the Architect./Engineer.

15 sqft

(ii Mortise locks with handles.(Make Godrej) 2 no.(iii) Hydraulic Door closer.(Make Godrej/ Universal) 2 no.(iv) Floor springs.for Glass door.(Make Godrej/ Universal) 3 no.

3 GLASS DOORS WITH LOGO A Providing and fixing of (3'-0"/ 3'-6" X8'-0" )12mm toughened glass door with18" long SS handles, floor spring (Ozone,) etc, locking

arrangement of brass make at top of standard make(patch fitting), including fixing of Frosted strip vision film & bank logo as directed bythe Bank/ Architects.

75 sqft

B FIXED GLAZING Providing and fixing external FIXED GLAZING comprising of 12 mm thick toughened glass of approved Make with top, bottom andvertical U Channel frames comprising of powder coated (shade as approved) 14 gauge Aluminium members of approved shade 1.5mmavg. thick top, bottom & vertical member with clip sections as per specifications and drawings to complete satisfaction of the Architect.

85 sqft

C BLOCK DOORSProviding and fixing solid core 38 mm solid core flush door finished with lippings in all side with necessary door hinges , cylindricallocks(golden, Godrej) , door clouser, door stoppers, etc with a frame work of T.W./Beech wood size 75mm x 62.5mm with necessaryhold fast fixed to the wall/partition. 1 mm laminate to be fixed on both sides duly finished,edges to be finished with wooden lippings.Awooden moulding size 1.5"x2/8" to be provided all along the periferi of the frame work in the both sides . All the wooden area to be dulypolished as per specification of the Architect. In case of Partly glazed door 8 mm thk etched toughened glass with granular blasting/sandblasting as per design of the Architect to be fixed with necessary mouldings.

a Partly glazed door with out etching & frosting

iii (7'-0" X3'-0" ) for PASSAGE DOOR & Record Room No. 2.00

b Blocked doors

4 COUNTERS AND TABLES a Providing and fixing SARAL HEAD/ RLP HEAD/ VIGILANCE with 10mm beveled toughened glass of approved make to be fitted on

top obtain the total height of 2’-6” as per detailed drawing, made up of 19mm board of approved Make and finished with 1 mm thicklaminate of approved make, and shade. Table(with one side drawer unit and another side drawer unit) shall be provided withdrawers sliding on telescopic channels and one cabinet with proper locking arrangements and keyboard with telescopic channels . Thework includes providing and fixing of foot rests, shelf for CPU, furniture locks, wire managers, spirit polishing of steam beach/ whitecedar beading etc. and The inner exposed surfaces to be finished with 0.8mm thik laminate of approved shade. complete in all respects tothe entire satisfaction of the Architect/Bank.

Table size: 5-'6" x x 2'-6" 3 no.

TENDER FOR FURNISHING WORKS FOR UNION BANK OF INDIA, SARAL HALDWANI, UTTARAKHAND

SIDE CREDENZAS

Providing and fixing SIDE CREDENZAS size 3' to 4'0" x 1'3" x 2'6" made of 19mm board of approved make finished with 1 mm thick laminate of approved Make and shade on top, back, sides and front having two drawers and cabinet below complete with all accessories like locks, handles, megnetic catcher etc. Teak wood beading on all exposed edges with spirit polish. (Should not be attahced with partitions)

23 no.

d WORK STATIONS TABLEProviding and fixing of COMPUTER work Stations as per layout plan and and 10mm beveled Toughened glass of approved make to befitted on top obtain the total height of 2'-6" high working top ( As per drawing) made up of 19mm board / ply of approved Make,finished with 1 mm thick laminate of approved Make, shade as approved as per the detailed drawing . The tables shall have as perapproved shade and color. All exposed surfaces (such as counter front, sides, drawers and cupboard etc) must be finished with 1mmthick laminate of approved make. Table top shall be finished with 1mm thick laminate. The inner exposed surfaces to be painted overone coat of primer and enamel paint of approved shade. Each unit of table shall be provided with keyboard tray with telescopicchannels. The work includes fixing of wire managers, locks, footrests, spirit polishing the steam beach beading, lipping, exposed frame,etc. as per drawings, and The inner exposed surfaces shall be finished with 0.8mm thik laminate of approved shade. complete in allrespects to the complete satisfaction of the Architect/Bank.

a Officers Table (4'-6" x 2'-6 x 2'-6") 9 nos

b Officers Table/ staff tables (4'-9" x 2'-6" x 2'-6") 14 nos

5 MISCELLANEOUS FURNITUREa Providing & fixing STORAGE CABINETS indipandent units (movable) 12 feet long (maximum) 4’-6” ht and 1’-6” deep as per layout

plan made up of 19mm board/ply of approved make and finished with 1mm thick laminate of approved make, shade and as per detaileddrawing . one shelves made up of 19mm thick board, each drawer(with lock) & cabinet(with lock) 19mm thickness portion everyplace must be finished with proper liping/ margin teak wood finish. In side and back shall be finished with 0.8mm thick laminate ofapproved Make and color The work includes supplying, fixing of hinges, magnetic catchers, handles, locks, teak lipping etc as specified.complete in all respects.

5 rft

b Full height STORAGE CABINATES upto 8'-6" false ceiling hight specification as per (a) 550 Sqft

c Half height STORAGE CABINATES upto 4'-0" hight specification as per (a) 120 Sqft

e Providing & fixing ELECTRICAL PANEL BOXING of 9’-0” ht and depth as per size of the electrical panel, layout plan made up of19mm board / ply of approved Make and finished with 1mm thick laminate of approved Make & shade , in side to be finished with0.8mm thik laminate of approved mke & colour. A fix glass window should also be given to show the indicator LEDS of the panel inside.The work also includes supplying, fixing of hinges, magnetic catchers, handles, Steam Beach lipping, Ventilator Grill etc complete in allrespects to the complete satisfaction of the Architect.

90 sqft

f COLUMN / WALL PANNELINGProviding and fixing of COLUMN PANNELING as per design, consisting of 10 mm thick MDF BOARD of approved Make fixed onwall with made of 2"x2" alluminium tublar section framework ( 16 gauge) 2’0” c/c both ways. The above shall be laminated with 1mmthick mica of approved Make, The work includes sprit polishing of wood beading, complete in all respects as per detailed drawings to thecomplete satisfaction of the Architect.

650 sqft

7 SOFT BOARD WITH WHITE BOARDProviding and fixing soft board with glass White board necessary framework and 12mm bwp plywood on top 12MM jolly board to be fixed finished with fabric @Rs80 , with necessary mouldings duly polished along the periferi.The work to be completed as per approval and satisfaction of the Architect.

125 Sft

TotalGST extra as applicable

SR. DESCRIPTION1 MDF. (Medium Density Fibre Board) – CONFIRMING TO IS : 12406 - 2003. (Density: 750 – 850 Kgs/m3) colour code follow as per Bank Norms.

2 PLYWOOD – BWP (Boiling Water Resistant, Termite Resistant & Borer Resistant) – CONFIRMING TO IS: 303.

3 BLOCK BOARD – CONFIRMING TO IS : 11255 - 2003.

4 FLUSH DOOR – CONFIRMING TO IS : 2202 (Part – 1) – 1991.

5 LAMINATE – CONFIRMING TO IS : 2046-1995.

6 Lipping & Moulding

7 Gypsum ceiling

8 Grid Ceiling

9 GI Support system for False Ceiling

10 Adhesive

11 Locks/Handles & all other hardware

12 Glass

13 Aluminium

14 Door Closer

15 FLOOR SPRING

Vertical Blinds

16 Paint

17 Wood Preservative

18 Cement

19 Presersative

20 Sanitary Fittings

21 CP fittings

22 GI pipe

23 Floor & Wall tiles

24 Overhead Water tank

Vista

Jaguar

Jindal/Bhushan

Nitco/Kajaria

Sintex

Nerolac / Asian Paints

Bison by British Paints / Termiseal by ICI

ACC / Ambuja/Birla Plus

Solignum/Black Japan / Termiseal

Kohler / Hindware

Godrej,Dorset

Modi/Asahi(Tata),Saint Gobain

Jindal/ Hindalco/ NALCO

OZONE/Dorma

OZONE/GODREJ

b

NOTE:1- The contractor is strictrly advised to use the makes specified/approved by the Bank/Architect, unspecified items will not be paid until they are changed with the specified ones.2- The Plywood used for the work shall be BWR ( Boiling water proof range) confirming to IS 303.

Place:

Date: Signature of contractor with seal

RECOMMENDED MAKE TO BE USED

MAKE / BRANDSCENTURY/GREENPLY/ ARCHIDPLY

CENTURY/GREENPLY/ ARCHIDPLY



CENTURY/GREENLAM/ ARCHIDPLY

First Class Teak Wood

Gypsum India, Saint - Gobain Gyproc india

Armstrong, Dexune

GYPSTEEL ULTRA

Fevicol SH.

S.No. DESCRIPTION OF WORKS UNIT QTY RATE AMOUNT

A. POINTS & WIRING

1 LIGHTS POINTS

1

Wiring for light point/ fan point/ wall fan point/ exhaust fan/ light sockets etc. with 1.5 sq.mm. PVCinsulated 1100 V Grade copper conductor (FRLS) wires & 1.5 sq.mm. copper earth wire in concealed/surface using 16 SWG MS conduits, accessories such as bends, tees, saddles, draw boxes, mounting boxes,inner plates, cover plates, ceiling rose etc. (wherever required) and chromium plates brass screws/ rowelplug etc. The circuit wiring starting from DB to point control box/ switch box using 2 X 2.5 sq.mm PVCinsulated 1100 V grade multistranded copper conductor wire & 2.5 sq.mm. PVC insulated earth wire (colorcode to be used). (Flexible conduit/ elbow not allowed). The conduit to be laid in ceiling with proper clamps/wall/ floor and filling the chase with cement mortar and finishing the same in original form/ woodenpartition/ above false ceiling with proper clamps etc. all complete.

(Wherever required as per standard specifications).i) Each circuit shall have independent earth wire. ii) Each point shall be earthed.iii) Circuit wiring is to be included in point wiring rates.

i Primary points controlled by one 6 amp. Modular switch. Nos. 45

ii Secondary light points controlled by one 6 amp. Modular switch. Nos. 25

iiiOne call bell point with ceiling rose/ 6amp. 3 pin sockets controlled by one 6 amp. Push Modular switch.With call bell

Nos. 1

ivOne wall fan/ ceiling/ exhaust fan point with 6-amp 3pin socket controlled by one 6 amp. Modular switch.The switch should be at switchboard level. Nos. 12

vOne 5 pin socket controlled by one 6 amp. Modular switch complete assembly includes plate box etc.Dependent Nos. 15

vi

Same as serial no 1 but using 2*1.5 + 1*1.5 Sq.mm Copper Conductor FRLS wires from DB to first 6A, 5Pin modular socket controlled by one 6A switch and looped to the nearest second point with same 2*2.5 +1*2.5 Sq.mm copper conductor wires FRLS insulated 1100V grade (max 3 points per circuit).

a Primary Point Nos. 8

b Secondary Point looped Nos. 4

2 POWER POINTSSame as serial no.1, but wiring for 16 Amp, 6-pin sockets by using 2* 2.5 sq.mm. PVC insulated 1100 V

grade copper conductor wire with independent 1* 2.5 sq.mm earth wire from D.B. to first point 1st socket

and 1st to 2nd, socket with 2*2.5 sq.mm and 1*2.5 earth wire including providing and fixing of 16 Amp, 6–pin socket with 16 Amp. Switch. (Modular type switch/ socket/ plate etc. complete assembly) max 2 pointsper circuit.

a) Primary Point Nos. 12

b) Secondary Point Nos. 3

3 AC POINTS FOR INDOOR & OUTDOOR UNITS

3(a)

Same as serial no.1, but wiring for A/C socket by using 2*6 sq.mm. PVC insulated 1100 V grade copperconductor wire and earthing with 1*4.0 sq.mm. PVC insulated 1100 V grade copper conductor wire withmodular type AC box (tiny trip type) with socket complete in all respects controlled by 25/32 A SP MCB tobe provided near indoor unit. The point starts from DB to stabilizer to the point near the indoor unitincluding top.Items should be executed after approval from Bank/ Architect.

Nos. 6

3(b)

Same as serial no.1, but wiring for A/C socket by using 2*4 sq.mm. PVC insulated 1100 V grade copperconductor wire and earthing with 1*4.0 sq.mm. PVC insulated 1100 V grade copper conductor wire ofweather proof type AC box with socket complete in all respects controlled by 25 A MCB to be providednear outdoor unit. The point starts from DB to the point near the outdoor unit.

Nos. 2

4 COMPUTER POINTS (UPS)

a

Wiring with 2x1.5 sq.mm. + 1x1.5 sq.mm. PVC insulated 1100 V grade multi stranded copper conductorwires in 2 mm thick PVC conduit from UPS DB to computer point. Each point to have 3 nos. 6 amps. 5 pinmodular type sockets, one 6 amps modular switch with all accessories, inner/ outer plates, metal box etc. andto be fixed on wooden partitions/ by grouting on wall etc. as per requirement at site. The switch should befixed above the top of counter with indicator and sockets under the counter. b) Same as above but loopedfrom the above 1st point to 2nd, point and 2nd point to 3rd point. (Maximum 3 points in a circuit)

Primary Points Nos. 29Secondary Points Nos. 3

BILL OF QUANTITY FOR ELECTRICAL WORK FOR UNION BANK OF INDIA,SARAL HALDWANI, UTTARAKHAND

ELECTRICAL WORKS

b

Wiring with 2x1.5 sq.mm + 1x1.5 sq.mm PVC insulated 1100 V grade multi stranded copper conductorwires in 2mmthick PVC conduit from UPS DB to computer point. Each point to have 1 nos. 16 amps 5 pinmodular type sockets, 1 No's 16 amps modular switch with all accessories, inner/ outer plates, metal box etcand to be fixed on wooden partitions/ by grouting on wall etc as per requirement at site. The switch shouldbe fixed above the top of counter and sockets under the counter. or as directed by the engineer in charge forthe rack supply in PA rack, CCTV etc. b) Same as above but looped from the above 1st point to 2nd point(Maximum 2 points in a circuit)

Primary Points Nos. 3Secondary Points Nos. 2

B.CONDUITING FOR TELEPHONE, COMPUTER &CONDUITING, WIRING FOR T.V. SYSTEM.

1 TELEPHONE SYSTEM

1.1

Wiring for VOICE from Jack Panel in data rack to computer workstation with Cat-6 voice cable in PVCconduits of size 20/ 25 mm including providing ferrules at both ends and termination at both ends includingproviding & fixing frame for Cat-6 with shutter, RJ 45 outlet, faceplate and mounting box complete ofmodular type. This work includes supply and laying of CAT-6 cable in PVC conduits throughout the length,from the I/O hub to the point.

Nos. 0

1.2Supplying, laying, effecting terminations, testing and commissioning of 0.51 mm dia Cu. Conductor,twisted, colour coded with polythene capor barrier, telephone cables in the existing tray or in conduitincluding providing &fixing conduit pipe or cable tray as required from building tag block to the floor asrequired.a) Supplying & fixing 20 pair krone tag block with enclosure. Nos. 0

b) P/L 20 Pair of PVC insulated PVC sheathed multi core jelly filled armored telephone. Mtr. 0

c)Panasonic Electronic Modular Switching System MODEL NS-300 (Digital IP PBX SYSTEM) For 6 COLines 2 Digital Extension and 16 Extensions, with DISA Greeting Message and Extension Caller IDExpandable upto 6 co & 32 Extensions.

Nos 0

d) MDF with Krone Modules 50 pairs with connector Nos 0

2 COMPUTER NETWORKING

2.1

Wiring for computer networking from Jack Panel in data rack to computer workstation with Cat-6 computercable in PVC conduits of size 20/ 25 mm including providing ferrules at both ends and termination at bothends including providing & fixing frame for Cat-6 with shutter, RJ 45 outlet, faceplate and mounting boxcomplete of modular type, this work includes supply and laying of CAT-6 cable in PVC conduits throughoutthe length, from the I/O hub to the point.

Nos. 55

2.2Providing & fixing 9 U (Rack with glass door, opening in the front power panel 1 (horizontal), cablemanager 1 lock & key).

Nos. 1

2.3 Providing &Installation, Testing & Commissioning of 24 port Jack Panel. Nos. 1

2.4 Supplying and fixing Patch Cord-2 Meter- (DBPS Mounting Cord) Nos. 52

2.5 Supplying and fixing Patch Cord-1 Meter- Nos. 53 Supply and fixing of 1.6 mm thick G.I. Box along with RG 6 T.V Co axial socket with Cover Plate. Nos. 04 Supply, drawing, connecting, testing and commissioning of T.V Coaxial cable RG 6 in existing conduit. RM 0

C. CABLES, MAINS & SUBMAINS

1

Supplying all materials and laying/ pulling 1100 volts grade PVC insulated copper conductor wires (FRLS)in MS conduit with all fixing accessories after cutting the floor, wall and the like etc. and plastering the floorlevel to original. Conduit must be 30 mm below the floor finish level. Items should be executed afterapproval from Bank/ Architect.

i 2 X 4 sq.mm. + 1 X 4 sq.mm. RM 0ii 2 X 6 sq.mm. + 1 X 6 sq.mm. RM 0iii 2 X 10 sq.mm. + 1 X 6 sq.mm. ( UPS DB) RM 85iv 1 X 10 sq.mm. Cu wire for earthing. RM 52v 4x10 sq.mm. +2x6sq.mm (Panel to TPN) RM 95

v

Supplying, laying, testing & commissioning of 3.5 C X 16 sq.mm. at 1100 volts grade PVC insulatedaluminum conductor armoured cable with 10 gauge earth copper wire including cables end termination usingappropriate Lugs, Glands, termination accessories, Clamps etc. as required as per specification (Light DB +Power DB).

RM 0

vi

Supplying, laying, testing & commissioning of 4 C X 35 sq.mm. at 1100 volts grade PVC insulatedaluminum conductor armoured cable with 10-gauge earth copper wire including cables end terminationusing appropriate Lugs, Glands, termination accessories, Clamps etc. as required as per specification (ACDB).

RM 0

PART (A) SUB TOTALGST @.....................

PART (A) SUB TOTAL INCLUDING GST

PART (B) SUB TOTALGST @ ………………

PART (B) SUB TOTAL INCLUDING GST

vii

Supplying, laying, testing & commissioning of 3.5 C x 50 sq.mm. at 1100 volts grade PVC insulatedaluminum conductor armored cable with 10 gauge earth copper wire including cables end termination usingappropriate Lugs, Glands, termination accessories, Clampsetc. as required as per specification. (Mains)

RM 25

D. DISTRIBUTION BOARD

Supplying, installing, testing &commissioning of surface/recessed mountings, Double door 415 volts TPNMCB distribution board of steel, 1.6 mm thick dust phosphatized and painted, inclusive of 100 amps, tinnedcopper bus bars, earth bar, common neutral link, din bar for mounting of MCB's detachable gland / knockout plate & with built in loose wire box, and superior make terminal connectors for all incoming andoutgoing circuits duly prewired with adequate size of PVC insulated copper wires between the bus bars andthe MCB's as well as the incomer and upto the terminal connectors/ neutral link and ready for installation offollowing ways as required.

Use 'B' curve MCB's for lighting & small power circuits, 'C' curve for motor duty i.e. for pumps, AC motors,window and split AC's etc. & 'D' curve for UPS DB's i.e. for computers/ PC's circuit. Main incomer &outgoing circuit MCB's shall be selected accordingly i.e. type B,C & D. Contractor to select the MCB'saccordingly as per the nature of the circuit/ load.Each DB shall have separate neutral links of rating not less than 100A for each phase. The main incomingneutral link shall be in addition to three outgoing neutral links and shall be of 125 A.

UPS DB's shall have a dedicated Earthing link fixed on insulated supports, which will be in addition to bodyearth link.All internal inter connecting wiring with in the DB's shall be PVC insulated flexible copper conductor wiresof adequate capacity as per the current rating. Inside each DB, a DB chart is to be fixed. Items should beexecuted after approval from Bank/Architects

a 4-way TPN DB (LIGHT DB/ Power DB) No. 2Incomer: -1 No. 63 Amp TPN (10 KA) MCB with 40 A DP MCCB (100 MA) each phaseOutgoing: -6 Nos.6/10 Amp (10 KA) SP MCB

b 4-way TPN DB (AC DB) No. 1Incomer :-1 No. 63 Amp TPN (10 KA) MCB with 63 A DP MCCB (100 MA) each phaseOutgoing :-6 Nos. 10/16/25/32 Amp (10 KA) SP MCB

c 4-way SPN DB with 2 Nos. 40 A (10 KA) DP MCB (For UPS Input) No. 1

d 12-way SPN DB (For UPS Sub DB) No. 2Incomer:-1 No. 63 Amp DP (10 KA) MCB Outgoing:-10 Nos.6/10/16/25Amp (10 KA) SP MCB

E (LIGHT FITTINGS & ACCESSORIES)

Supplying, installation with hanging support, testing and commissioning of following light fixtures withelectronic Ballasts, Tubes, lamps, all fixing materials including connecting wires etc. all complete as per thedirections of Engineer-in-charge (All LED Light Fixtures should be covered with minimum 3 Years onsitereplacement warranty). Items should be executed after approval from Bank/ Architect.

i LED 18 W tube 4'-0" As specified in tender document or approved by Bank/Architect. Nos. 3

iiFULL GLOW 2 X 2 LED 36 W slim Smart Panel of make As specified in tender document or approved byBank/Architect. Nos. 36

PART (C ) SUB TOTALGST @ ………………

PART (C ) SUB TOTAL INCLUDING GST

PART (D) SUB TOTALGST @..............

PART ( D ) SUB TOTAL INCLUDING GST

iiiSupplying, fixing, testing and commissioning of 12 W LED commercial type down lighter of make Asspecified in tender document or approved by

Nos. 25

ivLED Strip for cove lighting 12 W per 5 M with driver and necessary installation fittings Led strip light (5mtr.) make as specified in tender document or approved by Bank/Architect.

Nos. 0

vSupply, installation, testing and commissioning of following fans with all fixing materials like whitePolycarbonate 2 mm Hylem sheet cover, down rods, fan box as required etc. all complete as per thedirections of Engineer-in-charge.

aWall mounted fans 400 mm dia. make As specified in tender document or approved by concerned office incharge.

Nos. 10

bSupply & fixing of 230 mm exhaust fan 'Ventilair DX W' with self-closing louvers and plastic body with allaccessories etc. complete of make As specified in tender document or approved by concerned office incharge.

Nos. 2

cCeiling Fan- Supply, Erecting,and testing of approved/specified make ceiling fans complete with down rod,canopy, blades and Electronic speed regulator 230-250 volts including connection with all necessarymaterials as required. Make- Usha/ Havells/Crompton

Nos. 0

F. EARTHING SYSTEM

1

Supply, Installation, Testing and Commissioning of Maintenance Free Earthing system made up of copperbonded rod of 10 feet length,23 mm dia. (Minimum copper bonding shall be 0.25mm) along with Rod-toConductor connectors, Earth enhancement material, Pit Cover and other accessories as required and as perspecification and other applicable codes (include chamber for earthing, Earthing certificate to be submittedalong with the bill).

Nos

2

Supply, Installation, Testing and Commissioning of Maintenance Free Earthing system made up of copperbonded rod of 10 feet length, 17.2 mm dia. (Minimum copper bonding shall be 0.25 mm) along with Rod-to-Conductor connectors, Earth enhancement material, Pit Cover and other accessories as required and as perspecification and other applicable codes (include chamber for earthing, Earthing certificate to be submittedalong with the bill).

Nos 1

3 Providing and fixing of Copper/ GI strips in surface or in recess for loop earthing etc. as required.i 25 mm x 3 mm copper strip in B-class GI pipe RM 0ii 25 mm x 5 mm GI strip RM 0

iiiProviding and fixing 2 X 6mm Cu earth wire in PVC conduit on surface or in recess for loop earthing alongwith the existing surface/ recess cable as required.

RM 25

G. MAIN PANEL AND METER BOARD

Designing, fabrication, supply, installation, testing and commissioning of front operated cubicle typecompartmentalized, front access, free standing on 75MM "[" MS channel, dust and vermin proof (IP 42degree protection) panel suitable for use at 415V, 3 phase, 4-wire 50Hz system suitable for fault level ofrequired value symmetrical at 415V fabricated from 2mm thick CRCA MS sheets with hinged, gaskettted(Metal based neoprene) lockable doors having structural reinforcement including 3mm thick gland plates ontop and bottom, lifting hooks, GI earth strip of required size with 2 no’s earth terminals, 2 no’s 230V ACoperated 250 mm X 250 mm size axial fans for exhaust of heat with On-Off toggle switches including 2coated primer and 2 power coated paint finish of approved shade over metal surface cleaned and treatedwith seven tank process complete with interconnections etc. as per specifications as required. Main panelboard of approved make (Should be CPRI Approved, Type of Approval as instructed by the concernedoffice in charge)

As per the following specifications, (Part IV - Substation) and IS: 8623 comprising of followings panelmounting switchgears etc. as required, should be CPRI Approved.IS: 8623 comprising of followings panelmounting switchgears etc. as required, should be CPRI Approved. Note: Type of CPRI testing shall be asper Architect/ Bank's instructions. All switchgears shall have provision for entry of cables from the top orbottom through Cable Alley.

All live accessible parts shall be shrouded and all equipment shall be finger touch proof. The busbarsinsulation shall be withheat shrinkable sleeves SMC/ DMC shrouds and busbar supports shall be used.Padlocking facility shall be provided on all outgoing feeders’ doors and switch handles shall be lockable inOFF position.

Suitable arrangement shall be made for termination of multiple incoming cables.All KA values indicated shall be ICS breaking capacityGA drawings shall be got approved by concerned office in charge.

a. Floor panel shall consists of : -Items should be executed after approval from Bank/ Architect.

PART (F) SUB TOTAL

PART (E ) SUB TOTALGST @...............

PART ( E ) SUB TOTAL INCLUDING GST

GST @............PART (F ) SUB TOTAL INCLUDING GST

INCOMER1 no. 100 Amp 4P On Load Change over switch with 1 No. 100 Amps,TPN MCCB (25 KA) withextendable rotary handle each thermal over current, instantaneous, Short circuit release, Earth fault.

BUSBARS125 amps TPN pole bus bar chamber of suitable length with copper bus bars. All bus bars andinterconnections shall be of suitable size copper strips.

Set 1

b. INDICATING PANELDigital flush type class-1.0 accuracy multifunction meter showing V, A, PF etc. with 3 Nos. CurrentTransformers of 125/5A ratio, 15 VA Class-1.0 metering. - 1 setsRed/Green/Amber ON/ OFF/ TRIP indicating lamps with 2A SP MCB backup protection.1 set of three phase indicating lamps along with 2A SP MCB backup protection.Restricted Earth fault relay with 3 Nos. current transformers of 125/5 ratio, 15 VA Class 5P 10(Numeric Relay not required.)Under voltage, Overvoltage & phase reversal relay for persisted voltage of 105-180% & 20-95% of ratedvoltage (Numeric Relay not required).

OUTGOINGS: -2 Nos 63 A TPN MCB (10 kA) terminals suitable to receive cable on one side and wire connection to Busbars. (For Light DB & Spare)3 Nos 40 A DP MCB (10 kA) terminals suitable to receive cable on one side and wire connection to Busbars. 2 Nos 63 A TPN MCB (10 kA) terminals suitable to receive cable on one side and wire connection to Busbars. (for AC and Power DB)The electrical panel as described above and specifications complete. Set 1

DESCRIPTIONS.N. PVC Conduit

1 Ceiling Junction Boxes2 Wires & cables3 Modular Switches,Sockets etc4 Lighting Fixtures5 M.C.B./RCCB/RCBO etc6 Distribution Boards7 MCCB8 Change Over Switches9 End Termination accessories

10 Telephone Cables & accessoreies11 Fans/Exhaust fans12 Music Speakers13 Amplifiers14 DVR15 Rg11, CAT5/CAT6 cables/Telephone wires16 CCTV Dome Camera17 Hard Disk drive18 Smoke/Heat/Optical Fire Detectors19 Response Indicators, Hooters20 Telephone Tag Block

Edward,Siemens OR other ISI Krone

Place:

Date: Signature of contractor with seal

APPROVED MAKE LIST

Samsung,Honeywell , HIKVISIONLegrand, Molex, D’Link ,AMP

Honywell, HIKVision Seagate, HIKVISION

Edward,Siemens, Appolo Or other

Dowells/Usha/Brecco/CosmosHavells, Krone, Finolex, Crompton/Havell/USHA

Philips/Bosch/AhujaPhilips/Bosch/Ahuja

Philips/Wipro/CromptonLegrand/Havells/L&T

Same As AboveSchneider/Legrand/Havells

H.P.L./A.B.B./Standard/ L.& T.

Approved MakesPrecision/AKG

Home lite/ANCHORR.R./Havells/ Polycab

Legrand/Havells/L.& T.

GROSS SUB TOTAL (PART A + PART B + PART C + PART D + PART E + PART F + PART G + PART H + PART I

GRAND TOTAL AMOUNT

PART (G) SUB TOTALGST @....................

PART (G) SUB TOTAL INCLUDING GST

Sr. No 123456

Sr. No SPLIT TYPE AIR CONDITIONERS

A. PART -AHIGH SIDE WORK

Description Unit Quantity Rate Amount

1

Supplying, erection, testing and commissioning following wall mounted Split/ Roof mounted cassetteunits of (Toshiba/ O-General/Mitsubishi Heavy Industries) with cordless remote complete with allnecessary fittings duly insulated with 9 mm thick nitrile rubber pipe insulation with (evaporator coil –copper only), fan and fan motor, machine control panel improved Refrigerant Joints, .Air conditionersshall be fitted with hermetically sealed type suction cooled reciprocating or discharge cooled rotarycompressor or scroll compressor. Compressor unit operating on R-22/ R-410. All complete as per drawing,approval and instructions of the Employer (Rates to be inclusive of Copper refrigerant pipe with insulationand Drain pipe up to 5 Mtr. length).

a1.0 TR wall mounted split unit (Minimum 3-Star rating Non- inverter type) including all necessary fittingsand mountings as specified by the manufacturer. Nos. 2

b1.5 TR wall mounted split unit (Minimum 3-Star rating Non- inverter type) including all necessary fittingsand mountings as specified by the manufacturer.

Nos. 0

c2 TR wall mounted split unit (Minimum 3-Star rating Non- inverter type) including all necessary fittingsand mountings as specified by the manufacturer.

Nos. 0

d1.5 TR Cassette type unit with 4 way/ round air flow including all necessary fittings and mountings asspecified by the manufacturer (Three phase). (5 star or Equivalent energy saving latest model InverterType)

Nos.

e2.0 TR Cassette type unit with 4 way/ round air flow including all necessary fittings and mountings asspecified by the manufacturer (Three phase). (3 star or Equivalent energy saving latest model InverterType)

Nos. 6

f3.0 TR Cassette type unit with 4 way/ round air flow including all necessary fittings and mountings asspecified by the manufacturer (Three phase). ( 3 star or Equivalent energy saving latest model InverterType)PART A –HIGH SIDE WORK SUB TOTAL AMOUNT

B. PART –BLOW SIDE WORK

1 EXTRA REFRIGERANT PIPING

Supplying and laying of Extra copper refrigerant piping with nitrile rubber pipe insulation, both of size asspecified by the manufacturer suitable for 1.0 TR/ 1.5/2.0 TR Split type AC and 2.0/3.0 TR Cassette AC(From Indoor to outdoor Units) Beyond 3 M.

a For 1.0 T Split unit Mtr.b For 1.5 T Split unit Mtr. 30c For 2.0 T Split Unit Mtr. 0d For 1.5 T Cassette Unit Mtr.e For 2.0 T Cassette Unit Mtr. 45f For 3.0 T Cassette Unit Mtr.2 DRAIN PIPING

Providing and fixing drain piping up to drain as directed by the engineer in charge with all accessories e.g.elbows, unions, sockets, reducers, reducing tees, nipples etc. Complete job including cutting chiseling inwalls, fixing with GI clamps, floor and making good of all chases/ cuts etc. and discharging the drain into afloor trap/ gully as per site conditions with insulation, both as specified by the manufacturer.

a 25 mm dia PVC drain pipe for Split AC Mtr. 35b 32 mm dia PVC drain pipe for Cassette AC Mtr. 65c 40mm dia PVC drain pipe for Cassette AC Mtr

AIR-CONDITIONING WORKS: Air-conditioning System (Inverter Model/ 3 Star - Wall mounted Split Unit/ Ceiling Suspended Cassette unit)Equipment Make – Toshiba/ OGeneral/ Mitsubishi Heavy Industries- 3 star split.model – cassette (inverter units) with copper condenserAll the work of Drain pipe/copper pipe/cable shall be properly supported by clamps from the slab.

GST @....................

AIR-CONDITIONING WORKS:

AIR-CONDITIONING WORKS, UNION BANK OF INDIA, SARAL HALDWANI, UTTARAKHAND

Note: For any make, if OEM doesn’t has specific star rating for the product but that product has equivalent energy saving as compared to the star rating, then vendor shall mentioned the same against the model number.

2.0 TR Wall mounted Split Unit 3 Star Inverter Model1.5 TR Wall mounted Split Unit 3 Star Inverter Model1 TR Wall mounted Split Unit 3 Star Inverter Model

Product Model No. Particulars 3.0 TR Ceiling Suspended Cassette Unit 3 Star Non- Inverter Model or equivalent2.0 TR Ceiling Suspended Cassette Unit 3 Star Non- Inverter Model or equivalent1.5 TR Ceiling Suspended Cassette Unit 3 Star Non- Inverter Model or Equivalent

3 AUTOMATIC VOLTAGE CONTROLLERProviding and fixing of Stabilizer shall be Automatic version with copper coil transformer and the voltageselection range shall be minimum depending on lowest peak recorded average in a month. Precise outputvoltage range (130V-170V to 240V -270 V). Ensure the rating of Stabilizer shall be in accordance with maxrated power of ACs considering instantaneous peak load fluctuation.Providing and fixing Stabilizer with 3-4 step relay and input voltage range of 130-270 V and output to be230-240 V (Blue bird/ Logic state/ Inline/ V-Gaurd/Equivalent Reputed Make) (copper winding).

a 5 KVA (For 3.0/ 2.0 TR Split AC) Nos. b 4 KVA (For 1.5/ 2.0 TR Split AC) Nos. 0 c 3 KVA (For 1.0/ 1.5 TR Split AC) Nos. 2

4 AIR-CONDITIONERS STAND WITH MS- CAGE

1

Providing and fixing of lockable caging for outdoor unit grouted on wall or on roof with open able shuttermade of 10 X 10 mm MS square bars placed vertically @ 5” c/c welded with 40 X 3 mm MS flat all- round.The frame shall be of angle 35mm*35mm and it shall be fixed to wall or roof with proper MS bracket totackle the weight of outdoor unit. Item includes all necessary hardware, priming coat, synthetic enamelpaint, hanger, clamps other accessories etc. All complete as per approval and instructions of theemployer. Size shall be adequate for AC outdoor size & sufficient space around the outdoor suitable forservicing purpose for Outdoor unit.

a For 1.0 TR Hi Wall split units Nos. 2b For 1.5TR Hi Wall split units Nos.c For 2.0 TR Hi Wall split units Nos.d For 2.0 TR ceiling mounted cassette unit Nos. 6e For 3.0 TR ceiling mounted cassette unit Nos.

5 ELECTRICAL CABLESSuitable IS/BIS standard Cable of 1.1-2.2 KV, Multi strand, FRLS 2- 4 C / 1.5/2.5 -6.0 Sqmm) as per designrequirement of Peak load calculation of specific ACs system installed at site with 1”/1/2"/2” PVC conduitpipe between indoor/outdoor unit

aSupplying and laying of Extra Electrical interconnecting control cable from indoor to outdoor of size asspecified by the manufacturer suitable for 1.0 TR/ 1.5/2.0 TR Split type AC. Mtr. 25

bSupplying and laying of Extra Electrical interconnecting control cables from indoor to outdoor of size asspecified by the manufacturer suitable for 2.0/ 3.0 TR Cassette type AC. Mtr. 55

6 TIMER

aSupplying, installation and commissioning of automatic 24 HRS. programmable TIMER of required capacity to run A.C. alternately (L&T/ Sumsung / Panasonic reputed make). Nos. 0

7 CORE CUTTING a Core cutting member in Non RCC with civil works required at site etc. Nos. 8

PART BGST @....................PART B – LOW SIDE WORK SUB TOTAL AMOUNT

GRAND TOTAL (PART A + PART B) EXCLUDING GST

Note: The rates quoted includes all other taxes, duties, loading, unloading, transportation, other expenses etc. to site only GST will be paid Extra

CONCEPT DESIGN - INTERIOR

LAYOUT PLAN

VVA/BANK/UBI/HLD/ID

18July' 2022

1

1

NORTH:

SHEET No

DRAWING TITLE :

SCALE :

DRAWING NO. :R1

DATE :

CHECKED :DEALT :

ARCHITECT:

CONSULTANTS NAME & ADDRESS :

AR. RAHUL CHAUDHARY

Ar. Rahul Chaudhary

Ar. Rahul Chaudhary

1:75

CLIENT NAME & ADDRESS :

PROJECT NAME:

Consultancy Services with supervision of Total

furnishing work of Saral Situated at First Floor,

P.B. Complex near Central Hospital, Kaladungi

Road, Kusumkhera, Haldwani, Distt- Nainital.

Regional Office, Haldwani

Pramod Babu Complex near Central Hospital,

Kaladungi Road, Kusumkhera, Haldwani-263139

36, Keshav Road, Laxman Chowk, Opp.

Arya Samaj Mandir Dehradun (U.K.) -248001

24, First Floor, S2S Square Garh Road,

Meerut- 250002 (U.P)

Ph:+91-9899328602, +91-9997591118,

[email protected]

OPTION-02 (R1)

AutoCAD SHX Text

LIFT

AutoCAD SHX Text

VIGILANCE CABIN -02 9'-1"X11'-6"

AutoCAD SHX Text

DOCTOR'S CABIN-01 7'-0"X11'-6"

AutoCAD SHX Text

RECORD ROOM 12'-11"X11'-7"

AutoCAD SHX Text

SARAL HEAD 11'-0"X8'-0"

AutoCAD SHX Text

RLP HEAD 11'-0"X8'-0"

AutoCAD SHX Text

WORKSTATIONS 11'-0"X8'-3"

AutoCAD SHX Text


AutoCAD SHX Text

01

AutoCAD SHX Text

02

AutoCAD SHX Text

03

AutoCAD SHX Text

04

AutoCAD SHX Text

17

AutoCAD SHX Text

18

AutoCAD SHX Text

19

AutoCAD SHX Text

20

AutoCAD SHX Text

WORKSTATIONS

AutoCAD SHX Text

4'-0" WIDE PASSAGE

AutoCAD SHX Text

FULL HEIGHT STORAGE

AutoCAD SHX Text

FULL HEIGHT STORAGE

AutoCAD SHX Text

FULL HEIGHT STORAGE

AutoCAD SHX Text

FULL HEIGHT STORAGE

AutoCAD SHX Text

CABINET

AutoCAD SHX Text

CABINET

AutoCAD SHX Text

FULL HEIGHT STORAGE

AutoCAD SHX Text

ENTRY FOYER 6'-6"X12'-0"

AutoCAD SHX Text

RECORD ROOM 8'-7"X6'-1"

AutoCAD SHX Text

6'-6" WIDE PASSAGE

AutoCAD SHX Text

FD/FT

AutoCAD SHX Text

HF

AutoCAD SHX Text

AutoCAD SHX Text

TOILET (M) 7'-9"X5'-3"

AutoCAD SHX Text

TOILET (F) 6'-0"X6'-7"

AutoCAD SHX Text

4'-6" WIDE PASSAGE

AutoCAD SHX Text

COMMON AREA

AutoCAD SHX Text


AutoCAD SHX Text


AutoCAD SHX Text

3'-4" WIDE PASSAGE

AutoCAD SHX Text

BALCONY

AutoCAD SHX Text

WORKSTATIONS

AutoCAD SHX Text

WORKSTATIONS

AutoCAD SHX Text

WORKSTATIONS

AutoCAD SHX Text

05

AutoCAD SHX Text

06

AutoCAD SHX Text

07

AutoCAD SHX Text

08

AutoCAD SHX Text

09

AutoCAD SHX Text

10

AutoCAD SHX Text

13

AutoCAD SHX Text

14

AutoCAD SHX Text

11

AutoCAD SHX Text

12

AutoCAD SHX Text

15

AutoCAD SHX Text

16

AutoCAD SHX Text

21

AutoCAD SHX Text

22

AutoCAD SHX Text

FULL HEIGHT STORAGE

AutoCAD SHX Text

side cabinet

AutoCAD SHX Text

side cabinet

AutoCAD SHX Text

side cabinet

AutoCAD SHX Text

side cabinet

AutoCAD SHX Text

side cabinet

AutoCAD SHX Text

side cabinet

AutoCAD SHX Text

side cabinet

AutoCAD SHX Text

side cabinet

AutoCAD SHX Text

side cabinet

AutoCAD SHX Text

side cabinet

AutoCAD SHX Text

side cabinet

AutoCAD SHX Text

side cabinet

AutoCAD SHX Text

side cabinet

AutoCAD SHX Text

side cabinet

AutoCAD SHX Text

side cabinet

AutoCAD SHX Text

side cabinet

AutoCAD SHX Text

side cabinet

AutoCAD SHX Text

side cabinet

AutoCAD SHX Text

side cabinet

AutoCAD SHX Text

side cabinet

AutoCAD SHX Text

side cabinet

Tender MSME LOAN POINT HALDWANI - Union Bank of India

Documents

Transcript of Tender MSME LOAN POINT HALDWANI - Union Bank of India