CENTRAL RAILWAY - Amazon AWS
-
Upload
khangminh22 -
Category
Documents
-
view
1 -
download
0
Transcript of CENTRAL RAILWAY - Amazon AWS
1
CENTRAL RAILWAY
Engineering Department
(Construction)
TENDER DOCUMENT
Tender Notice No. : CAO(C) 12/2/2018 dated 08.05.2018
Name of work : Track work in Section-II (Kms.65.00 to Kms.145.00) in
connection with Pune-Miraj Doubling Project.
Approximate Cost : Rs. 5450.37 Lakh.
Earnest Money : As per tender notice.
Sale of Tender forms : Tender documents will be available on IREPs website
www.ireps.gov.in
Completion period As per tender notice
Date & Time of submission As per tender notice.
Date of opening As per tender notice.
Note : Details of Tender Notice, Tender document and corrigendum
issued from time to time alongwith eligibility criteria are
available on the web sites www.ireps.gov.in. Necessary
changes if required, would be posted on this web site at least
15 days in prior to opening of tender and may be seen on web
site.
2
INDEX
Sr.
No. Contents Page Nos
1 Cover page 1
2 Index 2
3 Special Instructions & Guidelines for Submitting e-Tenders 3-4
4 Section A
5 to 32
5 Tender Notice
6 Tender Declaration form
7 Acceptance of Tender
8 Regulations and Conditions for Tender (Part-I)
9 Annexure-I Agreement for Works(Format)
10 Annexure- I ,II, IIIA,IIIB, IV, VA, VB, VI, VII, VIIA ,IX
11 Section - B Special condition of Contract / GCC 33 to 87
12 Safety rules, GIST Of safety Instructions, Annexure XII to XIV
13 Section - C Scope of works and additional special conditions
88 to 96 14 Scope of work
15 Addl.Special Conditions
16 Section - D Technical specifications
97 TO
145
17 General
18
Open foundation, Structural concrete, Form work , Reinforcement ,
Miscellaneous Items , Specifications for Earth work 8, Guidelines on
fabrication of steel structure , Ann.I, III , JPO Digging work
19 Technical specification for track work
20 Agreement for works 146
3
SPECIAL INSTRUCTIONS & GUIDELINES FOR SUBMITTING e-TENDERS
1. Submission of tenders shall be ONLY through e-tendering on the website
www.ireps.gov.in . No documents shall be accepted after opening of the e-tender. Only
clarifications/verification shall be sought on the documents already submitted by
uploading online, if required.
2. Offer shall be submitted only in the name of the tenderer/s who intend to submit their
offer for the work, with digital signature of the Authorised Signatory / Power of Attorney
holder.
3. In case of JV firm/s, the offer shall be submitted in the name of the JV Firm/s only who
intend to submit their offer for the work with digital signature of the Authorised
Signatory of the JV firm who has been specifically nominated/holds the Power of
Attorney for this work or the Authorised Signatory of Lead Member of the JV firm.
(Note : Applicable only if JV firms are permitted to participate in the tender.)
4. Tenderer must deposit/pay Earnest Money Deposit (EMD) and Tender Document cost
(TDC) through Net Banking/Payment Gateway (Online Payment), as specified for the
tender.
5. Tenderer/s are required to upload scanned documents as specified in tender document.
Some of the Important documents are reiterated below:-
(a) Documents in support of fulfillment of Eligibility Criteria.
(i) Authentic Certificates clearly reflecting the Contractual Receipts for the last
three financial years & current financial year, which may be ANY ONE OR
MORE of the following :
Copy of Certificate from the employer/client.
Copy of Audited Financial Statements duly certified by the Chartered
Accountant. For current year, certificate from Chartered Accountant can be
submitted in place of Audited Financial Statements.
Copy of TDS Certificate or Form 26AS
(ii) Certificate(s) of Work Completed by the Firm in the last three financial years and
the current financial year, which satisfies the eligibility criteria of “Similar nature
of work”, as specified in the tender document.
Note : (A) While submitting Audited Financial Statements, all relevant pages should be
submitted so that Contractual Receipts can be worked out.
(B) In case of (i) above, if unattested documents are uploaded, then successful tenderer
will either submit attested copies or bring original documents for verification, when
called for.
(b) Tenderer‟s Declaration Form (As per Technical Bid Document)
(c) Affidavit verifying the genuineness of the documents submitted by the Tenderers/JV
firms (as per Annexure-VII A).
(d) Copies of legal documents depending on the category of the tenderer (Details given in
Tender Document).
(i) SOLE PROPRIETOR
Affidavit on Stamp paper or any other document, to establish that the
Tenderer is a Sole Proprietor of the firm.
(ii) PARTNERSHIT FIRM
Partnership Deed.
4
Power of Attorney.
(iii) COMPANY
Board Resolution passed by the Company in connection with participation in
the present tender.
Power of Attorney
Copy of Memorandum and Articles of Association
(iv) JOINT VENTURE FIRM :
MEMORANDUM OF UNDERSTANDING between the JV Partners.
Authorisation in favour of one member on behalf of JV firm.
Documents of all Constituent firms as per (i), (ii) & (iii) above, as the case
may be.
Consent of all partners of a Partnership firm for participation in the JV.
6. Wherever submission of an original document is specified in the tender document,
scanned copy of the original can be uploaded.
7. The entire tender document is not required to be printed, scanned and uploaded. Only the
tenderer‟s declaration form and applicable Annexures are required to be printed signed
and uploaded.
6
CENTRAL RAILWAY
Construction Organisation
Open e-Tender Notice No. CAO(C) 12 of 2018 dated 08.05.2018 Chief Engineer(Construction)/South, Central Railway, 6th floor, New Administrative Building, D.N. Road, CST
Mumbai - 400 001, for and on behalf of President of India invites Open tenders through e-tendering (Two packet
system), from reputed contractors for the following work.
Sr.
N
o
Name of the work Approx
Tender Cost
Earnest
Money
Deposit
Cost of
Tender forms
Completion period
1) (i)Track work in Section-I (Kms
0.00 to Kms 65.00) in connection
with Pune-Miraj Doubling
project.
Rs.4292.21 lakhs
Rs.22,96,110/- Rs.10,000/- 30 (Thirty) months
including monsoon
(ii)Track work in Section-II
(kms.65.00 to Kms.145.00) in
connection with Pune-Miraj
Doubling project.
Rs.5450.37 lakhs Rs.28,75,190/- Rs.25,000/- 30 (Thirty) months
including monsoon
(iii)Track work in Section-III
(kms.145.00 to Kms.216.00) in
connection with Pune-Miraj
Doubling project.
Rs.4256.21 lakhs Rs.22,78,110/- Rs.10,000/- 30 (Thirty) months
including monsoon
(iv)Track work in Section-IV
(kms.216.00 to Kms.280.00) in
connection with Pune-Miraj
Doubling project.
Rs.5042.98 lakhs Rs.26,71,490/- Rs.25,000/- 30 (Thirty) months
including monsoon
2) Validity of offer 120 days from the date of opening of tender for the work.
3) Website Address http://www.ireps.gov.in
4) Availability of Tender
Documents
Tender notice document can be seen on the above website.
5) Date & Time of
Submission &
Opening of Tender
The e-tenders duly completed in all respects, alongwith the requisite documents, should be
uploaded electronically on the above mentioned website, upto 12.30 hrs on 25.06.2018. These
tenders (Technical Bids only) will be opened on the same day after 12.30 hrs.
6) Joint Venture Firm Joint Venture (JV) firms will be allowed to participate in this tender. For detailed
guidelines/special conditions pertaining to JV Firms , tenders may please refer to tender
document.
7) Important note for
tenderers
a)The Tendering will solely be through e-tendering only. All intending tenderers need to first
register with IREPS website http://www.ireps.gov.in
b)Prospective tenderer/s are advised that before submitting their offer electronically, they
should refer to the Tender details regarding terms and conditions, eligibility criteria etc.
c)The mode of submission of cost of EMD & Tender Document (both separately), shall be
through Net Banking / Payment gateway (On line payment) only, on the IREPS website
(e-tender portal) http://www.ireps.gov.in
d)Tender documents & corrigendum issued from time to time are available on the website
mentioned above. Changes, if any, would be posted on this website at least 15 days in
advance of opening of tender and may be seen on this website.
For any additional information / clarification contact either on the above address or Dy.CE(C)PA, Ph No.020-
26105380 & Dy.CE(C)Miraj, Ph No.020-26105392 on any working day between 10.00 hrs to 17.30 hrs.
Sd/-
(Rajeev Kumar Mishra)
Chief Engineer (Const)/South,
Central Railway, Mumbai CSMT
For and on Behalf of President of India.
7
TENDERER‟S DECLARATION FORM
The President of India,
Acting through the
Office of the Chief Engineer (Construction)/South ,
Mumbai
I/We M/s ………………………………………………………………………….. have read the contents
of the Tender document ,including 0various conditions to tender attached hereto and hereby agree
to abide by the said conditions. I/We also agree to keep this Tender open for acceptance for a
period of 120 days from the date fixed for opening the same and in default thereof, I/We will be
liable for forfeiture of full amount of my/our “Earnest Money”.
1. I/We offer to do the work for As per NIT on ireps website (Name of work) at percent
above/below/at par the Unified Standard Schedule of Rates – 2011 and/or for NS items
mentioned in the attached schedules and hereby bind myself/ourselves to complete the work
in…………………number of months including monsoon in figures and words (As per Tender
Notice) from the date of issue of letter of acceptance of the tender. I/We also hereby agree to
abide by the Indian Railway‟s General Conditions of Contract July 2014 with up to date
corrections and to carry out the work according to the specifications laid down by the Railway
for the present contract.
2. The full amount of the earnest money has been paid online through net banking / payment
Gateway.
3. I fully understand that, the full value of the earnest money shall stand forfeited without prejudice to
any other rights or remedies if :-
(a) I/We do not execute the contract documents within seven days after receipt of notice
issued by the Railway that such documents are ready; and
(b) I/We do not commence the work within fifteen days after receipt to orders to that effect.
4. Until a formal agreement is prepared and executed, acceptance of this tender shall constitute a
binding contract between us subject to modifications as may be mutually agreed to between us
and indicated in the letter of acceptance of my/our offer for this work.
5. I/We also agree that in the event of my/our failure to execute the contract document as
hereinbefore provided or commence the work within the prescribed period after issue of letter of
acceptance of the tender, the Railway may be entitled to determine that I/We have abandoned the
contract and there upon my/our tender and acceptance thereof may be treated as cancelled and the
Railway shall be entitled to forfeit the full amount of earnest money and recover the damages for
such default.
6. I/We have not tampered/modified the tender forms in any manner. In case the document is found
to be tampered /modified, I /we understand that my /our tender is liable to be rejected and full
earnest money deposit will be forfeited and I /we am /are liable to be banned from doing business
with Railways and or prosecuted.
Date…………….
Contractor‟s address: Signature of Contractor
………………………….. Date…………………………
( To be signed by the Authorised Signatory/
POA Holder of tenderer/JV Firm )
…………………………… Signature of Witnesses
(1)…………………………..
(2)…………………………..
8
CENTRAL RAILWAY
ACCEPTANCE OF TENDER
I accept the Tender on reverse and agree to pay the rate as entered in the schedule of rates and
quantities at_______________ percent ABOVE/BELOW/AT PAR with the schedule of rates and
quantities for M.S. Items SOR-2002 / USSOR-2011 and N.S. items.
Chief Engineer(C)South
Central Railway
CONTRACTOR/S For and on behalf of The President of India
Date__________________
Witnesses :
(1) _________________________
(2) _________________________
9
REGULATIONS AND CONDITIONS FOR TENDER [PART- I ]
1. Meaning of Terms :- For these Regulations for Tender & Contract, the following terms shall
have the definitions, meanings assigned hereunder except where the context otherwise required :-
1.1 Railway Shall mean the President of the Republic of India or the Administrative
Officers of the Central Railway or of the Successor Railway authorised to
deal with any matters which these presents are concerned on his behalf.
1.2 General
Manager
Shall mean the Officer in-charge of the General Superintendence & Control
of the Railway & shall also include the General Manager (Construction) &
shall mean & include their successors, of the successor Railway.
1.3 Chief
Engineer
Shall mean the Officer in-charge of the Engineering Department of Central
Railway & shall also include Chief Engineer (Constn), Chief Signal &
Telecommunication Engineer, Chief Signal & Telecommunication Engineer
(Constn), Chief Electrical Engineer, Chief Electrical Engineer (Constn) and
shall mean & include their successors of the Successor Railway.
1.4 Divisional Rly
Manager
Shall mean the Officer in-charge of a Division of the Railway and shall mean
& include the Divisional Railway Manager of the Successor Railway.
1.5 Engineer shall mean the Divisional Engineer or the Executive Engineer, Divisional
Signal & Telecommunication Engineer, Divisional Signal & Telecommuni-
cations Engineer(Constn),Divil.Electrical Engineer,Divl.Electrical Engineer
(Construction),in executive charge of the works & shall include the superior
officers of the Engineering, Signal & Telecommunication, & Electrical
Department of Railway i.e., the Senior Divisional Engineer / Deputy Chief
Engineer/Chief Engineer/Chief Engineer(Construction), Senior Divl.Signal &
Telecommunication Engineer / Deputy Chief Signal & Telecommunication
Engineer/ Chief Signal & Telecommunication Engineer (Constn)/ Senior
Divl. Electrical Engineer / Deputy Chief Electrical Engineer / Chief Electrical
Engineer (Construction) & Chief Administrative Officer (Constn) & shall
mean & include the Engineer of the Successor Railway.
1.6 Engineers
Representative
shall mean the Assistant Engineer, Assistant Signal & Telecommunication
Engineer & Asstt.Electrical Engineer in direct charge of the works & shall
include any Sr.SE/SE/JE of Civil Engineering/Signal & Telecommunication
Engineering/ Electrical Engineering Department appointed by the Central
Railway and shall mean & include the Engineer's Representative of the
successor Railway.
1.7 Tenderer shall mean the person/the firm/co-operative or company whether in-corporate
or not who tenders for the works with a view to execute the works on contract
with the Railway & shall include their personal representatives, successors
and permitted assigns.
1.8 Limited
Tenders
shall mean tenders invited from all or some Contractors on the approved or
select list of contractors with the Railway.
1.9 Open Tenders shall mean the tenders invited in open and public manner and with adequate
notice.
1.10 Contractor shall mean the Person/Firm/Co-operative Society or Company whether
incorporated or not who enters into the contract with the Railway and shall
include their executors, administrators, successors and permitted assigns.
1.11 Contract shall mean & include the Agreement of Work Order, the accepted schedule of
rates of the Schedule or Rates of Central Railway modified by the tender
percentage for items of works quantified, or not quantified, the General
10
Conditions of Contract, the special conditions of contracts if any, the drawing,
the specifications, the special specifications, if any, and tender forms, if any.
1.12 Works shall mean the works to be executed in accordance with the contract.
1.13 Specifications shall mean the Standard specifications for materials and works of Central
Railway as specified in part III of the Works Hand Book issued under the
authority of the Chief Engineer or as amplified, added to or superseded by
special specifications, if any.
1.14 Schedule of
Rates of C. Rly
shall mean the Schedule of Rates issued under the authority of the Chief
Engineer from time to time.
1.15 Drawings shall mean the maps, drawings, plans and tracings or prints there of annexed
to the contract & shall include any modifications of such drawings and further
drawings as may be issued by the Engineer from time to time.
1.16 Construction
Plant
shall mean all appliances or things of whatsoever nature required for the
execution, completion or maintenance of the works or temporary works (as
hereinafter defined) but does not include materials or other things intended to
form or forming part of the permanent work.
1.17 Temporary
Works
shall mean all temporary works of every kind required for the execution
completion and/or maintenance of the works.
1.18 Site shall mean the lands and other places on, under, in or through which the
works are to be carried out and any other land's or places provided by the
Railway for the purpose of the contract.
1.19 Period of
Maintenance
shall mean the specified period of maintenance from the date of completion of
the works as certified by the Engineer.
2. Words importing the singular number shall also include the plural and vice versa where the
context requires. 3. These Regulations for Tender and Contract shall be read in conjunction with the Conditions of
Contract which are referred to herein and shall be subject to modifications, addition or suppression by special conditions of contract and/or special specifications, if any, annexed to the Tender Forms.
4. Omissions & Discrepancies:
a) The tenderers shall not take any advantage of any misinterpretation of the conditions due to typing or any other error/omission and if any doubt, shall bring it to the notice of the Engineer without delay. In case of any contradictions, only the printed rules and books should be followed and no claim for the misinterpretation shall be entertained.
Should a tenderer find discrepancies in or omissions from the drawings or any of the Tender Forms or should he be in doubt as to their meaning, he should at once notify the authority
inviting tenders who may send a written instruction to all tenderers. It shall be understood that every endeavor has been made to avoid any error which can materially affect the basis of the
tender and the successful tenderer shall take upon himself and provide for the risk of any error which may subsequently be discovered and shall make no subsequent claim on account
thereof.
4. Tender Form Fees‟: 4.1 Payment of Tender Document Cost (TDC) as per NIT in respect of e-tendering, shall be paid
separately through net banking or payment gateway only and shall be paid in the account of
(“FA&CAO (C), Central Railway, CSTM ”). The e-receipt of the transaction shall be
uploaded with the tender (Ref. Railway Board letter No.2015/CE – I / CT/5/1/ Dtd.31.08.2016).
5. Earnest Money Deposit :
11
Payment of Earnest Money Deposit (EMD) as per tender notice, in respect of e-tendering, shall be accepted through net banking or payment gateway only and shall be paid in the account of “FA&CAO (C), Central Railway, CSTM-”. The e-receipt of the transaction shall be uploaded with the tender.
Note: for Tender form fees & EMD These instruments i.e. D. D., Banker cheque, Cash receipt
& Fixed Deposit Receipt (FDR) will not be accepted as Tender Form Fees & EMD cost for
tenders invited on IREPS (e-tender portal) (Ref. Railway Board letter No.2015/CE – I / CT/5/1/
Dtd.31.08.2016).
5.1 The tenderer shall hold the offer open till such date as may be specified in the tender notice. It is
understood that the tender documents have been sold / issued to the tenderer and the tenderer is
being permitted to tender in consideration of the stipulation on his part that after submitting his
tender, he will not resile from his offer or modify the terms and conditions thereof in a manner
not acceptable to the Chief Engineer/Engineer. Should the tenderer fail to observe or comply
with the foregoing stipulation, the amount deposited as security for the due performance of the
above stipulation shall be forfeited to the Railway.
5.2 If the tender is accepted, the amount of earnest money will be held as security deposit for the due
& faithful fulfillment of the Contract in terms of Clause 16 of GCC. The earnest money of the
unsuccessful tenderer will as therein before provided be returned to the unsuccessful tenderers but
the Railway shall not be responsible for any loss or depreciation that may happen to the security
for the due performance of the stipulation to keep the offer open for the period specified in the
tender documents or to the earnest money while in their possession, nor be liable to pay interest
thereon.
6. Contractor‟s credentials & supporting documentation :- Eligibility Criteria for Tenderers :-
Only those firms which in their individual capacity satisfy the following, need to quote for this
tender :-
1) Eligibility Criteria :-
1.1 Criteria (a) Total contract amount received during the last three financial years and in the
current financial year upto date of opening of tender should be a minimum of 150% of
advertised tender value of the work as mentioned in the tender.
1.1.1 Note : following documents will be relied upon for working out the total Contractual
amount received by the tenderer to evaluate credentials against criterion (a) above:
i) Attested copy of Annual Income Tax returns filed with Income tax department.
ii) Attested copy of Tax Deducted at Source (TDS) certificate.
iii) Attested copy of Audited Balance sheet duly certified by the Chartered Accountant.
iv) Attested Certificates from Employers/Clients about contractual payment received for the work
done.
2. Tenderers Credentials & Evaluation criteria for ascertaining Suitability of
Tenderers :-
2.1 Criteria (b) Should have physically completed within the qualifying period i.e. the last
three financial years and current financial year up to date of opening of the tender (even
though the work might have commenced before the qualifying period), at least one
similar single work for a minimum value of 35% of advertised tender value as defined in
2.1.1 below.
2.1.1 As regards “Single Similar work” :- The tenderer should have physically completed
“(I) Any Civil Engineering work involving track work by manual or mechanical means
involving track linking /CTR/TSR/Deep screening / Turnout replacement or combination of
both these on running /non running lines. Cost of track work shall be at least 35% of the
tendered value of the proposed work.”
12
2.1.1.1 Works executed for Central / Statement Government / Semi Government Organizations /
Authorities, PSUs and Government of India Undertakings, will only be considered for
assessing the suitability of tenderers. Authentic Certificates from the concerned
Government Authorities shall be produced by the tenderer(s) to this effect, along with the
Tender offer.
2.1.2 Total value of similar nature of work completed during the qualifying period, and not the
payments received within the qualifying period alone, shall be considered.
2.1.3 In case, final bill of the similar single work has not been passed and final measurements have
not been recorded, the paid amount including statutory deductions will be considered. If the
final measurements have been recorded and work has been completed with negative
variation, then also the paid amount including statutory deductions will be considered.
However, if final measurements have been recorded and work has been completed with
positive variation but variation has not been sanctioned, original agreement value or last
sanctioned agreement value, whichever is lower shall be considered for judging eligibility.
2.1.4 Value of a completed work done by a member in all earlier Partnership firm or a JV firm
shall be reckoned only to the extent of the concerned member‟s share in that Partnership firm / JV
firm for the purpose of satisfying his compliance of the above mentioned condition, in the tender
under consideration.
Tenderers may carefully note that their Contract Agreement for this work is liable to be
terminated at any time later, in case the documents furnished by them are found to be untrue
/ misleading or any adverse point comes to light subsequently. The decision of Railway in
this regard shall be final & binding.
2.1.5 (i) Tenderers should submit documentary proof in regard to fulfilling the above eligibility criteria
(a) and (b) along with their offer. If the tenderer/s do not submit any proof of meeting with the eligibility
criteria as laid down in the NIT and tender conditions , the offer shall be summarily rejected. Documents
submitted in support of eligibility criteria after opening of tender will not be considered.
ii) There shall be no back reference to confirm the credentials except for the purpose of verifying the
attested complies of document s already submitted with the offer.
iii)However , it is clarified that where the tenderer has submitted at least some documents or statement ,
which establishes his credentials, seeking clarification or verification is permissible . The point to note is
that any clarification sought should be only to seek details of a document already submitted. A part , who
is not eligible as per the document submitted cannot be later permitted to add fresh documents that
makes him eligible . For example if a party has claimed Turnover or single work with reference to
specific works /work , seeking details of the work is permissible , but the party will not be permitted to
cite a new work/works if the original submission was not adequate once verified.
d)Tenderer‟s may carefully note that their Contract agreement for this work is liable to be terminated at
any time later in case any of the information furnished by them is found to be untrue or any adverse
points come to light subsequently. The decision of Railway in this regard shall be final and binding .
6.1.2. The tenderers should furnish list of works completed in the last three financial years, giving
description of work, Organization for whom executed, approx. value of contract at the time of award, date
of award & date of scheduled & actual completion of work. For large value multiple location &
composite projects, details in respect of individual location to be given, duly certified by Controlling
officer about the progress.
6.1.3. Scanned copies of supportive documents/certificates from the organizations with whom they
13
worked/are working should be uploaded along with summary filled in proforma. All scanned copies must
be attested and signed by the tenderer.
6.1.4. Certificates from private individuals for whom such works are executed/being executed will not
be accepted.
6.1.5. The offers of Tenderers who do not meet the eligibility criteria as mentioned vide (a) to (b) above
shall not be considered. The Tenderers who fail to upload documentary proof along with their offer will,
shall, not be considered.
6.1.6. Tenderers may carefully note that their Contract Agreement for this work is liable to be
terminated at any time later, in case any of the information furnished by them is found to be untrue or any
adverse point comes to light subsequently. The decision of Railway in this regard shall be final and
binding.
6.2. The tenderer is required to upload scanned copies of the following documents along with tender
papers duly filled & signed at all pages in website www.ireps.gov.in:
a) Tenderer‟s Declaration Form.
b) Annexure - I : Particulars of Tenderers.
c) Annexure - II : List of works completed in last three financial years.
d)Annexure –III A: List of works on hand.
e)Annexure No. – III B : List of works of similar nature completed in qualifying period.
f) Annexure –IV : List of personnel / organization available on hand and proposed to be
engaged for the subject work.
g) Annexure – V A: List of plant & Machinery (Owned) available on hand proposed to be
inducted on the subject work.
h) Annexure – V B : List of plant & machinery proposed to be hired for the work.
i) Annexure VI : Declaration For Site Visit.
j) Annexure VIII : Electronic Clearing Service (Credit Clearing).
k) Format VII / A : Format for affidavit to be submitted by tenderers along with the tender.
l) (i) Audited Balance Sheet duly certified by the Chartered Accountant distinctly showing
the amount received from contracts .
OR (ii) Certificates from Employers/Clients about contractual payment received for the work
done with various Departments/ Agencies.
m) Earnest money in prescribed form and manner.
n) Method statement, PERT Chart & Construction Schedule vis-a-vis deployment of
resources.
o) Bio-data of key personnel and/or construction Engineers to be involved in this work.
p) Affidavit of sole proprietorship / Partnership deeds / Papers of Limited Company /
Papers of Joint Venture (Including MOU and supporting papers of JV) as required .
q) Power of Attorney.
r) Any other document / drawing the Tenderers may like to submit in support of his/their
credentials/scheme.
(s) Performance record of firm last 5 years. (Refer clause 6.4 at below page).
6.3. Tenderer‟s Special Conditions
The tenderer should not stipulate any special conditions while submitting his tender. In such an
eventuality, Central Railway reserves the right to reject such tenders without assigning any
reasons whatsoever. Any special condition involving financial implication shall be mentioned on
14
offer sheet only and shall clearly indicate the monetary value of that special condition. Any
special condition involving financial implication without monetary value mentioned by the
tenderer shall not be considered. Railway reserves the right of rejecting /considering /partially
considering such conditions while accepting the tender and contractor shall not have any claim on
this account and he shall not withdraw the offer on this account .
6.4. Performance record for the last 5 years showing the following may be submitted
(a) Was denied credit bond or Bank Guarantee.
(b) Was incapable of performance of contract, resulting in rescinding of the same at firm‟s
risk and cost.
(c) Was unable to complete awarded work.
(d) Was penalized for failure to adhere to completion date.
(e) Earned bonus for early completion.
(f) Took recourse to arbitration for settlement for disputes.
6.5. Tenderers should quote their rates taking all aspects into consideration and offers with special
condition without monitory valuation will not be considered and liable to be rejected.
7. The following documents form part of contract
(a) Tender Document.
(b) Tender declaration form.
(c) Regulations and conditions for Tenders & Contract.
(d) Special conditions of contract (Section B).
(e) Scope of work, Additional Special Condition of Contract, Schedule of Quantities & Rates
(Section C).
(f) Technical Specifications (section D).
(g) Indian Railway‟s General Conditions of Contract (G.C.C.) July 2014 (Updated upto the
date).
(h) Central Railway‟s Unified Standard Specifications 2010 (As applied).
(i) Central Railway‟s Unified Standard Schedule of Rates – 2011 (Updated up to the date). (j) Latest version of relevant IS codes, Indian Railways Standard specifications and
other codes/specifications/drawings shall be applicable.
7.1 Order of Preference
In case of discrepancies noticed in the description of items in Tender schedule, General condition
of contract, Special condition of contract, Technical specification, Central Railway
Specification, IS specification, IRC specification etc., the order of preference for acceptance will
be as under :-
(i) Description of Items in Schedule of quantities & Rate along with foot note in item
(ii) Additional Special condition of contract
(iii) Special condition of contract
(iv) Technical Specification in Tender documents
(v) Indian Railway Standard specification including Specification published by RDSO.
(vi) General Condition of Contract.
(vii) Indian Standard specifications.
The Railway‟s decision in this regard will be final and binding on the contractor.
8. Inspection of site before tendering
Before submitting a tender, the tenderer will be deemed to have satisfied himself by actual
inspection of the site and locality of the works, that all conditions liable to be encountered during
the execution of the works are taken into account and that the “percentage/rates he enters in the
Tender Forms” is/are adequate and all inclusive to accord with the provisions in Clause 37 of the
General Conditions of Contract for the completion of works to the entire satisfaction of the
15
engineer. No claim shall be entertained regarding approaches/approach road in and outside
Railway land and contractor/s will bear entire expenses such as road-taxes, payment for right of
way, etc. to outsiders and for constructions of approaches/approach road etc.
9. When work is tendered for by a firm or company of contractors, the tender shall be signed by the
individual legally authorised to enter into commitments on their behalf.
The Railways will not be bound by any Power of Attorney granted by the tenderer or by changes
in the composition of the firm made subsequent to the execution of the contract. It may, however
recognize such Power of Attorney and changes after obtaining proper legal advice, the cost of
which will be charged to the Contractor.
9.1 Drawing for the work
The drawings, General Conditions of Contract and Specifications for materials and works of the
Central Railway for the works can be seen in the Office of Dy. Chief Engineer(C), at any time
during office hours.
10 As per CAO©‟s office Lr.No.E.W.187.R.465.XIV Dt.31.10.2017 – tenderer‟s will be permitted
to quote different rates for different groups of items.
(a) The tenderer must tender for all the items shown in the schedule of approximate quantities
attached. The quantities shown in the attached schedule are given as a guide and are approximate
only and are subject to variation according to the needs of the Railway. The Railway does not
guarantee work under each item of the schedule.
(b) There are various parts of the schedules in this tender document.
In case of any discrepancy between the rate quoted in “Figures” and “Words”, the rate quoted
in “Words” will prevail.
(c) Any condition quoted by the tenderer having financial implication shall be clearly mentioned on
the offer sheet itself, along with the monetary value of that condition, in absence of this, such
offer shall be summarily rejected.
(d) Tenderer shall give his offer for all the schedule / all items. Part offer for any schedule / item
shall not be considered.
(e) The tenderers should note that the item and basic rates of Master Schedule items are based on
USSR-2011.
11 Any number of corrections can be made by tenderers before due date and time of final
submission.
12. It shall not be obligatory on the said authority to accept the lowest tender and no tenderer shall
demand any explanation for the cause of rejection of his tender
13. If the tenderer deliberately gives wrong information in his tender or creates circumstance for the
acceptance of his tender, the Railway reserves the right to reject such tender at any stage.
14. If a tenderer expires after the submission of his tender or after the acceptance of his tender, the
Railway shall deem such tender as cancelled. If a partner of a firm expires after the submission
of their tender or after the acceptance of their tender, the Railway shall deem such tender as
cancelled unless the firm retains its character.
16
15. Non compliance with any of the conditions set forth herein above is liable to result in the tender
being rejected.
16. The authority for the acceptance of the tender will rest with the Chief Administrative
Officer(Cons)/Chief Engineer/ Deputy Chief Engineer/ Executive Engineer, who does not bind
himself to accept the lowest or any other tender nor does he undertake to assign reasons for
declining to consider any particular tender or tenders.
17. The successful Tenderer shall be required to execute an Agreement with the President of India
acting through the Chief Engineer(C)/Deputy Chief Engineer (C) for carrying out the work
according to the General Conditions of Contract July 2014, Indian Railways Unified Standard
Specifications (Works & Materials) 2010 Vol. I & Vol. II updated up to date and Special
Conditions & Special Specifications, technical specifications annexed with the tender.
18. The cost of Tender Document (Tender Form Fees) is not refundable and Tender document is not
transferable. Tender unaccompanied with requisite Tender Form Fees along with offer or
received in any other form than those mentioned in tender notice, shall be summarily rejected.
19. Execution of contract document
19.1. The Tenderer whose tender is accepted shall be required to appear at the office of General
Manager / General Manager (Construction)/ CAO (C) Office / Chief Engineer (Construction)
/ Dy. Chief Engineer (C) as the case may be in person, or if a firm or corporation, a duly
authorized representative, and execute the contract documents within seven days after notice
that the contract has been awarded to him. Failure to do so shall constitute a breach of the
agreement effected by the acceptance of the Tender in which case the full value of the earnest
money accompanying the tender, shall stand forfeited without prejudice to any other rights or
remedies.
19.2. In the event of any tenderer whose tender is accepted, refuses to execute the contract
documents as herein before provided, the Railway may determine that such tenderer has
abandoned the contract and thereupon his tender and the acceptance thereof shall be treated as
cancelled and the Railway shall be entitled to forfeit the full amount of the earnest money and
to recover the liquidated damage for such default.
19.3. Every contract shall be complete in respect of the documents it shall constitute. Not less than
5 copies of the contract documents shall be signed by the competent authority and the
contractor and one copy given to the contractor.
19.4. The earnest money deposited by the successful tenderer shall be forfeited if the contractor fails
to execute the Agreement or fails to start the work within a reasonable time (to be determined
by the Engineer after notification of the acceptance of his tender).
20. A) Completion Period
The works are required to be completed within a period of (As per Tender Notice) (Including
Monsoon) from the date of issue of acceptance letter.
The sequence in which work is programmed to be carried out shall be represented by a network
chart to be prepared by the Contractor and approved by the Engineer before commencement of
the work.
B) Extension of completion Period
The contractor shall apply for extension in completion period well in advance before expiry of
completion period as per clause no. 17 of General Condition of Contract. In the case the
contractor has failed to complete the work by the agreed date of completion and neither seek nor
17
willing to seek extension even after expiry of the agreed date of completion , the Railway reserve
right to terminate the contract with effect from date of completion, original or extended by giving
a notice to this effect. (Proforma at Annexure VII).
C) Maintenance Period
The work shall be maintained after completion for a period of AS PER NIT by the contractor and
he shall make good any defects, imperfection, shrinkage or faults which may appear, at his own
cost.
21. Partnership Deeds, Power of Attorneys etc.
21.1. 21.1 The tenderer shall clearly specify whether the tender is submitted on his own or on behalf of
a partnership concern. If the tender is submitted on behalf of partnership concern, he should
submit the certified copy of partnership deed along with the tender and authorization to sign the
tender documents on behalf of partnership firm. If these documents are not enclosed along with
tender documents, the tender will be treated as having been submitted by individual signing the
tender documents. The Railway will not be bound by any power of attorney granted by the
tenderer or by changes in the composition of the firm made subsequent to the execution of the
contract. It may, however, recognizes such power of attorney and changes after obtaining proper
legal advise the cost of which will be chargeable to the contractor.
The charges have been fixed at Rs.400/- payable by the tenderer at the time of submitting the
power of attorney for scrutiny and advice.
21.2 The tenderer whether sole proprietor, a limited company or a partnership firm if they want to act
through agent or individual partner(s) should submit along with the tender or at a later stage, a
power of attorney duly stamped and authenticated by a Notary Public or by Magistrate in favour
of the specific person whether he/they be partner(s) of the firm or any other person specifically
authorising him/them to submit the tender, sign the agreement, receive money, witness
measurements, sign measurement books, compromise, settle, relinquish any claim(s) preferred by
the firm and sign "No Claim Certificate" and refer all or any disputes to arbitration.
21.3 If the power of attorney is not accepted, otherwise than for legal defect, the charges will be
refunded. If the Power of Attorney is returned on account of legal defect for correction, separate
charges of Rs.200/- for scrutiny of corrected power of attorney will be payable by the tenderer
while resubmitting power of attorney. The same charges shall be recoverable for scrutiny of all
documents.
21.4 No power of attorney in favour of an individual person will be accepted if it is irrevocable
except when it is in favour of Bank.
21.5 In case, where the power of attorney/partnership deed has not been executed in English, the true
and authenticated copies of the translation of the same by Advocate, authorized translator of
courts and licensed petition writers should be supplied by the contractor/s while tendering for
the work.
21.6 Cancellation or creation or correction of any documents, such as Power of Attorney, Partnership
Deed, etc. which may have a bearing on the tender/contract should be communicated forthwith
by the tenderer/Contractor in writing, failing which Central Railway, Mumbai, shall not have
responsibility or liability for any action taken on the strength of the said documents.
22. Employment / Partnership Etc. of Retired Railway Employees:
22.1 Should a tenderer be a retired engineer of the Gazetted rank or any other Gazetted
officer working before his retirement, whether in the executive or administrative
capacity or whether holding a pensionable post or not, in the Engineering or any
other department of any of the railways owned and administered by the President of
India for the time being, or should a tenderer being partnership firm have as one of its
18
partners a retired engineer or retired Gazetted Officer as aforesaid, or should
tenderer being an incorporated company have any such retired engineer or retired
officer as one of its Directors or should a tenderer have in his employment any
retired Engineer or retired Gazetted Officer as aforesaid, the full information as to the
date of retirement of such Engineer or Gazetted Officer from the said service and in
case where such Engineer or Officer had not retired from Government service at least
1 years prior to the date of submission of the tender as to whether permission for
taking such contract, or if the contractor be a partnership firm or an incorporated
company, to become a partner or Director as the case may be, or to take the
employment under the contractor, has been obtained by the tenderer or the Engineer
or Officer, as the case may be from the President of India or any officer, duly
authorized by him in this behalf, shall be clearly stated in writing at the time of
submitting the tender. Tenders without the information above referred to or a
statement to the effect that no such retired Engineer or retired Gazetted Officer is so
associated with the tenderer, as the case may be, shall be rejected.( as per ACS No.3
dt.22.1.2015 circulated under Rly.Bds Lr.Ns.2014.CE-I.CT.O.9.RET)
22.2 Should a tenderer or contractor being an individual on the list of approved
Contractors, have a relative(s) or in the case of partnership firm or company of
contractors one or more of his shareholder(s) or a relative(s) of the shareholder(s)
employed in gazetted capacity in the Engineering or any other department of the
Railway, the authority inviting tenders shall be informed of the fact at the time of
submission of tender, failing which the tender may be disqualified /rejected or if such
fact subsequently comes to light, the contract may be rescinded in accordance with
provision in Clause 62 of Standard General Conditions of Contract. 22.3 Amended Clause No.59 (10) of GCC- 2014:- Restriction on the Employment of Retired
Engineers of Railway Services within two years of their retirement. (Authority: Railway
Board‟s letter No. 2014/CE-I/CT/0/9/RET dated 22/01/2015). The Contractor shall not, if he is a
retired Government Engineer of Gazetted rank, himself engage in or employ or associate a retired
Government Engineer of Gazetted rank, who has not completed two year from date of retirement,
in connection with this contract in any manner whatsoever without obtaining prior permission of
the President and if the Contractor is found to have contravened this provision, it will constitute
breach of contract and administration will be entitled to terminate the contract and forfeit Earnest
Money Deposit (EMD),Performance Guarantee(P.G.) and Security Deposit of that contract. 22.4 Amended Clause No.62(1)(xiii)(A) of GCC-2014 (Authority : Railway Board‟s letter
No.2014/CE-I/CT/0/9/RET dated 22/01/2015) At any time after the tender relating to the contract,
has been signed and submitted by the contractor, being a partnership firm admit as one of its
partners or employee under it or being an incorporated company elect or nominate or allow to act
as one of its directors or employee under it in any capacity whatsoever any retired engineer of the
gazetted rank or any other retired gazetted officer working before his retirement, whether in the
executive or administrative capacity, or whether holding any pensionable post or not, in the
Railways for time being owned and administered by the President of India before the expiry of one
year from the date of retirement from the said service of such Engineer or Officer unless such
Engineer or Officer has obtained permission from the President of India or any Officer duly
authorized by him in this behalf to become a partner or a director or to take employment under the
contract as the case may be or 23. Should the Railway decide to negotiate with a view to bring down the rates, the original offer will
still be binding in case nothing materializes out of the negotiations.
19
24. The Railway reserves the right of not to invite tenders for any work or works, or to invite open or
limited tenders, and when tenders are called, to accept a tender in whole or in part or reject any
tender or all tenders without assigning reason for any such action.
25.1 In case of Tenderer/s are Partnership firm/s, the following documents should be enclosed.
a) Certified copy of Partnership Deed.
b) Power of attorney in favour of one of the partner to sign the Agreement on behalf of all the
partners and create liability against the firm.
25.2 In case Tenderer are Proprietary firm OR HUF: the following documents should be enclosed.
Affidavit on Stamp paper of appropriate valuation declaring that his concern is a Proprietary
concern and he is sole proprietor of the concern OR he is in position of “KARTA” of Hindu
Undivided Family and he has authority, power and consent given by other co-partners to act on
behalf of HUF.
25.3 In case of Tenderer/s are limited companies, following documents should be submitted.
a) Certified copy of minutes of meeting of the directors of the company in which resolution
was passed to the effect.
i) Of authorizing Managing Director / One of the director / manager of the company to sign
Agreement
ii) of authorizing M.D. / Director / Manager or any other person to sign all other documents, contract
agreement etc. and create liability against the company and / or to do any other act on behalf of
the company.
b) Copy of Memorandum and articles of Association of the company.
c)Power of Attorney by the Competent Authorizing person to do act mentioned in item (ii) above.
26 PROVISION OF EFFICIENT AND COMPETENT STAFF AT WORK SITES BY
THE CONTRACTOR / (EMPLOYMENT OF TECHNICAL STAFF BY
CONTRACTOR): (Authority: Railway Board‟s letter No.2012/CE-I/CT/0/20
Dt.10.05.2013).
Addendum & Corrigendum Slip (ACS) to Indian Railways General Conditions of Contract,
Clause 26 to GCC.
26.1 The Contractor shall place and keep on the works at all times efficient and competent staff to
give the necessary directions to his workmen and to see that they execute their work in sound
and proper manner and shall employ only such supervisors, workmen and labourers in or
about the execution of any of these works as are careful and skilled in the various trades.
26.2 The Contractor shall at once remove from the works any agents, permitted sub-contractor,
supervisor, workman or labourer who shall be objected to by the Engineer and if and
whenever required by the Engineer, he shall submit a correct return showing the names of all
staff and workmen employed by him.
26.3 In the event of the Engineer being of the opinion that the Contractor is not employing on the
works a sufficient number of staff and workmen as is necessary for proper completion of the
works within the time prescribed, the Contractor shall forthwith on receiving intimation to
this effect deploy the additional number of staff and labour as specified by the Engineer
within seven days of being so required and failure on the part of the Contractor to comply
with such instructions will entitle the Railway to rescind the contract under Clause 62 of
these conditions.
Clause 26A to GCC: Deployment of qualified Engineers at work sites by the
contractor.
(26A.1)The contractor shall also employ Qualified Graduate Engineer or Qualified Diploma
20
Holder Engineer, based on value of contract, as may be prescribed by the Ministry of
Railways through separate instructions from time to time.
(26A.2) In case the contractor fails to employ the Engineer, as aforesaid in para 26A.1, he
shall be liable to pay penalty at the rates, as may be prescribed by the Ministry of Railways
through separate instructions from time to time for the default period for the provisions, as
contained in para 26A.1.
(26A.3) No. of qualified engineers required to be deployed by the contractor for various
activities contained in the works contract shall be specified in the tender documents as
“special condition of contract” by the tender inviting authority”.
(B) In terms of provisions of new Clause 26A.1 to the General conditions of Contract (GCC),
contractor shall also employ following Qualified Engineers during execution of the allotted
work :-
(a)One Qualified Graduate Engineer when cost of work to be executed is Rs 200 lakh and
above, and
(b)One Qualified Diploma Holder Engineer when cost of work to be executed is more than
Rs 25 lakh, but less than Rs 200 lakh.
(c) Further, in case the contractor fails to employ the Qualified Engineer, as aforesaid, in
terms of provisions of Clause (26A.2) to the General Conditions of Contract, shall be liable
to pay an amount of Rs.40,000 and Rs 25,000 for each month or part thereof for the default
period for the provisions, as contained in Para 3(a) and 3 (b) above respectively.
27. Verification of Credentials:
27.1
An affidavit is required to be submitted by the tenderers (as given in Annexure VII/A).
Based on this affidavit, Tender Committee will deliberate and decide eligibility of tenderers.
However, the suitability/eligibility of shortlisted tenderers will be provisional and same
shall be subject to verification of their credentials from issuing authority.
If contents in documents submitted by tenderers are found to be incorrect / false, action will
be taken against such tenderers as per provisions contained in Affidavit submitted by them as
Annexure VII/A. In such eventuality, next lowest eligible tenderer / offer will be
considered.
28. Method Statement
Tenderers have to submit the “Method Statement” clearly elaborating the system of works to
be adopted i.e. procedure of executing the various activities indicating the number/type of
machinery/equipment/Scaffolding/form works and other resources etc. etc. to be deployed on
this work to achieve required progress, sources of materials, procedure of arranging testing
of materials / finished products to ensure quality, details of safety measures to be taken while
working near running track, in rivers/viaducts or at heights for the safety of
Engineers/Workers. Further this should include the site management, security, hygiene &
welfare activities, communication, milestones & targets etc. for completing various
activities.Tenderer/s must submit the “Method Statement” before commencement of activity
& get it approved by the Engineer-in-charge before start of the activity.
29 Equipment & Machinery
Tenderer/s have to deploy the following minimum plant and machinery on this work to
achieve the required progress. The list of plant and machinery is given tentatively.
Contractor has to deploy equipment and machinery as per approved planning / programme,
BAR CHART matching with the progress of the work.
List of Minimum Equipment/Machinery to be deployed for work (For Earthwork) :-
Sr.No. Equipment/Machinery No.
29.1 Earthwork
(1) Earthwork excavators (L&T/ Poclain 200/300/320) or similar 4
21
Sr.No. Equipment/Machinery No.
(2) JCB 2
(3) Trailor mounted water tanker with sprinkling system 4
(4) Dozer 4
(5) Motor grader for top profile 1
(6) Vibratory Roller 4
(7) Rock drilling equipments (Capacity ) + Compressor 1 for Each 50000 M3
or part thereof
(8) Mechanized blending plant for blanketing 1
(9) Dumpers - Hywa or similar of 14 cum. Cap. 1 set of 5 dumpers
per excavator
29.2 Concrete works
(1) Batching & mixing plants of adequate capacity
As per requirement (2) Rock drilling equipments with compressor
(3) Pumps for bailing out water/mud
(4) Adequate shuttering material (preferably of steel)
(5) Needle vibrators of different sizes
29.3 List of Minimum Equipment/Machinery to be deployed for work(For Bridge Work)
Sr.No. Equipment / Machinery No.
1. Rock drilling equipments & compressor 2
2. Hand held Pneumatic rock breaking equipment (for bridges) 3
3. Needles for vibrator at each site of progress
a. 60mm dia
b. 40mm dia
c. 25mm dia
4 nos.
2 nos.
2 nos.
4. Shuttering - As per requirement of progress
5. Cranes - As per requirement
6. Automated concrete batching and mixing plant / Tie up with approved
RMC plants
1
7. Ordinary concrete mixer with weigh batcher of 1 bag capacity 4
8. Generator Set of required capacity. 1 at site /
casting
yard
In case the tenderer/s fails to deploy the plants and machinery as per agreed programme / planning
resulting in slow progress, action as per clause 62 of G.C.C. may be taken by Railways & penalty as
decided by Engineer in charge may be imposed. Decision of Engineer-in-charge in this regard will be
final and binding on to tenderer/s.
30 Planning for Progress 30.1 Tenderer/s should submit the programme for completion of work in the form of Bar
Chart within 15 days of issue of L.O.A.
Though the completion period of entire work is (As per tender Notice) however
individual activities are required to be completed in a phased manner so that work
of work of other contractor‟s are not affected adversely.
30.2 10 (ten) days mile stones for all the work, each activity shall to be prepared and submitted
by tenderer/s in the beginning of each month and got approved by Engineer in charge.
This shall match with the overall completion period for this work as per programme
indicated at Sr.No.1.
In case of failure of the contractor, to adhere the progress rate, without appropriate reason
22
acceptable to the Railways, the contractor is liable for action in accordance with GCC,
which may also include termination as per clause 62 of GCC.
31 Incentive Bonus for early completion of the work–Not Applicable.
32. Constitution of the firm 32.1 The tenderer/s who are constituents of firm, company, association or society must
forward attested copies of the constitution of their concern, partnership deed & power of
attorney with their tender. Tender documents in such cases are to be signed by such
persons (as may be legally competent to sign them on behalf of the firm, company,
association or society as the case may be). Co-operative societies must likewise submit an
attested copy of their certificate of registration along with the documents as above
mentioned.
32.2 The Railway will not be bound by any power of attorney granted by the tenderer/s or by
changes in the composition of the firm made subsequent to the execution of the contract.
The Railway may, however, recognize such power of attorney and changes after
obtaining proper legal advice, cost of which will be chargeable to the contractor.
32.3 If the tenderer expires after the submission of his tender or after the acceptance of his
tender, the railway shall deem such tender / contract as cancelled. If a partner of firm
expires after the submission of their tender the Railway shall deem such tender as
cancelled unless the firm retains its character.
32.4 If the contractor‟s firm is dissolved on account of death, retirement of any partners or for
any reason whatsoever, before fully completing the whole work or any part of it, under-
taken by the principal agreement the surviving partners shall remain jointly /severally
and personally liable to complete the whole work to the satisfaction of the Railway
and to pay compensation for losses sustained, if any by the Railway due to such
dissolution. The amount of such compensation shall be decided by Chief Engineer/
Const. of the Railway and his decision in the matter shall be final and binding on the
contractor.
32.5 The cancellation of any document such as power of attorney, partnership deed etc.,
shall forthwith be communicated to the Railway in writing, failing which the Railways
shall have no responsibility or liability for any action taken on the strength of the said
documents.
32.6 The value of contract and the quantities given in the attached schedule of items, rates and
quantities are approximate & are given only as guidance. These are subject to variations
/ additions & or omission. The quantum of work to be actually carried out shall not form
the basis of any dispute regarding the rates to be paid and shall not give rise to claim for
compensation on account of any increase or decrease either in the quantity or in the
contract value.
33. Form of declaration to be signed by the tenderer before tender negotiation meeting.
A tenderer before the negotiation meeting if held, is required to give a declaration as per
proforma given below :
FORM OF DECLARATION
I…….……………………………………………do declare that in the event of failure of
the contemplated negotiations relating to tender No…………… opened on
……………………….. my original tender shall remain open for acceptance on its
original terms and conditions.
I also declare that I am aware that during this negotiation, I cannot increase the originally
quoted rates against any of the individual items and that in the event of my doing so, the
same would not be considered at all i.e. reduction in rates during negotiation alone
would be considered and for some items if I increase the rates, the same would not be
considered and in lieu my originally quoted rates alone would be considered and my offer
23
would be evaluated accordingly.
34. Validity of offer
The tenderer/s shall keep the offer open for a period of 120 days from the date of opening
of the tender in which period tenderer/s cannot withdraw his/their offer subject to period
being extended further, if required, by mutual agreement from time to time. It is
understood that the tender documents have been sold/issued to the tenderer/s and
tenderer/s is/are being permitted to in consideration of stipulation on his/their part that
after submitting his/their offer he/they will not resile from his/their offer or modify the
terms and conditions thereof in a manner not acceptable to Central Railway should the
tenderer/s fail to observe to comply with the foregoing stipulation or fail to undertake
the contract after acceptance of his/their tender the entire amount deposited as earnest
money for the due performance of the stipulation & to keep the offer open for the
specified period, shall be forfeited to the Railway.
35.1 The tenderer shall visit the site of work and ascertain himself the conditions of work viz.
approach roads and accessibility, nature of soil/ rock, availability of materials, electric
power, water for work and drinking purposes, site for labour camps, stores, godowns,
extent of lead/lift in work, availability of skilled and unskilled labour etc. that may be
encountered in the course of execution of work. In short, he/they should familiarize
himself fully with the conditions obtaining at site and furnish a certificate to this effect,
in the proforma given in tender document.
35.2 As per CAO©‟s office Lr.No.E.W.187.R.465.XIV Dt.31.10.2017 – renderer‟s will be
permitted to quote different rates for different groups of items in figures as well as in
words Schedule of Rates & Quantities (offer sheet).
Every possible fluctuation, in the rate of labour, material and general commodities, and
other possibilities of each and every kind which may affect the rates, should be
considered & kept in view before quoting the rates and no claim on this account shall be
entertained by the Railway under any circumstances except the price escalation payable
as per price variation clause provided in the tender documents.
35.3 The rate/s should be quoted in figures as well as in words. If there is variation between
the rates quoted in figures and in words, the rate quoted in `words' shall be taken as
correct. If more than one or improper rates are tendered for the same item, the tender is
liable to be rejected.
35.4 Each page of the tender papers is to be signed digitally by the tenderer/s or such person/s
on his/their behalf who is/are legally authorized to sign for him/them.
35.5 Tenders containing erasures and alterations of the tender documents are liable to be
rejected.
35.6 The tenderer should not quote any special conditions. The Railway reserves the right
not to consider conditional tenders & reject the same without assigning any reason. Only
those additional conditions, which are explicitly accepted by the Railway, shall form
part of the contract.
35.7 The tenderer/s may note that railway reserves its right to either accept or reject any
tender without assigning any reasons whatsoever and tenderer/s shall have no claim/s on
this account.
35.8 Prospective tenderer/s may contact Chief Engineer/Construction/South, Central
Railway, Mumbai/ Dy.Chief Engineer/ Construction, Central Railway, Pune for
obtaining further clarifications, if required.
35.9 Tenderer/s to please note that no correspondence shall normally be made after
submission of tender towards any documents which are required for adjudging the
24
capability of the firm / tenderer/s as per eligibility criteria. The tenderer/s is/are
therefore, advised to submit all documents in one go with the offer.
36. Acceptance of tender
36.1 If the tenderer/s deliberately give/s a wrong information/whose credentials/ documents
in his/their tender and thereby creates/ create circumstances for the acceptance of
his/ their tender, Railway reserves the right to reject such tender at any stage, besides,
shall suspend the business with this tenderer for one year.
36.2 The authority for acceptance of the tenders rests with Dy.Chief Engineer/ Construction
/Chief Engineer (Const)/CAO (Const) /General Manager/Railway Board as the case may
be who does not undertake to assign reasons for declining to consider any particular
tender or tenders. He also reserves the right to accept the tender in whole or in part or to
divide the tender amongst more than one tenderer if deemed necessary.
36.3 The successful tenderer/s shall be required to execute an agreement with the President of
India acting through the General Manager/ CAO(Const)/CE(Const) / Dy. CE (Const.)
for carrying out of the work as per agreed conditions.
36.4 The contractor‟s operations and proceedings in connection with the works shall at all
times be conducted during the continuance of contract in accordance with the laws,
ordinance, rules and regulations for the time being in force and the contractor shall
further observe and comply with the bye-laws and regulations of the Govt. of
India, State Govt. and of Municipal & other authorities having jurisdiction in
connection with the works or site over operations such as these are carried out by the
contractor/s and shall give all notice required by such bye-laws and regulations. The
Hospital and medical regulations in force for the time being shall also be complied with
by the contractor/s and his workmen.
36.5 The contractor shall be responsible for the observance of the rules and regulations under
the mines act and mineral rules and Indian Metallurgical rules and regulations of
State/Central Govt. concerned as amended from time to time.
36.6 Contractor shall at all times keep the Railway administration indemnified against all
penalties that may be imposed by the Govt. of India or State Govt. for infringements or
any of the clauses of the mines act and rules made there under in respect of quarries
from which the ballast for these works is procured.
36.7 The tenderer/s shall submit an analysis of rates if called upon to do so for any N.S. item.
36.8 Non-compliance with any of the conditions set forth herein is liable to result in the
tender being rejected.
25
Annexure - I
AGREEMENT FOR WORKS (FORMAT)
CONTRACT AGREEMENT No._____________________Dated______________
Articles of Agreement made this ______ day of __________________, between the President of India
acting through the Railway Administration hereinafter called the “Railway”, of the one part and
M/s________________________, hereinafter called the “Contractor” on the other part.
Whereas the Contractor has agreed with the Railway for the performance of the works of _ _ _ _ _ _ _ set
forth in the schedule hereto annexed upon the General Conditions of Contract and the Specifications of
the Central Railway and the special conditions and special specifications, if any and in conformity with
the drawings hereunto annexed AND WHEREAS the performance of the said work is an act in which the
public are interested.
NOW THIS INDENTURE WITNESSETH that in consideration of the payments to be made by the
Railway, the contractor will duly perform the said works in the said schedule set-forth and shall execute
the same with great promptness, care and accuracy in a workman like manner to the satisfaction of the
Railway and will complete the same in accordance with the said specifications and said drawings of
conditions of contract on or before the _____day of ________________ and will maintain the said works
for a period of ______________ calendar months from the certified date of their completion and will
observe, fulfill and keep all the conditions therein mentioned (which shall be deemed and taken to be part
of this contract as if the same had been fully set forth herein) AND the Railway do hereby agree that if the
Contractor shall duly perform the said works in the manner aforesaid and observe and keep the said terms
and conditions, the Railway will pay or cause to be paid to the contractor for the said works onto final
completion thereof the amount due in respect thereof at the rates specified in the schedule hereto annexed.
Dy. Chief Engineer(C)
Central Railway, Pune,
For and on behalf of The President of India
Date :-
Signature of witness
Contractor /s ………………….
1.
Address …………………….
2.
Date:
26
Annexure-I
PARTICULARS OF TENDER(S)
[Para 6.2(a)]
1. Full name of Contractor/ Construction firm
2. Year of establishment of Firm
3. Registered Head Office Address,
Telephone no, Fax no, E-mail address.
4. Branch office Address, Telephone no, Fax no,
E-mail address
5. Details of Constitution of firm, names of
Partners/ Executives/Power of Attorney
holders, etc.
6. Particulars of Registration with Government/
Semi-Govt. Organization, Public Sector
Undertaking & Local Bodies etc.
Annexure-II
LIST OF WORKS COMPLETED IN LAST THREE FINANCIAL YEARS
[Para 6.2(b)]
Sr
N
o
Name of
Work
Name of
Organization for
whom executed
and Contract
awarding authority
Contract
agreement
No and date
of Award
Approx Value of
contract
Date of
Commencem
ent
Agreement
value Final
Value
Scheduled Actual
1 2 3 4 5 6 7 8
Date of Finish Period of completion Main features of the work Remarks
Scheduled Actual Schedule
d
Actual
9 10 11 12 13 14
Note:
(i) Supporting documents/certificates (duly attested) from the organisations with whom worked/are
working should be enclosed.
(ii) Certificate from private individuals for whom such works are executed/ being executed shall not be
accepted.
27
Annexure-III A
(A) LIST OF WORKS ON HAND
[Para 6.2(c)]
Sr
N
o
Nam
e
o
f
W
o
r
k
Name of
Organization
for whom
executed and
Contract
awarding
authority
Contract
agreement
No
and date of
Award
Approx Value of contract Date of
Commen
cement
Agreement
Value Payment
received
Aprox.
balance to be received
Schedule
d Actual
1 2 3 4 5 6 7 8 9
Date of Finish
Period of
completion
% age Progress Reasons
f
o
r
Delay, if
any
Main
Features
of the
work
Remarks
Schedule
d
Expect
e
d
Schedule
d
Expect
e
d
Physical Financi
a
l
10 11 12 13 14 15 16 17 18
Note:
(i) Supporting documents/certificates (duly attested) from the organisations with whom worked/are
working should be enclosed.
(ii) Certificate from private individuals for whom such works are executed/ being executed shall not be
accepted.
28
Annexure-III B
LIST OF WORKS OF SIMILAR NATURE OF WORKS COMPLETED IN QUALIFYING
PERIOD.
Tenderers are bound to enclose work done certificates of (ONE OR TWO), similar nature works
completed in the qualifying period as per the eligibility criteria under “SIMILAR NATURE OF
WORK”.
Tenderer has to mention that which work done certificate to be considered as “SIMILAR NATURE OF
WORK” to qualify eligibility criteria. Tenderer has also submit the following details along with
work done certificate, as under:-
Sr.
N
o
.
Name of
Work
C. Agt.
No.
Date of
commenc
ement
work
Scheduled
date of
completion
Actual
Date of
Completion
Detail
address of
Work
done
certificate
issuing
authority.
Telephone
Numbers,
Fax
Numbers
of Issuing
Authority
Telephone
Numbers
and
Mobile
Numbers
of
Contractor
Annexure-IV
LIST OF PERSONNEL/ORGANISATION AVAILABLE ON HAND AND PROPOSED TO BE
ENGAGED FOR THE SUBJECT WORK
[Para 6.2(d)]
Sr. No. Name &
Designation
Qualification Professional
Experience
Remarks
Note- Supporting documents should be attached
I hereby certify that no retired Engineer/Gazetted Officer of the Railways who has retired within 2 years
of date of submission of tender and has not obtained permission of competent authority has been
engaged by me/our firm. I also certify that none of my relative is engaged in Engineering
Department in Central Railway.
Signature of Tenderer(s)
29
Annexure-V A
A. LIST OF PLANT & MACHINERY (OWNED) AVAILABLE ON HAND AND PROPOSED TO
BE INDUCTED ON THE SUBJECT WORK[Para 6.2(e)]
Sr.
N
o
.
Particulars of
equip
ments
No. of
units
Kind/Make Capacity Age and
cond
ition
Remarks
Annexure – V B
B. LIST OF PLANT & MACHINERY PROPOSED TO BE HIRED FOR THE WORK
Sr. No. Particulars of
equipments
No. of
units
Capacity Remarks
Annexure-VI
DECLARATION FOR SITE VISIT
[Para 6.2(f)]
Name of work: (As per tender notice)
I/We hereby solemnly declare that I/We visited the sites of work personally and have made
myself/ourselves fully conversant of the conditions therein and in particular the
following:
(i) Topography of the area
(ii) Soil strata at site of work
(iii) Sources and availability of construction materials
(iv) Rates for construction materials, water, electricity including all local taxes,
royalties, octroi, etc
(v) Availability of local labour (both skilled and unskilled) and relevant labour
rates and labour laws
(vi) Existing roads, approaches, pathways to site of work
(vii) Space for stacking of materials, stores, office etc
(viii) Availability and rates of private land, etc required for various purposes
(ix) Trees, shrubs, bushes, debris etc required to be removed for site clearance
(x) Need of dewatering/pumping etc
(xi) Climatic conditions and availability of working days and working hours
(xii) Frequency/pattern of rail traffic, electrified tracks, road traffic etc
(xiii) Availability of rail/road traffic block
(xiv) Law and order situation.
(xv) Any other condition, which may affect rates.
I/We have quoted my/our rates for various items in the tender schedule taking into account
all the above factors likely to be encountered during execution of work. I/We shall not be
entitled for any claim against Railway on account of above factors.
Signature of Tenderer(s)
30
Annexure VII.
FORM No. E-5
Electronic Clearing Service (Credit Clearing)
PROFORMA OF NEFT PARTICULARS
1. Customer's Name / Name of
Tenderer / Name of Agency :
2. Name of Bank :
3. Name of Branch & Address :
4. Telephone Number of Bank:
5. E – Mail address of Bank :
6. Type of Account :
7. Account No. :
8. IFSC Code of Bank :
9. MICR Code of Bank :
Certified that the particulars furnished above are correct as per our records.
Signature : _____________________
Stamp of Bank : _________________
----------------------------------------------------------------------------------------------------------------
Declaration of Tenderer / Agency
I hereby declare that the particulars given above are correct and complete, If the transaction is
delayed or not effected at all for reasons of incomplete or incorrect information, I would not hold
the user institution responsible.
Signature of Tenderer: ____________________
Mobile No. of Tenderer : _________________
email address of Tenderer : _______________
Seal of the firm : _______________________
31
FORMAT VII/A
FORMAT FOR AFFIDAVIT TO BE SUBMITTED BY TENDERERS ALONG WITH THE TENDER
[Clause 27]
[To be executed in presence of Magistrate / Public Notary on Non-judicial Stamp paper of the value of
Rs.100/-. The Stamp paper has to be in the name of the tenderer]**
I, ___________________________________ (name and designation)** appointed as the Attorney / Authorised
Signatory of the tenderer (including its constituents), M/s
___________________________________________ (hereinafter called the tenderer) for the purpose of
the tender documents for the work of ___________________________________ (Name of work) as per
the Tender Notice No. ____________ dated _________of Central Railway, Survey & Construction, do
hereby solemnly affirm and state on the behalf of the tenderer including the constituents as under:
1. I/We the tenderer(s) am/are signing this document after carefully reading the contents.
2. I/We the tenderer(s) also accept all the conditions of the tender.
3. I/We hereby declare that I/We have verified the content of tender document available on Indian
Railway website https://www.ireps.gov.in. and there is no addition, no deletion or no alteration to
the content of the tender document. In case of any discrepancy noticed at any stage i.e. evaluation
of tenders, execution of work or final payment of the contract, the Master Copy available with the
Railway Administration shall be final and binding upon me/us.
4. I/We declare and certify that I/We have not made any misleading or false representation in the
forms, statements and attachments in proof of the qualification / requirements.
5. I/We also understand that my/our offer will be evaluated based on the document/ credentials
uploaded along with the offer and same shall be binding upon me/us.
I/We declare that the information and documents uploaded along with the tender by me/us are
correct and I/We are fully responsible for the correctness of the information and documents,
submitted by us.
I/We understand that if the certificates regarding eligibility criteria uploaded by us are found to be
forged/fake or incorrect at any time during process for evaluation of tenders, it shall lead to
forfeiture of the tender EMD besides suspending of business for one year. Further, I/We (insert
name of tenderer)** ____________________________ and all my/our constituents understand that
my/our offer shall be summarily rejected.
I/We also understand that if the certificates uploaded by us are found to be fake/forged or
incorrect at any time after the award of the contract, it will lead to termination of the
contract, along with forfeiture of EMD/SD and Performance Guarantee besides any other
action proposed in the contract.
DEPONENT
Seal and Signature of the Tenderer/s
VERIFICATION
I/We above named tenderer do hereby solemnly affirm and verify that the contents of my/ our above Affidavit are
true and correct. Nothing has been concealed and no part of it is false.
DEPONENT
Seal and Signature of the Tenderer
Place: _______________
Date: _______________
** The contents are only for guidance purpose. Details as appropriate, are to be filled in suitably by the tenderer.
Attestation to be done before the Magistrate / Notary Public.
32
Annexure IX
CONTRACT TERMINATION NOTICE [FORMAT]
[PARA 20 B]
No. Dated
Office of
CE(C),South
Central Railway, CST Mumbai.
To
M/s…………………
Sub :-………………..
Dear Sir,
1. In terms of the conditions of contract agreement no.__________________ dated ____________
governing the execution of the above work, it was required to be completed by the stipulated date
of completion / mutually extended date of completion, viz _________. You have failed to
complete the work by the agreed date f completion. You have also failed to apply for further
extension of period of completion on valid and reasonable grounds as acceptable to the Railway.
Due to your failure to fulfill your contractual obligations, the contract stands terminated with effect
from date of completion of the contract i.e _______________date.
2. Please note that for non fulfillment of the contract the Railway reserve the right to claim damages
under clause 62 of the General Conditions of Contract in addition to any other rights available to it
under the law.
3. Final measurements of the work done by you shall be recorded on ____________. Please arrange
to be present at site to witness and to sign the measurements, failing which the work will be
measured in your absence and such measurements as per provisions of the contract agreement
under clause 45 of General conditions of contract (GCC) shall, notwithstanding such absence, be
binding upon you whether or not you shall have signed the measurement book.
Yours Faithfully
For and on Behalf of President of India
34
Section-B
SPECIAL CONDITIONS OF CONTRACT
1. These special conditions supplement the Regulations and Conditions of Tenders and Contracts
(Section A), the General Conditions of Contract and the notes appearing under the relevant chapters
and sub-chapters of the USSOR-2011 and should be considered a part of the contract document.
Where the provisions of these conditions are at variance with the General Conditions of Contract,
these special conditions shall prevail.
The General Conditions of Contract will mean the General Conditions of Contract as amended
and/or corrected from time to time and obtaining at the time of acceptance of the tender and at the
time of execution of the agreement mentioned in clause 18 under Regulations and Conditions of
Tender. It should be the responsibility of the Contractor before submitting his tender and again
before entering into said agreement to ascertain all amendments and or corrections made to the said
General Conditions of Contract.
2. The code Nos., Description and Rates given in the schedule are based on the USSOR-2011. Any
discrepancy noticed during the execution of the work, in the working rates, quantity of cement etc.,
will be rectified by reference to the printed schedule which shall be treated as authoritative and
binding on the contractor. The relevant notes applicable to the respective Sub-chapters will apply to
the items of the tender schedule and should be considered as having been incorporated in the
Contract agreement and binding on the contractor.
3. For any other items not specially shown in the Schedule of Rates appended to the tender document,
Executive Engineer will offer rates as shown for the Suburban Zone in the Central Railway‟s
USSOR-2011 subject to the same percentage adjustment accepted in the contract being applicable
to the additional items.
4. Any foot note/s appearing below the item/s of the contract schedule will take precedence over these
Special Conditions. For detailed order of preference refer clause No.7.1 of Section A.
5. Any Specifications/conditions stated by the tenderer in the covering letter submitted alongwith his
tender shall be deemed to be a part of the contract only to such extent has have been explicitly
accepted by the Railway.
6. EARNEST MONEY :-
6.1(a) The tenderer shall be required to deposit earnest money with the Tender for the due
performance with the stipulation to keep the offer open till such date as specified in the Tender,
under the conditions of Tender. The earnest money shall be deposited as under :-
Value of the work (Tender Value) Earnest Money Deposit
For work estimated to cost upto Rs.1 Crore 2% of the estimated cost of the work
For work estimated to cost more than Rs.1
Crore
Rs.2 Lakhs plus ½%(Half Percent) of the
excess of estimated cost of work beyond Rs.1
Crore subject maximum of Rs.1 Crore.
The earnest money shall be rounded to the nearest Rs.10/-. This earnest money shall be applicable
to all modes of tendering.
(b) It shall be understood that the tender documents have been sold/issued to the tenderer and the
tenderer is permitted to tender in consideration of stipulation on his part, that after submitting
his tender he will not resile from his offer or modify the terms and conditions thereof in a
manner not acceptable to the Engineer. Should the tenderer fail to observe or comply with the
said stipulation, the aforesaid amount shall be liable to be forfeited to the Railway.
(c) If his tender is accepted this earnest money mentioned in sub clause (a) above will be retained as part
security for the due and faithful fulfillment of the contract in terms of Clause 16 of the General
Conditions of Contract. The Earnest Money of other tenderers shall, save as here before in provided, be
returned to them, but the Railway shall not be responsible for any loss or depreciation that may happen
thereto while in their possession, nor be liable to pay interest thereon.
(d) The Earnest Money should be Online transaction receipt.
35
6.2. Earnest Money Deposit :
Payment of Earnest Money Deposit (EMD) as per tender notice, in respect of e-tendering, shall be
accepted through net banking or payment gateway only and shall be paid in the account of
(“Dy.FA&CAO (C), Central Railway, Pune ”). The e-receipt of the transaction shall be uploaded with
the tender.
Note: for Tender form fees & EMD These instruments i.e. D. D., Banker cheque, Cash receipt & Fixed
Deposit Receipt (FDR) will not be accepted as Tender Form Fees & EMD cost for tenders invited on
IREPS (e-tender portal) (Ref. Railway Board letter No.2015/CE – I / CT/5/1/ Dtd.31.08.2016).
In case the tenderer withdraws his offer within the validity date of his offer or fails to execute the contract
after acceptance of his tender, the full Earnest Money shall be forfeited
7. SECURITY DEPOSIT
7.1 EARNEST MONEY AND SECURITY DEPOSIT
The Earnest Money deposited by the Contractor with his tender will be retained by the Railways as part
of security for the due and faithful fulfillment of the contract by the contractor. The balance to make up
the security deposit, the rates for which are given below, may be deposited by the Contractor in cash or
may be recovered by percentage deduction from the Contractor's "on account" bills. Provided also that in
case of defaulting contractor the Railway may retain any amount due for payment to the Contractor on the
pending "on account bills" so that the amounts so retained may not exceed 10% of the total value of the
contract.
7.2. Recovery of Security Deposit : Unless otherwise specified in the special conditions, if any, the
Security Deposit/Rate of recovery shall be as under:-
(a) Security Deposit for each work should be 5% of the contract value.
(b) The rate of recovery should be at the rate 10% of the on account bill amount till the full
security deposit is recovered.
(c) Security Deposits will be recovered only from the running bills of the contract and no
other mode of collecting SD such as SD in the form of instruments like BG (except Note
(ii) below); FD etc shall be accepted towards Security Deposit.
(d) Security Deposit shall be returned to the contractor after expiry of the maintenance period
in all the cases other than Note (i) mentioned below and after passing the final bill based
on No Claim Certificate with the approval of the Competent Authority. The Competent
Authority shall normally be the authority who is competent to sign the contract. If this
Competent Authority is of the rank lower than JA Grade, then a JA Grade Officer
(Concerned with the work) should issue the certificate. The certificate, inter alia, should
mention that the work has been completed in all respects and that all the contractual
obligations have been fulfilled by the contractors and that there is no due from the
contractor to Railways against the contract concerned. Before releasing the S.D., and
unconditional and unequivocal „NoClaim Certificate‟ from the contractor
concerned should be obtained.
Note- (i) After the work is physically completed, Security Deposit recovered from the running
bills of the contract can be returned to him, if he so desires, in lieu of FDR / irrevocable
Bank Guarantee for equivalent amount to be submitted by him.
(ii) In case of contracts of value of Rs.50 Crore and above, irrevocable Bank Guarantee can also
be accepted as a mode of obtaining security deposit.
(e) No interest will be payable upon Earnest Money and Security Deposit or amounts
payable to the contractor under the contract, but Government Securities deposited in
terms of Sub-Clause(1) of this clause will be payable with interest accrued thereon.
36
8. PERFORMANCE GUARANTEE (P.G.) (Authority:Rly.Brd‟slr.No.2007/CE.I/CT/18/Pt.XII.dated31.12.2010/ Rly.Bds Lr.No.2017/Trans./01/policy
Dt.17.11.17)The procedure for obtaining Performance Guarantee is outlined below :-
(a) The successful bidder shall have to submit a Performance Guarantee (PG) within 30
(thirty) days from the date of issue of Letter Of Acceptance (LOA). Extension of
time for submission of PG beyond 30 (thirty) days and up-to the date of submission
of PG from the date of issue of LOA may be given by the Authority who is
competent to sign the Contract agreement. However, a penal interest of 15% per
anum shall be charged for the delay beyond 30 days ie., from i.e. from 31st day
after the date of issue of LOA, a notice shall be served to the contractor to deposit
the PG immediately ( however not exceeding 90 days from the date of issue of LOA
). In case the contractor fails to submit the requisite PG even after 90 days from the
Date of issue of LOA, the contract shall be terminated duly forfeiting EMD and
other dues, if any payable against that contract. The failed contractor shall be
debarred from participating in re-tender for that work”.
(b) The successful bidder shall submit the Performance Guarantee(PG) in any of the
following forms, amounting to 5% of the contract value :-
i) A deposit of cash;
ii) Irrevocable bank guarantee;
iii) Govt. securities including state loan bonds at 5% below themarket value;
iv) Deposit receipts, Pay orders, Demand Drafts and Guarantee Bonds ( on
500/- Stamp paper ). These forms of Performance Guarantee could be either
of the State Bank of India or any of the nationalized banks.
v) Guarantee Bonds executed or deposits receipts tendered by all Scheduled
Banks;
vi) A deposit in the Post offie Saving Bank;
vii) A deposit in the National savings certificates;
viii) Twelve years National Defense Certificates;
ix) Ten years Defense Deposits;
x) National Defense Bonds;
xi) Unit Trust Certificates at 5% below the market value or at the face value
whichever is less; Also, FDR in favour of Dy.FA&CAO(C)PA Central
Railway, (free from any encumbrance) may be accepted.
Note :- The instruments as listed above will also be acceptable for
Guarantees in case of Mobilization Advance.
(c) The Performance Guarantee shall be submitted by the successful bidder after the Letter of
Acceptance (LOA) has been issued, but before signing of the contract agreement. This
PG, shall be initially valid upto the stipulated date of completion plus 60 days beyond
that. In case, the time for completion of work gets extended, the contractor shall get the
validity of PG extended to cover such extended time for completion of work plus 60
days.
(d) The value of PG to be submitted by the contractor will not change for variation upto
25%(either increase or decrease). In case during the course of execution, value of the
contract increases by more than 25% of the original contract value, an additional
Performance Guarantee amount to 5% (Five percent) for the excess value over the
original contract value shall be deposited by the contractor.
(e) The Performance Guarantee(PG) shall be released after physical completion of the work
based on „Completion Certificate‟, issued by the competent authority stating that the
contractor has completed the work in all respects satisfactorily. The Security Deposit
shall, however, be released only after expiry of the maintenance period and after passing
the final bill based on „No Claim Certificate‟ from the contractor.
37
(f) Whenever the contract is rescinded, the Security Deposit shall be forfeited and the
Performance Guarantee shall be en-cashed. The balance work shall be got done
independently without risk and cost of the failed contractor. The failed contractor shall
be debarred from participating in the tender for executing the balance work. If the failed
contractor is a JV or a Partnership firm, then every member / partner of such a firm shall
be debarred from participating in the tender for the balance work in his/her individual
capacity or as a partner of any other JV/partnership firm.
(g) The engineer shall not make a claim under the Performance Guarantee except for
amounts to which the President of India is entitled under the contract (Not withstanding
and / or without prejudice to any other provisions in the contract agreement) in the event
of :-
i. Failure by the contractor to extend the validity of the Performance Guarantee as
described herein above, in which event the Engineer may claim the full amount of the
Performance Guarantee.
ii. Failure by the contractor to pay President of India any amount due, either as agreed
by the contractor or determined under any of the Clauses/Conditions of the
agreement, within 30 days of the service of notice to this effect by Engineer.
iii. The contract being determined or rescinded under provision of the GCC, the
Performance Guarantee shall be forfeited in full and shall be absolutely at the
disposal of the President of India.
8.1 The contractor shall ensure that the concerned Banks renews the Deposit Receipts &
Guarantee Bonds well in time as and when required.
9. HIRE OF PLANT & MACHINERY AND OTHER FACILITIES :-
9.1. The contractor shall make his own arrangements for all plant and machinery other facilities
equipments, tools, including spare parts, fuel and consumable stores, and all labour and other
facilities required to ensure efficient methodical execution of the work. The rates quoted &
accepted shall be deemed to be inclusive of all charges of such items.
9.2 On the contractor‟s request, the Railway may, however, give on hire plant and
machinery/other facilities, equipment and tools, if available spare with the Railway, without
any commitment on the part of the Railway to do so, in which case, the hire charges for plant
and machinery will be calculated to cover interest, ordinary repairs and maintenance charges
at 5%, special repairs and maintenance charges at 10%, depreciation charges as per extant
rules of the Railway, and an additional 10% on the total of these four above, on the cost of
the Plant and Machinery, which will be present day market value plus freight and other
incidental charges increased by 12½% supervision charges.
9.3 Hire charges for items other than plant and machinery, which do not require any form of
repair and maintenance shall only take into account interest on capital, depreciation and an
additional 10% on these two.
9.4 The hire charges per day shall be arrived at by dividing the annual hire charges by 250,
which shall be assumed to be the number of working days in a year for this purpose only.
These hire charges will be payable from the day the plant is handed over to the day it is
returned to the Railway administration. If, however, during this period the plant remains out
of order for reasons beyond the control of the contractor, or is withdrawn for periodic
overhaul or any repairs, such periods shall not be counted for levy of hire charges. The
contractor shall enter into a separate agreement in this respect & the terms and conditions as
per the agreement will be final conclusive and binding on the contractor.
9.5 In the event of a plant or equipment or facility given on hire to the contractor not being
returned to the railway administration in a reasonably good working order considering
depreciation that it would have suffered for the period of hire, the Railway shall treat the
plant/facility as on sale, as per extant orders of the Railway, from the date it was initially
given on hire, withdrawing the hire terms and charges.
38
9.6 If, however, the plant & machinery/other facilities, equipments and tools requisitioned by the
contractor are not available in Railway‟s stock or the Railway decides not to supply the same
for reasons whatsoever, neither the Rly.shall be bound to arrange for the supply thereof nor
will the Railway‟s inability to supply them be accepted as an excuse for delay in the
completion of the works/or for any claims thereof.
10 SUPPLY OF MATERIALS BY RAILWAYS
10.1 Railway‟s materials issued to the contractor if any, will be used by the Contractor for the work in
such quantities as are indicated in the schedule or in relevant specifications or drawings or as
approved by the Engineers whose, decision thereon shall be final. Wastage of or damage to such
materials in any manner shall be totally avoided. If surplus material issued, if any, is not returned
in good condition immediately after completion of the work or if any quantity of material
supplied by the Railway is consumed in excess or wasted or damaged or lost or not satisfactorily
accounted for in that case recovery will be made from the Contractor at twice the market rate or
twice book rate at the time of last issue whichever is higher plus 5% freight and 2% incidental
charges plus 12 ½% supervision charges on the above cost arrived at for the quantity of material
consumed in excess or wasted or damaged, lost or not satisfactorily accounted for.
10.2. In case it is discovered that the quantity of steel or any other items issued by the Railway as
actually used in the work is less than the quantity/quantities specified to be used, the cost of steel
and for other such items not so used shall also be recovered from the Contractors on the
basis stipulated in sub-para above.
10.3. Action under this Clause will be without prejudice to the right of the Railway to take action
against the Contractor/s under the conditions of the Contract for not doing/completing the work
according to the prescribed specifications and approved drawings.
10.4. All material left over as `Surplus‟ or as `scraps‟ out of materials supplied by the Railway, should
be returned to the Railway‟s Stores at failing which the cost will be recovered, as per the
provision of clause 10.1 of the special conditions of Contract.
10.5 Tools, Plant And Materials Supplied By Railway : The Contractor shall take allreasonable care of
all tools, plant and materials or other property whether of a like description ornot belonging to the
Railway and committed to his charge for the purpose of the works and shallbe responsible for all
damage or loss caused by him, his agents, permitted subcontractor, or hisworkmen or others
while they are in his charge. The Contractors shall sign accountable receiptsfor tools, plants and
materials made over to him by the Engineer and on completion of the worksshall hand over the
unused balance of the same to the Engineer in good order and repair, fair wear and tear excepted,
and shall be responsible for any failure to account for the same or anydamage done thereto.
10.6 (a) Contractor To Arrange Supply Of Electric Power For Works : Unless otherwise provided in
the contract, the Contractor shall be responsible for arrangements to obtain supply of Electric
Power for the works.
(b) Electric Supply From The Railway System : The Railway may supply to the Contractor part or whole
of the electric power wherever available and possible, required for execution of works from the
Railway's existing electric supply systems at or near the site of works on specified terms and
conditions and such charges as shall be determined by the Railway and payable by the Contractor
provided the cost of arranging necessary connections to the Railway's Electric Supply systems
and laying of underground/overhead conductor, circuit protection, electric power meters,
transmission structure, shall be borne by the Contractor and that the Contractor shall not be
entitled to any compensation for interruption or failure of the Electric supply system.
39
11. USE OF RAILWAY MATERIALS SECURED WITH GOVERNMENT ASSISTANCE :-
11.1 The Railway shall not supply from its own quota to the contractors controlled or imported
commodities. Assistance will, however be given by recommending to appropriate authorities
on contractor‟s application for issue of import licenses and release of controlled commodities
if the Engineer is satisfied that this materials is actually required by the contractors for
carrying out the work and is not available in the country.
11.2 Where any raw materials for the execution of the contract are procured with the assistance of
Government either by issue from Government, stocks or purchases under arrangements made
or permit(s) or license(s) issued by the Government, the Contractor shall hold the materials
as trustee for the Govt. & use such materials economically & solely for the purpose of the
contract against which they are issued and not dispose them without permission of the
Govt.& return, if required by the Government, all surplus or unserviceable materials that
may be left by him after completion of the contract or on at its termination. The freight
charges for the return of the materials according to the direction of the purchaser shall be
borne by the contractor, in the event of contract being cancelled for any default on his part.
The decision of Government shall be final conclusive & binding on the contractor/s.
11.3 In the event of a breach of the aforesaid conditions, the contractor shall in addition to
throwing himself open to action for contravention of terms of the license (s) or the permit (s)
and/or for original breach of trust be liable to account to Government for all moneys,
advantages or profits resulting or which in the usual course would have resulted to him by
reason of such breach.
12. SETTING OUT OF WORKS :-
12.1. The Contractor/Contractor‟s nominated/authorized engineer shall set out the works with his
own labour, instruments and materials and shall be responsible for the true and perfect
setting out of the dimensions and alignment thereof. If at any time any error in this respect
shall appear during the progress of the work, the contractor at his own expense should rectify
such error if so required, to the satisfaction of the Engineer. The contractor shall be
responsible for maintaining the accuracy of the alignment, positions, levels and of the work
in accordance with the drawings, directions or instructions given from time to time to him
and every facility shall be given to the Engineer for checking of the same. The contractor at
his own cost shall rectify any error in the dimensions, alignments positions or levels of work
set out or constructed by him to the satisfaction of the Railway Engineer.
12.2 Adequate numbers of stable reference, survey platform suitable size at top of towers
supported on steel trestles of sufficient height for layout of bridge alignment, for setting up
survey equipments, direct observations from apex points to apex points on curves, over the
hutments shall be provided with contractors own material and his own cost. Engineers
decision in this regard is final & binding on the contractors.
12.3 The work shall be set out by the contractor to the satisfaction of the Engineer but his
approval thereof shall not or his joining with contractor in setting out the work, shall not
absolve or relieve the contractor from his entire and sole responsibility therefore.
12.4 Contractor shall also provide, fix & be responsible for the maintenance of all stakes, profiles,
levels, marks, points etc., must take all necessary precautions to prevent these being remov-
ed, altered or disturbed & will be held responsible for the consequences of such removal,
alterations or disturbances should the same take place & for their efficient reinstatement.
12.5 The contractor shall use modern survey precision equipment, such as accurate lasers, one
second least count theodolite of approved make, electronic distance meter of approved type
with Std deviation ± 5 mm per kilometer and precise leveling instrument of approved type.
13. SUPPLY OF WATER AND ELECTRICITY :-
13.1. The contractor shall make his own arrangements for water supply. Wherever it is
convenient to the Railway administration, the water from piped supply may be made available to
the contractor, provided the contractor shall arrange at his own expenses to effect the connections
40
and lay additional pipe lines and accessories to the site of work and that the contractor shall not be
entitled to any compensation for interruption or failure of the water supply. The contractor will
have to pay for such water supply or for supply from Railway well or tube wells at a rate of one
percent on the amount of all items or work appearing in the bills payable to the contractor in
respect of which work such water has been used by the contractor and such charges shall be
deducted from sums due or payable by the Railway to the contractor from time to time.
Connections to labour camps will not be permitted.
13.2. Contractor shall make his own arrangements for the operation of mechanical equipment‟s
required for the execution of work and /or for the purpose of lighting for working during day/night
time. Wherever, it is convenient to the Railway Administration, the electric supply may be made
available to the contractor provided the contractor shall arrange at his own expense to effect the
connection and lay additional wiring,provide meter & other accessories on the site. Such work of
laying wiring etc. shall be done under supervision of a qualified staff & a certificate shall be
required to be submitted to the effect that the work of wiring has been done as per rules or the work
shall have to be got done through Railway Organisation and the charges for the same shall have to
be borne by the contractor as per extant rules.
13.3. The contractor shall not be entitled to any compensation for interruption or failure of the
electric supply. The contractor will have to pay for such electric supply from Railway at rate
agreed to between contractor and Railway Administration and such charge shall be deducted from
the sums due or payable by the Railway to the contractor from time to time.
13.4. Water available locally in wells, creeks or nallahs may be brackish water at some
locations. It should be noted that no sea or brackish water shall be used in all classes of masonry,
reinforced and mass concrete work. In addition, water used on the above works shall be free from
earthy, vegetable or organic matter, oils, acids and alkaline substance in solutions or in suspension
and impurities and shall be fit for drinking.
14 TAXES, ROYALTIES AND PATENT RIGHTS (Authority HQ‟s letter No. EW/187/R/Royalty/III Dt.26.10.2010).
14.1 For all the works except work of earthwork for embankment / cutting and supply
of ballast All rates quoted in the tender shall be deemed to be inclusive of all taxes, royalties
payable by the contractor/s to the Govt. or public body or local authority and no
additional amount will be paid or claim entertained on this account by the Railway.
Contractor shall not have any claim whatsoever as a result of the increase in the rates
for such royalties, taxes, duties or any other forms of levies etc. (Concessional Sales
Tax Form and Octroi Exemption Certificate will be issued to Contractor on his specific
request, if legally permissible).
14.2 For works of earth work for embankment / cutting and/or supply of ballast
a)
All the rates quoted in the tender shall deemed to be inclusive of all royalties,
taxes, duties, octroi or any form of levies etc. payable by the contractor/s to the
Govt. or public body or local authority as applicable.
The rate of royalty considered in the rates of tender schedule are as per rates
circulated by the Government of Maharashtra vide Govt. Notification No.
Gou/Khani/10/1009/PRA KRA 309/KH (1) Dt.11.02.2010 which is Rs 200/- per
brass.Claim towards such royalty should be unfailingly accompanied by proof of
payment and rate thereof. In the absence of these, royalty payment will not be
released.
b) However, in case of any subsequent increase in the rates of royalties, the
increased amount will be reimbursed to the contractor only on production of
documentary proof of payment of royalty at such increased rates along with State
41
Govt.‟s order.
c) Similarly in case of decrease in the rate of royalty charges or its waival, payment
of royalty will be regulated by such reduced rate and recovery shall be effected
accordingly.
d) Reimbursement/recovery, if required, shall be worked out separately and
submitted along with claims for on-account payments.
e) In case of all other taxes, duties, octroi or any form of levies etc. no additional
amount will be paid or claim entertained on this account by the Railway.
Contractor shall not have any claim whatsoever as a result of the increase in the
rates for such, taxes, duties or any other form of levies etc.
f) The amount of reimbursement or recovery, as the case may be, as per revised
rate of royalty shall be applicable only for the quantity of work executed by the
contractor after the Government Resolution for revision of rate of royalty has
come into effect.
g) The reimbursement/recoveries as per the revised rate of royalty shall be effective
only for the original completion period of the work. However, the amount as per
revised rate of royalty is payable/recoverable during the extended period of the
contract, provided the PVC was part of the original contract & the extension has
been granted on administrative ground i.e. under Clause 17-A (i), (ii) or (iii) of
GCC. Where extensions of time has been granted due to contractor‟s failure
under Clause 17 (B) of the General Conditions of Contract, the reimbursement
due to change in rate of royalty shall not be payable for such extended periods,
however decrease in the rate of royalty or its waival, the difference in the amount
will be recovered from the payment of the contractor for such extended periods
under Clause 17 (B) of GCC.
14.3 The contractor shall defray the cost of all royalties, fees and other payments in
respect of patents, Patent rights and licenses which may be payable to patented
licensee or other person or corporation and shall obtain all necessary licenses. In case
of any breach (whether willfully or inadvertently) by the contractor of this
provision, the contractor shall indemnify the Railway and its officers, servants,
representatives against all claims, proceedings, damages, cost charges, loss and
liability which they or any of them may sustain incur or be put to by reason or
inconsequence of, directly or indirectly, any such breach and against payment of any
royalties, damages or other moneys which the Railway may have to make to any
person or paid in total to the patent rights in respect of the users of any machine,
instructions, process, articles, matters or thing constructed, manufactured, supplied or
delivered by the contractor to his order under this contract.
14.4 Form for availing concessional sales tax for supply to Government Deptt. will be
issued for supply contracts only on request of contractor if legally permissible
15. PAYMENT OF ROYALTY CHARGES : 15.1 All payment of royalty charges etc. to the State Government in connection with
extraction and supply of rubble/stone ballast/sand, from other than Railway land acquired by
Railways under Land Acquisition Act-1985, have to be borne and paid by the contractor and
will be governed as per Para 14 above .
The Railways in consultation with the respective State Governments will confirm
percentage of Royalty Charges to be recovered for supply of minor minerals. The Railway
Administration is entitled to deduct from the contractors and keep in deposit such amount
equal to the proportionate Royalty Charges from each on account bills and the same will be
released as and when the contractor submits a receipt/documents/ clearance certificate
42
certifying that Royalty Charges have been paid by the Contractors, relating to the contract.
The contractor will be required to obtain a final Royalty clearance certificate from the
concerned State/Revenue Authorities/Collector and produce the same to CE(C) / Dy.CE(C)
/XEN(C) after completion of supply but before the release of final bill. If in any case the
contractor fails to produce the clearance certificate for Royalty Charges, final bills will be
passed after retaining an amount equal to the amount of unpaid Royalty charges, as
intimated by the Revenue Authorities/Collector or as calculated on the basis of relevant
Rates, for payment of Royalty Charges applicable to the area. No claim regarding interest
charges for delay in payment of the retained amount on Royalty account shall be
entertained.
The retained amount will be released, at the discretion of the administration, on production
of clear Bank Guarantee covering the amount so withheld towards Royalty Charges/State
taxes.
16. LEGAL CHARGES :- A fee of Rs.400.00 per legal document like partnership deed or power of
attorney executed before or after the execution of the contract will be recovered from the contractor
for obtaining legal Advice in the Law Officer.
17. EMPLOYMENT OF STAFF
Should a tenderer be a retired engineer of the Gazetted rank or any other Gazetted
officer working before his retirement, whether in the executive or administrative
capacity or whether holding a pensionable post or not, in the Engineering or any other
department of any of the railways owned and administered by the President of India for
the time being, or should a tenderer being partnership firm have as one of its partners a
retired engineer or retired Gazetted Officer as aforesaid, or should a tenderer being an
incorporated company have any such retired engineer or retired officer as one of its
Directors or should a tenderer have in his employment any retired Engineer or retired
Gazetted Officer as aforesaid, the full information as to the date of retirement of such
Engineer or Gazetted Officer from the said service and in case where such Engineer or
Officer had not retired from Government service at least 1 years prior to the date of
submission of the tender as to whether permission for taking such contract, or if the
contractor be a partnership firm or an incorporated company, to become a partner or
Director as the case may be, or to take the employment under the contractor, has been
obtained by the tenderer or the Engineer or Officer, as the case may be from the
President of India or any officer, duly authorized by him in this behalf, shall be clearly
stated in writing at the time of submitting the tender. Tenders without the information
above referred to or a statement to the effect that no such retired Engineer or retired
Gazetted Officer is so associated with the tenderer, as the case may be, shall be
rejected.
18. VARIATION IN CONTRACT QUANTITIES (Authority: Item No.9 toRailway Board‟s letter No.2007/CE-I/CT/18 dated 28.9.2007
and Item No.2 to letter No.2007/CE-I/CT/18 Pt.XII dated 31.12.2010&Railway
Board‟s letter No.2007/CE-I/CT/18/Pt XII dt.15.12.11)&New clause 42 (4) of General
condition of contract July 2014.
The procedure detailed below shall be adopted for dealing with variation quantities
during the execution of work contracts.
1). Individual NS items in contracts shall be operated with variation of plus or minus
25% and payment would be made as per the agreement rate. For this, no finance
concurrence would be required.
2). In case of increase in quantity of an individual item by more than 25% of the
Agreement quantity is considered as unavoidable, the same shall be got executed by
floating a fresh tender.
If floating a fresh tender for operating that item is considered not practicable, quantity
43
of that item may be operated in excess of 125% of the agreement quantity subject to
the following condition:
(a) Operation of an item by more than 125% of the agreement quantity needs the
approval of an officer of the rank not less than S.A Grade;
(i) Quantities operated in excess of 125% but upto 140% of the agreement
quantity of the concerned item, shall be paid at 98% of the rate awarded for that
item in that particular tender;
(ii)Quantities operated in excess of 140% but upto 150% of the agreement
quantity of the concerned item, shall be paid at 96% of the rate awarded for that
item in that particular tender.
(iii) Variation in quantities of individual items beyond 150% will be prohibited
And would be permitted only in exceptional unavoidable circumstances with the
Concurrence of associate finance and shall be paid at 96% of the rate awarded
for that item in that particular tender.
(b) The variation in quantities as per the above formula will apply only to the
individual items of the contract and not on the overall contract value.
(c) Execution of quantities beyond 150% of the overall agreement value should not be
Permitted and, if found necessary, should be only through fresh tenders or by
negotiating with existing contractor, with prior personal concurrence of
FA&CAO/FA&CAO (C)and approval of General Manager.
3). In cases where decrease is involved during execution of contract;
(a) The contract signing authority can decrease the items upto 25% of individual item
without finance concurrence.
(b) For decrease beyond 25% of individual items or 25% of contract
agreement value, the approval of an officer not less than rank of S.A.
Grade may be taken after obtaining „No Claim Certificate‟ from the
contractor and with finance concurrence, giving detailed reasons for
each such decrease in the quantities.
(c) It should be certified that the work proposed to be reduced will not
be required in the same work.
4). The limit for varying quantities for minor value items shall be 100%
(as against 25% prescribed for other items). A minor value item for this
purpose is defined as an item whose original agreement value is less than
1% of the total original agreement value.
5). No such quantity variation limit shall apply for foundation items.
6). As far as SOR items are concerned, the limit of 25% would apply to
the value of SOR schedule as a whole and not on individual SOR items
However, in case of NS items, the limit of 25% would apply on the
individual items irrespective of the manner of quoting the rate (single
percentage rate or individual item rate).
7). For the tenders accepted at the Zonal Railways level, variations in the
quantities will be approved by the authority in whose powers revised
value of the agreement lies.
44
8). For tenders accepted by General Manager, variations upto 125% of the
original agreement value may be accepted by General Manager.
9). For tenders accepted by Board Members and Railway Ministers,
variations upto 110% of the original agreement value may be accepted by
General Manager.
10). The aspect of vitiation of tender with respect to variation in quantities
should be checked and avoided. In case of vitiation of the tender (both for
increase as well as decrease of value of contract agreement), sanction of
the competent authority as per single tender should be obtained.
11).(Authority : Railway Board vide letter No. 2007/CE-I/CT/18/Pt. XII
dated 15.12.2011), The provision contained in the referred clause 42
(2) (ii) of GCC relating to variation in case of earthwork – “In case of
earthwork, the variation limit of 25% shall apply to the gross quantity of
earthwork and variation in the quantities of individual classifications of
soil shall not be subject to this limit”.
19. UNFORESEEN ITEM OF WORK :- If in the course of work, any unforeseen item of work not
already covered by the Schedule of items in schedule are required to be done, the rate for the same
shall be fixed by mutual agreement based on similar, of corresponding of combination of items of
work available in the said schedule or will be derived from the various items provided in the
Central Railway‟s USSR-2011 as the case may be depending on the nature & specification of the
work involved or by any other procedure mutually agreed upon. In the event of deriving the rate
from the Central Railway USSR-2011, the rate so derived will be subject to the percentage
increase/decrease as per the miscellaneous item specifically provided for in the schedule. If,
however, the work is entirely of different nature, the rates to be paid shall be fixed through work /
market study / Rate analysis for a representative portion of work when a reasonable rate of progress
has been established for (i) direct material (ii) direct labour (iii) hire charges for major plants &
machineries (iv) supervision charges @ 5% on sum of (i) to (iii) (v) Contingencies 1% on sum of
(i) to (iv), (vi) Work Contract Tax 2% on sum of (i) to (v). The rate thus arrived at, will be
enhanced by 10% to cover the contractor‟s profit.
20. STORAGE OF INFLAMMABLE ARTICLES :- No inflammable materials, such as petroleum
oil etc. within the meaning of the Indian Petroleum Act and Indian Explosive Act shall be stored at
site or adjacent land until the approval of the Rly & necessary license under the act has been obtain
-ed by the Contractor. All due precautions required under the Acts shall be taken by the contractor.
21. ANTI-LARVAL WORKS :- The contractor shall at his cost carry out all anti-larval works as per
the Bye-law of the local authorities concerned or as may be directed by the Engineer during the
execution of the work/s under this contract. If the contractor/s fails to carry out such work/s the
Railway may carry out the same and recover the cost thereof from the contractor in the same way,
as other Railway amounts are recoverable.
22. LAND, SERVICE ROADS, APPROACHES
i) The Contractor has to provide a Site office (approx. 20m2 area) with basic amenities to
Railway staff for controlling day-to-day activities along with toilets, urinals, water/electric
connections, etc. at each work site.
ii) The rates for all items of the schedule shall be inclusive of the cost of all arrangements
for crossing obstructions to be crossed in the course of the work over land or across water and the
cost of providing and maintenance of approach and/or service roads that may be necessary for
bringing and removing the plants, machinery and material to and from the site of work including
rent for use and /or compensation for damage if any to intervening private land reversed by such
approach/service roads, and including cost of acquisition of land, if required for the purpose. The
contractor will be permitted to make use of available service roads of the Railways free of cost.
45
Railway reserves the right to make use of the contractor service road without paying any charges
to him.
iii) After completion of the work, the Contractor shall clear all the land under his temporary
occupancy to useable condition without any cost to CENTRAL RAILWAY and hand over to the
concerned parties before the completion of Maintenance period.
23. TELEPHONE FACILITIES :- The Contractor shall have to make an arrangement for providing
telephone facilities at the site of work at his own cost. The telephone facilities provided by the
Contractor shall be allowed to be used by the Railway staff without any charges.
24 TRANSPORT FACILITY
The contractor is required to provide private transport facilities from Dy.CE© PA‟s Office to the work
site, through out the execution period exclusively for the Railway officials free of cost will all
expenses to facilitate inspection of work.
25. The tenderer should note that the rates quoted shall embrace all operations necessary for the
satisfactory completion of the work to finish and shall include all charges for handling, transport,
lead, lift, labour, housing, sanitation, water supply materials fuel, tools and plants, electric power,
workshop facilities, machinery security, lighting etc. and all other expenses of every kinds.
26. EMERGENCY WORK
26.1 In the event of any accident or failure occurring in or about the work of arising out for or
in connection with the construction completion or maintenance of the work which in the opinion
of the Engineer require immediate attention, the Railway may be with its own workmen or other
agency execute or partly execute the necessary work or carry out repairs if the Engineer
considers that the contractor is not in a position to do so in time and charge the cost thereof, as to
be determined by the Chief Engineer/Const. to the contractor.
26.2 In terms of clause of GCC, the material and plants brought by the contractor on the site
or land occupied by the contractor in connection with the works and intended to be used for
execution thereof shall immediately, they are brought upon the sites of this said land be deemed
to be the property of the Railway, vehicles, equipments, plant and machinery of the contractor
can be drafted by the Railway Administration at their discretion in case of accidents, natural
calamities involving human lives, breaches, stoppage of train operations or any contingencies
which require such requisitioning as essential. The decision in this regard of the Engineer-in-
charge or his superiors i.e. Senior Engineer / Executive Engineer/Dy. Chief Engineer etc. shall
be final and beyond the ambit of arbitration clause.
26.3 The tenderer is required to submit the list of equipment, machinery, construction tools
and plants available /deployed at site. The successful tenderer on receipt of acceptance letter and
conveying their consent shall submit name, addresses, telephone numbers, Fax number/E Mail
address of the persons to be contacted for requisitioning the above items as detailed in forgoing
clause and notify from time to time if any change in the list of equipments/machinery or the
addresses/ individuals to the Engineer-in-charge in writing. The name and address, telephone
numbers and the contractor officials name shall also be displayed at the site of work.
26.4 The manpower, consumable items and maintenance of the above tools and plants when
requisitioned shall be the responsibility of the tenderer/contractor so that the equipments,
machinery, tools and plants shall be available for effective utilization at the accident sites,
natural calamities, breaches sites etc.
26.5 The contractor shall be paid hire charges including all cost like manpower, fuel etc., for
the drafted vehicles / equipment by operating suitable Non Schedule items at the rates decided
mutually between the Engineer and the contractor. Operation of Non Schedule item will be
approved with vetting of associate finance by Dy.CE(C) operating the contract. However, if the
contractor is not satisfied with Engineer‟s decision, he may appeal to the CAO(C) within 30 days
of getting the decision of the Engineer supported by the analysis of the rates claimed. The
CAO(C)‟s decision after hearing both the parties in the matter would be final and binding on the
46
contractor.
26.6 In case Railway withdraw / drafts / takes possession of contractor‟s vehicle / equipment,
a log book will be maintained by Railway‟s representative & it will be jointly signed by
Railway‟s authorized representative & contractor‟s driver of vehicle / operator of equipment.
Payment will be made accordingly on agreed rates.
26.7 The contractor shall provide following information about the vehicle / equipment
available with them at the time of entering into contract.
S.N. Particulars of
vehicle/equipment
No. of kind /
make unit
Cacap
Acacit
y
Age &
condition
Present
location
Remarks
27. NIGHT WORK :- The provision in clause 23 of General conditions of contract should be noted
regarding execution of work between sunrise. If the Railway, is however, satisfied that the work is
not likely to be completed in time except by resorting to night work, by special order, the contractor
would be required to carry out the work even at night without conferring any right on the contractor
for claiming for extra payment for introducing night working. The decision of the engineer in this
regard will be final and binding on the contractor.
28. DISPOSAL OF SURPLUS EXCAVATED MATERIALS
The contractor shall at all time keep the site free from all surplus earth, surplus materials, and
all rubbish which shall arise from the works & should dispose of the surplus excavated
materials as ordered by the Engineer failing which it will be done at the cost of the contractor
and cost will be deducted from his dues.
The contractor shall within 15 days of completion of entire works remove all unused & surplus
materials tools & plants staging and refuge or other materials produced by his operations and
shall leave the site in a clear and tidy conditions.
29. PATENT RIGHTS
The contractor shall defray the cost of all royalties, fees and other payments in respect of
Patents, Patent rights and Licenses which may be payable to Patented Licensee or other Person
or Corporation and shall obtain all necessary licenses. In case of any breach (whether willfully or
inadvertently) by the contractor of this provision, the contractor shall indemnify the Railway
and its officers, servants, representatives against all claims, proceedings, damages, cost
charges, loss and liability which they or any of them may sustain, incur or be put to by
reason or in consequence of, directly or indirectly, any such breach and against payment of
any royalties, damages or other moneys which the Railway may have to make to any person or
paid in total to the Patent Rights in respect of the users of any machine, instructions, process,
articles, matters or thing constructed, manufactured, supplied or delivered by the contractor to
his order under this contract.
30. PERMIT OR PARWANA
The contractor will at his own expense obtain such permits or parwana from whomsoever
necessary for carrying out work or for any other purpose as may be necessary to enable him to
perform his part of the contract. The Railway Admn. will not under any circumstances be liable
to obtain any permit or parwana whatso-ever, for the contractor.
31. NOTICE TO PUBLIC BODIES :- The contractor shall give to the Municipality, Police and other
authorities all notices that may be required by the law & obtain all requisite licenses for temporary
obstructions,enclosures & pay all fees,taxes & charges which may be leviable on account of his
own operation in execution the contract. He should make good any damage to adjoining premise
whether public or private and provide and maintain any light etc. required in night.
32. FIGURES,DIMENSIONS :- Figures & dimensions on drawings shall supersede measurements by
scale, and drawings to a large scale shall take precedence over those to a smaller scale.
33. CARE OF STAFF
No quarters will be provided by the Railway for accommodation of the contractor or any of his staff
47
employed on the work. The contractor may be allowed to erect any labour camps for housing the labour
at or near the site work on available Railway land but it will be binding on them to remove the temporary
hutments, jungles etc. from Railway land before payment of final bill. The contractor shall at his own
cost make all necessary and adequate arrangements for importation, feeding and preservation of the
hygiene of his staff. The contractor shall permit inspection at all times, of all sanitary arrangements made
by him, by the engineer or his assistant or the Medical staff of the Railway. If the contractor fails to
make adequate medical and sanitary arrangements these will be provided by the railway and the cost
thereof, will be recovered from the contractor.
34. FIRST-AID
The Contractor shall provide medical facilities at the site as may be prescribed by the Engineer on the
advice of the Railway Medical Authority in relation to the strength of the Contractor's resident staff and
workmen.
The contractor shall maintain in a readily accessible place first aid appliance including an adequate
supply of sterilised dressing and sterilised cotton wool. The appliance shall be placed under the charge of
responsible person who shall be available during working hours.
35. DAMAGE FROM ACCIDENTS, FLOODS OR TIDES
i) The contractor shall take all precautions against damage from accidents, floods or tide. No
compensation will be allowed to the contractor for his tools, plants, materials machines and other
equipment lost or damaged by any cause whatsoever. The contractor shall be liable to make good
the damages to any structure or part of a structure, plant or material of every description
belonging to the Railway administration, lost or damaged by any cause during the course of
contractor‟s work.
ii) The Railway Administration will not be liable to pay to the contractor any charges for
rectification or repairs to any damage, which may have occurred from any cause whatsoever, to
any part of the new structures during construction. No claims in this regard will be arbitrable.
36. SITE INSPECTION BY ENGINEER OR HIS REPRESENTATIVE
36.1 A site inspection register will be maintained by the Contractor or his representative in
which the contractor will be bound to sign day to day entries made by the Engineer or his
representative. The contractor is required to take note of the instructions given to him by the
Engineer through the site inspection register and should comply with the same within a reasonable
time. The contractor will also arrange to receive all the letters etc. issued to him at the site of works. The
register should be machine numbered and shall be given to the Engineer to keep in his custody.
36.2 The contractor shall, from time to time (before the surface of any portion or the site is
interfered with or the work thereon begun) take such levels as the Engineer may direct in his presence
or any person authorised by him in writing. Such levels approved and checked by him or such authorised
persons shall be recorded in writing and signed by the contractor and shall form the basis of the
measurements immediately before any portion of the work.
36.3 The contractor shall have to make & maintain at his own cost suitable approach road and path,
etc. for proper inspection of the various works. He shall also provide all facilities as required by the
Engineer such as Ladder and other appliances for satisfactory inspection of the works and places where
materials for the work are stored or prepared.
36.4 Inspection Registers and Records :- The contractor shall maintain accurate records, plans and
charts showing the dates and progress of all main operations and the Engineer and his representative
shall have access to this information at all times. Records of tests made shall be handed over to the
Engineer's representative after carrying out the tests. The following registers will be maintained at site, by
the contractor and signed by Railway‟s representative.
i. Site Order Book - The contractor shall promptly acknowledge orders given therein by the
Engineer or his representative or his superior officers and comply with them. The compliance
shall be reported by the Contractor to the Engineer in good time so that it can be checked.
48
ii. Cement Register - This register will be maintained to record daily receipt and
consumption of the cement duly indicating the balance quantity. The quantum of
the work done for the cement issued on a particular date will also be maintained.
iii. Steel Register - This register will record the receipts of steel items and details of
reinforcements and members wherever steel is used.
iv. Pre-stressing Register – The details of Pre-stressing cables/strands, their actual
lengths, profile details, stressing details, grouting details etc. shall be maintained in
this register.
v. Technical Register – All technical details as per approved drawings shall be
maintained in this register for all activities.
vi. Labour Register - This register will be maintained to show daily strength of labour
in different categories employed by the contractor.
vii. Log Book of events - All events are required to be chronologically logged in this
book date and shift-wise.
viii. Material Passing & Testing Register - Register will show material brought at site,
passed, rejected etc. with quantity, specifications & test results etc.
ix. Daily progress register- which shall indicate daily progress of work done by the
contractor shall be got signed at least once in three days Engineer in token of
acceptance. The format of the Register will be advised by the Engineer.
x. Hindrance Register :- Which shall indicate the obstacles caused due to any reasons
such as monsoon, shortage of labours, failure of machinery, natural calamities,
strike, shortage of material etc.
Any other register considered necessary by the Engineer shall be maintained at site in which the
representative to the Engineer & the Contractor/s or his their authorised representative will have
to sign. The registers, programs, charts etc. will be the property of the Railway.
36.5 Facilities For Inspection : The Contractor shall afford the Engineer and the Engineer's
Representative every facility for entering in and upon every portion of the work at all hours for
the purpose of inspection or otherwise and shall provide all labour, materials, planks, ladders,
pumps, appliances and things of every kind required for the purpose and the Engineer and the
Engineer's Representative shall at all times have free access to every part of the works and to all
places at which materials for the works are stored or being prepared.
37. OPENING UP OF WORK OR MATERIALS FOR INSPECTION OR TEST
Should the Engineer, or any representative consider it necessary for the purpose of enabling
inspection of tests analysis to be made to verify or ascertain the quality of any part of the works
or of any materials, the contractor shall as and when required by the Engineer or his
representatives open up the work or materials for inspection or test or analysis, pull down or cut
into any part of the work to make such openings, into under or through any part of the
works as may be directed and shall/provide all things facilities which in the opinion of the
Engineer or his representative are necessary & essential for the purpose of inspection or test or
analysis of the works or of any part thereof or the materials, or of workmanship and the
contractor shall close up, cover, rebuild and made good the whole at his own cost, as and when
directed by and to the satisfaction of Engineer provided always that of the work in the opinion
of the Engineer is found to his satisfaction and in accordance with the contract. The excess
expenditure in such examination, inspection or test shall, upon the certificate of the engineer, be
borne by the Railways.
38. GENERAL
38.1 PROVISION OF LIGHT SIGNALS ETC. : The contractor/s shall make such provision
for lighting the works, materials and plant and provide all such marks and lights, signals &
49
other appliances as may be necessary or as may be required by the Engineer or other
responsible authorities during the execution completion and maintenance of the work and
shall provide all labour, stores, etc. required for their efficient working and use at any time of
day or night. He/They shall also provide all arrangement of every description of watching &
maintenance required in connection with the foregoing & all other services for protection of any
securing all dangerous places whether to the contractor's workmen or to other persons & or
vehicular traffic until the work is certified by the engineer to have been completed & taken over
in accordance with the contract.
38.2 The contractor/s will provide upon the works to the satisfaction of the Engineer and at
such, places as he may nominate, proper and sufficient life saving, fire fighting and first aid
appliances which shall at all times be available for use.
38.3 LABOUR CAMPS : Land for setting up a workshop by the contractor or for his labour
camp or for any other purpose, shall have to be arranged by the contractor at his own cost and
under his own arrangements. The contractor, however, will be permitted to make use of the
railway land to the extent that can be made available to him free of cost, by the railway in the
vicinity of the site of works. The contractor/s shall at all times be responsible for any damage
or trespass committed by his agent and workmen for carrying out the work.
38.4 The Railway Administration may recommend to the concerned authorities the issue of
necessary transport permits for the work. The contractor shall, however, furnish full justification
for the above facilities, to enable the Railway Administration to address the State Government or
other authorities in this connection. The contractor shall also maintain regular log book of
receipts and issue of the materials to work, if so required by the Civil Authorities. No claim
would, however, be entertained by the non-issue of any priority permits or owing to any
interruption in supply.
38.5 No claim for idle labour and or idle machinery etc. on any account will be entertained.
Similarly no claim shall be entertained for business loss or any such loss.
38.6 Plea of Custom: The plea of `Custom' prevailing will not, on any account, be permitted
as an excuse for infringement of any of the conditions of contract or specifications.
38.7 Employment of Staff: The contract is liable for cancellation if either the contractor
himself or any of his employee is found to be a person of Gazetted rank of Engineering
Department which includes Civil, Mechanical, Electrical, Signal & Telecommunication
Departments of Railways whether pensionable or non-pensionable who after retirement has
sought engagement as contractor for or in connection with the execution of public works whether
on Railway, PWD or Defense Forces or as an employee of such contractor within 2 years of his
retirement without obtaining the permission of the President of India before taking up such
engagement or employment.
39. TRESPASS
The contractor shall at all times be responsible for any damage or trespass committed by his
agents and workmen in carrying out the work, unless such trespass is authorised by the Engineer.
40. Provisions Of Payments Of Wages Act : The Contractor shall comply with the provisions of the
Payment of Wages Act, 1936 and the rules made there-under in respect of all employees
employed by him either directly or through petty contractors or sub-contractors in the works. If in
compliance with the terms of the contract, the Contractor directly or through petty contractors or
sub-contractors shall supply any labour to be used wholly or partly under the direct orders and
50
control of the Engineer whether in connection with the works to be executed hereunder or
otherwise for the purpose of the Engineer, such labour shall never the less be deemed to comprise
persons employed by the contractor and any moneys which may be ordered to be paid by the
Engineer shall be deemed to be moneys payable by the Engineer on behalf of the Contractor and
the Engineer may on failure of the Contractor to repay such money to the Railways deduct the
same from any moneys due to the Contractor in terms of the contract. The Railway shall be
entitled to deduct from any moneys due to the contractor (whether under this contract or any other
contract) all moneys paid or payable by the Railway by way of compensation of aforesaid or for
costs of expenses in connection with any claim thereto and thedecision of the Engineer upon any
question arising out of the effect or force of this Clause shallbe final and binding upon the
Contractor.
Provisions of Contract Labour (Regulation And Abolition) Act, 1970:
As per clause No. 55-A of General conditions of contract, following conditions will be applicable:-
(1) The Contractor shall comply with the provision of the contract labour (Regulationand
Abolition) Act, 1970 and the Contract labour (Regulation and Abolition) Central Rules 1971as
modified from time to time, wherever applicable and shall also indemnify the Railway fromand
against any claims under the aforesaid Act and the Rules.
(2) The Contractor shall obtain a valid license under the aforesaid Act as modified fromtime to
time before the commencement of the work and continue to have a valid license untilthe
completion of the work. Any failure to fulfill the requirement shall attract the penal provision of
the Contract arising out of the resultant non-execution of the work.
(3) The Contractor shall pay to the labour employed by him directly or through subcontractors
the wages as per provision of the aforesaid Act and the Rules wherever applicable. The
Contractor shall notwithstanding the provisions of the contract to the contrary, cause to be paid
the wages to labour indirectly engaged on the works including any engaged bysub-contractors in
connection with the said work, as if the labour had been immediately employed by him.
(4) In respect of all labour directly or indirectly employed in the work for performance ofthe
contractor's part of the contract, the Contractor shall comply with or cause to be compliedwith the provisions of the aforesaid Act and Rules wherever applicable.
(5) In every case in which, by virtue of the provisions of the aforesaid Act or the Rules,the
Railway is obliged to pay any amount of wages to a workman employed by the Contractor or his
sub-contractor in execution of the work or to incur any expenditure on account of the Contingent,
liability of the Railway due to the contractor's failure to fulfill his statutory obligations under the
aforesaid Act or the rules, the Railway will recover from the Contractor, the amount of wages so
paid or the amount of expenditure so incurred and without prejudice to the rights of the Railway
under the Section 20, Sub-Section (2) and Section 2, Sub-Section (4) of the aforesaid Act, the
Railway shall be at liberty to recover such amount or part thereof by deducting it from the
Security Deposit and/or from any sum due by the Railway to the contractor whether under the
contract or otherwise. The Railway shall not be bound to contest any claim made against it under
Sub-Section (1) of Section 20 and Sub-Section (4) of Section 21 of the aforesaid Act except on
the written request of the Contractor and upon his giving to the Railway full security for all costs
for which the Railway might become liable in contesting such claim. The decision of the Railway
regarding the amount actually recoverable from the contractor as stated above shall be final and
binding on the Contractor.
41. If the Contractor is a co-operative labour contractor, or Society/Vendor Co-operative Society,
there shall be no element of contractor or ex-contractors in that Society in any capacity nor shall
there be any close relative of the Contractor or ex-contractor associating with the Society as an
office bearer. The Railway administration reserve the right to terminate the contract of the
51
Society at any time without any reason after giving notice of one calendar month, in case of
breach of the above clause.
42. BLASTING
42.1 In the procurement, transport, storage, issue and use of explosives, the contractor shall abide by
the specification and provisions incorporated in the IS Specification No.4801-1967 and IS
Specification No. 4756-1968 as amended from time to time. He shall also abide by all the rules
and regulations provided in the Indian Explosives Act 1884 amended from time to time and such
other Acts and rules as may be enacted and laid from time to time by the Government for such
works.
42.2. Prior to carrying out any blasting the contractor shall obtain the concurrence of the engineers and
shall be at all times bound to carry out his instructions regarding provision of blanketing, the type,
number, size and placing and firing of charges. Where the blasting has to be carried out close to
running line, the engineer may restrict the sizes and number of shots to be fired at a time so that
adjoining tracks and works are not adversely affected and so that the rock beyond the desired
profile of the cutting etc. is not cracked or disturbed. Blasting in close proximity to track
structures and power lines will be carried out only under traffic power blocks. For works near
telephone or telegraph wires, the contractor must advise the engineer in good time, so that he can
satisfy himself that safe working methods are being adopted. The contractor will only fire
charges at the time notified to him by the engineer and will observe all precautions considered
necessary as ordered by the engineer. The contractor will have no claim for damages or loss due
to any delay established or claimed to have occurred to the progress of any part of the work as a
result of obeying such instruction of the engineer or taking such safety precautions as to the
engineer may order to be taken from time to time.
42.3. The traffic and power blocks required for carrying out the blasting will be settled in advance and
the contractor will be advised of the availability of blocks at least 6 hours in advance. If however,
the block could not be made available due to any reason whatsoever, the contractor will have no
claim for any loss.
43. PAYMENT THROUGH ECS / EFT
a. Tenderer should give consent in a mandate form for receipt of payment through ECS/EFT.
b. Tenderer to provide the details of bank A/c in line with RBI guidelines for the same. These
details will include bank name, Brach name and address, Account type, Bank A/c No. and
bank & Branch Code as appearing on MICR cheque issued by bank.
c. Tenderers to attach certificate from their bank certifying the correctness of all above
mentioned information (as mentioned in Para (b) above.)
d. In case of nonpayment through ECS/EFT or where ECS/EFT facility is not available, payment
will be released through cheques.
44. RATES FINAL AND BINDING EXCEPT FOR EXCALATION FORMULA
44.1 Save as otherwise expressly specified elsewhere in this tender document, the rates to be quoted by
the Tenderer against the description of items under Schedule (All parts) shall include the cost of :-
(i) All preliminary incidental and temporary works to carry out & complete the work in all
respects.
(ii) All labour, material, tools, plants, equipments, transport, handling, construction of
services road, walkways, jetties, slipways, etc., required in connection with the main item
of work and also the auxiliary and incidental works.
(iii) All investigations, testing & all other items of work required to comply with the special
conditions, specifications & other tender documents mentioned in para 7 of Section „A‟.
(iv) Operating all necessary facilities required for departmental inspections and visits to be
carried out by Railway Officials.
(v) All the elements of Sales Tax, Central & local taxes and any other taxes, levies, octroi as
per the extant rules.
52
(vi) Items required to be carried out as mentioned in tender document and any other items
required to be carried out to complete the work.
(vii) The rates quoted by the Tenderer and accepted by Central Railway, Mumbai shall hold
good till the completion of the work. No claims based on the fluctuation of prices, taxes,
etc. shall be admissible, except as per escalation clause mentioned in the tender
document.
(viii)No payment for items other than those stipulated in Schedule (all parts) will be
entertained unless this are specifically brought out as a separate item agreed between
Railway and the Contractor.
(ix) The rates given in the attached schedule of rates tendered by the contractor and as
accepted by the Railways will form the basis of payment for such items under this
contract.
44.2 No material price variation or wages escalation on any account whatsoever the compensation for
`Force Majure' etc. shall be payable under this contract except price escalation payable as per
price escalation clause, provided separately in the tender documents.
44.3 The rates for any item of work not included in the (Schedule of Items, Rates and Quantities) &
which the contractor may be called upon to do by Railway Administration shall be fixed by the
supplementary written agreement between the contractor and the Railway before the particular
item or items of work is/are executed. In the event of such agreement not being entered into and
executed the Railway may execute these works by making alternative arrangements. Railways
will not be responsible for any loss or damages on this account.
44.4 It should be specifically noted by the tenderers that no separate loading, unloading and leading
charges for materials (which are supplied by the Railway) shall be paid for by the Railways and
the rates quoted by the tenderer/s shall be inclusive of all these charges.
44.5 In case of the Master Schedule items, the item nos., description, units and rates given in schedule
of rates are as per Central Railway Standard Schedule of Rates 2002 and any discrepancy during
the execution of the work in the working rates, quantity and units etc. should be rectified by
reference to the printed schedule of rates which be treated as authority and will be binding on the
contractor.
44.6 Payment for the work done will be made to the contractor only when the formal agreement has
been executed between the contractor and the President of India acting through competent
authority of Railway.
44.7 The rates quoted by the contractor as per Schedule of Items, Rates and Quantities shall form the
basis of „on account payment' or the various items under this contract.
44.8 In the course of execution of various items of work under schedule of Items, Rates and Quantities
running bills payment for partly completed works will be made to the contractor. The quantum of
such work for payment shall be decided by the Engineer-in-charge whose decision shall be
final and binding on the contractor.
44.9 No on account payment' by the Railway shall protect the contractor/s against or prevent the
Railway from recovering from the contractor/s any over payment made to him/them.
44.10 Final payment of the balance amount due, exclusive of the security deposit, will be made after the
completion of the entire work and on the certification of the Engineer that work has been
completed in all respects and found satisfactory. The security deposit will be refunded after the
date of completion according to relevant clause given elsewhere in these conditions.
44.11 All payments in respect of the contract during the currency of the contract shall be made through
Electronic Clearing System (ECS) / Electronic Funds Transfer (EFT). The successful tenderer on
award of contract must submit ECS/EFT/RTGS Mandate Form complete in all respects as
detailed at Annexure-J of the tender document. However, if the facility of ECS/EFT/RTGS is not
available at a particular location the payment shall be made by Cheque. In such case the
successful tenderer on award of contract will have to furnish contractor‟s Bank Account Number
53
and Name of the Bank against which all payments in respect of the contract during the currency
of contract shall be made.
45. MAINTENANCE PERIOD
The work shall be maintained after completion for a period of As per Tender notice/NIT by the
contractor and he shall make good any defects, imperfection, shrinkages or faults which may
appear, at his own cost.
46. PRICE VARIATION CLAUSE:
(Circulated as per Railway Board‟s letter No.2007/CE-I/CT/18/Pt.19 Dtd.14.12.2012 & circulated
vide HQ‟s letter No.187/R/465/1/Vo. II Dtd.24.01.2013).
Price variation clause (PVC) shall be applicable only for contracts of value (Contract Agreement
Value) Rs. 50 lakh and more. PVC clause withdrawn, where the completion period is below one
year .(Ref. As per CAO © CSTM‟s Lr.No.CHQ/AC/DP-CR.01/2016-17 Dt.27.9.2017)
46
A.1
Applicability: Price Variation Clause (PVC) shall be applicable only for contracts of value
as prescribed by the Ministry of Railways through instructions / circulars issued
from time to time and irrespective of the contract completion period. Variation in
quantities shall not be taken into account for applicability of PVC in the contract.
Materials supplied free of cost by Railway to the contractors shall fall outside the purview
of Price Variation Clause. If, in any case, accepted offer includes some specific payment
to be made to consultants or some materials supplied by Railway free or at fixed rate, such
payments shall be excluded from the gross value of the work for the purpose of payment /
recovery of price variation.
A.2 Base Month: The Base Month for „Price Variation Clause‟ shall be taken as month of
opening of tender including extensions, if any, unless otherwise stated elsewhere. The
quarter for applicability of PVC shall commence from the month following the month of
opening of tender. The Price Variation shall be based on the average Price Index of the
quarter under consideration.
A.3 Validity: Rates accepted by Railway Administration shall hold good till the completion of
the work and no additional or individual claim shall be admissible on account of
fluctuations in market rates, increase in taxes / any other levies/tolls etc. except that
payment/recovery for overall market situation shall be made as per Price Variation Clause
given hereunder.
A.4 Adjustment for variation in price of material, labour, fuel explosives, detonators, steel,
concreting, ferrous, non – ferrous, insulators, zinc and cement shall be determined in the
manner prescribed.
A.5 Components of various items in a contract on which variation in prices be admissible, shall
be Material, Labour, Fuel, Explosives, Detonators, Steel, Cement & Lime, Concreting,
Ferrous, Non ferrous, Insulator, Zinc, Erection etc. However, for fixed components, no
price variation shall be admissible.
A.6 The percentages of labour component, material component, fuel component etc. in various
types of Engineering Works shall be as under:
Component Percentage
(A) Earthwork Contracts:
Labour Component 50%
Fuel Component 20%
Other Material Components 15%
Fixed Component * 15%
(B) Ballast and Quarry Products Contracts:
Labour Component 55%
Fuel Component 15%
54
Other Material Components 15%
Fixed Component * 15%
(C) Tunneling Contracts:
Labour Component 45%
Fuel Component 15%
Explosive Component 15%
Detonators Component 5%
Other Material Component 5%
Fixed Component * 15%
(D) Other Works Contracts:
Labour Component 30%
Material Component 40%
Fuel Component 15%
Fixed Component * 15%
* It shall not be considered for any price variation.
A.7 Formulae: The Amount of variation in prices in several components (labour material
etc) shall be worked out by the following formulae:
(i) W x (Lq – Lb) Lc
L = ------------------ x --------
Lb 100
(ii) W x (Mq – Mb) Mc
M = ------------------ x --------
Mb 100
(iii) W x (Fq – Fb) Fc
F = ------------------ x --------
Fb 100
(iv) W x (Eq – Eb) Ec
E = ------------------ x --------
Eb 100
(v) W x (Dq – Db) Dc
D = ------------------ x --------
Db 100
(vi) S = Sw x ( Sq – Sb)
(vii) C = Cv x (Cq – Cb ) / Cb
For Railway Electrification Works:
(viii) T = [(Cs – Co) / Co x 0.4136] x Tc
(ix) R = [(Rt – Ro) / Ro + (Zt – Zo)/ Zo x 0.06] x Rc
(x) N = [(Pt – Po / Po)] x Nc
(xi) Z = [(Zt – Zo)/ Zo] x Zc
(xii) I = [ (It – Io) / It] x 85
Where,
L Amount of price variation in Labour.
M Amount of price variation in Materials.
F Amount of price variation in Fuel.
E Amount of price variation in Explosives.
D Amount of price variation in Detonators.
55
S Amount of price variation in Steel.
C Amount of price variation in Cement.
T Amount of price variation in Concreting.
R Amount of price variation in Ferrous Items.
N Amount of price variation in Non-Ferrous Items.
Z Amount of price variation in Zinc.
I Amount in price variation in Insulator.
Lc % of Labour Component.
Mc % of Material Component.
Fc % of Fuel Component.
Ec % of Explosive Component.
Dc % of Detonators Component.
Tc % of Concreting Component.
Rc % of Ferrous Component.
Nc % of Non Ferrous Component.
Zc % of Zinc Component.
W Gross value of work done by contractor as per on-account bill(s),
Excluding cost of materials supplied by Railway at fixed price, minus the
price values ofcement and steel. This will also exclude specific payment,
if any, to be madeto the consultants engaged by contractors (such payment
shall be indicatedin the contractor‟s offer).
Lb Consumer Price Index Number for Industrial Workers - All India :
Published inR.B.I. Bulletin for the base period.
Lq Consumer Price Index Number for Industrial Workers - All India :
Published inR.B.I. Bulletin for the average price index of the 3 months of
the quarter under consideration.
Mb Index Number of Wholesale Prices – By Groups and Sub-Groups : All
commodities – as published in the R.B.I. Bulletin for the base period.
Mq Index Number of Wholesale Prices – By Groups and Sub-Groups : All
commodities – as published in the R.B.I. Bulletin for the average price
index of the 3 months of the quarter under consideration.
Fb Index Number of Wholesale Prices – By Groups and Sub-Groups for Fuel
andPower as published in the R.B.I. Bulletin for the base period.
Fq Index Number of Wholesale Prices – By Groups and Sub-Groups for Fuel
andPower as published in the R.B.I. Bulletin for the average price index of
the 3months of the quarter under consideration.
Eb Cost of explosives, as fixed by DGS&D in the relevant rate contract of the
Firm from whom purchases of explosives are made by the contractor for
the base period.
Eq Cost of explosives, as fixed by DGS&D in the relevant rate contract of the
Firm from whom purchases of explosives are made by the contractor for
theaverage price index of the 3 months of the quarter under consideration.
Db Cost of detonators, as fixed by DGS&D in the relevant rate contract of the
firm from whom purchases of detonators are made by the contractor for the
base period.
Dq Cost of detonators, as fixed by DGS&D in the relevant rate contract of the
firm from whom purchases of detonators are made by the contractor for the
average price index of the 3 months of the quarter under consideration.
Sw Weight of steel in tonne, supplied by the contractor as per the „on-account‟
bill for the month under consideration.
56
Sq SAIL‟s (Steel Authority of India Limited) ex-works price plus Excise Duty
thereof (in rupees per tonne) for the relevant category of steel supplied by
the contractor, as prevailing on the first day of the month in which the steel
was purchased by the contractor (or) as prevailing on the first day of the
month in which steel was brought to the site by the contractor, whichever
is lower.
In case, there is no notification by SAIL for the month under consideration,
the price of steel, as notified in the last available month shall be taken.
Sb SAIL‟s ex-works price plus Excise Duty thereof (in Rs. per tonne) for the
relevant category of steel supplied by the contractor as prevailing on the
first day of the month in which the tender was opened.
In case, there is no notification by SAIL for the month under consideration,
the price of steel, as notified in the last available month shall be taken.
Cv Value of Cement supplied by Contractor as per on account bill in the
quarterunder consideration.
Cb Index No. of Wholesale Price of sub-group (of Cement & Lime) as
Published in RBI Bulletin for the base period.
Cq Index No. of Wholesale Price of sub-group (of Cement & Lime) as
Published in RBI Bulletin for the average price index of the 3 months of
the quarter under consideration.
Cs RBI wholesale price index for cement & lime for the month which is six
months prior to date of casting of foundation.
Co RBI wholesale price index for cement & lime for the month which is one
month prior to date of opening of tender
Rt IEEMA price index for Iron & Steel for the month which is two months
prior to date of inspection of material.
Ro IEEMA price index for Iron & Steel for the month which is one month
prior to-date of opening of tender.
Pt IEEMA price for Copper wire bar for the month which is two months prior
to date of inspection of material.
Po IEEMA price for Copper wire bar for the month which is one month prior
to date of opening of tender.
Zt IEEMA price for Zinc for the month which is two months prior to date of
inspection of material.
Zo IEEMA price for Zinc for the month which is one month prior to date of
opening of tender.
It RBI wholesale price index for Structural Clay Products for the month
which istwo months prior to date of inspection of material.
Io RBI wholesale price index for Structural Clay Products for the month
which is one month prior to date of opening of tender.
A.8 The demands for escalation of cost shall be allowed on the basis of provisional indices
made available by Reserve Bank of India. Any adjustment needed to be done based
on the finally published indices shall be made as and when they become available.
A.9 Relevant categories of steel for the purpose of operating Price Variation formula, as
mentioned in this Clause, based on SAIL‟s ex- works price plus Excise Duty thereof,
shall be as under:
SL Category of Steel Supplied In Railway
Work
Category of steel produced by SAIL Whose Ex-
Works Price Plus Excise Duty Would Be
Adopted to Determine Price Variation.
57
1 Reinforcement bars and other rounds TMT 8 mm IS 1786 FE 415/FE 500
2 All types and sizes of angles. Angle 65 x 65 x 6 mm IS 2062 E250A SK
3 All types and sizes of plates PM Plates above 10-20 mm IS 2062 E250A SK
4 All types and sizes of channels & joists. Channels 200 x 75 mm IS 2062 E250A SK
5 Any other section of steel not covered in
the above categories and
excluding HTS
Average of price for the 3 categories covered
under SL 1, 2&3 above.
A.10 Price Variation During Extended Period of Contract :
The Price adjustment as worked out above, i.e. either increase or decrease shall be
applicable up to the stipulated date of completion of work including the extended period of
completion where such extension has been granted under Clause 17-A of the
General Conditions of Contract. However, where extension of time has been granted due to
contractor‟s failure under Clause 17-B of the Standard General Conditions of Contract,
price adjustment shall be done as follows:
(a) In case the indices increase above the indices applicable to the last month of
original completion period or the extended period under Clause 17-A, the price
adjustment for the period of extension granted under clause 17-B shall be limited
to the amount payable as per the Indices applicable to the last month of original
completion period or the extended period under Clause 17-A of the standard
General Conditions of Contract; as the case may be.
(b) In case the indices fall below the indices applicable to the last month of original /
extended period of completion under Clause 17-A, as the case may be; then the
lower indices shall be adopted for the price adjustment for the period of extension
under Clause 17-B of the Standard General Conditions of Contract.
46A.7- Rly.Bds Lr.No.2017.CE-I.CT.4.GST Dt.5.7.2017 –
Subsequent to enactment of GST Act, 2017, Board (ME & FC) has approved revision to para 46A.9 and terms
SQ & SB mentioned in para 46A.7 of clause 46A, Part-11 of Indian Railways Standard General Conditions of
Contract. The revised para 46A.9 and terms SQ & SB mentioned in para 46A.7 of clause 46A, Part-11 of
Indian Railways Standard General Conditions of Contract, July 2014 shall be read as under:
46A.7: Formula:
SQ SA1L‟s (Steel Authority of India Limited) ex-works price plus applicable
GST and Cess on GST (if any) thereof (in rupees per tonne) for the relevant category of steel supplied by
the contractor, as prevailing on the first day of the month in which the steel was purchased by the contractor
(or) as prevailing on the first day of the month in which steel was brought to the site by the contractor,
whichever is lower .
In case, there is no notification by SAIL for the month under consideration, the price of steel, as notified
in the last available month shall be taken
SB SAIL‟s ex-works price plus applicable GST and Cess on GST (if any) thereof (in Rs. per tonne) for the
relevant category of steel supplied by the contractor as prevailing on the first day of the month in which the
tender was opened .
In case, there is no notification by SAIL for the month under consideration, the price of steel, as notified in the
last available month shall be taken
46A.9: Relevant categories of steel for the purpose of operating Price Variation formula, as mentioned in this
Clause, based on SAIL‟s ex-works price plus applicable GST and Cess on GST (if any) thereof, shall be as
under :
SL Category Of Steel
Supplied In Railway Work
Category Of Steel Produced By SAIL Whose Ex-Works Price
Plus applicable GST and Cess on GST (if any) Would Be
58
Adopted To Determine Price Variation
1 Reinforcement bars and other
rounds
Tmt 8 MM is 1786 Fe 415/Fe 500.
2. All types and sizes of angles PM Plates above 10-20 mm IS 2062, E250 A SK
3 All types and sizes
of plates
PM Plates above 10-20 mm IS 2062 E250A SK
4 All types and sizes
Of channels and joists
Channels 200 x 75 mm IS 2062 E250A SK
5 Any other section of steel not
covered in the above categories
and excluding HTS
Average of price for the 3
categories covered under SL 1,2 & 3 above.
47. FORCE MAJEURE CLAUSE
If at any time, during the continuance of this contract, the performance in whole or in part by either party
of any obligation under this contract shall be prevented or delayed by reason of any war, hostility, acts of
public enemy, civil commotion, sabotage, serious loss or damage by fire, explosions, epidemics, strikes,
lockouts or acts of God (hereinafter, referred to events) provided, notice of the happening of any such
event is given by either party to the other within 60 days from the date of occurrence thereof, neither
party shall by reason of such event, be entitled to terminate this contract nor shall either party have any
claim for damages against the other in respect of such non-performance of delay in performance, and
works under the contract shall be resumed as soon as practicable after such event has come to an end or
ceased to exist, and the decision of the Engineer as to whether the works have been so resumed or not
shall be final and conclusive, provided further that if the performance in whole or in part of any
obligation under this contract is prevented or delayed by reason of any such event for a period exceeding
90 days, either party may at its option terminate the contract by giving notice to the other party.
48. TEMPORARY LABOUR COLONY:
The contractor may be allowed to put temporary labour colony on their request, but it will be
binding on them to remove the temporary hutments, jungles, etc. from the Railway land before
finalization of final bill.
49. WORK PREPARED AWAY FROM THE SITE
The contractor shall give the Engineer written notice of the preparation or manufacture at a place
away from site, of any materials or components to be used on the works, stating the place & time
of preparation or manufacture, so that the Engineer may inspect all stages of the production
process. Failure to give such notice may result in the rejection of the materials or components.
50. CONSTRUCTION PROGRAMME
Construction work should be planned in such a way, that there will be unhindered progress of the
bridge construction. For this purpose, construction programme will be finalised by the contractor
in consultation with Engineer of CENTRAL RAILWAY, Mumbai whose decision will be final &
binding.
Apart from the above, the contractor shall afford all reasonable facilities to other contractors
employed by CENTRAL RAILWAY, Mumbai or by any other authority to execute work on the
site. This includes instrumentation, testing, etc. In case of disputes, decisions of the Engineer
shall be final & binding.
51. COMPLETION DRAWINGS
Contractor should submit to Railways 1 set of completion drawings (all detailed drawings) after
completion of work, on polyester based tracing films (75 microns thick, one side mat of superior
quality) in black indelible ink duly incorporating all additions and alterations in red ink along
with a copy of the same on a CD, 6 blue prints and 1 copy on RTF. It will be paid under relevant
item.
52. DELAYED COMPLETION AND LIQUIDATED DAMAGES
The Railway administration reserve right to levy token penalty to be recovered from the
59
contractor as deemed fit based on the merit of the case while granting extension under clause 17
(B) of GCC (delay due to contractor). Particularly attention is invited to Clause 17 of General
Conditions of Contract (Updated up to the date) in this connection. Regarding liquidated damages
referred to in clause 17-B, it is clarified that the Contract value mentioned therein refers to the
overall contract value.
53. HANDING OVER OF WORK
In addition to what has been stipulated in clause 40 of General Condition of Contract, it is made
clear that all the works and materials before being finally taken over by CENTRAL RAILWAY
will be entirely liability of the contractor for guarding, maintaining and making good any
damages of any magnitude. It is however understood that before taking over such work
CENTRAL RAILWAY will not put it to its regular use as distinct from casual or incidental one
except as specially mentioned elsewhere in this contract or mutually agreed to.
54. ALTERNATIVE DUE TO REJECTED WORK
In the event of any sub-structure or super-structure are abandoned on account of rejection by the
Railway, the extra cost involved in providing further alternative arrangements shall be borne by
the Contractor. The rates offered shall be deemed to have provided for this contingency.
55. ISSUE OF IDENEITY CARDS BY CONTRACTORS
(i) The Contractor is bound to issue Identity card to each and every person employed by him
and deployed for execution of the Contract work as per the prescribed format provided in the
tender document (Annexure-IX), at his cost. Failure on the part of the Contractor to issue Identity
cards to their employees will be treated as breach of contract conditions and therefore will be
dealt as per Clause No.62 (vii) of General Conditions of Contract.
(ii) It is mandatory on the part of every employee, deployed by the Contractors to keep in his
possession the Identity card, issued by the Contractor throughout the execution of the work.
Failure to possess such Identity will be treated as unauthorised presence in the Railway premises.
Such persons shall be liable for prosecution as per law.
(iii) It is mandatory for the Contractors to submit the list of the employees issued with the
Identity cards and deployed for execution of the particular contract, to the Railway‟s Engineer at
site before commencement of the work and also for any subsequent changes made during the
execution of the work.
No claims whatsoever arising out of implementation of special conditions pertaining to issue of
Identity cards shall be admissible.
56. DETERMINATION OF CONTRACT OWING DEFAULT OF CONTRACTOR
(Amendments clause No.62 of General Condition of Contract)
56.1 If the Contractor should: - .
(i) Becomes bankrupt or insolvent, or
(ii) Make an arrangement with of assignment, in favour of his creditors, or agree to carry out
the contract under a Committee of Inspection of his creditors, or
(iii) Being a Company or Corporation, go into liquidation (other than a voluntary liquidation for
the purposes of amalgamation or reconstruction), or
(iv) Have an execution levied on his goods or property on the works, or
(v) Assign the contract or any part thereof otherwise than as provided in Clause 7 of GCC, or
(vi) Abandon the contract, or
(vii) Persistently disregard the instructions of the Engineer, or contravene any provision of the
contract, or
(viii) Fail to adhere to. the agreed programme of work by a margin of 10% of the stipulated
period, or
(ix) Fail to remove materials from the site or to pull down and replace work after receiving
from the Engineer notice to the effect that the said materials or works have been
60
condemned or rejected under Clause 25and 27 of these Conditions, or
(x) Fail to take steps to employ competent or additional staff and labour as required under
clause 26 of the Conditions, or
(xi) Fail to afford the Engineer or Engineer's representative proper facilities for inspecting the
works or any part thereof as required under clause 28 of the Conditions, or
(xii) Promise, offer or give any bribe, commission, gift or advantage either himself or through
his partner, agent or servant to any officer or employee of the Railway or to any person on
his or on their behalf in relation to the execution of this or any other contract with this
Railway.
(xiii) (A) At any time after the tender relating to the contract, has been signed and submitted by
the Contractor, being a partnership firm admit as one of its partners or employ under it or
being an incorporated company elect or nominate or allow to act as one of its directors or
employ under it in any capacity whatsoever any retired engineer of the gazetted rank or any
other retired gazetted officer working before his retirement, whether in the executive or
administrative capacity, or whether holding any pensionable post or not, in the Railways for
the time being owned and administered by the President of India before the expiry of two
years from the date of retirement from the said service of such Engineer or Officer unless
such Engineer or Officer has obtained permission from the President of India or any officer
duly authorized by him in this behalf to become a partner or a director or to take
employment under the contract as the case may be, or
(B) Fail to give at the time of submitting the said tender:-
a)The correct information as to the date of retirement of such retired engineer or retired officer
from the said service, or as to whether any such retired engineer or retired officer was under the
employment of the Contractor at the time of submitting the said tender, or
b) The correct information as to such engineers or officers obtaining permission to take
employment under the Contractor, or
c) Being a partnership firm, the correct information as to, whether any of its partners was such a
retired engineer or a retired officer, or
d) Being in incorporated company, correct information as to whether any of its directors was
such. a retired engineer or a retired officer, or
e)Being such a retired engineer or retired officer suppress and not disclose at the time of
submitting the said tender the fact of his being such a retired engineer or a retired officer or make
at the time of submitting the said tender a wrong statement in relation to his obtaining permission
to take the contract or if the Contractor be a partnership firm or an incorporated company to be a
partner or director of such firm or company as the case may be or to seek employment under the
Contractor.
Then and in any of the said cases, the Engineer on behalf of the Railway may serve the
Contractor with a notice (Proforma at Annexure IX) in writing to that effect and if the
Contractor does not within seven days after the delivery to him of such notice proceed to make
good his default in so far as the same is capable of being made good and carry on the work or
comply with such directions as aforesaid to the entire satisfaction of the Engineer, the Railway
shall be entitled after giving 48 hours notice (Proforma at Annexure X) in writing under the hand
of the Engineer to rescind the contract as a whole or in part or parts (as may be specified in such
notice) and after expiry of 48 hours notice, a final termination notice (Proforma at Annexure-XI)
should be issued.
56.2 Right of Railway after rescission of contract owing to default of Contractor
In the event of any or several of the courses, referred to in sub-clause (1) of this clause, being adopted:-
(a) The Contractor shall have no claim to compensation for any loss sustained by him by reason of his
61
having purchased or procured any materials or entered into any commitments or made any advances on
account of or with a view to the execution of the, works or the performance of the contract and Contractor
shall not be entitled to recover or be paid any sum for any work thereto for actually performed under the
contract unless and until the Engineer shall have certified the performance of such work and the value
payable in respect thereof and the Contractor shall only be entitled to be paid the value so certified.
(b) The Engineer or the Engineer's Representative shall be entitled to take possession of any materials,
tools, implements, machinery and buildings on the works or on the property on which these are being or
ought to have been executed, and to retain and employ the same in the further execution of the works or
any. part thereof until the completion of the works without the Contractor being entitled to any
compensation for the use and employment thereof or for wear and tear or destruction thereof.
(c) The Engineer shall as soon as may be practicable after removal of the Contractor fix and determine
ex-parte or by or after reference to the parties or after such investigation or enquiries as he may consider
fit to make or institute and shall certify what amount (if any) had at the time of recession of-the contract
been reasonably earned by or would reasonably accrue to the Contractor in respect of the work then
actually done by him under the contract and what was the value of any unused, or partially used
materials, any constructional plant and any temporary works upon the site. The legitimate amount due to
the contractor after making necessary deductions and certified by the engineer should be released
expeditiously.
57. SETTLEMENT OF DISPUTES
57.1Settlement of disputes and differences arising out of contract shall be done as per
clauses 63 and 64 of General Conditions of Contract (Updated up to the date).
57.2. Claims to be restricted to 20% of contract value- The provision of Clauses 63 & 64 of General
Conditions of Contract will be applicable only for settlement of claims or disputes between the parties for
value less than or equal to 20% of the value of the contract and when claims of disputes are of value more
than 20% of the value of the contract, provision of clause 63 & 64 and other relevant clause of the
General Conditions of Contract will not be applicable and arbitration will not be a remedy for settlement
of such disputes.
57.3 Excepted matters not to be referred to arbitration- In terms of clause 63 of General Conditions
of Contract (Updated upto the date), the disputes and differences, for which provision has been made in
following clauses of General Conditions of the contract of the contract, shall be deemed as „Excepted
matters‟ and decisions of the Railway authority thereon shall be final and binding on the contractor and
these „Excepted matter‟ shall stand specifically excluded from the purview of the arbitration clause and
not referred to arbitration.
1 Clause 8 Assistance by the Railway for the Stores to be obtained
by the Contractor
2 Clause 18(1) Illegal Gratification
3 Clause 18(2) Monetary dealings with any employee of the Railway
4 Clause 22(5) Meaning and intent of specification and drawings
5 Clause 39(1) Rates for extra items of works
6 Clause 39(2) Payment to the Contractor for work executed before
determination of rates
7 Clause 43(2) Signing of “No Claim” Certificate
8 Clause 45(a) Objections to recorded measurements within 7days
9 Clause 55 Provisions of payments of Wages Act
10 Clause 55-A(5) Recovery from Contractor wages paid to Contractor‟s
62
labour
11 Clause 57 Provision of Workmen‟s Compensation Act
12 Clause 57-A Provision of Mines Act
13 Clause 61(1) Right of Railway to determine the contract
14 Clause 61(2) Payment on determination of contract
15 Clause 62(1) to
(xiii)(B) or (clause
52 above)
Determination of contract owing to default of Contractor
57.4. In terms of clause 63 of General Conditions of Contract (updated up to the date of opening of
tender), the disputes and differences, for which provision has been made in “Special Conditions
of Contract” included in tender documents, shall also be deemed as „Excepted matters‟ and
decisions of the Railway authority thereon shall be final and binding on the contractor and these
„Excepted matter‟ shall stand specifically excluded from the purview of the arbitration clause and
not referred to arbitration.
57.5. Arbitrators to be appointed only by General Manager of Railways
57.6. The Claimant Contractor shall seek reference to Arbitration to settle the disputes only within the
ambit of conditions of mentioned above.
Recently Railway Board has issued letter No.2015/CE-I/CT/ARB/18 Dtd.11.11.2016 in connection
with Modification of Clause 64 of GCC for dealing of arbitration cases. The modified
clause No. 64 of GCC is reproduced below. 64.(1): Demand For Arbitration :
64. (1) (i) :
In the event of any dispute or difference between the parties hereto as to the
construction or operation of this contract, or the respective rights and liabilities
of the parties on any matter in question, dispute or difference on any account
or as to the withholding by the Railway of any certificate to which the
contractor may claim to be entitled to, or if the Railway fails to make a
decision within 120 days, then and in any such case, but except in any of the
“excepted matters” referred to in Clause 63 of these Conditions, the contractor,
after 120 days but within 180 days of his presenting his final claim on disputed
matters shall demand in writing that the dispute or difference be referred to
arbitration.
64.(1) (ii) (a) :
The demand for arbitration shall specify the matters which are in question, or
subject of the dispute or difference as also the amount of claim item-wise.
Only such disputeor difference, in respect of which the demand has been
made, together with counter claims or set off, given by the Railway, shall be
referred to arbitration and other matters shall not be included in the reference.
64.(1) (ii) (b) :
The parties may waive off the applicability of sub-section 12(5) of Arbitration
and Conciliation (Amendment) Act 2015. If they agree for such waiver, in
writing after dispute having arisen between them, in the format given under
below clause of these conditions.
64. (1) (iii) (a) :
The Arbitration proceedings shall be assumed to have commenced from the
63
day, a written and valid demand for arbitration is received by the Railway.
64. (1) (iii) (b) :
The claimant shall submit his claim stating the facts supporting the claims
along with all the relevant documents and the relief or remedy sought against
each claim within a period of 30 days from the date of appointment of the
Arbitral Tribunal.
64. (1) (iii) (c) :
The Railway shall submit its defence statement and counter claim(s), if any,
within a period of 60 days of receipt of copy of claims from Tribunal
thereafter, unless otherwise extension has been granted by Tribunal.
64. (1) (iii) (d) :
Place of Arbitration : The place of arbitration would be within the
geographical limits of the Division of the Railway where the cause of action
arose or the Headquarters of the concerned Railway or any other place with the
written consent of both the parties.
61.(1) (iv) :
No new claim shall be added during proceedings by either party. However, a
party may amend or supplement the original claim or defence thereof during
the course of arbitration proceedings subject to acceptance by Tribunal having
due regard to the delay in making it.
64.(1) (v) :
If the contractor(s) does/do not prefer his/their specific and final claims in
writing, within a period of 90 days of receiving the intimation from the
Railways that the final bill is ready for payment, he/they will be deemed to
have waived his/their claim(s) and the Railway shall be discharged and
released of all liabilities under the contract in respect of these claims.
64.(2) :Obligation During Pendency Of Arbitration :
Work under the contract shall, unless otherwise directed by the Engineer,
continue during the arbitration proceedings, and no payment due or payable by
the Railway shall be withheld on account of such proceedings, provided,
however, it shall be open for Arbitral Tribunal to consider and decide whether
or not such work should continue during arbitration proceedings.
64. (3) :Appointment of Arbitrator :
64. (3) (a) : Appointment of Arbitrator where applicability of section 12(5) of
Arbitration and conciliation Act has been waived off:
64.(3) (a) (i) :
In cases where the total value of all claims in question added together does not
exceed Rs.1,00,00,000.00 (Rupees One Crore only), the Arbitral Tribunal shall
consist of a Sole Arbitrator who shall be a Gazetted Officer of Railway not
below JA Grade, nominated by the General Manager. The sole arbitrator shall
be appointed within 60 days from the day when a written and valid demand
for arbitration is received by GM.
64.(3) (a) (ii) :
64
In cases not covered by the Clause 64(3)(a)(i), the Arbitral Tribunal shall
consist of a Panel of three Gazetted Railway Officers not below JA Grade or 2
Railway Gazetted Officers not below JA Grade and a retired Railway Officer,
retired not below the rank of SAG Officer, as the arbitrators. For this purpose,
the Railway will send a panel of at least four (4) names of Gazetted Railway
Officers of one or more departments of the Railway which may also include
the name(s) of retired Railway Officer(s) empanelled to work as Railway
Arbitrator to the contractor within 60 days from the day when a written and
valid demand for arbitration is received by the GM.
Contractor will be asked to suggest to General Manager at least 2 names out of
the panel for appointment as contractor‟s nominee within 30 days from the
date of dispatch of the request by Railway. The General Manager shall appoint
at least one out of them as the contractor‟s nominee and will, also
simultaneously appoint the balance number of arbitrators either from the panel
or from outside the panel, duly indicating the „presiding arbitrator‟ from
amongst the 3 arbitrators so appointed. GM shall complete this exercise of
appointing the Arbitral Tribunal within 30 days from the receipt of the names
of contractor‟s nominees. While nominating the arbitrators, it will be necessary
to ensure that one of them is from the Accounts Department. An officer of
Selection Grade of the Accounts Department shall be considered of equal
status to the officers in SA grade of other departments of the Railway for the
purpose of appointment of arbitrator.
64 (3) (b) : Appointment of Arbitrator where applicability of section 12 (5) of A & C Act
has not been waived off:
The Arbitral Tribunal shall consists of Panel of three (3) retired Railway
Officer, retired not below the rank of SAG Officer, as the arbitrators. For this
purpose, the Railway will send a panel of at least four (4) names of retired
Railway Officer(s) emplanelled to work as Railway Arbitrator duly indicating
their retirement date to the contractor within 60 days from the day when a
written and valid demand for arbitration is received by the GM.
Contractor will be asked to suggest to General Manager at least 2 names out of
the panel for appointment as contractor‟s nominee within 30 days from the
date of dispatch of the request by Railway. The General Manager shall
appoint at least one out them as the contractor‟s nominee and will, also
simultaneously appoint the balance number of arbitrators either from the panel
or from outside the panel, duly indicating the presiding arbitrator from
amongst the 3 arbitrators so appointed GM shall complete this exercise of
appointing the Arbitral Tribunal within 30 days from the receipt of the names
of contractor‟s nominees. While nominating the arbitrators, it will be
necessary to ensure that one of them has served in the Account Department.
64.(3) (c) (i)
If one or more of the arbitrators appointed as above refuses to act as arbitrator,
withdraws from his office as arbitrator, or vacates his/their office/offices or
is/are unable or unwilling to perform his functions as arbitrator for any reason
whatsoever or dies or in the opinion of the General Manager fails to act
without undue delay, the General Manager shall appoint new
arbitrator/arbitrators to act in his/their place in the same manner in which the
earlier arbitrator/arbitrators had been appointed. Such re-constituted Tribunal
may, at its discretion, proceed with the reference from the stage at which it
65
was left by the previous arbitrator (s).
64.(3) (c) (ii) : (a) The Arbitral Tribunal shall have power to call for such evidence by way of
affidavits or otherwise as the Arbitral Tribunal shall think proper, and it shall
be the duty of the parties hereto to do or cause to be done all such things as
may be necessary to enable the Arbitral Tribunal to make the award without
any delay. The proceedings shall normally be conducted on the basis of
documents and written statements.
(b) Before proceeding into the merits of any dispute, the Arbitral Tribunal shall
first decide and pass its orders over any plea submitted / objections raised by
any party, if any, regarding appointment of Arbitral Tribunal, validity of
arbitration agreement jurisdiction and scope of the Tribunal to deal with the
dispute(s) submitted to arbitration applicability of time „limitation‟ to any
dispute, any violation of agreed procedure regarding conduct of the arbitral
proceedings or plea for interim measures of protection and record its orders in
day to day proceedings. A copy of the proceedings duly signed by all the
members of tribunal should be provided to both the parties.
64. (3) (c) (iii) (i) Qualification of Arbitrator (s)
(a) Serving Gazetted Railway Officers of note below JA Grade level.
(b) Retired Railway Officer not below SA Grade level, three years after his
date of retirement.
(c) Age of arbitrator at the time of appointment shall be below 70 years.
(ii) An arbitrator may be appointed notwithstanding the total number of
arbitration cases in which he has been appointed in the past.
(iii)While appointing arbitrator(s) under Sub-Clause 64. (3) (a) (i), 64 (3) (a)
(ii) &64 (3) (b) above, due care shall be taken that he/they is/are not the
one/those who had an opportunity to deal with the matters to which the
contract relates or who in the course of his/their duties as Railway servant(s)
expressed views on all or any of the matters under dispute or differences. The
proceedings of the Arbitral Tribunal or the award made by such Tribunal will,
however, not be invalid merely for the reason that one or more arbitrator had,
in the course of his service, opportunity to deal with the matters to which the
contract relates or who in the course of his/their duties expressed views on all
or any of the matters under dispute.
64.(3) (d) (i) : The arbitral award shall state item wise, the sum and reasons upon which it is
based. The analysis and reasons shall be detailed enough so that the award
could be inferred therefrom.
64.(3) (d) (ii) : A party may apply for corrections of any computational errors, any
typographical or clerical errors or any other error of similar nature occurring in
the award of a Tribunal and interpretation of a specific point of award to
Tribunal within 60 days of receipt of the award.
64. (3) (d) (iii) :
A party may apply to Tribunal within 60 days of receipt of award to make an
additional award as to claims presented in the arbitral proceedings but omitted
from the arbitral award.
66
64. (4) :
In case of the Tribunal, comprising of three Members, any ruling on award
shall be made by a majority of Members of Tribunal. In the absence of such a
majority, the views of the Presiding Arbitrator shall prevail.
64. (5) : Where the arbitral award is for the payment of money, no interest shall be
payable on whole or any part of the money for any period till the date on
which the award is made.
64. (6) : (a) The cost of arbitration shall be borne by the respective parties. The cost
shall inter-alia include fee of the arbitrator(s), as per the rates fixed by Railway
Board from time to time and the fee shall be borne equally by both the parties,
provided parties sign an agreement in the format given at Annexure II to these
condition after / while referring these disputes to Arbitration. Further, the fee
payable to the arbitrator(s) would be governed by the instructions issued on the
subject by Railway Board from time to time irrespective of the fact whether
the arbitrator(s) is / are appointed by the Railway Administration or by the
court of law unless specifically directed by Hon‟ble court otherwise on the
matter.
(b) (i) Sole Arbitrator shall be entitled for 25% extra fee over the fee
prescribed by Railway Board from time to time.
(ii) Arbitrator tribunal shall be entitled 50% extra fee if Award is decided
within six months.
64.7 :
Subject to the provisions of the aforesaid Arbitration and Conciliation Act
1996 and the rules thereunder and relevant para of General Conditions of
Contract (GCC) and any statutory modifications thereof shall apply to the
appointment of arbitrators and arbitration proceedings under this Clause.
58. SALES TAX/TUR OVER/LOCAL TAX OR ANY OTHER TAX, ETC. –
As shown at Sr.No.68 A
59. SPECIAL CONDITIONS FOR TENDER DOCUMENT SUBMITTED ONLINE
(a) These special conditions are applicable to tender document and considered as part of it,
which is submitted online.
(b) Tenderers may note that permitting of online submission of tender document is an added
facility for convenience of Tenderer/s. Railway, however, reserves right to extend this facility for
selected works or continue only with direct sale of tender forms. In case, tender document is
incomplete due to network failure or delay or incomplete document submission, whatsoever,
Railway shall not be responsible in anyway. Railway shall not be responsible for any
direct/indirect loss of business/profit resulting from inability to use this facility.
(c) The Tenderer/s shall download & print the Tender document solely for the purpose of
bidding for above work and downloaded document shall not be used, copied or reproduced for
any other purpose.
(d) The end of tender document is indicated by “End of Tender Document” marker.
Tenderer/s should carefully see that above marker appears on the last page of downloaded tender
document to ensure that downloaded document is complete. Tenderer is suggested to check the
integrity and completeness of document before submission.
(e) The tender document downloaded from website though does not bear signature of Rly
authority shall have same authority as having directly purchased from Rly office. Tenderers
while submitting his offer must upload certified and duly signed/ attested copies of all
supporting documents.
(f) The Tenderer/s are required to pay non-refundable cost of tender document in the form
67
prescribed in tender notice while uploading their offer. In case they fail to furnish the requisite
cost of tender document in prescribed form, their offer shall be rejected. The cost of EMD shall
not be merged with cost of tender form and shall be separately furnished.
(g) The Tenderer/s shall maintain the integrity of tender document and shall not make any
change/addition/deletion/tampering, whatsoever, in the submitted documents. The Tenderer/s
offer shall be rejected and full earnest money shall be forfeited, in case it is detected after
submission of offer, that they have made any modification in submitted documents. In case such
modification is noticed even after award of contract, Rly is liable to terminate the contract on
contractor‟s default. In addition Railway reserves the right to take action against the firm as
deemed fit, which may include Banning of Business Dealings with the firm and the firm is also
liable to be prosecuted as per the law. After award of work agreement will be prepared based on
the master copy of tender document available in the Railway‟s office. In case, any discrepancy is
noted in tender document submitted by Tenderer, the Master document kept with Rly shall
prevail and decision of Rly thereon shall be final and binding on Tenderer/Contractor.
(h) The Tenderer/s shall not be reimbursed with the cost of stationery, uploading, scanning,
etc. Offer of Tenderer/s is liable to be rejected by Railway, if tender document is not submitted
as per instructions contained in the tender document. Further Tenderer shall bear expenses of
Internet connection and telephone charges, if any for uploading and submission of tender
document. (i) The Tenderer/s shall keep themselves updated about any modification in tender notice
and tender document, issued by Railway through newspapers, website or E-mail or any other means and
shall act accordingly. It is the responsibility of the Tenderer to check any correction or any modifications
published subsequently in Web site and the same shall be taken into account while submitting the tender.
Tenderers‟ offer is liable to be rejected if they have not enclosed all the corrections/corrigendum along
with downloaded tender documents.
(j) The “Additional Conditions for Tender Document downloaded from Website” must be
completely read and understood by the Tenderer and Railway shall not be liable to for any incorrect
submission of tender document.
(k) The following declaration should be given by the Tenderer while submitting the tender:
Declaration I/We have uploaded the tender document on website https://www.ireps.gov.in and I/We have not
tampered/modified the tender forms in any manner. In case the document is found to be
tampered/modified, I/We understand that my/our tender is liable to be rejected and full earnest money
deposit will be forfeited and I/we am/are liable to be banned from doing business with Railways and/or
prosecuted.
Signature of Tenderer
60. SPECIAL CONDITION OF CONTRACT FOR DRAFTING THE VEHICLE AND
EQUIPMENT OF CONTRACTOR IN CASE OF ACCIDENT/NATURAL CALAMITIES
INVOLVING HUMAN LIVES.
i) Railway reserves the right to withdraw/draft/take over possession of any of the vehicles and
equipments of the contractor deployed by him at the work site in case of Railway
accident/natural calamities involving loss of human lives occur and deploy, utilize, engage
them for work of relief, restoration of Railway service etc. The said vehicles and equipments
along with Drivers/operators shall be immediately handed over to Railway Administration on
advice of Engineer or Engineer‟s Representative. The decision of the Railway as to type,
number of vehicle and period of engagement shall be final and binding on the contractor.
ii) The crew, fuel and maintenance of the vehicles during the above period shall be provided by
the Contractor to the satisfaction of Railways.
68
iii) The Contractor shall be paid hire charges for the drafted vehicles/equipment by operating
suitable Non-Schedule items at the rates decided mutually between the Engineer and the
Contractor. Operation of Non-Schedule item will be approved with the vetting of associate
finance by DY. CE(C) operating the contract. However, if the Contractor is not satisfied with
Engineer‟s decision, he may appeal to the CAO(C) within 30 days of getting the decision of
the Engineer supported by the analysis of the rates claimed. The CAO(C)‟s decision after
hearing both the parties in the matter would be final and binding on the contractor.
iv) In case Railway withdraws/drafts/takes possession of Contractor‟s vehicle/equipment, log
book will be maintained by Railway‟s representative and it will be jointly signed by
Railway‟s authorized representative & contractor‟s driver of vehicle/operator of equipment.
Payment will be made accordingly on agreed rates.
v) The contractor shall provide following information about the vehicle/equipment available
with them at the time of entering into contract. Sr.N
o
.
Particulars of
Vehicle/
equip
ment
No. of
Unit
Kind/ Make Capacity Age&
Co
ndi
tio
n
Present
Location
Remarks
61. Approval of Drawings
61.1 It should be specifically noted that some of the detailed drawings may not have been finalized by
the Railways and will, therefore, be supplied to the contractor as and when they are finalized. No
compensation whatsoever on this account shall be payable by the Railway administration.
61.2 No claim whatsoever shall be entertained by the Railway on account of any delay or hold up of
the work / works arising out of delay in approval of drawings, changes, modifications, alterations,
additions, omission and the site layout plans or details drawings and design and/or late supply of
such materials as are required to be arranged by the Railway or due to any other factor on
Railway account.
62. No claim for idle labours and/or idle machinery etc. on any account will be entertained. Similarly,
no claim shall be entertained for business loss or any such loss.
63. Safety measures at work site
In addition to various instructions/provisions made in the contract document following discipline will be
enforced during execution of the work at contractor‟s own cost.
i) The equipment can enter Rly premises only from nominated entry points.
ii) Even in case contractor engage separate supply agency, they have to take permission for the
drivers being engaged and ensure presence of assistant driver/competent lookout man who
will responsible for all action of movement of vehicle. He should be in proper uniform and
with hand signals, warning device etc.
iii) Night working should be done under direct supervision of Railway official.
iv) All protective signals, boards etc. shall be provided by the contractor at his cost, for which
no extra payment shall be made being incidental to the work.
64. PAYMENT OF ADVANCES TO CONTRACTORS: ( not applicable for this contract)
(Authority: Railway Board‟s letter Board‟s letter No.2007/CE-I/CT/18 Pt.2 Dtd.04.10.2012).
On request of the contractor, the Railway will pay the contractor the following advances for the
work, if the estimated value of the tender exceeds Rs. 25.00 Crores (Twenty Five Crores), subject
to conditions stated hereunder. The value of Contract for the purpose of this clause shall be
exclusive of the cost of material supplied to the Contractor free of cost or at fixed prices:
69
(a) Mobilization advance: (Refer Railway Board‟s letter Board‟s letter No.2007/CE-I/CT/18 Pt.2
Dtd.04.10.2012) :
This shall be limited to 10% of the contract value and shall be
payable in two stage as indicated below:
Stage –I 5% (Five Percent) of the contract value on signing of the contract agreement.
Stage –II 5% (Five Percent) of the contract value on mobilization of site establishment, setting up
offices, bringing in equipments and actual commencement of the work.
(b) Advance Against Machinery and Equipment :
This advance shall be limited to a maximum of 10% of the contract value against new Machinery
& Equipment, involving substantial outlay, brought to site and essentially required for the work.
This advance shall not exceed 75% of the purchase price of such Equipment and shall be payable
when hypotheticated to the President of India by a suitable bond or alternatively covered by an
irrevocable Bank Guarantee for full cost of the Plant & Equipment from a Nationalised Bank in
India or the State Bank of India in a form acceptable to Railways. The Plant & Equipment shall
be insured for the full value and for the entire period, they are required for the work. This plant &
Equipment shall not be removed from the site of work without prior written permission of the
Engineer. No advance should be given against old Plant & Machinery.
(c) Advance For Accelerating Progress Of The Work During Course of Execution of Contract:
This advance shall be decided on the merits of each case and shall be restricted to a maximum of
5% of contract value or Rs. 1 Crore , whichever is less. This will be granted by the General
Manager on the recommendations of Chief Engineer – in – charge, in consultation with the
Associate Finance.
(d) Advances in Exceptional Cases :
General Managers are further empowered to grant advances in exceptional cases upto a maximum
of Rs. 5 lakh in respect of, even contracts of value of less than Rs.50 lakh, if considered
absolutely essential, depending on the merits of each case and circumstances in each situation, to
be recommended by the Chief Engineer in charge and in consultation with the Associate Finance.
(e) The above advance are subject to the following conditions -
(i) The advance shall carry an interest of 4.5% per annum above the Base Rate of State Bank of
India, as effective on the date of approval of payment of the advance by the competent authority
and be restricted only for high value tenders of Rs.25 crore and above.
(ii) Advances except those against machinery and equiupment, shall be payable against
irrevocable guarantee (Bank Guarantee, FDRs, KVPs / NSCs) of at least 110% of the value of the
sanctioned advance amount (covering principal plus interest). The Bank Guarantee shall be from
a Nationalised Bank or State Bank of India in a form acceptable to the Railways;
(iii) The recovery shall commence when the value of contract executed reached 15% of original
contract value and shall be completed when the value of work executed reached 85% of the
original contract value. The instalments on each “on account bill” will be on pro-rata basis;
(iv) That the grant of advance is primarily on Railway‟s own interest;
(v) That a contract does not receive advances for same work from different officers;
(vi) That arrangements are made with the Accounts Officer for proper accounts being kept with
regard to payment and recovery of these advances; and
(vii) That all necessary precautions are taken to secure Government from the possibility of loss
and for preventing the system becoming more general or counting longer than what may be
absolutely necessary for proper progress of the work.
(f) Method of Recovery of Interest -
Interest shall be recovered on the advance outstanding for the period commencing from the date
of payment of advance till date of particular on –account bill (through which recovery of
principal is effected) and adjusted fully against on – account bill along with pro-rata principal
recovery. In the event of any short – fall, the same shall be carried forward to the next on –
70
account bill and shall attract interest @ 4.5% per annum above the Base Rate of State Bank of
India, as effective on the date of approval of payment of the advance by the competent authority.
The Bank Guarantee for such advances shall clearly at least 110% of the value of the sanctioned
advance amount (covering principal plus interest).
65. GUIDELINES FOR PARTICIPATION OF JOINT VENTURE FIRMS IN WORKS
TENDER(Authority Railway Board letter No. 2002/CE-I/CT/37 Dt.07.09.2011 & Railway Board
letter No. 2002/CE-I/CT/37 JV Pt III Dt.05/14.11.2013).
This clause shall be applicable for works tenders of value as approved and communicated by
Railway Board from time to time.
65.1 Separate identity/name shall be given to the Joint venture firm.
65.2 Number of members in a JV firm shall not be more than three, if the work involves only
one department (say Civil or S & T or Electrical or Mechanical) and shall not be more
than five if the work involves more than one department.
65.3 A member of JV firm shall not be permitted to participate either in individual capacity or
as a member of another JV firm in the same tender.
65.4 The tender form shall be purchased and submitted only in the name of the JV firm and
not in the name of any constituent member.
65.5 Please note that, payment of Earnest Money Deposit (EMD) as per tender
notice, in respect of e-tendering, should be accepted through net banking or
payment gateway only. The e-receipt of the transaction shall be uploaded
with the tender. 65.6 One of the members of the JV firm shall be the Lead Member who shall have a majority
(at least 51%) share of interest in the JV firm and also, must have satisfactorily completed
in the last three previous financial years and the current financial year upto the date of
opening of the tender, one similar single work for a minimum value of 35% of advertised
tender value. The other members shall have a share of not less than 20% each in case of
JV firms with upto three members and not less than 10% each in case of JV Firms with
more than three members. In case of JV Firm with foreign member(s), the Lead Member
has to be an Indian Firm with a minimum share of 51%.
65.7 A copy of Memorandum of Understanding (MOU) executed by the JV members shall be
submitted by the JV Firm along with the tender. The complete details of the members of
JV firm, their share and responsibility in the JV firm etc. particularly with reference to
financial, technical and other obligations shall be furnished in the MOU.
65.8 Once the tender is submitted, the MOU shall not be modified/altered/terminated during
the validity of the tender. In case the tenderer fails to observe/comply with this
stipulation, the full Earnest Money Deposit (EMD) shall be forfeited.
65.9 Approval for change of constitution of JV firm shall be kept at the sole discretion of the
Employer (Railways). The constitution of the JV firm shall not be allowed to be modified
after submission of the tender bid by the JV firm except when modification becomes
inevitable due to succession laws etc. and in any case the minimum eligibility criteria
should not get vitiated. However, the Lead Member shall continue to be the Lead
Member of the JV Firm. Failure to observe this requirement would render the offer
invalid.
65.10 Similarly, after the contract is awarded, the constitution of JV firm shall not be allowed to be
altered during the currency of contract except when modification become inevitable due to
succession laws etc. and in any case the minimum eligibility criteria should not get vitiated.
Failure to observe this stipulation shall be deemed to be breach of contract with all consequential
penal action as per contract conditions.
71
65.11 On award of contract to a JV firm, a single Performance Guarantee shall be required to be
submitted by the JV firm as per tender conditions. All the Guarantees like performance
Guarantee, Bank Guarantee for Mobilization advance, machinery Advance etc. shall be accepted
only in the name of the JV firm and no splitting of guarantees amongst the members of the JV
firm shall be permitted.
65.12 On issue of LOA (Letter of Acceptance), an agreement among the members of the JV firm (to
whom the work has been awarded) shall be executed and got registered before the registrar of the
Companies under Companies Act or before the Registrar / Sub-Registrar under the Registration
Act, 1908. This JV agreement shall be submitted by the JV firm to the Railways before signing
the contract agreement for the work. In case the tenderer fails to observe/comply with this
stipulation, the full Earnest Money Deposit (EMD) shall be forfeited and other penal action due
shall be taken against partners of the JV and the JV. This joint venture agreement shall have,
inter-alia, following clauses :-
i) Joint and several liability- Members of the JV firm to which the contract is awarded, shall be
jointly and severally liable to the Employer (Railways) for execution of the project in accordance
with General and Special conditions of contract. The JV members shall also be liable jointly and
severally for the loss, damages caused to the railways during the course of execution of the
contract or due to non- execution of the contract or part thereof.
ii) Duration of the Joint Venture Agreement- It shall be valid during the entire currency of the
contract including the period of extension, if any and the maintenance period after the work is
completed.
iii) Governing Laws – The Joint venture Agreement shall in all respect be governed by and
interpreted in accordance with Indian Laws.
65.13 Authorized Member - Joint Venture members shall authorize one of the members on behalf of the
Joint Venture firm to deal with the tender, sign the agreement or enter into contract in respect of
the said tender, to receive payment, to witness joint measurement of work done, to sign
measurement books and similar such action in respect of the said tender/contract. All
notices/correspondences with respect to the contract would be sent only to this authorised
member of the JV firm.
65.14 No member of the Joint Venture firm shall have the right to assign or transfer the interest right or
liability in the contract without the written consent of the other members and that of the
employer(Railways) in respect of said tender/contract.
65.15 Documents to be enclosed by the JV firm along with the tender :
65.15.1 In case one or more of the members of the JV firm is/are partnership firm(s), following
documents shall be submitted;
a) Notary certified copy of the Partnership Deed.
b) Consent of all the partners to enter into the Joint Venture Agreement on a stamp
paper of appropriate value(in original).
c) Power of Attorney(duly registered as per prevailing law) in favour of one of the
partners of the partnership firm to sign the JV Agreement on behalf of the
partnership firm and create liability against the firm.
72
65.15.2 In case one or more members is/are proprietary Firm or HUF, the following documents shall be
enclosed.
Affidavit on stamp paper of appropriate value declaring that his/her concern is a Proprietary
concern and he/she is sole proprietor of the concern OR he/she is in position of “Karta” of Hindu
Undivided Family (HUF) and he/she has the authority, power and consent given by other partners
to act on behalf of HUF.
65.15.3 In case one or more members is/are limited companies, the following documents shall be
submitted:
a) Notary certified copy of resolution of the Directors of the company, permitting the company to enter
into a JV agreement, authorizing MD or one of the directors or Managers of the company to sign JV
Agreement, such other documents required to be signed on behalf of the company and enter into liability
against the company and/or do any other act on behalf of the company.
b) Copy of Memorandum and articles of Association of the Company.
c)Power of Attorney (duly registered as per prevailing law) by the company authorising the person to
do/act mentioned in the para (a) above.
65.15.4 All the members of the JV shall certify that they are not black listed or debarred by Railways or
any other Ministry/Department/ PSU(Public Sector Undertaking) of the Govt. of India/State Govt. from
participation in tenders/contract on the date of opening of bids either in their individual capacity or as
member of the JV firm in which they were / are members.
65.16 Credential & Qualifying Criteria: Technical and financial eligibility of the JV Firm shall be
adjudged based on satisfactory fulfillment of the following criteria:
65.16.1 Technical Eligibility Criteria („a‟ or „b‟ mentioned hereunder) :
(a) Either the JV firm or Lead Member of the JV Firm must have satisfactorily completed in the last
three previous financial years and the current financial year upto the date of opening of the
tender, one similar single work for a minimum of 35% of advertised value of the tender.
OR
(b) (i) In case of composite works (e.g. works involving more than one distinct component, such as
Civil Engineering works, S & T works, Electrical works, OHE works etc and in the case of major bridges
– substructure, superstructure etc.), for each component, at least 35% of the value of any of such
components individually for single similar nature of work should have been satisfactorily completed by
the JV firm or by any member of the JV Firm in the previous three financial years and the current
financial year up to the date of opening of tender. The member satisfying technical eligibility criteria for
the largest component of the work shall be the Lead Member and that Member shall have a majority (at
least 51%) share of interest in the JV firm.
(ii) In such cases, what constitutes a component in a composite work shall be clearly pre-defined
with estimated tender cost of it, as part of the tender documents without any ambiguity. Any work or set
of works shall be considered to be a separate component, only when cost of the component is more than 2
Crore each.
(iv) However, as long as the JV firm or any member of the JV Firm meets with the requirements in
one or more components of the work, and has completed a minimum of 35% of the advertised value of
the tender for the same value of the component, and resultantly, all the members of the JV collectively,
then meet the prescribed technical eligibility criteria, the JV shall stand technically qualified.
NOTE: Value of completed work done by a Member in an earlier JV Firm shall be reckoned only to the
extent of the concerned member‟s share in that JV firm for the purpose of satisfying his/her
compliance to the above mentioned technical eligibility criteria in the tender under consideration.
65.16.2 Financial Eligibility Criteria: The contractual payments received by the JV Firm or the arithmetic
sum of contractual payments received by all the members of JV Firm in the previous three financial years
and the current financial year upto the date of opening of tender shall be at least 150% of the estimated
73
value of the work as mentioned in the tender.
NOTE: Contractual payment received by a Member in an earlier JV Firm shall be reckoned only to the
extent of the concerned member‟s share in that JV Firm for the purpose of satisfying compliance of the
above mentioned financial eligibility criteria in tender under consideration.
66. Provisions of “The Building and Other Construction Workers (Regulation of Employment and
Conditions of Service) Act, 1996” and “The Building and other Construction Worker‟s Welfare Cess
Act, 1996”. (Authority : Railway Board‟s letter no. 2008/CE-I/CT/6, Dated 29.11.2013)
The tenderers, for carrying out any construction work, must get themselves registered with the
Registering Officer under Section-7 of the Building and Other Construction Workers Act, 1996 and rules
made thereto by the concerned State Govt. and submit certificate of Registration,issued from the
Registering Officer of the concerned State Govt. (Labour Dept.). As per this Act, the tenderer shall be
levied a cess @1% of cost of construction work, which would be deducted from each bill. Cost of
material, when supplied under a separate schedule item, shall be outside the purview of cess.
67. INCOME TAX
Under Section 194(C) of the Income Tax Act 1961 deduction of 2% plus surcharge if applicable
on Income Tax will be made for sums paid for carrying out the work under this contract. The
percentage of deduction may however vary as per the amendments if any made in the section
194(C) of IT Act 1961.
68. GST/TURNOVER/LOCAL TAX OR ANY OTHER TAX, ETC. :- The element of
GST/commercial tax including Turn Over Tax on works contract, Octroi, Royalty, Toll Tax, Local
Tax, Duties/Levies as well as Services and any other Tax levied by Central Govt., State Govt. or
Local Bodies, if any, shall be considered to be included in the rates quoted by the tenderer/s in the
tender schedule. GST /commercial tax/turnover tax on works contract will be recovered from the
contractor‟s bill at the rate as applicable as per rules framed by Central Govt., State Govt. or Local
Bodies from time to time and remitted to the Central Govt., State Govt. or Local Bodies by the
Railways.
68A. WORKS CONTRACT TAX (WCT)
WCT shall be deducted @ 2% of the Contract Value. WCT registration is required to be done by
the Contractor with the Sales Tax Authority of the respective State and is to be produced within 2
(two) months of awarding of contract, failing which the first „ On Account Bill‟ shall not be
passed.
In exceptional circumstances, when an account bill can not be withheld in the interest of targeted
work and the contractor is not able to produce the WCT Registration even after a lapse of 2 (two)
Months period, an amount equivalent to 4% of the overall Contract Value shall be deducted from
his „On Account Bill‟ The amount of 4% will be to cover 2% towards WCT and another 2% as
additional security.
i) Please refer to GST Clause which replaced WCT (Works Contract Tax)
69. SALES TAX/TUR OVER/LOCAL TAX OR ANY OTHER TAX, ETC. Replaced by GST
Latest circulars as applicable
The element of Sales Tax / commercial tax including Turn Over Tax on works contract, Octroi,
Royalty, Toll Tax, Local Tax, Duties/Levies as well as Services and any other Tax levied by
Central Govt., State Govt. or Local Bodies, if any, shall be considered to be included in the rates
quoted by the tenderer/s in the tender schedule. Sales tax /commercial tax/turnover tax on works
contract will be recovered from the contractor‟s bill at the rate as applicable as per rules framed
by Central Govt., State Govt. or Local Bodies from time to time and remitted to the Central
Govt., State Govt. or Local Bodies by the Railways.
70. ASSOCIATING A SUB – CONTRACTOR FOR THE WORKS:
74
Contractor may associate sub – contractor/s of repute for doing specialized works with the
explicit approval of the Chief Engineer, Central Railway, Mumbai. This has to be spelt out at the
time of tendering. If further changes are required at later date, this has got to be approved by the
Chief Engineer, Central Railway, Mumbai. Such consent if given shall not however relieve the
contractor from any liability or obligation under the contract and he shall be responsible for the
acts, defaults & neglects of the sub-contractor, his agents, servants or workmen as fully as if they
the acts, defaults or neglects of the contractor, his agents, servants or workmen, provided always
that provision of labour on a piece – work basis shall not be deemed to be a sub – contract under
this clause. All payment by Central Railway, Mumbai shall be made only to the principal
contractor. The tenderer/s must specify and furnish (if not already complied with) the names of
consultants and / or agencies proposed to be associated during construction, at the time of
tendering itself and no change either in the designated consultants / associates agencies for
construction, shall be permitted, in the event of work being allotted to him/ them, without the
prior approval of Central Railway.
71. MODIFIED CLAUSE 52 of G.C.C.
(Circulated as per Railway Board‟s letter No.2010/CE-1/CT/41/ New Delhi Dtd 27.04.2011).
Clause No.52 Withholding and lien in respect of sums claimed:-
Whenever any claim or claims for payment of a sum of money arises out of or under the contract
against the contractor, the Railway shall be entitled to withhold and also have a lien to retain such
sum or sums in whole or in part from the security, if any, deposited by the contractor and for the
purpose aforesaid, the Railway shall be entitled to withhold the said cash security deposits or the
security if any, furnished as the case may be and also have a lien over the same pending
finalization or adjudication of any such claim. In the event of the security being insufficient to
cover the claimed amount or amounts or if no security has been taken from the contractor, the
Railway shall be entitled to withhold and have a lien to the extent of the such claimed amount or
amounts referred to supra, from any sum or sums found payable or which at any time thereafter
may become payable to the contractor under the same contract or any other contract with this or
any other Railway or any Department of the Contract Government pending finalization or
adjudication of any such claim.
It is an agreed term of the contract that the sum of money or moneys so withheld or retained
under the lien referred to above, by the Railway will be kept withheld or retained as such by the
Railways till the claim arising out or under the contract is determined by the arbitrator (if the
contract governed by the arbitration clause) or by the competent court as the case may be and that
the contractor will have no claim for interest or damages whatsoever on any account in respect of
such withholding or retention under the lien referred to supra and duly notified as such to the
contractor. For the purpose of this clause, where the contractor is a partnership firm or a limited
company, the Railway shall be entitled to withhold and also have a lien to retain towards such
claimed amount or amounts in whole or in part from any sum found payable to any partner /
limited company, as the case may be whether in his individual capacity or otherwise.
Clause No. 52-A Lien A respect of claims in Other Contracts:
i) Any sum of money due and payable to the contractor (including the security deposit
returnable to him) under the contract may be withheld or retained by way of lien by the Railway,
against any claim of this or any other Railway or any other Department of the Central
Government in respect of payment of a sum of money arising out of or under any other contract
made by the contractor with this or any other Department of the Central Government.
ii) However, recovery of claims of railway in regard to terminated contracts may be made
from the final bills, security deposits and performance guarantees of other contract or contract
executed by the contractor. The performance guarantee submitted by the contractor against other
75
contracts if required, may be withheld and encashed. In addition, 10% of each subsequent „On –
account bill‟ may be withheld, if required, for recovery of railway‟s dues against the terminated
contract.
iii) It is an agreed term of the contract that the sum of money so withheld or retained under this clause by the
Railway will be kept withheld or retained as such by the Railway till the claim arising out of or under any
other contract is either mutually settled or determined by arbitration, if the other contract is governed by
arbitration clause or by the competent court as the case may be and contractor shall have no claim for
interest or damages whatsoever on this account or on any other ground in respect of any sum of money
withheld or retained under this clause and duly notified as such to the contractor.
72. ALTERNATIVE DUE TO REJECTED WORK:
In The event of any sub – structure of super structure are abandoned on account of rejection by the
Railway, the extra cost involved in providing further alternative arrangements shall be borne by the
Contractor. The rates offered shall be deemed to have provided for this contingency.
73. Provision of Employees Provident Fund and Miscellaneous Provision Act, 1952: The contractor shall comply with the provisions of Para 30 & 36-B of the Employees Provident Fund
Scheme, 1952; para 3 & 4 of Employees Pension Scheme, 1955; and para 7 & 8 of Employees Deposit
Linked Insurance Scheme, 1976; as modified from time to time through enactment of “Employees
Provident Fund & Miscellaneous Provisions Act, 1952”, wherever applicable and shall also indemnify
the Railway from the against any claims under the aforesaid Act and the Rules (Authority : Railway
Board‟s letter No.2012/CE-I/CT/0/22 Dtd.14.12.2012).
74. Reporting of Accidents: The Contractor shall be responsible for the safety of all employees directly or through petty contractors or
sub-contractor employed by him on the works and shall report serious accidents to any of them and
however and wherever occurring on the works to the Engineer or the Engineers Representative and shall
make every arrangements to render all possible assistance.
75. Provision of Workmen‟s Compensation Act: In every case in which by virtue of the provisions of Section 12 Sub-Section (1) of the Workmen‟s
Compensation Act 1923, Railway is obliged to pay compensation to a workman directly or through petty
contractor or subcontractor employed by the Contractor in executing the work, Railway will recover from
the Contractor the amount of the compensation so paid, and, without prejudice to the rights of Railway
under Section 12 Sub-section (2) of the said act, Railway shall be at liberty to recover such amount or
any part thereof by deducting it from the Security Deposit or from any sum due by Railway to the
Contractor whether under these conditions or otherwise, Railway shall not be bound to contest any claim
made against it under Section 12 Sub-Section (1) of the said Act except on the written request of the
Contractor and upon his giving to Railway full security for all costs for which Railway might become
liable in consequence of contesting such claim.
76. IMPLEMENTATION OF [RECS] 1996 & BUILDING & OTHER CONSTRUCTION
WORKERS WELFARE CESS ACT 1996 IN RLY.CONTRACTS :- As given at Sr.No.66 (Railway
Board‟s Letter No.2008/CE-I/CT/6 dt.09.07.2008).
77. GST (GOODS AND SERVICES TAX 2017) with effective from 01/07/2017
77.1 Migration to GST regime: (Authority Rly. Board Letter No. 2008/RS(G)/777/1 dt.
29.05.2017
“For the tenders due to open before role out of GST- All the bidders /tenderers while quoting
the rates should clearly indicate the rate of applicable duties and taxes included in the prices
quoted by them. Any variation in tax structure/ rate due to introduction of GST, shall be dealt
76
with under Statutory Variation Clouse.
For the tenders opening after role out of GST- All the bidders / tenders should ensure that they are
GST compliant and their quoted tax structure/ rates are as per GST Law.”
77.2 Implementation of GST Act, 2017- Procedure for payment of Contractual bill. ( Rly. Bds
Lr.No.2016.CE-I.CT.12.GST.Pt.I Dt.29.6.2017
On Indian Railways presently „work executed by contractor‟ is recorded in measurement books
by railway, duly accepted by contractor. Railway prepares „on account / final contract certificate‟ for the
payable amount based on the work executed and the rates quoted by the contractor duly deducting various
statutory taxes like - work contract tax/ service tax/royalties/income tax etc. as per applicable rates.
Further, railways deposit the statutory deductions themselves to the concerned authorities.
2. With GST act in force, it will be the responsibility of service providers (i.e. contractors) to
submlt the invoice (bill) duly segregating the GST component from the Gross amount of work executed.
3. Railways are therefore advised to follow the procedure as mentioned below while dealing with
contractor‟s payment, once GST is applicable:
(A) (i) All works contracts are to be provided with goods/service code based on the
type of contract. In case contract consists of both goods & service, then interpretation regarding
nature of contract shall be done as per clause 8, Chapter III of CGST Act, 2017. The goods/service
code is notified by Ministry of Finance and can be downloaded from the website www.cbec.gov.in.
(ii) The „on account / final contract certificate‟ shall be prepared by the Railway on the basis of
quantity of work executed and agreemental rates, duly segregating the GST component
as detailed in para (iii) below.
(iii) Since the agreemental rates of contracts are inclusive of all taxes as per clause 37 of GCC-
2014, the calculation of „Gross amount of work executed‟, „Amount of work executed
excluding GST amount‟ and „GST amount‟ in the „on account / final contract certificate‟ shall
be done as under:
Let Z = Gross amount of work executed on the basis of quantum of work
executed and agreemental rates.
X = Amount of world executed excluding GST amount.
Y = GST amount as per applicable GST rate for that goods/service code.
R = Percentage rate of GST for that goods/service code
Then, Z = X+Y, Y = X*R/100
(iv) Percentage rate of GST for various types of goods/services as finalised by GST council can
be downloaded from the website www.cbec.gov.in.
(B) (i) Once the „on account / final contract certificate‟ is prepared by railway and
communicated to contractor, the contractor shall submit invoice (bill) on his Letter head duly
segregating the „Amount of work executed excluding GST amount‟ and „GST amount‟ (i.e. “X” &
“Y” as mentioned in para 3(A)(iii) above) along with Invoice No. (bill No.) and all other details
required under GST act. The sample GST compliant invoice is annexed herewith.
(ii) In case contractor is liable to be registered under GST Act, Railway shall pay
to the Contractor „Gross amount of work executed‟ (i.e. “Z” as mentioned in para
3A(iii) above) duly deducting all other leviable taxes like I/Tax, labour cess, royalty etc. as applicable.
Contractor shall be liable to pay „GST amount‟ to respective authority himself. Whereas,
railway shall deposit all other taxes deducted to concerned authority as is being done presently.
(iii) In case contractor is not liable to be reglstered under GST Act, contractor shall be paid
“Amount of work executed excluding GST amount” (i.e. “X” as mentioned in para 3A(iii)
above) duly deducting all other leviable taxes like I/Tax, labour cess, royalty etc. as applicable.
Railway shall deposit „GST amount‟ as well as all other taxes deducted to concerned authority.
(iv) In case any need arises to modify the Invoice (Bill) due to any reason, contractor shall
submit amended fresh invoice for processing the payment.
77
Note : All rates quoted in the tender shall be deemed to be inclusive of GST(Goods Service Tax) payable
by the contracto/s to the Govt. Or public body or local authority as on the date of opening of
tender and no additional amount will be paid or claim entertained on this account by the Railway.
II) However in case of any subsequent increase in the rates of GST, the increased amount will be
reimbursed to the contractor only on production of documentary proof of payment of GST at such
increased rates along with State /Central Govt. „s order .
iii) Similarly in case of decrease in the rate of GST charges or its waival , payment of GST will be
regulated by such reduced rate and recovery shall be affected from the Contractor accordingly .
iv ) Reimbursement , if required , shall be worked out separately by the contractor and submitted
alongwith claims for on account payments .
v)Recovery if required shall be worked out separately by the contract ans submitted alongwith claims for
on account payments .
vi) Recovery if required shall be worked out separately by Railways and the amount so worked out shall
be deducted from Contractor‟S BILLS for on account payments .
vii) The amount of reimbursement or recovery , as the case may be as per revised rate of GST shall be
applicable only for the quantity of work executed by the contractor after the Govt. Resolution for
revision of rate of GST has come into effect.
viii) The reimbursement /recoveries as per the revised rate of GST shall be effective only for the original
completion period of the work . However, the amount as per revised rate of GST is payable
/recoverable during the extended period of the contract , and the extension has been granted on
administrative grounds ie., under Clause 17 a(i)(ii) or
(iii) of GCC .Where extensions of time has been granted due to contractor‟s failure under Clause 17(b) of
the GCC , the reimbursement due to change in rate of GST .
77.3 Subsequent to the enactment of GST Act, Rly Board has approved modification to para (a) of
clause 6, Part – I of Indian Railway Standard General Condition of Contract, July 2017. The revised para
(A) of clause 6 shall be read as under
(Authority Rly. Board letter No. 2017/CE-I-CT4/GST dt. 23.06.2017) & Letter No. 2008/RS(G)/
777/1 dt. 06/07/2017)
(i) Before submitting a tender, the tenderer will be deemed to have satisfied himself by actual
inspection of the site and locality of the works, that all conditions liable to be encountered during
the execution of the works are taken into account and that the rates he enters in the tender forms
are adequate and all inclusive to accord with the provisions in Clause=37 of the Standard General
Conditions of Contract for the completion of works to the entire satisfaction of the Engineer.
(ii) Tenderer will examine the various provisions of The Central Goods and Services Tax Act,
2017(IGST)/ Integrated Goods and Services Tax Act, 2017(IGST)/ Union Territory Goods and
Services Tax Act, 2017(UTGST)/ respective state‟s State Goods and Services Tax Act(SGST)
also, as Notified by Central/State Government as amended from time to time and applicable
Taxes before bidding. Tenderers will ensure that full benefit of Input Tax Credit (ITC) likely to
be availed by them is duly considered while quoting rates.
(iii) The successful Tenderer who is liable to be registered under CGST/ IGST/ UTGST/ SGST Act
shall submit GSTIN along with other details required under CGST/ IGST/ UTGST/ SGST Act to
railway immediately after the award of contract, without which no payment shall be released to
the contractor.
The contractor shall be responsible for deposition of applicable GST to the concerned authority.
(iv) In case the successful tenderer is not liable to be registered under CGST/ IGST/
UTGST/ SGST Act, the railway shall deduct the applicable GST from his/ their bills under
reverse charge mechanism (RCM) and deposit the same to the concerned authority. 77.4. As per Latest Railway Board Guidelines vendors required to submit GST Nos. in the desired
format .( Rly.bd‟s Lr.No.2016..CE-I.CT.12.GST.Pt.I Dt.29.6.2017 )
78
Annexure -XI
SAFETY RULES[Para 25(ii)]
1. Suitable scaffolds should be provided for workmen for all works that cannot safely be done from
the ground or from solid construction except such short period work as can be done safely from
ladders. When a ladder is used an extra labour shall be engaged for holding the ladder and if the
ladder is used for carrying materials as will, suitable foot-holds and hand holds shall be provided on
the ladder and the ladder shall be given an inclination not steeper than one horizontal to four
vertical (1:4).
2. Scaffolding or staging more than 3.5 meters above the ground or floor swung or suspended from an
overhead support or erected with stationary support shall have a guard rail properly attached bolted,
braced and otherwise secured above the floor or platform of such scaffolding or staging and
extending along the entire length thereof with only such opening as may be necessary for the
delivery of materials. Such scaffolding or staging shall be so fastened as to prevent it from swaying
from the building or structure.
3. Working platform gangways and stairways should be so constructed that they should not sag
unduly or unequally, and where the height of the platform or the gangway or the stairway is more
than 3.5 meters above ground level or floor level, they should be closely boarded, should have
adequate width and should be suitably fastened as described in the Para above.
4. Safe means of access shall be provided to all working platforms and other working places. Every
ladder shall be securely fixed. No portable single ladder shall be over 10 meters in length while the
width between side rails in swung ladder shall in no case be less than 300 mm for ladder up to and
including 3.5 meters in length. For longer ladders this width should be increased by at least 20 mm
for each additional meter of length. Uniform steps spacing shall not exceed 300 mm. Adequate
precautions shall be taken to prevent danger from electrical equipment. No materials on any of the
sides of work shall be so stacked or placed as to cause danger for inconvenience to any persons or
the public.
The contractor shall provide all necessary fencing and lights to protect the public from accident,
and shall be bound to bear the expenses of defense of every suit, action or other proceedings at law
that may be brought by any persons for injury sustained owing to neglect of the above precautions
and to pay any damages and cost which may be awarded in any such suit, action or proceedings to
any such persons or which may with the consent of the contractor be paid to compromise any claim
by any such person.
5. Before any demolition work is commenced and also during the process of the work :-
(a) All roads and open areas adjacent to the work site shall either be closed or suitably protected.
(b) No electric cable or apparatus which is liable to be a source of danger over a cable or apparatus
used by the operator shall remain electrically charged.
(c) All practical steps shall be taken to prevent danger to persons employed from risk of fire or
explosion of flooding. No floor, roof or other part of the building shall be so overloaded with
debris or materials as to render it unsafe.
6. All necessary personal safety equipment as considered adequate by the Engineer-in-charge should
be kept available for the use of the persons employed on the site and maintained in a condition
suitable for immediate use and the contractor should take adequate steps to ensure proper use of
equipment by these concerned.
(a) Workers employed on mixing asphalt materials, cement and live mortar shall be provided with
protective goggles.
(b) Those engaged in white washing and mixing or attaching of cement bags or any material
which is injurious to the eyes shall be provided with protective goggles.
(c) Those engaged in welding works shall be provided with welder's protective eyesight lids.
(d) Stone breakers shall be provided with protective goggle and protective clothing and seated at
sufficiently safe intervals.
79
7. In case the contractors have to ply vehicles for the purpose connected with the contract adjacent to
Railway track, the Railway Administration will be at liberty to post an experienced staff as flag
man for guidance of the movements of such vehicles so as to prevent accidents and the contractor
will bear wages including all etc. of the staff posted as flag man for the period of Contract for such
periods during which such staff is posted for the purposes. The Rly. Administration will be sole
judge in the absolute discretion, of the fact that it is necessary to post any staff, that which of the
staff will be suitable for the purpose, that what should be the wages & other allowance payable by
the contractor for staff posted for the purpose. The Rly. Administration will have a right without
prejudice to other remedies to deduct the wages etc. of such staff from the bills of the contractor in
respect of this contract of from any moneys or the contractor, whatsoever, available with the
Railway Administration. The contractor will be liable for any over payments under Workman
Compensation Act on account of any injury sustained to Railway servant during that period.
8. When the work is done near any place where there is risk of drowning, all necessary equipment
should be provided and kept ready for use and all necessary steps taken for prompt rescue of any
persons in danger and adequate provision should be made for prompt first aid treatment of all
injuries likely to be sustained during the course of the work.
9. Use of hoisting machines and tackle including their attachment anchorage and supports shall
conform the following standards or conditions :-
(a) i. These shall be of good mechanical construction, sound materials and adequate strength and
free from patent defect and shall be kept in good repair and in good working order.
ii. Every rope used in hoisting or lowering down the materials or as a means of suspension shall
be of durable quality and adequate strength and free from patent defects.
(b) Every Crane Driver or hoisting appliances operator shall be properly qualified and no person
under the age of 21 yrs shall be in-charge of any hoisting machine including any scaffolding.
(c) In case of every hoisting machine and of every cabin ring, shackle, swivel and pulley block
used in hoisting or as means of suspension, safe working load shall be ascertained by
adequate means. Every hoisting machine and all gear referred to above shall be plainly
marked within the safe working load.
In case of a hoisting machine having a variable safe working load, each safe working load of
the conditions under which it is applicable shall be clearly indicated. No part of any
machinery or any gear referred to above in this paragraph shall be loaded beyond the safe
working load except for the purpose of testing.
(d) In case of departmental machine, the safe working load shall be notified by the Electrical
Engineer-in-charge. As regards contractor's machines, the contractor shall notify safe
working load of the machine to the Engineer-in-charge whenever he brings any machinery to
site of work and get it verified by the Electrical Engineer concerned.
10. Motors, gearing transmission, electric wiring and the dangerous part of hoisting appliances should
be provided with efficient safe guards. Hoisting appliances should be provided with such means as
will reduce to the minimum, the risk of accidental descent of the load. Adequate precautions should
be taken to reduce to the minimum, the risk of any part of a suspended load becoming accidentally
displaced. When workers are employed on electrical installations, which are already energized
insulating mats, wearing apparel, such as gloves, sleeves & both as may be necessary should be
provided. The workers should not wear any rings, watches and carry keys or other materials, which
are good conductors of electricity.
11. All scaffolds, ladders and other safety devices mentioned or described herein shall be maintained in
safe condition and no scaffold ladder or equipment shall be altered or removed while it is in use.
Adequate washing facilities should be provided at or near places of work.
12. These safety provisions should be brought to the notice of all concerned & displayed on a notice
board at a prominent place at the work spot. The persons responsible for compliance of the safety
code shall be named herein by the contractor.
80
13. To ensure effective endorsement of the rules and regulations relating to safety precautions, the
arrangements made by the contractor shall be open to inspection by Labour Officer/Engineer-in-
charge of the Department or their representative.
14. Notwithstanding the above clause from (1) to (13) there is nothing in these to exempt or relieve the
contractor from the operation of any other act or Rule in force in the Republic of India.
*****
81
GIST of safety instruction of Central Railway
1. The instructions/guidelines regarding safety at work site issued from time to time can be seen in
the Office of Dy.Chief Engineer(C)Pune at any time during office hours. The successful tenderer
shall obtain copy of hand book and copies of instructions/guidelines on safety at construction
worksite issued by Central Railway Construction Organisation free of cost from his office on award
of contract and religiously follow all safety instructions prescribed therein to see that the work is
executed in a safe manner.
The list of important instructions issued in the last five years on safety measures at work site are
given as under, copies of which shall be collected by the successful bidder from the office of the
Dy.CE(C)/Pune for ensuring strict compliance in execution of work.
Sr.No Date Letter No. Subject
1 28/07/02 EW/187/R/465/9/
Vol.II
Compendium on training to supervisors and
operators of contractors
2 06/11/02 EW/187/R/465/9/
Vol.II
Compendium of instruction on safety issued
by Northern Railway
3 09/02/04 &
08/06/04
EW/187/R/465/
Compendium Cir
Handbook on safety at construction work sites
4 01/09/04 EW/187/R/WKS-
Policy/V
Correction slip No.69 dt.23.05.2001 for Para
No.286 of IRPWM regarding safe working.
5 17/08/06 CON/CAO(C)/Misc/
Genl./2006
Safety measures to be adopted at work sites
6 15/12/06 EW/187/R/465/
Safety Policy
Safety in dismantling of bridges and structures
7 17/12/04 Rly Bd‟s DO ltr.No.
2004/Sig/G/7 JPO
No.1/Sig/2004
Undertaking digging work in the vicinity of
underground signaling, electrical and
telecommunication cables.
8 18/01/08 CE Circular No.190 vide
letter no.T103/ PWT-
18/XXI dt.18-01-08
Procedural order for ensuring safety at work
site issued by PCE, Central Railway
The GIST of important instructions on the above subject is given as under :-
I. The contractor shall not start any work without the permission of railway supervisor at site.
II. Wherever the road vehicles and/or machinery are required to work in the close vicinity of
railway line, the work shall be so carried out that there is no infringement to the Railway‟s
schedule of dimensions. For this purpose, the area where road vehicles and/or machinery are
required to ply, shall be demarcated and acknowledged by the contractor. Special care shall
be taken for turning / reversal of road vehicles/machinery without infringing the running
track. Barricading shall be provided wherever justified & feasible as per site condition.
(a) The road vehicle shall be run or machinery shall be worked so as not to come closer
than 6.0m from centre line of nearest running track.
(b) The land strip adjacent to running tracks, where road vehicle is to ply or machinery is
to work, shall be demarcated by lime in advance in consultation with the Railway‟s
supervisor. Wooden pegs at interval not exceeding 75m, shall be provided along the
line marking as permanent marks. The road vehicles shall ply or machinery shall work
so as not to infringe the line of demarcation.
(c) i. In no case the road vehicle shall run or machinery shall work at distance less
than 3.5m from central line of track.
ii. Demarcation of land shall be done by bright colored ribbon/nylon chord
suspended on 75cm. high wooden/bamboo posts at distance of 3.5m from center
line of nearest running track.
82
iii. Railway Supervisor shall issue suitable caution order to driver of approaching
train about road vehicles plying or machineries working close to running tracks.
The train driver shall be advised to whistle freely to warn about the approaching
train. Whistle boards shall be provided wherever considered necessary.
iv. Look out men shall be posted along the track at a distance of 800m from such
locations who will carry red flag and whistle to warn the road vehicle/ machinery
user about the approaching train.
v. On curves where visibility is poor, addition look out men shall be posted.
(d) Under unavoidable condition, if road vehicles is to ply or machinery is to work closure
to 3.5m due to site conditions or requirement of work, following precautions shall be
observed.
* Plying of vehicle or working of machinery closure to 3.5m of running track shall be
done only under protection of track. Traffic block shall be imposed wherever consider
necessary.
* Railway supervisor shall issue suitable caution order to driver of approaching train
about road vehicles plying or machineries working close to running track. The train
driver shall be advised to whistle freely to warn about the approaching train.
(e) The location where vehicle will take a turn shall be demarcated duly approved by
railway representative. The road vehicle driver shall always face the Railways track
during the course of turning/reversing his vehicle. Presence of an authorized Railways
representative shall be ensured at such location.
III. The road vehicles will ply only between sun rise and sun set.
IV. Road vehicle shall not be allow to run along the track during night hours generally. In
unavoidable situation, however, vehicle shall be allowed to work during night hours only in
the presence of an authorized railway‟s representative & where adequate lighting
arrangement are made & where adequate precaution as mentioned earlier have been ensured.
V. Nominated vehicle and drivers will be utilised for work in the presence of at least one
flagman and one supervisor certified for such work.
VI. Contractor shall fully responsible for ensuring safety and in case of any accident, shall bear
cost of all damages to this equipment & men & also damages to railway & its passengers.
VII. Assistant Officer / Sr. Scale Officer shall issue competency certificate after checking
license & their working to all driver of nominated vehicles/machinery. Inspector at site shall
ensure that the driver who does not possess competency certificate will not work at site.
VIII. Vulnerable locations where construction work adjacent to running line can cause accident
should be protected by suitable strong barrier which should be included as a paid item in
contract schedule. This location should be decided by Executive Engineer in-charge of the
work at the beginning of construction and intimated to contractor in writing. The barrier
should be painted with retro reflective paint at suitable interval to give warning at night.
2. Electrical cables and singling cables are running along the railway line. Care shall be taken to
protect such cables during execution and vehicle movements. Contractor shall take all required
precautions as prescribed in Joint Procedural order for undertaking digging work in the vicinity of
underground signaling, electrical and telecommunications cable as communicated vide Rly Board‟s
DO letter No.2004/Sig/G/7 JPO No.1/Sig/2004 dt.17.12.2004. Tenderers can see copy of this joint
procedural order in the Office of Dy.Chief Engineer (C) Pune. Successful tenderers hall obtain the
copy of this order before commencement of work for their guidelines and ensuring strict
compliance.
A Penalty to be imposed for damages to cable shall be as under ( As per Rly.Bds Lr.No.2003.Teld.RCIL.1.
Pt.IX Dt.24.6.2013 :
Cable Damaged Penaty per location
Only quad cable or signaling cable Rs.1 lakh
Only OFC Rs.1.25 lakh
83
Both OFC & Quad Rs.1.5 lakh
Electrical cable Rs.1.0 lakh
Deduction will be imposed on contractor in case of damage to Electrical / S&T cables due to
default on the part of the contractor which will be in addition to recovery for cost of
restoration of cables. The decision of Engg-In-Charge on fixing up of responsibility on
contractor on this account will be final conclusive and legally binding on the contractor.
84
Annexure- XII
IDENTITY CARD OF RAILWAY CONTRACTOR‟S LABOUR
(Space for Photo)
I) Sr.No.
II) Name of Establishment :-
III) Name of Contractor :-
IV) Name of Contract Worker with address :-
V) Signature of Card Holder :-
VI) Signature of Contractor on the Photograph with his seal :-
(Countersigned by concerned Validity date of Identity Card
Sr.Supervisor of Railway)
*****
85
Annexure- XIII
PERFORMANCE GUARANTEE BOND
(to be submitted by Contractors as per new clause added in the GCC by Railway Board vide Lr.No.2003.CE-
I.CT.4.Pt.1 Dt.12/15.6.2006)
In consideration of the President of India (hereinafter called “The Government”) having agreed to exempt________
(here in after called “the said contractor(s) from the demand, under the terms and conditions of Tender No.
opened on ……………..awarded to M/s vide Acceptance Lr.No………… dt…….
hereinafter called the said contract of Performance guarantee for the due fulfillment by the said contractor/s of the
terms and conditions contain in the said agreement, on production of irrevocable Bank Guarantee amounting to 5%
of Contract value ie., for Rs……. (Rs……only)
1. We……………………(indicate the name of the Bank) hereinafter referred to as the Bank, at
the request of ……………. contractor(s) do here by undertake to pay to the Government an amount not exceeding
Rs………. (Rs……..only) against any loss or damage caused to or suffered or would be caused to or suffered by the
Government by reason of any breach by the said contractor of any of the terms or conditions contained in the said
Contract.
(We undertake to keep this Performance Guarantee in force till the satisfactory completion of the work and
maintenance period is over )
2. We…………… (indicate the name of the bank) do hereby undertake (and promise) to pay the
amounts due and payable under this guarantee without any demur merely on a demand from the Government stating
that the amount / claim is due by way of loss or damage caused to or would be caused or suffered by the
Government by reasons of breach by the said contractor(s) of any of the terms or conditions contained in the said
agreement or by reason of the contractor(s) failure to perform the said agreement loss. Any such demand made on
the Bank shall be conclusive as regards the amount due and payable by the Bank under this guarantee. However, our
liability under this guarantee shall be restricted to an amount not exceeding Rs……….. (Rs…………. Only).
3. (a) We ………… ( indicate the name of Bank ) undertake to pay to the Government any
money so demanded notwithstanding any dispute or disputes raised by the contractor(s)/supplier(s) in any suite or
proceeding pending before any court or Tribunal relating thereto our liability under this present being absolute
and unequivocal.
(b) The payment so made by us under this bond shall be a valid discharge of our liability for payment there
under & the contractor(s)/supplier(s) shall have no claim against us for making such payment.
4. We,…………….. (indicate the name of bank) further agree that the guarantee herein contained shall
remain in full force and effect during the period that would be taken for the performance of the said Contract and
that it shall continue to be enforceable till all the dues of the Government under or by virtue of the said agreement
have been fully paid and its claims satisfied or discharged or till ……….. Office/ Department Ministry of________
certify that the terms and conditions of the said agreement have been fully and properly carried out by the said
contractor(s) and accordingly discharges this guarantee. Unless a demand or claim under this guarantee is made on
us in writing on or before the _____________ we shall be discharged from all liability under this guarantee
thereafter.
5. We, ………….. ( indicate the name of Bank ) further agree with the Government that the Government shall have
the fullest liberty without our consent and without effecting in any manner our obligations hereunder to vary any of
the terms and conditions of the said agreement or to extend time of performance by the said contractor from time to
time or to postpone for any time or from time to time any to the powers exercisable by the Government against the
said contractor (s) and to forbear or enforce any of the terms and conditions relating to said Contract and we shall
not be relieved from our liability by reason of any such variation, or extension being granted to the said
contractor(s) or for any forbearance act or omission on the part of the Government or any indulgence by the
Government to the said contractor(s) or by any such matter or thing whatsoever which under the law relating to
sureties would, but for this provision have affect of so relieving us.
6. This guarantee will not be discharged due to the change in the constitution of the Bank or the
Contractor(s)/Suppliers(s) .
7. We, ………….. (indicate the name of the Bank) lastly undertake not to revoke this guarantee during its
currency except with the previous consent of the Government in writing.
Dated: the day of for
(indicate the name of bank)
Signature of Bank Authorised official
86
(Name) Designation
Full Address
Witness
1………………………………….
2………………………………..
Annexure – XII
Agreement towards Waiver under Section 12 (5) and Section 31 – A (5) of Arbitration and
Conciliation (Amendment) Act. --
I / We ………………….. (Name of agency / contractor) with reference to agreement No.
………………… raise disputes as to the construction and operation of this contract, or the
respective rights and liabilities, withholding of certificate and demand arbitration in respect of
following claims:
Brief of claim :
(i) Claim 1- Detailed at Annexure -
(ii) Claim 2 –
(iii) Claim 3 -
I / We ……………… (Post of Engineer) with reference to agreement No. ………….. hereby
raise disputes as to the construction and operation of this contract, or the respective rights and
liabilities, withholding of certificate and demand arbitration in respect of following claims:
I / We ………… do / do not agree to waive off applicability of section 12(5) of Arbitration and
Conciliation (Amendment), Act.
Signature of Claimant ……………………. Signature of Respondent …………………
(Agreement under Section 31(5)
I / We ………….. (Name of claimant) with reference to agreement No. …………. Hereby waive
off the applicability of sub section 31 – A (2) to 31 – A (4) of the Arbitration and Conciliation
(Amendment) Act. We further agree that the cost of arbitration will be shared by the parties as
per clause 64(6) of GCC.
Signature of Claimant ……………………. Signature of Respondent …………………
*Strike out whichever not applicable.
******
87
Annexure-XIV
SUPPLEMENTARY AGREEMENT
Articles of agreement made this day _______ in the year Two thousand and Five between the President of
India, acting through the ___________________ CENTRAL Railway Administration having his office at
__________________ herein after called the Railway of the one part and
_____________________________________ of the second part.
Whereas the party hereto of the other part executed an agreement with the party hereto of the first part
being agreement No._____________dt.__________for the performance __________________________
herein after called the „Principal Agreement‟.
And whereas it was agreed by and between the parties hereto that the works would be completed by the
party hereto of the second part on ______________date last extended‟ and whereas the party hereto of the
second part has executed the work to the entire satisfaction of the party hereto of the first part. And
whereas the party hereto of the first part already made payment of the party hereto of the second part
diverse sums from time to time aggregating to Rs._______________ including the final bill bearing
voucher No.______________ dated ___________( the receipt of which is hereby acknowledged by the
party hereto of the second part in full and final settlement of all his /its claims under the principal
agreement.
And whereas the party hereto of the second part have received further sum of Rs._____________ through
the final bill bearing voucher No.____________ dated ______________(the receipt of which is hereby
acknowledged by the party thereto of the second part) from the party hereto the first part in full and final
settlement of all his/its disputed claims under principal agreement.
Now, it is hereby agreed by and between the parties in the consideration of sums already paid (by the
party hereto of the first part to the party hereto of the second part against all outstanding dues and claims
for, all works done under the aforesaid principal agreement including/excluding the security deposit the
party hereto of the second part have no further dues of claims against the party hereto the first part under
the said Principal Agreement. It is further agreed by and between the parties that the party hereto of the
second part has accepted the said sums mentioned above in full and final satisfaction of all its dues and
claims under the said Principal Agreement.
It is further agreed and understood by and between the parties that in consideration of the payment
already made, under the agreement, the said Principal Agreement shall stand finally discharged and
rescinded all the terms and conditions including the arbitration clause.
It is further agreed and understood by and between the parties that the arbitration clause contained in the
said principal agreement shall cease to have any effect and/or shall be deemed to be non-existent for all
purposes.
Dy.Chief Engineer/Const./Pune
Central Railway
Signature of the contractor/s for and on behalf of the President of India
Witness
1 _______________________
2. _______________________
ADDRESS: _______________________
89
Scope of work
Name of work :- Laying and linking of track, Ballast Supply,AT welding of &
Flashbutt Welding etc. and other Miscellaneous work in Sec.II ( Kms.65.00 to Kms.145.00 ) in connection with Pune -Miraj Doubling
project. *****
Scope of Work for Proposed PUNE to MIRAJ Doubling work
PWAY PORTION
1. Transportation of various P.Way material from places as directed by Railway to
work site
2. Laying of sleepers and Linking of Track .
3. Carrying , transportation and hauling of P.Way material for track linking .
4. Alteration and modification in existing yards including slewing of existing lines.
5. Supply of Ballast and Leading out the same for Preparation of Ballast Bed for
Linking of track.
6. Various works incidental to commissioning of line fixing various boards
caution indicator boards, hectometer post, gradient posts, curve boards, station
marking of curves and turnouts and fixing of boundary stones .
7. Various works like weed cleaning, rail gauge face greasing, SEJ oiling &
greasing, weld painting and various markings on rail and posts .
8. Provisions of joggle fish plates at various location, surface of level crossing
gates, standardization of level crossings gate layout, check rail, guard rail
provision of lifting barrier.
9. Other miscellaneous works for commissioning of lines . Contractor will take necessary safety precautions during the work for Protection of track and passengers as the work is near the running track and on existing Platform. Necessary safety barricading has to be ensured at work site. Competent Supervisor and Staff has to be deputed at work site exclusively for ensuring safety during the work. Note : 1. The scope is tentative and contractor will not be entitled for any compensation on account of reduction or increase or change in scope of the work 2) The completion Period for Ballast Supply will be 24 months. 3) Even within these 24 months, the contractor will be required to supply
proportionate quantity on pro-data basis every month. In case of contractors failure in this respect, Railway will be at liberty to take the ballast from any other source/contractor. Loss if any to Railway on this account will be recovered from the contractor apart from reduction in quantity in this
90
contract. Railway will also be at liberty to part terminating the contract on
this account. 4) While making monthly Pro-data supply, the priority of location will be
decided by railways and no claim whatsoever will be entertained by the Railways on this account.
5) Ballast will be Paid for only in Two stages:
Supply and
Spreading/ Insertion. No payment will be made for leading out ballast. Therefore it is incumbent
upon contractors to supply the ballast as close to the point of its insertion, as practicable. Necessary liaisoning with local Land owners etc for stacking of ballast, if required, in their land will be contractors responsibility as well as risk and the same should be factorial into before quoting their rates.
6) Supply of P.way materials, not included in this contract will be made by railway. However if due to some unforeseen circumstances if the same is not being possible, the same may be get procured through this contract at a mutually agreed rate, which will be based on the last accepted rates of such within the railway or its PSU’s as may be relevant and no claim will be entertained by railways on this account.
7) Ancillary & Incidental Works :-Any other ancillary and related works incidental to main work including all the temporary arrangements etc required for execution & successful completion of the work as decided by the Engineer – in – Charge.
8) The work is spread out over the entire section and the contractor will have to carry out work at several sites simultaneously, as per the priority and decision of Raiwlays.
9) Site(s) will be handed over to the contractor in phases as per the priority of the railways and no claims will be admissible on this ground.
10) For each and every site, a sub target date of completion may be advised to the contractor, commensurate with the work load, which will be proportionate with the overall completion period for the complete scope. No claim will be admissible on this ground. In case of a contractor not being able to meet these sub target dates of completion, necessary action will be taken as per GCC, including part or full termination of the contract.
11) The scope of Work includes Flash Butt welding of rails either by Mobile Flash Butt Welding plant or by Stationary Flash Butt welding Plant. Decision of Railway regarding this will be binding upon the contractor. Railway will provide the space for stationary Flash Butt Welding Plant and will supply Rails to plant for their welding, Loading of welded rail panels into the EUR/BFR will be the responsibility of contractor no additional payment will be made for this. Also no additional payment will be made for installing stationery Flash Butt welding Plant. However, payment for shifting of stationery FB welding plant from one location to other will be paid in relevant item.
91
SPECIAL CONDITIONS
Name of Work:- Laying and linking of track, Ballast Supply,AT welding of & Flashbutt
Welding etc. and other Miscellaneous work in Sec.I ( Kms.65.00 to Kms.145.00 ) in
connection with Pune -Miraj Doubling project.
1. Two Skilled Labourers for Pway activities (Preferable Retired/ Experienced Pway
Staff) and 4 semiskilled Labourers shall be arranged by the contractors immediately
as soon as acceptance letter is received by the contractor and shall continue to
remain till completion of work for assisting the Railway Supervisors / Site Engineers
for carrying out necessary day to day works like layout marking, assisting in
measurement, handling of various survey instruments, records, register etc. They
shall be under exclusive & total control of Railway Supervisors and no additional
payment for this will be made. Failure to comply this, will invite necessary recovery
at appropriate rates to be worked out by Railways. The decision on rates of recovery
as worked out & approved by Engineer in charge will be final and binding on the
contractor.
2. Contractor shall arrange to provide 2 nos of 4 wheeler service vehicle such as
Tavera, Scorpio, Innova or equivalent similar vehicle from commencement of work
till completion continuously for Railways Supervisors, Engineers, Staff with all
consumables, fuel, driver, maintenance along with all required equipments and tools
& plants like level, staff, theodolite etc. connected with the proposed work, for their
day to day movement to site of work. No separate payment for this facility shall be
made. Decision of the Engineer-in-charge in this regard, shall be final and conclusive
and binding on the contractor. The Intending tenderers should take in to account
/consider all the probable expenditure on this account while quoting the overall rate
in the tender.
3. Site Office for Engineer and other Supervisory staff :- The contractor shall arrange to
provide at least two fully furnished office accommodation each of 20 sq.m. area with
toilet facility with water connection and required furniture items like beds tables,
chairs, cupboards, lockers etc. Work includes providing electric supply & all electrical
items like lights, fans and complete wiring, telephone etc. complete. The Contractor
shall provide these office accommodations within 1 month from the date of the
commencement of work or 1 month from the date of providing the land till
completion of CRS INSPECTION at reasonably near the work sites. No payment will
be made for this.
4. Accommodation for Engineer and other Supervisory staff :- The contractor shall
arrange to provide at least two fully furnished rooms accommodation each of 50
sq.m. area with attached toilet with water connection and required furniture items
like Beds, Cushion, cupboards, lockers etc. The Contractor shall provide these room
accommodations within 1 month from the date of the commencement of work till the
completion of CRS INSPECTION. No payment will be made for this.
5. Contractor should bring within one month of issue of acceptance letter, Two
latest HP Desktop/Laptop computer or similar with Intel HD Graphics HD Camera
, Antivirus (18 months) with one A-4 size laser jet printer, one A-3 size inkjet
Printers , 1 table and 4 chairs during the progress of work for exclusive use of
Railway supervisor for monitoring day to day progress & quantity calculation /
Bills etc.. No extra payment will be made to contractor on this account,
contractor’s should take in to a/c this aspect while quoting rate in Tender. The
above computer shall be provided with licensed Software’s of Antivirus, MS
Office, of latest version available in market. Contractors shall also be responsible
92
for ensuring the working conditions of PC and Printer & shall arrange required
repairs (AMC) and spares including
consumables like cartridges for printers & stationery including CDs and Pen-
drives etc. till completion of work including extended completion period, if any.
6. Contractor shall depute additional one skilled computer litrate person having good
knowledge of Autocad and One skilled surveyor having good working knowledge of
layout marking in field and survey instruments like Theodolite, Auto level, Total
Station Equipments etc.. They shall be under exclusive and total control of Railway
Supervisors / Site Engineers and no payment for this will be made.
7. Contractor must deploy at least one retired PWI as approved by Railway Engineer.
Competency of such PWI & Supervisor shall be decided by the Railway and decision
of the Railway Engineer will be final conclusive and binding on Contractor/s.
Contractor has to replace such PWI supervisor if ordered by the Railway Site
Engineer. The Contractor shall engage adequate number of supervisors with
experience and well conversant with track laying work. They will be recruited after
specific approval of the Railway engineer about the working safety rules.
8. Contractor will depute technically qualified person to represent him at site of work
who will authorized to sign the acknowledgement of instructions and orders given
during the course of wok and inspections. The Instructions acknowledged by the
authorized representative, will be binding on the contractor and no separate
instructions will be given to the contractors and In absence of such supervisor no
work will be allowed to progress.
9. Wherever lead or lift is not mentioned or specified it should be clearly understood
that it means “ALL LEAD & LIFTS” for which no extra payment will be made.
10. Contractor will have to apply graphite grease on the central leg and eye of MCI insert
and then clip should be driven while linking & laying of track or in turnouts & no
extra payment shall be paid on this account.
11. Contractor has to make the ballast profile good before commissioning and inspection
of line to the satisfaction of Railway’s Engineer as per directive. No extra payment
will be made to the contractor for this.
12. Contractor has to do one round of ERC greasing and rail gauge face greasing in
curves , before commissioning of line and inspection by CRS, with contractor’s
material, labour, tools & plant. No extra payment will be made to the contractor for
this.
13. The contractor shall be bound to store his own material/materials issued by the
Railways including P. way materials for the work at the place earmarked for this
purpose by the Engineer-in-charge, away from the running racks without infringing
track parameters, with proper locking arrangement and watch, so that the materials
are neither misused by miscreants nor cause any physical harm to Public/employees.
The contractor shall at his own expense provide suitable temporary shed/sheds for
this purpose and shall remove the shed/sheds when it is no longer required.
Safeguarding of the materials is the responsibility of the contractor even if the
materials are deemed to be owned by the Railway.
93
14 Codes, Manuals & By laws: - The contractor shall arrange 1 set of hard copies of all
relevant IS codes, manuals, by-laws to Railways at his own cost for reference and
use by Railways either in hard copy.
15. The contractor will have to arrange for sufficient plant, machineries, and labour at all
times during the execution of work and ensure strictly that there is no delay on this
account. Any decision by Railway’s representative as to minimum number of
Labours, equipments, materials plants & machinery in this regard shall be final and
binding on the contractors.
16. The contractor shall arrange communication facility for himself, railway
representatives and at site office at their own cost, during the entire execution
period. 4 nos of mobile Phone with sim card will be provided to railway
representatives exclusively along with timely recharge for this during the execution
of work & no extra payment shall be made for this.
17. It should be specifically noted that some of the detailed drawings may not have been
finalized by the Railway and will, therefore, be supplied to the contractors on specific
requisition or demand from contractors as and when they are finalized. No
compensation, whatsoever, on this account shall be payable by the Railway.
18. No claim for idle labour and or idle machinery etc. on any account whatsoever will be
entertained. Similarly, no claim shall also be entertained for business loss or any
such loss even if preferred or raised by the contractors.
19. It is primary responsibility of the contractor to obtain all necessary permissions,
permits / pervanas etc. from all concern authorities. However Railway may provide
all necessary help for obtaining the permission. Contractor is not entitled for any
compensations such as idling of machinery, staff etc. on account of any delay in work
for getting these permissions.
20. Contractor has to provide all necessary signal boards etc. for road traffic diversion if
required; being incidental to work & no extra payment for the same will be made.
Contractor has to take all necessary precaution for the safety of the road traffic.
21. While doing the work, if any obstruction is met with, such as water pipeline,
sewerage, gas pipeline, electrical cable, telephone cable or any other structure which
is to be cleared, it will be removed by the contractor/s for which necessary payment
shall be made under appropriate items of schedule or additional item may be
processed as per laid down procedure.
22. It shall be noted that while carrying out the work, other agencies Contractor/s will
also be working in the area and contractor will have to execute the work in total co-
ordination with other agencies Contractor/s etc.. The contractors should ensure that
no obstruction is caused to the working of other contractor in the vicinity and
nuisance to the residents of the adjacent area.
23. At the close of daily work special care is to be taken to clear sites from loose
materials, rail pieces etc. which can be misused for sabotage.
24. The contractor shall submit a programme for completion of the work in form of Bar /
Pert chart Chart before the commencement of work as per the target and schedule
given by railway within completion period.
94
25. During the execution of work, the contractor will have to co – ordinate with other
contractors / railway supervisors working in the section of civil as well as other
department’s i.e. Electrical, S&T, and Telecom etc.
26. The Contractor has to bring one total station instrument at site for fixing centre line
of track and alignment of curves which will be available at site of work as and when
required. Also he has to bring one auto level for leveling work at site. Nothing extra
will be paid on this account.
27. The centre line and level will be given for alignment of track by the railway with
contractor’s total station and auto level instruments brought at site by contractor and
which shall be maintained and adhered by contractor while laying of track till
completion.
28. The scope of work include all activities related to P.way work till commissioning of
line like Transportaion of Pway materials, Ballast supply, Ballast running out, Linking
of Track including turn outs derailing switch, switch expansion joints, sandhumps,
dead ends, welding of rails etc. Hence contractor has to plan each activity in such a
manner that it does not hamper the progress of other activities. Critical activities
should be identified and taken up. Various works incidental to commissioning of line
like various caution indicator boards, hectometer post, gradient posts, curve boards,
station marking of curves, turnouts, weed cleaning, rail gauge face greasing, SEJ
oiling & greasing, weld painting and marking, Provisions of joggle fish plates at
various location, surface of level crossing gates, standardization of level crossings
gate layout, check rail & guard rail provision, lifting barrier and sliding boom
provision, height gauge marking etc. have to be carried out by contractor. Contractor
should prepare a PERT activity chart and bar chart taking all the activities into
account as per the opening target section wise abd submit for approval. Work shall
be progressed as per approved/ agreed bar chart.
29. Contractor shall provide required persons for protection of track while executing the
work near the / existing track as mentioned in the IRPWM and necessary training to
the concern person will be given training from the Divisional training school Pune for
which contractor have to bear the full cost of training as notified time to time for this
railway will not pay any extra payment. All safety precautions for running of trains in
section are to be followed. Contractor will provide look out ment with flag/ H>S
lamps during block periods and during normal working period also.
30. Contractor is responsible for fixing of caution order board, engineering boards etc. as
& when required for carrying out the work with proper safety of track.
31. Only Competent person should only be deputed at site. Competency certificate will
be issued by Railway officer AXEN/ XEN for the following staffs:-
a.) Black smith / fitter
b.) Drilling Team
c.) Cutting Team
d.) Protection man
e.) Site Supervisor.
f.) Surveyors.
32. Contractor will issue Identity cards for all the staff countersigned by Railway
supervisor. Person without identity card will not be allowed on work site.
95
33. Railway will provide required Traffic & Power block if required for linking newly laid
track with the existing running line for Non interlocking Block (Pre NI and NI Block).
Contractor shall arrange the following resources at least 48 hours prior to Pre-NI
working and up to 7 days of post NI -
a) Minimum 100 labours with experienced supervisors & with requisite tools i.e 50
Nos Straight Bar, 30 Nos Mortar pan, 30 nos Wire Claws, 15 Nos Double ended
Spanner, 10 nos Hammer, 6 Nos track lifting jack (15 MT capacity), 20 nos Rail
tongue etc. as advised by Site Engineer.
b) 3 nos Rail cutting machine with separate staff & operator for its use (Saw Type)
and 2 Nos Abrasive rail cutting machine with separate staff & operator for its use
with operator fuel, spare blades ( Partner or Similar)
c) 3 nos Drilling machine for drilling holes in rail in block with separate staff &
operator for its use with operator fuel, spare drill bits of various sizes as directed
by the Site engineer.
d.) 3 nos Black Smith + 3 men for each Team with separate staff & operator for its
use.
34. During the work contractor, should stack materials like ballast, sleepers, rails etc on
cess or at null point to prevent damage of prepared formation as directed by
engineer incharge.
35. No Extra payment shall be made for making approaches and access up to worksites
wherever is required as per site conditions.
36. If 20 Rail Panels are supplied in place of 10 rail panel then will be made on prorata
basis as for 10 rail panels, no additional claim shall be entertained on this Account.
37. Contractor has to supply ballast at nearest possible spot so that it can be put on
track. No additional payment for leading out shall be made except provided in the
tender schedule. No claim of contractor shall be entertained on this account. If
required, contractor shall procure land for this on his own cost or he should make his
own arrangement to shift the ballast from available land on his own cost.
38. Contractor must visit the site before quoting rates for the work. He should get
acquainted with approaches, existing the site conditions, vicinity of hutment,
availability of labours and other obligatory structures etc. & quote the rate
accordingly.
39. The site order book/ Register, activity Register & progress report register will be
maintained at site. They will be got signed by the representatives of railways and
contractor daily.
40. The Contractor shall have to keep ready necessary “FIRST AID” facilities etc available
all along, while working in day or night for labour working.
41. The contractor must ensure the safety of labours engaged by him while crossing the
track during the course of execution of work. The railway will not be responsible for
any injury sustained by labour. Any claim for compensation what so ever arising out
of such accident shall be paid by the contractor including any fatal accident, thereto.
42. Scope of work involves fixing of boundary stones contractor will have to fix boundary
stones as and when required or shall fix the missing boundary stones payment for
the same will be done by adding appropriate item in the schedule.
43. Each Fish plated joint with fish bolts and nuts will be lubricated with Black oil or
reclaimed oil. No extra payment shall be allowed for the same.
96
44. The scope of work includes insitu glued joint, thermit and flash butt welds for which
contractor shall depute RDSO approved vendors and shall use only RDSO/RITES
inspected materials as prescribed time to time by railway.
45. Contractor shall maintain the track till CRS inspection and 3 months thereafter or
handing over to open line whichever is earlier . Any deficiencies on maintenance
account must be attended by contractor on his own by deputing his labour,
machinery, tools and plants etc.
46. Contractor shall keep the Section clean from shrub, grass, small bushes etc. till the
CRS Inspection. No other payment, except as mentioned in NS Item in tender
schedule shall be made on this account.
47. The contractor will be held responsible for any loss or damage or injury caused
during work to the labour or the RAILWAY/ PUBLIC PRIVATE persons due to
negligence. The contractor shall bear all the consequence, losses and expenditures
etc thus involved on that account.
48. Contractor shall maintain proper sanitation and cleanliness at work site . Portable
toilets with watering facility should be provided for labour as directed.
98
No.2004/Sig/G/7 J.P.O No.1 /Sig/2004
JOINT PROCEDURE ORDER FOR UNDERTAKING DIGGING WORK IN THE VICINITY OF
UNDERGROUND SIGNALLING, ELECTRICAL AND TELECOMMUNICATION CABLES.
A. A number of Engineering works in connection with gauge conversion/doubling/third line are in
progress on various railways, which require extensive digging work near the running track, in close
vicinity of other working S&T cables carrying vital safety circuits as well as electrical cables feeding
the power supply to Cabins, ASM room, RRI Cabin, Intermediate Block Huts (IBH) etc. Similarly,
S&T organization under open line or construction units under CAO/C are executing various signaling
and telecommunication works requiring digging of earth for laying of cables or casting of foundations
for the erection of signal posts etc. Rail Tel are also executing the work of laying of quad cable and
OFC on various Railways as a part of sanctioned works for exclusive use of Railways for carrying
voice and data i.e. administrative and control communication, PRS, FOIS etc. or shared by Rail Tel
Corporation of India Ltd. On certain sections digging is also required for laying of electrical cable and
casting of foundation for the erection of OHE masts by Electrical Deptt. Generally, these works are
executed by Contractors employed by these organizations.
B. However, while carrying out these works in the vicinity of working signaling, telecommunication and
electrical cables, at times, cable cuts take place due to JCB machines working along the track or
during the digging work being done by Contractors carrying out the Civil Engineering works.
Similarly, such cable cuts are also resulting due to works undertaken by S&T or Electrical depts.
Such cable faults results in the failure of vital signaling and telecommunication circuits.
C. Henceforth, the following joint procedure shall be followed by Engineering, Electrical and S&T (and
Rail Tel organization, wherever such works are being done by them) Officers of the respective
divisions and by the Construction Organization, while carrying out any digging work near to existing
signaling & telecommunication and electrical cables, so that the instances of cable cut due to
execution of works can be controlled and minimized.
1. S&T Department (and Rail Tel, where they have laid the cables) & Electrical Deptts. shall
provide a detailed cable route plan showing exact location of cable at an interval of 20m or
wherever there is change in alignment so that the same is located easily by the Engineering
official/contractor. This cable route plans shall be made available to the DSTE/DEN or
Dy,CE/C as the case may be by Sr.DSTE/DSTE or Sr.DEE/DEE of the divisions or Dy.CSTE/C
or Dy.CEE/C within a reasonable time in duplicate. DSE/DEN or Dy.CE/C will send copies to
their field unit i.e. AEN /SE/P.Way & works.
2. Before taking up any digging activity on a particular work by any agency, Sr.DSTE/ DSTE or
Sr.DEE/DEE of the section shall be approached in writing by the concerned Engg or S&T or
Electrical officer for permitting to undertake the work. After ensuring that the concerned
executing agencies, including the contractor have fully understood the S&T and Electrical cable
route plan shall permit the work in writing.
3. After getting the permission from S&T or Electrical Deptt. as the case may be, the relevant
portion of the cable route plan shall be attached to the letter through which permission is issued
to the contractor by concerned Engineering Official for commencement of work & ensuring
that the contractors have fully understood the cable route plan and precautions to be taken to
prevent damage to the underground cables. The contractor shall be asked to study the cable plan
and follow it meticulously to ensure that the safety of the cable is not endangered. Such a
provision, including any penalty for default, should form part of agreement also. It is advisable
that a suitable post of SE (Sig) or SE (Tele) or SE (Elect.) shall be created chargeable to the
estimates of doubling / Gauge conversion, who can help Engg. agencies in the execution of the
work. However, basic responsibility will be of the Department executing the work and the
Contractor.
99
4. The SE(P.Way) or SE (Works) shall pass on the information to the concerned SE(Sig) or
SE(Tele) or SE(Elect.) about the works being taken up by the contractors in their sections at
least 3 days in advance of the day of the work. In addition Engineering control shall also be
informed by SE(P.Way) or SE(Works), which in turn shall pass on the information to the Test
Room / Network Operation centre of Rail Tel/TPC/Electrical Control.
5. On receiving the above information, SE(Sig) or SE(Tele) or SE(Elect) shall visit the site on or
before the date of taking up the work and issue permission to the contractor to commence the
work after checking that adequate precautions have been take to avoid the damage to the
cables. The permissions shall be granted within 3 days of submission of such requests.
6. The name of the contractor, his contact telephones number, the nature of the work shall be
notified in the Engineering Control as soon as the concerned Engg. official issued the letter
authorizing commencement of work to the contractor. Test Room be given a copy & Test Room
shall collect any further details from the Engineering control and shall pass it on to S&T/Rail
Tel & Elect officials regularly.
7. In case of works being taken up by the State Government, National Highway Authority etc. the
details of the permission given i.e. the nature of work, kilometer etc. be given to the Engineering
Control including the contract person‟s number so that the work can be done in a panned
manner. The permission letter shall indicate the contact numbers of Test Room/Network
Operations centre of Rail Tel/TPC/Elect. Control.
8. Where the nature of the work taken up bythe Engineering department is such that the OFC or
other S&T cables or Electrical cables is to be shifted and relocated, notice of minimum one
week shall be given so that the Division/Rail Tel/Construction can plan the works properly for
shifting. Such shifting works shall, in addition, for security and integrity of the cables, be
supervised by S&T supervisors/Rail Tel supervisors/Electrical Supervisors.
9. The concerned SE(P.Way) SE(Works),/SE(Sig)/SE(Tele)/SE(Elect.) or Rail Tel supervisors,
supervising the work of the contractor shall ensure that the existing emergency sockets are not
damaged in view of their importance in providing communication during accident/emergency.
10. In case of minor nature of works where shifting of cable is not required, in order to prevent
damage to the cable, the Engineering contractor shall take out the S&T or optical fire cable or
Electrical cable carefully from the trench and place it properly alongside at a safe location
before starting the earthwork under the supervision of SE(Sig.) or SE(Tele) or SE(Electrical).
The cable shall be reburied soon after completion of excavation with proper care including
placement of the brick over the cable by the concerned S&T supervisors or Electrical
Supervisors. However, the work will be charged to the concerned engineering works.
11. In all the sections where major project are to be taken up/going on Rail Tel/S&T Dept. shall
deploy their official to take preventive/corrective action at site of work.
12. No new OFC/Quad cable shall be laid close to existing track. It shall be laid close to Railway
boundary as per extant instructions i.e. 1.0m from the Railway boundary to the extent possible
to avoid any interference with future works (doubling etc.) It shall be ensured in the new works
of cable laying that the cable route is properly identified with electronic or Concrete markers.
Henceforth, wherever cable laying is planed and before undertaking the laying work, the cable
route plan of the same shall be got approved from the concerned Sr.DEN or Dy CE/Constn. to
avoid possible damages in future. Such approvals shall be granted within 7 days of submission
of the requests.
13. The works of excavating the trench and laying of the cable should proceed in quick succession,
leaving a minimum time between the two activities.
14. Any damage caused to OFC/Quad cable or Electrical cable during execution of the work,
necessary debit shall be raised on Engineering Department who shall bear the cost of the
corrective action.
15. All types of bonds i.e. rail bond, cross bond and structure bond shall be restored by the
Contractor with a view to keep the rail voltage low to ensure safety of personnel.
100
16. Above joint circular shall be applicable for construction as well as open line organization of
Engineering, S&T & Electrical.
17. The S&T cable and Electrical cable route plan should be got approved be got approved from the
concerned. Sr. DSTE/DSTE & Sr. DEE/DEE respectively, before undertaking the work and
completion cable route plan should be finalized Block section by Block section as soon as the
work is completed.
C] SPECIAL CONDITIONS OF CONTRACT - PART II :-
(TECHNICAL SPECIFICATIONS FOR TRACK WORKS)
(A) General 1 Railway Specifications for Materials & works shall be adopted. Some additional specifications are
added herewith. Notwithstanding any provisions made in the C.R specifications, the provisions made
in the technical specifications shall be binding. All provisions in Railways manuals such as
Permanent way (IRPWM), LWR, Bridge etc are binding on the contractor & all the provisions in
these manuals shall be strictly followed.
2 These special conditions supplement the conditions of the tender and the contract and conditions
incorporated in specifications for materials and works of the Central Railway corrected up to latest
correction slip. When provision of these special conditions are at variance with the General
Conditions of Contract and other documents mentioned above, then these special conditions will
prevail.
3 Contractor must visit the site before quoting rates for the work. He should get acquainted with the
approaches, existing site conditions, vicinity of track, vicinity of hutment, availability of labours &
other obligatory structures etc. & quote the rate accordingly.
4 In the absence of any specification for any work on material the relevant Indian standard
specification would be applicable and where no Indian standard specification exists, relevant
international specification or the specification given by Railway would be followed. Decision of
Railway in this regard would be final and binding on the contractor.
5 Setting Out: The Contractor shall establish working Bench Marks tied with the Reference Bench
Mark in the area soon after taking possession of the site. The working Bench Marks, alignment /
levels pegs should be got approved from the Engineer.
6 All dimensions and levels shown on the drawings or mentioned in documents forming part of or
issued under the Contract shall be verified by the Contractor on the site and he shall immediately
inform the Engineer of any apparent errors or discrepancies in such dimensions or levels.
7 The Railway administration reserves the right to operate fully or partly up to any extent or delete any
items of this tender schedule as required as per site condition and the contractor will have no right to
claim on this account.
8 Contractor has to make his own arrangement of water and electricity etc. and Railways will entertain
no claim on this account.
9 The Railway will not provide any new service roads for movement of contractor's vehicles. However,
the contractor free of charges can use existing service roads within Railways premises.
10 Contractors have to make approach road/service road wherever required even through the private
lands. The element of service road with prior permission of land owner is deemed to have been
considered while quoting the rate and no extra, what-so-ever, will be paid to the contractor against the
premium / compensation paid by them, if any, to the land owners on this account. The Railway
however, reserves the rights to make use of these roads formed and maintained by the contractor as
and when necessary without any payment to the contractor. The Railways will entertain no claim on
this account.
11 The contractor will arrange his own tools and plants, crane, other equipments, consumable etc.
required for doing the work.
101
12 The contractor will be held responsible for any loss or damage or injury caused during the course of
work to the labours or to the Railway/ Public Private person due to his negligence. The contractor
shall bear all the consequence losses and expenditure thus involved on that account.
13 The work should be carried out without any interference to normal working of the Railway track and
the structures. The Railway reserves the right to have the damages made good by the contractor. The
contractor, if necessary shall provide barricades as required while working near the existing running
lines. The decision of Engineer-in-charge will be final and binding on the contractor in this regard.
14 The contractor must ensure the safety of labourer engaged by him while crossing the track during the
course of execution of work. The Railway will not be responsible for any injury sustained by
labourers. Any claim for compensation what so ever arising out of such accident shall be paid by the
contractor including any fatal accident.
15 Contractors shall have to keep ready necessary first aid facilities etc available all along while working
in the day or night for labours while working.
16 All safety precautions for running of trains in section are to be followed. Contractors will provide
lookout men with the flags/H.S. Lamps during block periods and during normal working period also.
17 Tenderers are required to submit a Bar chart along with the tender documents duly indicating the
programme for completion of work within prescribed completion period showing activities &
resource deployment.
18 The rates of all the items are inclusive of sales tax, royalty fees, octroi duty, as payable under the
sales Tax Act or local bodies Act. The Railways will not pay to the contractor any of these taxes and
the contractor will not be compensated for any amount paid by him by way of such taxes or duties.
19 The Railways will not undertake to supply tools and equipments to the contractors. However under
compelling circumstances the tools and equipment can be given on hire basis if available / spare-able
with/by the Railways. Railways shall decide hire charges for each tool.
20 During the execution of work, the contractor will have to co-ordinate with other contractors working
in the section of civil as well as other departments i.e. electrical and S&T. The site order book and
progress report register will be maintained at site. The representative of Railways and contractor will
sign them.
21 Relevant provisions of Codes, I.R. P.Way manual, LWR manual, AT welding specifications etc. shall
be observed strictly by the contractor at all times as per the directives of the Railways Site Engineer.
22 In addition, in case there is any current standard circular of Railway Board/RDSO or Chief Engineer
to be followed for any track standard, the same could be enforced to be followed under directives of
the Railways Engineer -in-charge of the above work.
23 Wherever lead or lift is not mentioned it should be clearly understood that it mean "All lead and all
lifts" for which no extra payment shall be made.
24 Contractor will have to provide labour for taking measurements of work done or during course of
work whenever necessary with all equipments needed such as Gauge level, tapes etc. as approved by
the Railway no extra payment will be made for the same.
25 If any tools i.e. Bar straightening, wire claw, pick beaters, screening baskets etc. if available will be
given to contractor then hire charges will be paid by contractor at the rate decided by Railway.
26 Contractors will have to apply Grease (Specification for Grease No.IS: 480-1981) to „O‟ graphite on
the central leg of ERC and eye of the MCI insert and then clip should be driven while linking &
laying of track or in turnouts.
27 All details of handing and taking over sections for different stages of packing, imposition and
removal of speed restrictions, measurement of track parameters, accountal of released material etc.,
should be recorded.
28 Wherever the unit per metre has been used it means per running metre of tracks as a whole consisting
of operation on both the rails. It shall not mean that separate payment for left and right rail will be
given unless otherwise specified.
102
(B) Transportation of Track materials
1. For sleepers to be transported from sleeper factory, the loading will be done by Concrete Sleeper
factory free of cost.
2. Unloading will be done at the site with the help of the crane by the Contractors trained/skilled staff
and the sleepers/ rails shall be stacked in proper sequenced batches, thus avoiding the possibility of
mixing up. The unloading shall be done near the track to the extent approachable road exists and
stacked as directed by the Site Engineer.
3. Railway will not be responsible for any damage or accident to the vehicles as well as any labour
working on the vehicle during the contract.
4. The concrete sleeper should be handled carefully during transportation, unloading and stacking. The
contractor will be held responsible for any damage or loss to the concrete sleeper during transit or
unloading.
5. The contractor will arrange transit Insurance for the sleepers being transported.
6. Payment for the transportation charges will be arranged only after the receipt of the materials by the
consignee and not on proof of dispatch.
7. All incidental charges like Octroi, Road tax, entry tax, etc. will be borne by the contractor.
8. Fittings will, generally, be supplied from the Railway Depot either at Pune or Daund. However it may
be required to transport the material from other locations also.
9. All the materials shall be kept clear of infringement during loading, unloading and handling.
10. Weigh-bridge charges, if any are to be paid by the Contractor.
11. Rate of transportation includes making up of temporary approach roads to the locations / Points of
unloading and stacking of sleepers / rails in the section at the location as directed by Engineer-in-
Charge.
12. Excess material unloaded in section shall have to be re-transported and stacked to correct locations by
the contractor at his own cost as per instruction of Engineer-in-Charge.
13. All efforts will be made by Railways to supply required number of sleepers / Railway within
stipulated completion period. However, if due to unforeseen reasons beyond the control of
manufacture, supply is delayed, the contractor shall be granted suitable extension. However, no claim
or compensation on this account will be entertained.
14. Railway‟s materials in charge of contractor may be subjected to check by the Railway officials at any
time and the contractor shall give all facilities for inspection / counting of the materials.
15. After unloading of the Rails the same should be stacked as per para 254 of Indian Railway P. Way
Manual 2004 and as directed by Engineer-in-Charge whose decision in this regard will be final and
binding on the contractor and only then the item will be considered as completed.
16. Measurement :-
17.1 For sleepers of any kind, transported from a sleeper factory, the weight given by the
factory will be taken.
17.2 For transportation of released / second hand sleepers, actual weighment will be done
initially to arrive at the unit weight per sleeper and subsequently the payment will be
done on unit weight thus arrived.
17.3 For transportation of loose fittings, miscellaneous items, mixed items, the payment will
be done on actual weighment.
17.4 For transportation / hauling of released / second hand rails, wherever feasible actual
weighment will be done, otherwise 5% deduction will be made for wear and tear from the
nominal sectional weight.
(C) Issue and accountal of new / released material
1. The Railway's material will be issued on specific requisition of the contractor and as per
requirements consistent with progress of work from the railway‟s depots or at any other specified
location as per direction of Engineer -in-charge at site.
103
2. The contractor will be responsible for safe custody of all the track fittings and materials handed
over to him for linking of track and any losses due to breakages, thefts or misuse will have to be
made good by the contractor before the track is handed over by the contractor to the railway.
3. Track materials issued by the Railway shall be used solely and economically for the purpose of
the work covered by this contract only. The materials shall be used in such quantities and
proportions as specified in the terms of work & as are indicated in the Schedule & in the relevant
specification of drawings as approved by the Engineer whose decision thereon shall be final.
Wastage of or damage to such materials in any manner shall be totally avoided.
4. Any materials left over as surplus or as scrap out of the material supplied by the railways free of
cost, shall be returned to the Railways at railway's depots or other godowns anywhere as directed
by engineer -in-charge at site. Materials shall be returned in good and whole condition.
5. The safe custody of all types of P.Way materials released and surplus will be the responsibility of
the contractor till the same are returned and handed over to the nominated Railways depots. The
recovery will be made from the contractor for loss of Railways materials by his workmen as per
extent rules.
6. Contractor will be responsible for collecting released material if any and transporting it to
Railway stores depot and stacking as directed by Engineer in charge.
7. In case it is noticed that on completion or termination of the work, the consumption of the
material has been found in excess of the quantities laid down and the contractor is unable to
account fully for the material issued either due to neglect in the safe custody or for any other
reasons the cost of such quantity of the material will be recovered from the contractors at twice
the prevailing procurement cost, at the time of last issue i.e. 2 times purchase price plus 5%
freight charges.
8. In case some of the newly placed fittings are found to be damaged, broken, it shall be replaced by
contractor free of cost.
9. Any loss due to possible theft or any other account will be contractor‟s responsibility for which
no payment will be made by the Railways and final payment will be made as per fittings used and
counted in the completed track.
10. Security of Track fittings when fixed in track or at his depot will be contractor‟s responsibility.
11. All released materials, till they are disposed off to depots will remain with contractor and will be
responsible for safeguarding the same. Any loss will be recovered at double of prevailing rates as
decided by Railway.
12. The materials like small fittings etc. form site depot to actual place of work will have to be
transported by the contractor at his own cost. No claim will be entrained on account of crossing of
the track if any and the rate quoted should be inclusive of all lead and handling and also cover all
precautions to lift and stack properly as are considered necessary during the course of execution.
(D) Spreading out stone ballast from stack
1. Ballast will be carried from ballast stacks along the alignment and will be spread evenly wherever
required as directed by Railway Engineer. Initially carpet layer of 10-15 cm as directed by
Railways Engineer shall be laid on prepared formation which will be rolled by roller & then after
linking of track, balance ballasting is to be done to achieve the desired ballast profile given by
IRPWM.
2. The ballast from the stack should be removed right up to the bottom of the stack till stacking
ground becomes visible. Care shall be taken to see that ground soil is not mixed in ballast while
loading by JCB from stack bottom.
3. As far as possible, the stack once broken should be completely run out unless instructed otherwise
by the Railway‟s Site Engineer.
4. For leading out ballast, the measurements of Railways stacks already recorded for ballast supply
work will be considered for payments & no claim on this account will be admissible.
(E) Laying and linking of track
104
1. The work will involve Laying and fixing New rails/predrilled and pre-cut rails on previously laid
sleepers at specified spacing, fixing fish plates and fish bolts and other rail and rail-sleeper
fastenings such as clamps as per Railway‟s drawing and / or as per extant instructions or keeping
provision for flash butt welding, fixing keys/ clips and other rail and rail-sleeper fastenings to
obtain gauge as per Railway‟s drawing and / or as per extant instructions, fixing grooved rubber
pads, liners and elastic rail clips as per standard drawing and as per extant instructions.
2. Rates shall be inclusive of the following items of work of assembling of track:
a) Incidental loading / unloading of stone ballast by head load or by any other means such as
trucks, dumpers Contractor's dip lorry etc.
b) Incidental loading, unloading and stacking at site all Railways materials/released material
during transportation of the same.
c) Straightening the rails / rail panels by JIM-Crowing or by mechanical Hydraulic rail benders
before linking them in the track.
d) Incidental hauling of rails, and MBC sleepers to bring on exact location while laying and
linking of track.
e) Making up standard ballast profile after initial packing.
f) Standard gap has to be maintained on the rails joints.
g) Dressing and leveling of top of formation before the laying of track.
3. The center line and levels will be taken for the alignment of track by Contractor‟s Engineer using
his own theodolite/level which will be checked by Railway‟s Engineer & confirmed for carrying
out work. These shall be maintained & further adhered while laying of track.
4. The above item of the work envisages laying and linking of sleepers and rails of section as
specified in the schedule and fixing rail and rail-sleeper fastenings and fittings etc. Including all
leads, lifts / descents etc, unless otherwise mentioned in the respective items, and all incidental
works.
5. The measurements for payment shall be per running meter of track as stipulated in the item,
measure to the nearest centimeter.
6. The work shall be carried out as per the Railway‟s standard drawings, project sheets, provisions
contained in Indian Railway‟s Permanent Way Manual and the extant instructions.
7. Rail / Rail panels of equal length shall be used in pair for laying and fixing.
8. Rail joints shall be square to alignment, while on the curved alignment; cutting of inner rails shall
be done at suitable intervals when lead of inner rail is equal to half pitch. (Cuts to be paid for
separately).
9. The fish bolts shall be applied one coat of black oil as prescribed. Hammering of fish bolts is
prohibited. The fish bolts shall not be over tightened and shall be tightened with standard spanner /
torque spanner. The inner two fish bolts should be tightened first.
10. The frozen (gapless) joints are required to be provided at specified locations such as at combination
fishplates, joints behind CMS Crossings and SEJs with closure etc.
11. It shall be ensured that the handling of rail is as per extant instructions and shall not infringe the
Railway‟s schedule of Dimensions.
12. Use of kinky rail should be avoided.
13. Marking on rails with punch or chisel is prohibited.
14. The driving of the keys / clamps shall be done with a standard keying Hammer / approved
mechanical means.
15. The above keying / clamping operation shall be completed on the base rail first which shall be first
aligned and fixed in position before the other rail is fixed to the gauge as stipulated.
16. The gauge shall be maintained as per para 403 of the Indian Railways Permanent Way Manual or
as per extant instructions.
17. The contractor will have to straighten the rails by Jim crow or with hydraulic bender before putting
them in track wherever necessary.
105
18. Oiling and greasing of fish plates before fastening the rails will have to be done with contractors
tools and consumables like plumage, kerosene oil, black oil, brushes etc. For 100 nos. of single
rails joints the requirement is approximately as under. No extra payment for this will be made.
Rate of linking track should include this work.
Plumago - 11 lbs/5Kgs.
Kerosene oil - 7-1/2 lbs/3.40 Kg.
Black oil - 6 lbs/2.72 Kg.
19. No extra payment shall be made either for testing or rectification of defects. Engine shall be
provided by Railway without hire charges for testing of track.
20. All lead will mean lead up to one Km. on either side unless otherwise specified in the description of
non-scheduled items.
21. Contractor should quote his rates inclusive of all the works arising out of Special Conditions of
Contract incidental, applicable to each non-scheduled item for which no separate payment is
intended to be made to the contractor.
22. The hiring and position of crane for lifting of sleepers and rails is entirely the responsibility of
contractor.
23. Contractor will have to give spacing for laying MBC sleepers on rails as per drawing supplied to
them at the rate of 1660/1540 Nos. in a KM, as directed at site by the engineer.
24. Contractor will be responsible for giving correct alignment in straight and in curve portion required
as per proposal depending upon degree of curvature, until alignment is approved by PWI-in-charge.
It will be responsibility of contractor to rectify the defects till it is approved by Engineer -in-charge
for this work no extra payment will be made.
25. Contractor shall arrange his own dip lorry or material lorry/dolly etc. for carrying of rails, fittings
etc. over track wherever required as per site conditions. Labour for protection of track, wherever
required, is to be arranged by contractor under directives of Railways engineer at site.
26. The materials like small fittings from site depot to actual place of work will have to be transported
by the contractor at his own cost. No claim will be entertained on account of crossing of the track
if any and the rate quoted should be inclusive of all lead and handling and also cover all
precautions to lift and stack properly as are considered necessary during the course of execution.
27. The consumable stores like graphite, oil, cotton waste, coal tar, paint, painting brushes etc. required
for the work will have to be arranged by the contractor at his own cost required as per the current
prevailing circulars.
28. 1st and 2
nd through packing will be done in accordance with the relevant provisions of IRPWM to
make the track fit for 20 KMPH and 45 KMPH respectively as stipulated in the items.
29. Contractor shall be permitted to construct temporary sheds for his labour/stores etc subject to
condition that hygienic condition shall be maintained at all the level in the surrounding. The
contractor at his own cost shall arrange water supply and electric connections. All this temporary
sheds/stores so constructed shall be removed by the contractor and site cleared of all debris,
leftover material etc. shall be handed over back to Railway otherwise Railway reserves the right to
stop refund of security deposit and /or/ payment of final bill etc. In this matter decision of the
Railway Authorities shall be final and binding on the contractor.
30. After the work is over, the ballast section, cess and side drains will conform to ballast profile as
laid down in manuals.
31. Squaring of sleepers-Gauge variations and kinks inevitably result from sleepers getting out of
square. Squaring of sleepers shall be ensured.
32. The spacing of sleepers on the sighting rail should first be checked and correctly chalk- marked.
Corresponding marks should then be made on the other rail using the square at every point.
33. Squaring should be done by planting the crowbars firmly against the sleeper and pushing it. Under
no circumstances should sleepers be hammered. Sleepers that are squared should be re-gauged
immediately, the fastenings tightened and repacked.
106
34. Contractors will have to apply Grease (Specification for Grease No.IS:480-l98l) to „0‟ graphited on
the central leg of ERC and eye of the MCI insert and then clip should be driven while linking and
laying of track or in turnouts. No extra payment shall be allowed for the same.
35. Track geometry after laying the track shall conform to Track Geometry Standard.
a. Gauge Sleeper to sleeper variation (+/-) 2 mm
b. Expansion gap Over average gap worked out by recording 22
successive gap
(+/-) 2 mm
c. Joints i) Low joints not permitted
ii) High joints not more than (+/-) 2 mm
iii) Square-ness of joints on straight (+/-) 10 mm
d. Spacing of
sleepers
With respect to theoretical spacing (+/-) 20 mm
e. Cross level To be recorded on every 4th sleeper (+/-) 3 mm
f. Alignment On straight on 40 meter above (+/-) 2 mm
On curves of radius more than 300 mm on 20
meter variation ever theoretical versions.
5 mm
On curves of radius less than 500 on 20 meter
variation over theoretical versions
10 mm
g. Longitudinal
level
Variation in longitudinal level with reference to
approved longitudinal sections.
50 m
36. Slewing of track to correct alignment :- Slewing of track should be directed by the mate who
on straights should sight the rail from a distance of 50 to 60 meters. On curves, the peg should be
erected first and the slewing done. When slewing, the crow bars should be planted well into the
ballast at an angle not more than 30 degrees from the vertical otherwise lifting of track may
occur.
37. Gauging :- The basic requirement is uniform gauge over a continuous stretch so long as it is
within the permissible limits of tightness or slackness. Gauging should only be done after
ensuring that sleepers are truly square, Standard key hammers shall always be used, Beaters and
heavier hammers should not be used, as this causes over driving of keys/ER Clips and strain M.I.
inserts. The Track gauge should be held firm with one lug against the base rail and the other end
being swiveled over the opposite rails. The tightest position obtained determines the correct point
to test the gauge.
38. Spacing of sleepers : The spacing of sleepers on the sighting rail should first be checked and
correctly chalk-marked. Corresponding marks should then be made on the other rail using the
square at every point.
39. Boxing of ballast section and tidying : -
a. After completing the preceding operations in sequence, clean ballast should be dressed to the
specified dimensions, template being used for the purpose, Hemp chords 6mm dia of a
sufficient length should be used for lining the top and bottom edges of the ballast, if
inadequate, full section of ballast should be provided near the rail seat, the deficiency being
reflected along the centre of the track and not under the rails or in the shoulder.
b. The cess should then be tidied up. Where earth ridging exists at the edge of the bank, this
should be removed. Cess should be maintained to the correct depth below rail level
according to the ballast section and formation profile.
c. If track Geometry is not maintained and any mishap takes place on the track being
maintained by contractor, due to track deficiency, contractor will be held responsible for the
same & loss to Railway will be recovered from the contractor as deemed fit.
107
d. In switch portion contractor has to carryout all ancillary works for S&T requirement i.e.
housing of tongue rail with stock rail, for adequate length, grinding of head of stud bolt,
grinding of special chair etc. as directed by site Engineer. The payment of assembly can be
made after completion of works for S&T requirement on producing written certificate from
Site Engineer
(F) Specification for cutting of rails
1. The above item of work envisages cutting of rails on cess / running track as specified in the
schedule at isolated locations / nominated Depots / Stacks complete with handling of rails and all
incidental works.
2. The measurements for payment shall be for each complete cut at the specified points.
3. The work shall be carried out as per provisions in Permanent Way Manual.
4. The cut shall be made by Rail cutting machine (saw type) or by abrasive Rail cutter as specified in
the contract.
5. The cut shall be made in a plane at right angle to the foot as well as the running edge of the rail.
The burr, if any, shall be removed.
6. Flame / Gas cutting is forbidden use of Jim-crow to aid cutting is forbidden.
7. The contractor shall arrange for the rail cutting machine (saw type) and hacksaw blade and / or the
abrasive rail cutter and abrasive disc which should be procured from the approved firm(s) for
manufacture / supply of the same, a list of which is given in the Annexure. The rate includes cost
of operation and maintenance of these machines.
8. For cutting of rails and drilling holes in rails, these shall be done through mechanical means only
preferably petrol driven machines. For cutting of rail in block, use of abrasive rail cutter will be
mandatory. The Contractor will be required to keep sufficient number of machines for such
purposes in the section along with stand by, as no delay on account of non-availability of these
machines will be acceptable.
(G) Specification for drilling holes in rails
1. The above item of work envisages drilling and chamfering of holes of prescribed diameter in rails
on cess / running track as specified in schedule at isolated locations / nominated Depot / Stacks
complete with handling of rails and all incidental works.
2. The measurements for payment shall be for each hole drilled including chamfering complete.
3. The work shall be carried out as per the Railway‟s standard drawings and / or as given in Indian
Railways Permanent Way Manual.
4. The drilling shall be done by Rail drilling machine only. Punch or Reaming / Drifting shall not be
permitted. After drilling the hole, the same shall be chamfered with chamfering tools to remove
burrs and for work hardening the hole, on both sides of rail web. The use of flame / gas cutting
equipment is forbidden.
(H) Handling of rails and Protection of rail surface :-
1. Surface notches of even less than 0.75mm depth are liable to cause rail fracture in service,
therefore avoid impact abrasion of rails against separators in wagons and round link chains slings
for securing the rails.
2. Use conventional slings for lifting rails made of flat link chains. Lifting of rails preferably with
magnet lifting device.
3. These rails are thermally very sensitive and are likely to develop metallurgical defects, if exposed
to localised heating which produces very hard and brittle material, therefore avoid heating, flame
cutting on or adjacent to rails and contact with electric arcs and molten metal splashes, i.e. from
loose cables or adjacent welding operations.
4. Do flame cutting when found essential after pre-heating, a minimum of 10 cm. of rail length on
either side of the cutting about 250-350 degrees uniform movement of heating torch before starting
cutting operations.
5. The rails can with stand normal degree of corrosion but localised corrosion in fitting may cause
subsequent rail fractures therefore avoid contact with injurious substances, which produce high
108
corrosion of steel, i.e. acids, alkalis, salts etc. Stack rails on a well-drained place over uniform
supports of wooden battens.
6. The single point slinging increases risk of excessive bending and surface damage to the rails. The
overhang beyond the outer lifting point should not be greater than one half the distance between
lifting points therefore avoid single point slinging. Use two point slinging for rail length up to 10
meter. Next four point slinging with 36 metre rails.
7. Railways will give recommended locations of lifting points for various rail lengths on demand by
contractors. Suitably increase to number of lifting points when handling welded panel of longer
length. Use of lifting beams fitted with slings is desirable.
8. Safety of personnel: Avoid standing under suspended loads. Use protective gloves and clothing to
minimize the risk of skin abrasion. Wear distinctive coloured helmet and clothing for easy
identification by crane and machinery drivers to avoid accident.
(I) First and subsequent packing:
1. Provision has been kept for two round of through packing for making the track fit for speed of 45
Kmph. Details of track parameters for which thorough packing is enclosed with the specifications
of the tender and in Permanent Way Manual. The work should be carried out strictly as per the
direction of the Engineer In-charge.
2. Through packing of newly laid plain track/ slewed track or Turnouts includes spacing, squaring,
gauging, aligning on straight/ curved portion, bringing the track parameters within limits prescribed
in IRPWM, boxing, dressing, ballast section as per standard profile with contractor‟s labour, tools
and plants etc.
3. Before carrying out any through packing joint measurement of track parameters as mentioned in
IRPWM will be jointly recorded by Railway‟s representative and contractor‟s representative. The
parameters will be again jointly recorded after the completion of through packing the contractor.
4. Each round of through packing will be carried out as per Item No. 224 of IRPWM. The track
parameters should be brought within the tolerances as per para No. 316 of IRPWM.
(J) Assembly and laying of turnouts 1. The turnouts should be assembled on uniform layer of stone ballast of specified thickness for which
payment will be made under the item of running out of ballast.
2. The stock joint of the switch to be kept perfectly square.
3. All fittings and components as per standard drawing of turnouts are to be provided and they will be
fully tightened. This item includes provision of switch and crossing gauge tie plates.
4. Rail closer for turnouts will be cut as per standard drawing for the turnouts on PSC sleepers.
5. Provision of stretcher bars and allied fixtures will have to be done in collaboration with S&T
department.
6. Holes and cuts will be paid extra.
7. The Turnouts will be assembled as per RDSO Drg.No.T-4733 & 4734 for 1 in 12 (52 Kg), T-4866
and 4877 for 1 in 8½ (52 Kg), T-4219 and 4220 the standard drawings. For 1 in 12 (60 kg), T-4966
and 4967 for 1 in 8½ (60 Kg).
8. For making a machine joints, a drill of 27.5 mm or 28 mm will be used.
9. Tongue rail will have to be set flush with stock rails over tapered portion of tongue rail by jim-
crowing and other adjustment like packing, lifting of adjoining switch and the length of stretcher
bars etc.
10. Opening of 115 mm will be provided at both LH & RH sides of the toe of the switches.
11. The gap between the top of leading stretcher bar and bottom of stock rail should not be more than
1.5 mm on both LH and RH sides.
12. This item includes fixing of gauge tie plate on switch portion and may involve filing of butt plate,
drilling of additional hole etc. for setting of switch.
13. This item will be carried out in collaboration with S&T department.
14. In switch portion contractor has to carryout all ancillary works for S&T requirement i.e. housing of
tongue rail with stock rail, for adequate length, grinding of head of stud bolt, grinding of special
109
chair etc. as directed by Site Engineer. This work should be finished during traffic block only. The
payment of assembly can be made after completion of works of S&T requirement on producing
written certificate from Site Engineer.
(K) Thermit welding of rails – Thermit welding of rails
(i) For Thermit welding of rails in the section, the contractor will be required to arrange for the
labour, machinery, consumables and other accessories required. Welding will be done by
RDSO‟s approved Welder and Welding portion used for welding shall be from RDSO
approved Supplier for portion.
(ii) The scope of work includes welding of rail joints in BG track under jurisdiction of
Dy.Chief Engineer(C)Pune for the work of Lonand-Phaltan New BG line and Ghorpuri
yard Pune for GIT Phase-II.
(iii) The track structure for main line will be 52 kg/90 UTS 1st class on MBC sleeper with
elastic fastenings and for yards 52 kg 2nd
class rails on MBC sleepers with elastic fastening.
(iv) The work will have to be executed strictly conforming to the following
conditions/specifications etc.
(a) Manual for Fusion welding of Rails by the Alumino Thermit process 2006.
(b) Indian Railway Standard specification for fusion welding of Rails alumino Thermit
process (IRIT-19-1994) as amended.
(c) Manual for Ultrasonic Testing of Rails & Welds 1998 (incl. check list of Ultrasonic
Testing of Rail Welds (Annex-X para 6.8 & 7.10)
(v) The contractors are required to acquaint themselves & obtain all the details relating
correction slips/Additions/Corrigendum‟s issued by Railways from time to time for Sr.No.1
to 2 above since work is essentially to be executed as per procedures laid down therein i.e.
latest correction slips/additions/corrigendum‟s to the date of execution. The portions should
be from RDSO approved agency for manufacture of portion and welding shall be executed
through RDSO approved welders only.
(vi) This item covers following aspects, cost of which is to be borne by the contractor and no
any extra charges shall be paid by Railways for the same.
(a) Welding to be done as per the Manual for fusion welding of rails by Alumino
Thermit process – 2006 and RDSO‟s specification No.T-19-1994 with up to date
correction slips.
(b) The work shall be executed only through supervisors and welders who have been
trained and approved by RDSO as competent to undertake rail welding works.
(c) The welding to be carried out on running lines, Deadlines/line under construction,
on cess or in situ etc. with or without traffic block as per requirement. The sleepers
and fittings if shifted or removed for welding are to be refixed to their normal
position after welding and finishing of joints.
(d) Work to be done with preheating technology such as compressed air petrol/LPG
along with use of Three piece moulds only.
(e) Loading, unloading & transportation of portions and other materials shall be the
responsibility of a contractor & required to be carried out at his own cost & same
will not be paid by Railways.
(f) Pulling/handling of rail upto 50 meters shall be the responsibility of the contractor
and same will not be paid by Railways.
(g) making of gap, supporting on wooden block (ghutka), if required to facilitate
welding, aligning, fixing of welding boxes, heating of joints, ignition and fusion of
portion etc. as per standard procedure is to be carried out.
(h) Cutting of excess molten metal by trimmer or by chisel, finishing including filing
of welded joints to tolerances laid down in AT welding manual as corrected with
contractor‟s tools, plants, labour, equipments, fuel etc. and including anti corrosive
110
painting of weld collar and fixing identification code on aluminium strips/painting
the details on web of the rail.
(i) Payment of 5% of welds will be held up in every bill & same will be released after
completion of USFD testing for the joints for which payment is made through
earlier bills, if found sound during testing.
Specifications for welding of rails :
1. Indian Railway Standard Specification for fusion welding of rails by Alumino Thermit
process T-19-1994
2. Manual for welding of rail joints by the Alumino-Thermic cess (RDSO).
Additional Special Conditions :
1. No Price escalation will be admissible except as provided for in the following :
(a) The accepted rate is based on the base price of commercial grade aluminum ingots as on
date of opening of tender including excise duty and on the basis of requirements of
aluminum per joint. For this purpose quantity of aluminum shall be taken at 3.0 kg/joint.
Any variation in the rate of aluminum from the base price will be to the account of the
Railway. While claiming price escalation, the contractor shall produce documentary proof
in support of his claim. The aluminum rate prevailing on the date of testing recorded in
RDSO‟s test certificate will be considered for effecting increased/decrease on the rates of
joints welded with that portion. The Railway will make an additional payment of 30 paise
per welded joint for every `.100.00 increase in the controlled/manufacture (Bharat
AL.Co.,ltd.,) rate of Commercial Grade Aluminum including Excise duty per tone, over
and above the base price prevailing on the date of opening of tender.
Necessary certificate for variation in cost shall be produced from M/s Bharat Aluminum
Co. ltd. If the price of aluminum, reduces then the cost per joint will be reduced by 30 paise
per joint for every `100/- decrease, increase/decrease less than `.100.00 per tone will be
ignored.
(b) The Railway will recommend the concerned authorities for the allotment of commercial
grade aluminium to the contractor at the rate of 3.0 kg each joint ordered. This will be
made on receipt of request from the contractor. The responsibility for obtaining the raw
materials, even these recommended by the Railway, will rest solely on the contractor.
Delay in the execution of the work due non-supply of any raw materials will not be
accepted as a valid reason for non fulfillment or delay in completion of welding work.
(L) Track Tamping by Machines :- Pre-tamping attention :- To achieve good results the
contractor should carry out the following preparatory work before taking up the tamping:-
(a) Ballasting where there is shortage of ballast.
(b) Heaping up of ballast in the tamping zone, to ensure effective packing.
(c) Making up of low cess.
(d) Cleaning of pumping joints and providing additional clean ballast, where necessary.
(e) Attending to Hogged joints before tamping.
(f) Tightening of all fittings and fastenings like fish bolts and keys, splitting of cotters, and
replacement of worn out fittings.
(g) Removing & replacing broken and damaged sleepers with good sleepers.
(h) Squaring of sleepers and spacing adjustment; re-gauging to be done as necessary.
(i) Adjusting creep and expansion gap in rails.
(j) Examination of rails for cracks etc.
(k) Realigning of curves which are badly out of alignment.
(l) Clearing of ballast on sleepers to make them visible to the operator.
111
(m) All obstructions such as signal rods, cables, pipes, level crossing check rails, etc., likely to be
damaged by the tampers should be clearly marked and made known to the tamping operator
before he starts work. Tight overhead clearance should also be brought to his notice; the
beginning and end of transitions should be marked. Super elevation should be marked on
every second sleeper so that it can guide the operator for leveling up correctly.
Post Tamping Attention :- The contractor shall pay attention to the following points :-
(a) As some of the rigid fastenings might get loose, tightening of fittings should be done
immediately after tamping.
(b) Any broken fitting should be replaced.
(c) Proper quality check of work done by tamping machine is important. Immediately after the
tamping work, the track should be checked, in respect of cross levels and alignment, and
action taken as considered necessary.
(d) The ballast should be dressed neatly and proper consolidation of ballast between the sleepers
should be done.
(M) Maintenance period :-
A. Free Maintenance Period :- Free maintenance period of this work is upto the starting of
regular passenger or goods trains in the section. For this the contractor is required to
maintain, at his own cost, the track and turnouts by deputing suitable and adequate labour
with tools and supervisor. He is required to rectify any defects found out or developed in
the track geometry and ballast profile, at his own cost, after running of any kind of rolling
stock such as rolling engine, material train, ballast train, trial train or engine, CRS
specials etc before the starting of regular passenger or goods trains in the section.
B. Paid Maintenance Period :- After starting of regular Goods / Passenger train services in
the section, the contractor will have to maintain the section till handing over of the
section to open line as per special condition of contract Technical Specification for track
works Para(N) of Tender document .
(N) Paid Maintenance of track :-
1. Period for payment for the maintenance of track under the stipulated item in the schedule will be
counted from the day of running of regular passenger or goods train services in the section.
2. Contractor has to engage two separate gangs of 15 Gangmen, in each gang plus one qualified
Mate with each gang for this purpose throughout the maintenance period. In addition, Keyman to
patrol the track shall be deployed as per the programme given by Railways Site Engineer to cover
the entire track daily throughout the paid maintenance period. Rate includes these activities also.
It will be the sole responsibility of the contractor to attend the portion of track and turnouts,
which requires the maintenance for safe running of traffic maintaining track parameters for
normal sectional speed as per IRPWM. In this connection the instructions of site engineer must be
complied strictly and the track defects are attended immediately to the entire satisfaction of site
Engineers.
In case of any default on the part of contractor in deploying the required manpower stipulated
above, the penalty of Rs.500.00/Gangman per day of said default will be imposed / recovered.
This item will be operated till the section is handed over to open line after commissioning and
starting of regular goods train or passenger train services in the section. The decision of Engineer-
In-Charge with regard to operation of this item and regarding imposition of penalty will be final
and binding on the contractor.
*****
112
1. SPECIFICATION FOR LEADING / HAULING COLLECTIONS AND STACKING /
SPREADING OF RAILS.
1. The above item of work envisages:-
(i) Leading/Hauling/stacking rails from Railway‟s nominated depots/stacks/locations and
(ii) Stacking/spreading the rails or rail panels at the nominated Depots/Stacks/ Location, as
per Railway‟s requirements and/or as directed by the Engineer or his representative
completed with all incidental works.
2. The nominated Locations for the purpose of this work shall have been inspected by the
Contractor before submitting the Tender.
3. Without in any way restricting or modifying the provision of the General Conditions of the
Contract in this regard, the rates for the above quoted work shall be inclusive of (except as
specifically provided in the schedule of work) all costs of Contractor labour, Equipments,
Consumables, Tools & Plants and Machinery etc. complete for the above.
4. The work shall be carried out strictly as per instructions laid down in Indian Railway‟s Permanent
Way Manual and / or as per instructions of the Engineer or his Representative whose decision in
this regard shall be final and conclusive.
5. In addition to the above, the work shall be conform to the following :-Carrying rail on the heads
or shoulders is prohibited. For handling rails, sings, rail tongs, rail dollies etc. or other similar
equipment shall only be used.
(i) While stacking/spreading rails care shall be ensure that:
(a) The rails are sorted rail-section wise and/or class wise.
(b) The rails are stacked/spread on level ground.
(c) These rails are support and stacked in a manner directed by the Engineer or his
Representative.
(d) The rails are so spread as to rest evenly along their entire length or on supports closely
spaced with the flat-footed rails resting on the foot.
(e) In case of spreading rails alongside track, the rails will be paired as per the instructions of
the Engineer-in-charge.
(ii) While working in the vicinity of existing open line track it should be carried out only
under the Supervision of the Railway‟s Engineer or his authorised representative and to
ensure that Schedule of dimensions are not infringed with.
*****
113
2. SPECIFICATION FOR COLLECTING / LEADING AND STACKING OF MAIN
LINE PSC SLEEPERS/TURNOUT AND SPECIAL PSC SLEEPERS.
1. The above item of work envisages: -
(i) Collecting / leading & stacking of PSC sleepers from Railway‟s nominated locations.
(ii) Stacking the sleepers at the nominated Locations, as per Railway‟s requirements and / or
as directed by the Engineer or his Representative complete with leads as specified in the
schedule, all lifts and descents and incidental works.
2. The nominated locations for the purpose of this work shall have been inspected by the
Contractor before submitting the tender and the accepted rate is deemed to be inclusive of all
leads, lifts etc.
3. Without in any way restricting or modifying the provision of the General Conditions of the
contract in this regard, the rates for the above quoted work shall be inclusive of all costs of
Contractor‟s labour, consumables, tools & plants and machinery etc. complete for the above.
4. The work shall be carried out strictly as per instructions laid down in Indian Railway Permanent
way manual and/or as per instructions of the Engineer or his representative whose decision in this
regard shall be final and conclusive.
5. In addition to the above, the work shall conform to the following:
(i) While handling adequate care should be taken to avoid any physical damage to the
sleepers. In case of damage to sleepers due to negligence of contractor, recoveries will
be made from contractor‟s bills and Engineer‟s decision in this regard will be final.
ii) While stacking sleepers care shall be taken to ensure that :-
a) The sleepers are sorted out separately as directed by the Engineer or his
Representative.
b) The sleepers are stacked on reasonably level ground.
c) The sleepers are supported in a manner directed by the Engineer or his
Representative.
*****
114
3. SPECIFICATION FOR REMOVING EXISTING RAILS/RAIL PANELS FROM
TRACK.
1 The above item of the work envisages removing existing rails/rail panels from existing track at
locations as per Railway‟s requirements and/or as directed by the Engineer or his Representative
complete with removal of rail sleeper, fastenings, fish plate, bolts etc. and all incidental works.
2. The nominated locations for the purpose of this work shall have been inspected by the contractor
before submitting the Tender.
3. Without in any way restricting or modifying the provisions of the General Conditions of contract
in this regard, the rate for the above quoted work shall be inclusive of all costs of contractor‟s
labour, materials, consumables, tools & plants and machinery etc. complete for the above.
4. The work shall be carried out strictly as per the Railway‟s standard drawings, instructions laid
down in Indian Railway‟s Permanent Way Manual and the instructions of the Engineer or his
Representative whose decision in this regard shall be final in conclusive.
5. i. The work will involve removing fish plated and fish bolts, sleeper rail fastenings
and removing the rail from the sleepers and placing it safe distance away from the
track, as directed by the Engineer in charge.
ii. The work shall be carried out only under the supervision of the engineer in charge of his
authorized representative under full traffic block.
iii. The rails removed from the track should be cleared from the existing track as directed by
the engineer in charge and should not infringe the Railway schedule of dimensions.
iv. Fishplates, bolts, nuts and clips/keys etc. removed during the operation should stacked as
directed by the engineer in charge. Payment for extra leads, if any, shall be made under
the relevant items of the schedule.
v. For handling rails, slings, rail tongs, rail dollies etc. or other similar standard equipments
should only be used.
*****
115
4. SPECIFICATION FOR INSERTING RAILS/RAIL PANELS IN EXISTING TRACK
1. The above item of the work envisages inserting Railway‟s rails off section as specified in the
schedule including providing and fixing Railway‟s rail and rail sleeper fastenings and fittings etc.
complete on existing sleepers at locations as per Railway‟s requirements and/or as directed by the
Engineer or his Representative complete including all incidental works.
2. The nominated locations for the purpose of this work shall have been inspected by the contractor
before submitting the Tender.
3. Without in any way restricting or modifying the provisions of the General Conditions of Contract
in this regard, the rate for the above quoted work shall be inclusive of all costs of Contractor‟s
labour, materials, consumables, tools & plants and machinery etc. complete for the above.
4. The work shall be carried out strictly as per the Railway‟s standard drawings, instructions laid
down in Indian Railway‟s Permanent Way annual and the instructions of the Engineer or his
Representatives whose decision in this regard shall be final and conclusive.
5. The work will involve :-
(i) Inserting predrilled and precut rails on previously laid sleeper as per railway‟s drawing
and / or directed by the Engineer-in-charge.
(ii) Rail / Rail panels of equal length shall be used in pairs for inserting and joints shall be
square.
(iii) Rail joints shall be square to alignment, while on the curved alignment, cutting of inner
rails shall be done at suitable intervals when lead of inner rail is equal to half pitch (Cuts
to be paid for separately).
(iv) Fixing railway‟s fish plate and fish bolts and other rails and rail-sleeper fastenings as per
railway‟s drawing and / or as directed by the engineer – in-charge. The fish bolts shall be
applied one coat of black oil as specified by Engineer – in – charge. In case of LWR
track, instead of provision of fish plated joints, contract shall arrange for requirements of
SKV welding/FB welding joint provision as per directives of Engineer taking care of
relevant specification applicable.
(v) Hammering of fish bolts is prohibited. The fish bolts should not be over tightened and
the first two fish bolts to be tightened first. Baring of bolts as required by Railway will
be done bu the Contractor at no extra cost.
*****
116
5. SPECIFICATION FOR REMOVING SLEEPERS FROM EXISTING TRACK.
1. The above item of the work envisages removing sleepers from existing tack at locations as per
Railway‟s requirements and / or as directed by the Engineer or his Representative complete with
removal of rail-sleeper fastenings etc. and all incidental works.
2. The nominated Depots / Stacks / Locations for the purpose of this work submitting the Tender.
3. Without in any way restricting or modifying the provisions of the General Conditions of Contract
in this regard, the rate for the above quoted work shall to inclusive of all costs of Contractor‟s
labour, materials, consumables, tools & plants and machinery etc. complete for the above.
4. The work shall be carried out strictly as per the Railway‟s standard drawings, instructions laid
down in Indian Railway‟s Permanent way manual and the instructions of the Engineer or his
Representative whose decision in this regard shall be final and conclusive.
5. The work shall be carried out only under the supervision of the Engineer – in – charge or his
authorised representative under speed restriction.
6. The work will involve.
(i) Removing sleeper – Rail fastenings and removing the sleepers from the track including
bare minimum removal of ballast to enable the removal of sleepers.
(ii) The sleepers removed from the track should be cleared from the existing track as directed
by the Engineer – in – charge and should not infringe the Railway schedule of
dimensions.
(iii) Sleepers and the fittings removed during the operation should be stacked as directed by
the Engineer – in – charge.
(iv) For handling sleepers standard equipments should only be used and it must be ensured
that no damage is caused to the sleeper. In case of damage to sleepers due to negligence
of Contractor recoveries will be mad from the Contractors bills and the Engineer decision
in this regard would be considered as final.
(v) While handling concrete sleepers extra care is to be taken by using suitable tools /
equipments / gadgets to avoid damage to concrete sleepers.
(vi) Fixing Railway‟s key / clips and other rail and rail – sleeper fastenings to obtain gauge as
per Railway‟s drawing and / or as directed by Engineer – in-charge.
(vii) In case of inserting rails / rail panels on concrete sleepers this work will include fixing
grooved rubber pads, liners and elastic rail clips as directed by the Engineer and as per
the standard drawing.
(viii) The work shall be carried out only under the supervision of the Engineer-in-charge of his
authorised representative under full traffic block.
(ix) It should be ensured that the handling of rail is as directed by the Engineer in charge and
should not infringe the Railway schedule of dimensions.
(x) For handling rails, slings, rail tongs etc. or other similar standard equipments should only
be used.
(xi) Marking on rails with punch or chisel is prohibited.
(xii) The driving of the keys shall be done with a standard keying hammer (1.8 Kg.)
(xiii) The above operation shall be completed on the base rail first, aligned and fixed to the
gauge as stipulated.
*****
117
6. SPECIFICATION FOR INSERTING SLEEPERS IN EXISTING TRACK :-
1. The above item of the envisages inserting sleepers as specified in the schedule in the existing
track locations as per Rly‟s requirements and / or as directed by the Engineer or his representative
complete with providing of rail-sleeper fastenings etc. & all incidental works.
2. The nominated locations for the purpose of this work shall have been inspected by the Contractor
before submitting the Tender.
3. Without in any way restricting or modifying the provisions of the GCC in this regard, the rate for
the above quoted work shall be inclusive of all costs of Contractor‟s labour, materials,
consumables, tools & plants and machinery etc. complete for the above.
4. The work shall be carried out strictly as per the Rly‟s Standard drawings, instructions laid down
in Indian Railway‟s Permanent Way Manual and the instruction of the Engineer or his
Representative whose decision in this regard shall be final and conclusive.
5. The work shall be carried out under the supervision of the Engineer-in-charge or his authorised
representative under speed restriction.
6. The work will include :-
i. Inserting the sleepers in the existing track including providing rail-sleeper fastenings etc. as
directed by the Engineer–in-charge.
ii. The sleepers positions shall be marked on the rail foot by the contractor any they should be
inserted exactly at these location. Work should be executed in a manner so as not to infringe
the Railway‟s schedule of dimension.
iii. The rail-sleeper fastenings like keys, clips, rubber pads, liners. Loose jaws etc. should be
fitted as per The Railways standard drawing or as directed by the Engineer– in-charge.
iv. For handling sleepers standard equipments should only be used and it must be ensured that no
damage is caused to the sleeper. In case of damage to sleepers due to contractor‟s negligence
recoveries would be made and Engineer decision in this regard would be final.
v. White laying concrete sleepers necessary steps have to be ensured to prevent seizure of ERCs
inserts. All the ERCs & MCI inserts be thoroughly cleaned. Grease to IS 408-
1981(specification for Grease No.0 Graphited) should be applied on the central leg of the
ERC and eye of MCI insert and then the clip should be driven at the time of making the
panels. The grease will be arranged by the contractor.
vi. The sleepers and rail-sleeper fastenings will be provided free by the railway.
7. On stretches where deep screening is not being done simultaneously the work will also include.
i. Removing ballast at location where sleeper is to be inserted upto 50mm below the bottom
of sleeper being inserted.
ii. Putting back the ballast so removed into track after the insertion of the sleeper.
iii. Initial packing of the sleeper so inserted so as to maintain track geometry as directed by
Engineer-in-charge.
8. SPECIFICATION FOR SHALLOW SCREENING OF TRACK
1. The above item of work envisages shallow screening of ballast as outlined in para of
IRPWM.
2. The work of shallow screening to be carried out without any speed restriction and without
any traffic block.
3. The work involves removing ballast between sleepers & shoulder upto 50 mm below sleeper
bottom. The ballast so removed, shall be screened by using portable ballast cleaners / inclined
ballast screens. Use of wire baskets is not permissible for screening.
4. Muck/spoils to be disposed off suitably for ensuring proper drainage of track.
5. Where track is land with LWR & CWR extra care and precautions as envisaged in LWR
manual to be followed.
*****
118
ANNEXURE-I
A. Track Geometry Standard during initial laying :
a) Gauge Sleeper to sleeper variation (+/-) 2 mm
b) Expansion gap Over average gap worked out by recording 22
successive gap
(+/-) 2 mm
c) Joints i) Low joints not permitted
ii) High joints not more than (+/-) 2 mm
iii) Squareness of joints on straight (+/-) 10 mm
d) Spacing of
sleepers
With respect to theoretical spacing (+/-) 20 mm
e) Cross level To be recorded on every 4th sleeper (+/-) 3 mm
f) Alignment On straight on 40 metre above (+/-) 2 mm
On curves of radius more than 300 mm on 20
metre variation ever theoretical versions.
5 mm
On curves of radius less than 500. on 20m
variation over theoretical versions
10 mm
g) Longitudinal
level
Variation in longitudinal level with reference
to approved longitudinal sections.
50 mm
Squaring of sleepers-Gauge variations and kinks inevitably result from sleepers getting out of
square.
i) The spacing of sleepers on the sighting rail should first be checked and correctly chalk- marked.
Corresponding marks should then be made on the other rail using the square at every points.
ii) Squaring should be done by planting the crow bars firmly against the sleeper and pushing it. Under
no circumstances should sleepers be hammered. Sleepers that are squared should be re-gauged
immediately, the fastenings tightened and repacked.
B. SLEWING OF TRACK TO CORRECT ALIGNMENT :
i) Slewing of track should be directed by the mate who on straights should sight the rail
from a distance of 50 to 60 meters. On curves, the peg should be erected first and the
slewing done.
ii) When Slewing, the crow bars should be planted well into the ballast at an angle not more
than 30 degrees from the vertical otherwise lifting of track may occur.
C. GAUGING :
i) The basic requirement is uniform gauge over a continuous stretch so long as it is within
the permissible limits of tightness or slackness.
ii) Gauging should only be done after ensuring that sleepers are truly square, Standard key
hammers shall always be used, Beaters and heavier hammers should not be used, as this
causes over driving of keys/ER Clips and strain M.I. inserts.
iii) The Track gauge should be held firm with one lug against the base rail and the other end
being swiveled over the opposite rails. The tightest position obtained determines the
correct point to test the gauge.
D. SPACING OF SLEEPERS :- The spacing of sleepers on the sighting rail should first be checked
and correctly chalk-marked. Corresponding marks should then be made on the other rail using
the square at every point.
E. BOXING OF BALLAST SECTION AND TIDYING :-
i. After completing the preceding operations in sequence, clean ballast should be dressed to the specified
dimensions, template being used for the purpose, Hemp chords 6mm dia of a sufficient length should be
119
used for lining the top and bottom edges of the ballast, if inadequate, full section of ballast should be
provided near the rail seat, the deficiency being reflected along the centre of the track and not under the
rails or in the shoulder.
ii. The cess should then be tidied up. Where earth ridging is existing at the edge of the bank, this should
be removed. Cess should be maintained to the correct depth below rail level according to the ballast
section and formation profile.
iii. If track Geometry is not maintained and any mishap takes place on the track being maintained by
contractor, due to track deficiency, contractor will be held responsible for the same and loss to Railway
will be recovered from the contractor.
*****
ANNEXURE-II
GUIDELINE FOR HANDLING AND MAINTENANCE OF
6O KG/52 KG/ 90 UTS RAILS
-**-
1. PROTECTION OF STRAIGHTNESS :- Barely visible straightness deviation, for example, a
deflection of 0.75 mm. Over 1.5 meters span, renders a rail unacceptable and requires careful
handling and stacking therefore.
AVOID:
o Heavy Static Loading.
o Sudden impact of dynamic loading
o Excessive end drop and flange overlaps while lifting, moving,
o Localised points or line contact loading in stacking
o Criss-cross stacking of rails of alternative layers straight angles as far as possible.
DO:
o Keep rails horizontal and straight while lifting, moving.
o Stack rail of same length on firm level base of well drained soil preferably of concrete
with uniform support of wooden battens of about 4" thickness.
o Stack subsequent Layers on uniformly placed spacers and keep rail ends in vertical
alignment with base support.
o Keep rail ends in vertical alignment.
o Place rails of shorter length in upper layers.
2. PROTECTION OF RAIL SURFACE.:
Surface notches of even less than 0.75mm depth are liable to cause rail fracture in service,
therefore:
AVOID:
o Impact abrasion of rails against separators in wagons.
o Round link chains slings for securing the rails.
DO:
o Use conventional slings for lifting rails made of flat link chains.
o Lifting of rails preferably with magnet lifting device.
3. PREVENTION OF METALLURGICAL DAMAGE :
These rails are thermally very sensitive and are likely to develop metallurgical defects, if exposed
to Localised heating which produces very hard, brittle ad failures, therefore :
AVOID:
o Heating, flame cutting on or adjacent to rails.
o Contact with electric arcs and molten metal splashes, i.e. from loose cables or adjacent
welding operations.
DO:
Flame cutting when found essential after pre-heating, a minimum of 10 cm. of rail length
on either side of the cutting about 250-350 degrees uniform movement of heating torch
before starting cutting operations.
120
4. PROTECTION FROM CONTRACT WITH INJURIOUS SUBSTANCES:
The rails can with stand normal degree of corrosion but localised corrosion in fitting may cause
subsequent rail fractures therefore:
AVOID:
Contact with injurious substances, which produce high corrosion of steel, i.e. acids,
alkalis, salts etc.
DO:
Stack rails on a well drained place over uniform supports of wooden battens.
5. SLINGING PRINCIPLES :- The single point slinging increases risk of excessive bending and
surface damage to the rails. The overhang beyond the outer lifting point should not be greater
than one half the distance between lifting points therefore:
AVOID:
Single point slinging.
DO:
Use two point slinging for rail length up to 10 meter.
Next four point slinging with 36 metre rails.
Recommended locations of lifting points for various rail lengths will be given by
Railways on demand by contractors.
Suitably increase to number of lifting points when handling welded panel of longer
length.
Use of lifting beams fitted with slings is desirable.
6 SAFETY OF PERSONNEL :
AVOID:
Standing under suspended loads:
DO:
Use protective gloves and clothing to minimize the risk of skin abrasion.
Wear distinctive coloured helmet and clothing for easy identification by crane and
machinery drivers to avoid accident.
7 PREFERABLE LIFTING AND HANDLING DEVICES :
Magnet lifting device, in this device two or more magnets depending on the rail length are
suspended from a lifting spreader beam.
*****
121
SPECIAL CONDITION OF CONTRACT FOR SUPPLY OF SKV PROTIONS AND THEIR
WELDING AND FINISHING OF RAIL JOINTS
1. The special conditions, tender conditions instructions to tenderers and the general condition of contract as amended upto date shall govern the work under this contract. If there is any conflict
between the special conditions and instruction to tenderer on one hand and General conditions of
contract on the other, the former shall prevail. 2. The work shall conform to IRS specification No. T. 19-1994 – Fusion welding of rails by “Alumino
Thermic process” with the latest amendments. The contractor process should have the RDSO‟s / Board‟s approval for various types of portions and proof there of should be submitted along with
the tender. Packing – To be supplied in moisture roof packing.
Sampling – One random sample per 300 or part there or will be rested for reaction test. If the values are
not within the specified values, the entire batch will be rejected. 3. Prefabricated mould made from high silica sand to IS 1987 –74 mixed with sodium silicate to the
required consistency followed by passing CO2 gas through the mixture for hardening and as approved by RDSO.
4. The supply of alumino-thermic welding portion as a regular measure will be carried out by only
such firms as have been approved by the Railway Board/RDSO for various types of portions. In respect of the new firms, the approval procedure will involve the stages mentioned in T. 19.1994 part
B under item 10 to 15.
5. The tenderer will supply Thermit portions duly approved by RDSO in respect of quality and weight.
6. Inspection of Thermit portions of welding will be done by RDSO.
7. Variation in quantities: The number of portions in various categories is approximate and is likely to vary. The tenderer shall not have any objection to supply portion according to the
requirements of the Railway. 8. The total quantity under all the items combined can be increased or decreased up to 25% of he
contracted quantity at the discretion of Railway. The variation under individual item can be up to
any extent as long as the variation in aggregate quantity is upto 25%. The contractor shall not prefer any claims for compensation or for any extra payment on account of such variation.
However Railway will give reasonable notice in writing of any such variation and will also suitable consider the extension of completion period to cover supply of additional quantity of portions.
9. Dispatch: consignee particulars for dispatch of portions to depot PWI/Section Engineer (P.Way)
will be furnished by Dy.CE© . 10. Portions will have to be supplied to the depot/depots nominated by Dy.CE© over each sub-
division Generally one depot will be identified for the jurisdiction of each of SE(T) and nomination approved by Dy.CE© . The contractors will here to supply the materials to the depots, so
nominated for each SE(T). 11. Performance: If the contractor fails to produce satisfactory progress after one month of
commencement of the contract, the Railway reserves the rights to terminate the contract on this
account. 12. Payment: The testing charges for estimation of aluminum by spectrometer in Thermit steel will
be borne by the contractor wherever such estimation of Aluminum is to be done by the inspecting agency.
13. Wherever necessary the sales tax form required entering the state will be obtained by railway
from the respective state Government Department and will be sent to the supplier before commencement of supply.
14. Wherever octroi is charged, necessary octroi clearance exemption certificate will be issued by Railways on specific request from the contractor. Further it is clarified that Railway will not
reimburse the contractor if such certificates are not accepted by the Municipal corporation/Municipal councils.
122
15. The payment condition as laid down in Clause 45 and 46 of G.C.C. – 2014 shall generally apply.
However contractor will have to sign the measurement in the M.B for final bill.
16. Portion along with accessories/complementary materials shall be supplied with each consignment while working out the requirements of accessories/complementary items fraction shall be
rounded off to the next higher figure treating each consignment as a unit.
17. The contractor shall not directly or indirectly use any invention so as to infringe such patents or so as to involve the Railway in any infringement there of and the contractor shall hold Railway
harmless and indemnified against all costs, damages, charges or expenses etc. arising out of or in connection with any such infringement.
18. The Railway reserves the right to bye pass lowest/lower rates and to award the contract in full or in part or to reject it without assigning any reason.
Work specification
1.1 All the finished welded joints shall be checked to ensured that the joint geometry is within the following tolerances:
i) Vertical Misalignment + 1.0 mm (Measured at the end of 1m straight edge) 0.0mm.
ii) Lateral Misalignment + 0.5 mm (Measured at the center of 1m straight edge)
iii) Head finishing on sides + 0.3mm on gauge side (Measured at the center of 10cm straight edge).
iv) Finishing top table surface + 0.4mm(Measured at the end of 10cm straight edge) v) Web Zone (under side of head web, top of based and fillets and underside of rail) +
10mm –0.0 mm for Thermit welding. NOTE: - Dispensation for joint geometry, in case of old rails may be permitted by Dy.CE © .
The details of geometry of each joint shall be jointly signed by the firm‟s and
Railway‟s representative and kept as a record. Any joint found not conforming to the above stipulations shall be cut and re-welded free of cost by the firm. Only such
joints will qualify for payment as are finished to the above tolerance.
2.1 Parameters of SKV Welding
52 KG 60KG i) Approximate weight of welding portions 12.50kg 13.5kg
ii) Preheating time, air petrol fuel mixture. As prescribed for process approved by RDSO iii) Initial gap between Rail ends 25 + 1mm 25+ 1 mm
iv) Preheating technique Top heating Top heating
v) Type of mould Pre-fabricated mould made from high silica sand to IS 1087-74 mixed with sodium
silicate to the required consistency followed by passing CO2gas through mixture.
Description of work 3.1 the work of Thermic welding of rail joints shall be done as under:-
i) Outside the track on cess or in depots.
ii) In situ, under traffic in block or with caution order as deemed fit by the Railway.
In case of (ii) above, the contractor shall have no claim whatsoever on the Railway even if suitable time under block caution order is not available. However, appropriate extension to time of
completion will be given by the railway.
3.2 The rails to be welded conform to IRS Specification No. 11-1936/TRS specifications No. T. 12.53/T/12-55/T-12-64 and RDSO specification No. T. 19-1994 and also as amended up to
date. Satisfactory performance
4.1 The contractor will be responsible for the welded joints remaining satisfactory for the guarantee period as specified in the specification and a sum equal to 2% of the total
123
amount billed will be kept as a security deposit for two years or the extended period of 3
years, if necessary and for every joints failing during the period, 3 times the cost of welding as being paid to the contractor for one rail joints will be recovered from this sum if the joints
are not re-welded by the contractor. In case the number of welded joints failing during the guarantee period increases more than 2%, the Railway administration will reserve the right
to terminate/suspend the contract and all the direct and indirect damages/ losses caused to
the railway on this account will be realized from the contractor. In case of contracts so suspended the contractor shall be allowed to restart the work lonely after Railway have
satisfied after a review about the contractor„s ability to carry out the welding work to the required quality and specification.
4.2 No recovery on account of cost of labour and material s supplied for the work will be made from the contractors in case of joints spoiled during the execution of work or the joints
rejected during ultrasonic testing up to a limit of 2% only, but beyond this limit, recovery
will be made from the contractor at Rs. 468/- per joint for 52kg and Rs. 504/- per joint for 60 kg.
Work to be done by contractor 5.1 The contractor should satisfy himself from time to time about the metallurgical property of
the rails to be welded and apply the correct technique for producing satisfactory welded
joints from such rails. The contractor will arrange for the chemical analysis of the rail pieces or rails borings at his own cost. Rail piece or rail boring will be supplied by the Railway free
of cost if so desired. 5.2 The contractor will be responsible for ensuring that the rails are brought to correct
alignment and level before welding. 5.3 The contractor will be responsible for proper filling of the joints and their finish to he
specified tolerance after welding. The contractor shall supply the required welding plant and
Thermit mixture suitable for welding rails by Alumino Thermic process. Other material such as patterns and mould boxes/and moulding and luting sand required for the work will also
be supplied by the contractor at his own cost. The contractor will have to use-approved type of weld Trimmers and Grinding Trolley for timing filling and finishing of the Thermit welded
joints to the prescribed tolerances. The cold chiseling of the joint by chisels and hammers
are not permissible. All the equipments and machines will be approved by Engineer. The rates quoted would be deemed to have been including the provision of all tools, plants,
equipment and machines etc. 5.4 The contractor shall normally carryout any work between sunset and sunrise. He should
make his own arrangement to protect the work against wind and weather during the course
of actual execution should the Engineer permit or order welding in night hours, contractor shall make his own arrangement for lighting.
5.5 The contractor will arrange to train the Railway staff in the welding technique and also be responsible for providing his own technical trained staff required to supervise the work
during the progress. 5.6 The contractor should be able to deeply sufficient number of welding supervisors for carrying
out the work. The contractor should organize the work at sufficient number of locations with
adequate plant and equipment, so as to obtain the prescribed progress of work. The average daily progress of work in each division should be in proportion to the work to be
carried out in each division. If the contractor fails to produce this progress after one month of commencement of this contract
and maintain the same there after the Railway reserves the rights to terminate the contract
on this account.
5.7 The contractor will also provide each welding party metallic straight edges of 1 m to 10 cm length, one set of filter gauge measuring in units of 0.1 mm to 2mm and other tools, plants
required.
124
5.8 The contractor should start the work of manufacturing of portions within 10 days of the
receipt of the acceptance letter. 5.9 The contractor will provide trained welders, skilled and unskilled labour for the work.
5.10 The welding work should be carried out by self-contained units at each location so that all types of work concerning each joints i.e. lifting packing, leveling, alignment, moulding,
welding, trimming by mechanical means will be carried out by the same party. For this
purpose the contractor will provide the following lab our for each self contained unit. 1. Trainee welders -1 No.
2. Moulders -1No. 3. Striker -1No.
4. Alignments fitter -1No. 5. Luters -2Nos.
6. Khalasis -3Nos.
5.11 For finishing of joints khalasi will be provided by the contractor at the rate of one khalasi for every 2 joints per day. It should be ensured by the contractor that the work of finishing the
welded joints keeps pace with the welding. Before commencement of work, he will submit a certificate that all the skilled/unskilled lab our deputed for the work has been adequately
trained.
5.12 No payment shall be made for sample welds to the contractor but the petrol and lab out required for the same will be supplied by the contractor free of cost. The contractor will
also arrange for the transport of these joints at his own cost from the site of work, the contractor‟s work for testing. In case any test joint picked up under clause 14.3 of IRST-T-
1965 fail/fails, the guarantee period of 2 years shall be extended for further period of one year for the particular KM/kms. Representative joints of which falls.
Work to be done by Railway.
6.1 The railway will provide a permanent way official for supervision of the work. 6.2 The Railway shall provide wooden blocks and wedges and such other tools, which are
usually required for lifting or leveling or placing the rails in position for welding purpose. 6.3 The permanent Way supervisor in charge of the work will make necessary arrangements for
sage working and traffic blocks. The arrangements made by the Railway for safe working
will not relieve the contractor of his liability for indemnifying the Railway against all costs, damages, charges or expenses as per clause 54 to clause 57 of the General condition of
contract - 2014 in case the Railway has become liable to costs, damages charges or expenses due to the negligence of the contractor.
6.4 The Railway shall remove all kinks and twists in these rails particularly within 2 meters of
ends and before handing over the same to the contractor for welding. 6.5 The facility of rail transport will be given free of cost for the work of welding of rail joints by
the Railway for the contractor‟s materials, tool and plant from contractor‟s local store depot to the site of work and the return of tools and plant only to contractor works only such
material tools and plants as required for the work will be given under this facility. 6.7 The contractor his representative and his supervisors will be carried on push trolley from the
nearest station to the site of work, provided the necessary indemnity bond is signed by the
contractor in the first instance on behalf of himself and his personnel and then separately by each of the contractor‟s personnel required to be carried on the push trolley.
6.8 All the miscellaneous and auxiliary items of work such as erection of huts and temporary sheds posting of watchmen and flagmen, lorrying of materials, plants and tools will be
carried out by the Railway with its own separate lab our under the direct supervision of the
section Engineer (T) deputed for the purpose. 6.9 Suitable temporary accommodation for storage of the contractor‟s plant, tools and
consumable stores will be arranged free as close to the site of work as possible on a specific request from the contractor, Tented accommodation for contractors supervisory staff will be
dealt with in accordance with clause 59 of GCC 1999/2014.
125
6.10 On completion of welding USFD testing of the weld shall be done by the Railways as per
procedure given in Annexure I of T- 19-1994. The payment wills dependent on good and acceptable joints only.
6.11 During the course of the work the Railway will be responsible for – i) Pulling out rails and/or out rails for creating gap for welding the correct amount
to be specified by the contractor.
ii) Shifting sleepers to insert wooden blocks and wedges for alignment. iii) Pulling back rails repack sleepers after welding.
iv) Providing cut pieces after removing any spoilt joint by cutting. v) Opening out fishplates, bolts, nuts, keys and putting them back when necessary.
6.12 Inspection of Thermit portions for welding will be done by R.D.S.O./ RITES or its representatives.
6.13 The testing charges for estimation of aluminum by spectrograph method in Thermit steel
will be borne by the contractor whenever such estimation of aluminum is to be done by the inspecting Agency.
6.15 Welding during rains will not be permitted except on certain sections as may be decided by the Dy.CE©. The Railway will made available for the work free of cost survey umbrellas
during the monsoon season.
6.16 Sale Tax, Royalties and octroi duties if any, that may be payable under any State government or local bodies Act or Rule on any of the material that may be supplied or used
by the contractor on the work will be payable by the contractor. The Railway will neither pay the taxes or duties nor be bound to compensate the contractor for any amounts paid
by him by way of these taxes or duties.
INDIAN RAILWAY STANDARD SPECIFICATION FOR FUSION WELDING OF RAILS BY ALUMINO-THERMIC PROCESS
Serial No. IRS T19-1994 FOREWORD
This specification is issued under the fixed serial No. T-19. This was originally adopted in 1961 and was revised in 1965 and 1984. This third revision is necessitated to including current technological
improvements in the process. In this revised specification, test requirements of 90 UTS 110 UTS and HEAD hardened rails have been incorporated, acceptable percentage of porosity, tapping, time and
transverse breaking load requirements have been revised.
1. INTRODUCITON
1.1 The soundness of the welds produced by alumino-thermic process depends on the quality of (a) alumino-thermic mixture hereinafter referred to as the „MIXTURE‟ and (b) the
technical control exercised during the preparation for and the execution of the welding by this process.
1.2 The quantity of the „MIXTURE‟ required for welding one rail joint shall be called a „portion‟.
1.3 A batch shall consist of a number of „ portion‟ manufactured from similarly and simultaneously treated raw materials.
1.4 „Portions‟ manufactured by agencies approved by RDSO and accepted by nominated inspection authority shall only be used.
1.5 Except for welds executed for laboratory evaluation and acceptance test, all welds shall
be executed under the supervision of personnel possessing valid competency certificate either from RDSO of from Thermit portion plant, Northern Railway, Charbagh, Lucknow.
1.6 No changes in weld design, range of weld metal chemistry, its acceptance tests and the methods of welding shall be made without the consent of the approving authority.
Approving Authority shall mean Director Genera, Research Design & Standards organization (Ministry of Railway), Manak Nagar Lucknow- 226011 or his representative.
126
1.7 The numerical values may be rounded off as per IS: 2.
2. SCOPE 2.1 This specification is for A.T. welding of rails to IRS Specification T-12 and UIC
Specification 860-0, alloy Steel Rails, viz., Chrome Manganese and Chrome- Vanadium and Head Hardened rails.
2.2 This Indian Railway Standard covers:-
(a) Technical requirements for Thermit portions and welded joints including various acceptance tests.
(b) Procedure for approval of Alumino-thermic “portion manufactures”. (c) Procedure for approval of A.T.Welding Supervisors, Welders and contracting
firms. (d) Acceptance tests for in-situ and cessAlumino- Thermic joints.
2.3 Reference Documents: This standard refers to the following Indian Standards of the Bureau of Indian Standards: These Should be available at the manufacturers works for reference.
(i) IS :2 Rules for rounding off numerical values. (ii) IS : 187 Cotton long cloth.
(iii) IS: 9738 polyethylene bags for general purpose.
(iv) IS: 2500(Pt.1) Sampling inspection tables: Part I inspection by attributes ad by count of defects.
(v) IS : 1500 Method foe Brinell hardness test foe metallic materials.
Part A- Technical requirements for Thermit Portions
3. SUPPLY OF THE “ PORTIONS” 3.1 The „portion‟ shall be submitted for acceptance batch wise. A batch shall consist of 300 portions
or part thereof manufactured from similarly and simultaneously treated raw materials. Batch
numbering shall be given year wise in a six digits code, whose first two digits will indicate two digits of the year of manufacture and the balance 4 digits, the serial number of the batch. The
batch number at the beginning of each year shall, therefore, commence from 0001. 3.2 Every portion shall be packed in a moisture proof bag of polyethylene to IS: 9738, “ Indian
Standard Specification for Polyethylene bags for general purposes” Grade HM HDPE of 150
micron thickness which should be sealed so as to make it air tight. The polyethylene bag should then be packed in a heavy-duty bag made of new cloth to IS: 187. The open end of the cloth
bag shall be stitched and sealed in such a manner that there is no access to the portion without damaging the bag or breaking its seal.
3.3 Following particulars shall be indicated on two similar labels- one placed inside the polyethylene
bag containing the portion and the other outside with the seal on the bag:- (i) Batch No.
(ii) Portion No. (iii) Date of manufacture.
(iv) The section and grade of rail to be welded. (v) Welding Technique.
(vi) Insignia of the firm.
The insignia of the firm and rail type should be printed on the exterior of the cloth bag as per the under mentioned color scheme.
S. No. Rail Type colour 1. 72 UTS Red
2. 90 UTS Green
3. 110 UTS Black (Chrome Manganese & Chrome- Vanadium)
4. 110UTS Head Hardened Yellow
127
the bags containing portion shall be packed in a sturdy wooden/Heavy duty corrugated card board
approved by RDSO/metallic container. No container with the portion bags shall weigh more than 60 kg. Any bag of „portion‟ found damaged at the time of delivery shall NOT be accepted.
4. ACCEPTANCE TESTS
The following tests shall be conducted for assessing the quality of portions: -
1. Reaction test. 2. Mechanical and Metallurgical test on test welds.
For this purpose, one portion shall be randomly selected per batch for tests as per clause
And 4.2 The weight of each portion shall be recorded by the inspector. a. Reaction test
i. Reaction test shall be carried out on one of the selected portions.
ii. During the course of the Alumino-thermic reaction, observations in regard to the characteristics of the reaction, i.e., whether it is quiet, normal or boiling shall be made.
Reaction, which is boiling, shall be rejected. The reaction and tapping shall be within 20+3 seconds. The Alumino-thermic steel shall be made poured in standard mould so as to obtain
a bar having diameter between 25 to 35 mm.
iii. A transverse section shall be cut from the middle third portion of the bar of Alumino-thermic steel obtained from reaction test as laid down in clause 4.1.2 Aluminium, content of the steel
shall be determined spectroscopically at two points located at the mid-radii of the cross section. The aluminium content at both the points shall be between 0.15% to 0.65%.
b. Mechanical and Metallurgical tests on test welds i. Two new rail pieces of same section and grade, each approximately 750 mm long, shall
be used to make test wed joint. The welded joint shall be made as per the technique
offered by the manufacturer. The rail table and sides of railhead shall be finished to the geometrical tolerances specified in Clause 18.1.
ii. Hardness test Brielle hardness test shall be carried out at the welded zone, heat affected zones and parent
metal of the rails in accordance with IS: 1500 “Method for Brinell Hardness test for steel”. The
test shall be done on the top surface to the head of the test weld with a ball of 10 mm die and a test load of 3000 kg maintained for 10 secs. The average hardness number ( of two readings)
determined for the weld metal at locations shown as „A‟ in Fig. 1 shall be within +20_0 HB of the hardness values of rail as shown in table1. The average hardness number (of two reading) on
each heat affected zone at locations shown as „B‟ and „C‟ in fig. I shall be within (-) 20 HB for
locations B and (+) 20 HB for locations C of the actual hardness of the parent rail.
Type of rail 72 UTS rail 90 UTS rail UIC Cr- Mn or Cr-V alloy steel rail
Head hardened Rail
Average Hardness
(BHN)
230 265 310 365
4.1.1 Transverse breaking load test
4.1.1 The test weld shall be supported on cylindrical or semi-cylindrical or semi-cylindrical supports having a distance of tone meter between them from center or center. The weld shall be at the
center of the span and loaded in such a manner that the foot of the rail is in tension. The diameter of mandrel and the supports shall be between 30 to 50mm. The load shall be
gradually increased (rate of loading shall not exceed 2.5t/sec.) till rupture occurs.
The test weld shall withstand a minimum load and show corresponding minimum deflection as stipulated in Table-2 for different section as types of rails.
128
TABLE-2
Rail type Rail Section Min. transverse breaking
load in tones
Min deflection in mm at the
center at the load
in col.3
72 UTS to IRS T-12 60R 50 15
72 UTS to IRS T 75R 60 15
72 UTS to IRS T 90R 70 15
72 UTS to IRS T 52kg 85 18
72 UTS to IRS T 60kg 95 18
90 UTS to IRS T-12/UIC 860-0 or
equivalent.
75kg 65 15
90R 85 15
52kg 90 15
60kg 115 15
Alloy steel (Cr-Mn or Cr-V
type 110 UTS
52kg 95 10
60kg 115 10
Head Hardened rails 60kg 115 15
4.1.1.2 If the fracture does not occur through weld, a slice shall be cut transversely at the weld and etched in boiling 1:1 Hydrochloric acid for about 20 minutes to determine casting defects if
any.
4.1.1.3The fractured surface of the weld, or in case where macro-etching is done on transverse section through the joint, shall not show defects such as blow holes, porosity and inclusions
etc. exceeding total permissible area of defect shown in Table-3. however, the size of any individual defect shall not exceed 2m diameter. The defects should not be interconnected
and none of these shall extend upto the outer surface of the weld. There shall not be any
lack of fusion. The fractured surface shall also not show the presence of accretions or mirror like structure and shall be crystalline in appearance.
TABLE-3
Area of permissible defects
Rails Section Permissible total area of defect (mm2)
60R 19.0
75R 23.7
90R 28.5
52kg 33.0
60kg 38.4
4.1 Retests
4.1.1 if the results of any of the rests referred to in clause 4.1 and 4.2 are found to be
unsatisfactory, the batch will stand rejected. However, retests can be carried out at the manufacturer‟s request. These retests shall be carried out as per para4.1 and 4.2 on twice
the original sample size. 4.1.2 If the results of all the retest samples are satisfactory, the batch represented by the sample
portions shall be accepted. If any sample fails to meet the requirements of any of the tests, the batch shall be rejected.
5 REPROCESSING In the event of a batch failing to comply with the requirements of clause 4, the manufacturer may
resubmit the batch after necessary reprocessing ONCE only. The reprocessed portion shall be submitted under a separate batch number with a suffix ‟R‟ and shall be tested as per clause 4 above.
129
6. ACCEPTANCE
6.1 Acceptance shall be done batch wise. Every individual batch that satisfies the conditions prescribed in this specification shall be accepted. Each bag containing the portion shall be sealed
by the manufacturer and the container shall be suitable stamped/seal shall be such that it shall not be possible to open the container without breaking stamp/seal.
6.2 The manufacturer shall dispatch the portions to the consignee preferably within 60 days from the
date of acceptance. 7. DISPOSALM OF REJECTED PORTIONS
In case the batch fails to meet the requirements of clause 4 , it shall be rejected. The rejected portions shall be separately stored and a proper accountal shall be kept. The disposal of these
rejected portions shall be advised to the inspecting agency. 8. TESTING FACILITIES
The manufacturer shall, at his own expense, supply all labour, materials, consumables, rail
pieces and appliances for testing, both the initial test and retests as may be carried out in presence of the Inspecting Officer, in his own premises or at any other acceptable place in
accordance with this specification.
9. INSPECITON OF PREMISES AND RECORDS.
The purchaser or the inspecting Officer shall have free access to the premises of the manufacturer at all reasonable times. They shall be at liberty to inspect all the records and the manufacture of
portions at any stage.
PART „B‟ – APROVAL OF “PORTION MANUFACTURERS” 10. The approval of “portion Manufacturer” shall be given separately for each section and
metallurgy of rail and for each technique of welding.
11. For the purpose of approval, the following definitions shall apply. “Portion Manufacturer” shall mean the organization manufacturing the „portion‟. In addition, the
“portion Manufacturer” may execute A.T. Welding of rail joints by his technique. “Approving Authority” shall be director General, Research, Designs & Standards Organization,
Ministry of Railways, Manak Nagar, Lucknow- 226011 or his representative.
12. PROCEDURE FOR APPROVAL OF “PORTION MANUFACTURER”
12.1 The application for approval shall be submitted by the “portion Manufacturer” to the Approving authority, indicating the rail for which portion is being offered and the welding
technique.
12.2 Approving Authority “ on receipt of such as application, shall forward necessary preformed to be filled in by the applicant. The amount to9 be deposited shall also be intimated.
12.3 The applicant shall return the preformed, duly filled in , along with a demand draft for the prescribed amount drawn in favor of Director(finance), Research, Designs & Standards
Organization, Manak Nagar, Lucknow- 226011. 12.4 If the information submitted by the applicant is prima facie found to be satisfactory, the
Approving Authority shall inspect the premises of the applicant for assessment. If the
assessment is satisfactory, tests and trials shall be undertaken by the Approving Authority. 12.5 Tests and trials for approval of “portion manufacturers”
12.5.1 The portion Manufacturer shall manufacture a batch of 150 „portions‟ at his own cost. Samples shall be drawn at raniom by the Approving Authority and the following laboratory
tests shall be carried out at the Manufacturer‟s works premises or at a laboratory mutually
agreed upon between the manufacturer and the approving authority: i) Six numbers of reaction tests will be conducted as per clause 4.1.
ii) Twelve tests weld joints shall be made as per clause 4.2.2. the joints shall be subjected to following tests:-
(a) Ultrasonic test on all the joints as per procedure laid down at Annexure-1. (b) Brinell Hardness test on all the joints as per clause 4.2.2.
130
(c) Transverse load and deflection test as pr clause 4.2.2 on six randomly selected joints.
(d) Magnetic crack detection and macro examination on deep etched longitudinal sections, across the weld on the remaining six joints. This examination shall not reveal any lack of
fusion or cracks. Other welding defects, e.g. porosity, inclusions etc. shall not exceed 0.5% of the weld area in longitudinal section. The defects should not be interconnected
and none of these shall extend upto the outer surface.
12.1.1 RETEST If the results of any of the tests referred to in clause 12.5.1 fail to meet the requirements of the test,
the technique shall be rejected. However retest can be carried out at the request of the “portion manufacturer” provided not more than 2 joints have failed in ultrasonic testing and
not more than one joint has failed in each of the other tests mentioned in clause 12.5.1.
For retest, same number of test specimens as mentioned for each test in clause 12.5.1 shall be
welded. None of the sample joint should fail in retest.
13 FATIGUE TEST 13.1 fatigue testing of Thermit welding techniques shall be arranged by the manufacturer
at his own expense. Following principle shall be followed: -
i) For 90 UTS metallurgy-Anyone section out of 52 kg/60kg (when both the sections have been
developed the lighter section should be selected for fatigue testing). ii) For 72 UTS metallurgy- Any one section out of 90R/52kg (when both the section have been
developed the lighter section should be selected for fatigue testing). iii) Development of any other A.T. Welding technology such as, wider gap, gas heating, Chrome
Mariganese/Head Hardened rails shall also be got separately fatigue tested before
standardization. However, one section for one technique shall be required to be fatigue tested.
13.2 The weld samples shall be tested in a recognized laboratory / test center for which prior approval of RDSO shall be necessary.
13.3 Following scheme shall be followed for fatigue testing of thermit welded rails joints:-
i) Three weld samples shall be made in presence of RDSO representatives. ii) The weld sample shall be dame with one meter long new rail pieces to have an
overall length of 2.0 m. the rail and joint shall be ultrasonically tested. iii) Testing shall be done for stress ranges of tensile 20 kg/mm2 to compressive 4
kg/mm 2 (These are the stresses on the bottom surface of rail foot.) . The test
frequency shall be anyone frequency between 8.33 Hrs. to 12 Hr. iv) A joint shall be deemed to have passed if it withstands a minimum of 2 million
cycles. v) The technique shall be deemed to have cleared fatigue test if all the three samples
pass the above test. 13.4 Retest
In case of failure of not more than one joint in the above test, retest can be carried out at the request of the
portion manufacturer. For the purpose of retest, three more weld samples shall be made in pressure of RDSO representative and subjected to be above test.
The technique shall be deemed to have passed the fatigue test if all the three retest samples pass the test.
14.FIELD TRAILS
14.1 Subject to the results of the testes in clause 12 and 13 being satisfactory, service trials for a period of one year or till passage of 10 m GMT traffic over the joint, whichever is earlier, shall
be undertaken on 50 to 100 trial joints welded using the above batch of portion. For the purpose of field trials, and order shall be placed by the nominated Zonal railway on the
131
manufacturer for supply of portions as well as welding of trial joints. The trial joints shall be
distinctly marked by painting letter “I” on the web of the rail beyond 300 mm from the joints. During execution of trail welding at site, spoilt joints, if any, shall be cut and rewelded by the
contractor at his own expense.
All the trial joints shall be ultrasonically tested soon after welding s per procedure at Annexure-
1. Up to a maximum of 5% defective welds, shall be cut and rewelded by the manufacturer at his own expense. If more than 5% joints are found defective, the trail shall be discontinued
considering the technique to be unsatisfactory. All the defective joints shall be removed from track by the manufacturer at his own expense.
14.2 Failures of more than 2% joints during service trailer will render the technique unacceptable.
15. The approving authority shall have free access to the premises of the portion manufacturer at all
reasonable times. The portion manufacturer shall furnish all the technical data to the approving authority as and when called for.
16. PART-C: PROCEDURE FOR APPROVAL OF A.T.WELDING SUPERVISIORS AND
WELDERS.
16.1 For the purpose of approval, the following definitions shall apply: - “Welding supervisor “shall mean an individual engaged with portion manufacturer with adequate
knowledge and competence for supervising and executing Alumino Thermic welding of rail joints.
“Welder “shall mean an individual with adequate skill and competence for executing Alumino Thermic welding of rail joints at site.
The approval of welding supervisors/welders for execution of Alumino-Thermic welds at site shall be given
separately for the following categories of welding techniques: a) Welding of 72 UTS and 90 UTS rails with standard gap:
b) Wide gap welding. c) Welding of 110 UTS and Head Hardened rails.
16.2 Competency certificates for welding supervisors and welders of the zonal railways shall be issued by the Thermit portion plant of Northern Railway at Lucknow. Competency certificates
for welding supervisors and welders of firms shall be issued by D. G. (M&C) R.D.S.O., Lucknow.
16.3 Test weld joints will be made using any rail section at the discretion of the approving
authority. Welding supervisors/welders found competent shall be deemed to be fit for A.T. welding of all rail section for the particular category as per clause 16.1. For execution of test
weld joints, the welding supervisor/welder desirous of obtaining approval shall have to utilize his own welding team, rails, implements and „portions‟ procured from approved
manufacturers.
16.4 The firm shall pay in advance, charges for certification of supervisor/welders as per the rates
decided by RDSO for this purpose. Payment should be made through demand draft drawn in favor of Director (Finance), RDSO Manak Nagar Lucknow- 226011.
16.5 Six test welds shall be made by the welding supervisor/welder and his team for the particular
category of welding technique (as per clause 16.1) for which approval is sought. Following
tests shall be carried out at the sponsoring firm‟s works premises or at RDSO, Lucknow :- a) Ultrasonic testing as per procedure mentioned at Annexure-1. Failure of more than
one test weld will disqualify the welding supervisor/welder. b) The ultrasonically sound joints will be subjected to following tests:-
i) Brinell hardness test on all the test welds as per clause 4.2.2. ii) Transverse load and deflection tests on any three test welds as per clause 4.2.3.
132
iii) Magnetic crack detection and macro examination of remaining three test welds
longitudinally sectioned across the weld as per clause 12.5.1 (ii)(d). iv) Joint geometry as per clause 13.1
16.1 If the test results are satisfactory, a provisional competency certificate, valid for two years, shall be issued to the welding supervisor/welder on behalf of the sponsoring firm. The
provisionally approved welding supervisor/welder‟s competency shall be re-assessed by
RDSO/TPP, lucknow after two years for issue of competency certificate valid for five years. 16.1.1 For the purpose of reassessment, the welding supervisor/welder shall submit, to the
approving Authority, the following details duly countersigned by the concerned Assistant Engineer of Zonal Railway.
a) A record of joints welded/supervised by him. b) No. of joints failed in service.
16.1.2 Based on the above details and personal interview, the approving authority will issue
competency certificate. Fresh competency certificate will have to be issued whenever there is a change in the process of welding or when a person who has been earlier trained and issued
with a final competency certificate has not been executing welding for a period of more than 2 years or the work done by him has been rated as unsatisfactory.
16.1.3 Renewal of competency certificate will be made based on performance or actual testing.
16.1.4 A 10 character “identification Code Number “shall be used for numbering of competency certificates and identification of supervisors and welders. The first three characters shall be
alphabets which would indicate the agency (Railway or Firm) or which the supervisor or welder belongs, the next digit (S or N) would denote a supervisor or welder, the next three
numbers would be allotted to the particular person (specific person number), next two numbers shall denote the year of issue of the competency certificate and the last alphabet (P
or F) shall indicate whether it is “provisional” or “Final” competency certificate. For example,
NR0S0019F would indicate a welding supervisor of Northern Railway with specific person number 1; the final competency certificate having been issued in the year 1990. The specific
person number will be continuous for a zonal Railway/Firm. The organization issuing competency certificates shall ensure that there is no duplication of the “ Identification Code
Number”. An annual list of valid competency certificates will be circulated by the agency
issuing the competency certificates to the Zonal railway. Zonal Railway should constantly update and maintain the list of supervisors and welders along with their identification code.
133
PART-D – ACCEPTANCE TEST OF JOINTS WELDED AT SITE
17.EXECUTION OF WELDS AT SITE
17.1 Alumino- thermic welding of rails shall be executed at site only under the direct supervision of
welding supervisor and by welder, both having valid competency certificate issued by RDSO/TPP, Lucknow (see Part “C”).
17.2 All Alumino-thermic welding work shall be executed with the use of Weld Trimmer and profile Grinder. Additionally, rail tensors shall be used wherever work is done on welded rails.
Note:- In case of welding of old rails dispensations for not using weld trimmers and profile grinder
shall be obtained from chief Engineer. 18. ACCEPTANCE TESTS
18.1 joint geometry. All the finish-welded joints shall be checked to ensure that the joint geometry is within the
following tolerance.-
i) vertical + 1.0mm (Measured at the end of 1m straight
edge) misalignment -0.0mm (Fig. 18.1 (a)
ii) Lateral + 0.5mm (Measured at the center of 1m straight Misalignment edge) (Fig. 18.1 (b))
iii) Head finishing + 0.3 mm on gauge side (Measured at the center of 10
on side cm straight edge (Fig. 18.1(c) iv) Finishing top + 0.4 mm (Measured at the end of 10 cm
tables surface -0mm straight edge ( fig . 18.1 (d))
Note:- Dispensation for joint geometry ion case of old rails may be permitted by Chief Engineer. The
details of geometry of each joint shall be jointly signed by the firm‟s and railway‟s representative and kept as a record. Any joint found not conforming to the above stipulations
shall be cut and rewelded, free of cost, by the firm.
18.1 Ultrasonic testing All the welded joints shall be ultrasonically tested by the Railways as per the procedure given
at Annexure-1. This testing shall be completed as early as possible after welding but before the welding team leaves the
welding site. All the joints which are found to be defective shall be cut and rewelded by the firm using their portion, equipments, labour and consumables.
Where one bad joint is required to be replaced by two new joints, the entire cost of both the joints shall be borne by the firm. Such rewelded joints shall also be tested ultrasonically and if found defective, shall again
be cut and rewelded free of cost. 18.2 Sample test joint
One out of every 100 joints welded per batch shall be selected at random by the purchaser or by the
inspecting officer within one month of welding and subjected to hardness and transverse test as per clause 4.2 and the joint shall comply with provision laid down therein.
18.2.1 In the event of the failure of sample test joint in any of the requirements of this specification, the Railway will be at liberty to suspend further welding. However, two more randomly selected joints
from the same lot of 100 joints shall be subjected to retests as per clause 4.2. Both the joints should
clear all the testes. If the report is also not satisfactory, further welding joints shall be suspended until the firm has examined the welding technique and satisfies the requirements of Clause 4 by welding one
test joint. The clearance for recommencement of welding shall be given by RDSO.
134
19. GUARANTEE
19.1 Rail joints welded by a firm shall be guaranteed against failure for a period of two years from the date of welding the joints in track or from the date such welded joints made in cess‟ are inserted in
the track. Any such welded joint, which fails within the guarantee. Period shall be re-welded free of cost by firm as per stipulations of clause. 18.2.
19.2 In case of failure of sample test joints (refer Clause 18.3), the period of guarantee for 100 joints
represented by the sample joint shall be extended for a further period of none year. In case of failure of joints or joints exhibiting signs of failure by cracking within extended period of guarantee,
the joint shall be rewelded free of cost by the supplier as per stipulations of Clause 18.2. 19.3 The welded joints with the extended period of guarantee shall be marked „X‟ with yellow paint on
the outer side of the web of the rails bear the joint in addition to be markings prescribed in Clause 20. Such marked joints shall be kept under careful observation by the purchaser.
20. MARKING
Each joint shall have a distinctive mark indicating month year welder‟s code and weld number on the web of the rail in the welded joint in the following manner:
** ** *** *** **
Month last two digits agency specific person Weld
No. of year Number
This should de done by punching on as Aluminum strip, which should be fixed to the web of the rail with suitable epoxy adhesive at approximately 300 mm from the joint. The Agency and Specific person
number (for welder shall be as per clause 16.6.4. the welded joints shall be serially numbered in a kilometer. Repair weds/additional welds done at a later date may be given continuing weld
number in that kilometer. For example, the last Thermit weld number in a particular kilometer
was 88 and subsequently a Thermit weld has been executed, it shall be numbered 89 irrespective of its location in that kilometer.
21 WITHDRAWAL OF APPROVAL OF PORTION MANUFACTURER/ WELDING SUPERVISOR /WELDER FROM APPROVED LIST.
The approving authority can delete the name of any portion Manufacturer/welding
Supervisor/welder from the approved list based on complaints regarding the performance.
135
ANNEXURE-1
PROCEDURE FOR ULTRASONIC TESTING OF ALUMINO THERMIT RAIL JOINTS
1. Scope
This procedure covers the requirement of ultrasonic testing of aluminothermit (AT) welding rail joints
immediately after execution of the weld.
2. General conditions of test 2.1 Surface preparation
After execution of the AT weld, the welded zone shall be dressed properly to facilitate placement of probes and to avoid incidence of spurious signals on the CRT. The head surface shall be dressed to obtain
reasonably flat and smooth surface. The flange of the web upto a distance of 200mm on either side
of the weld collar shall be thoroughly cleaned with a wire brush to ensure freedom from dust, dirt, surface unevenness etc.
2.2 Complant Water/oil shall be used as couplant.
2.3 Sensitivit
The equipment sensitivity shall be set for normal, 700 and 800 probes in accordance with the procedure laid down in Para 4. The sensitivity to adjusted shall be considered as normal gain sensitivity and shall be
utilized during ATW testing. The sensitivity level shall not be altered during the course of testing. 3. Apparatus required
3.1 Equipment Any RDSO approved model of rail tester shall be considered suitable for testing of AT Welded rail
joints.
3.2 probes During ultrasonic examination of AT welded joints, the following probes shall be utilized.
(a) Normal (00), 4 MHz.
(b) 700, 2 MHz.
(c) 800, 1.25 MHz. 3.3 Cable
One co-axial cable of suitable length for connection 800 probe to flaw detector shall be used. The length should not exceed more than 5 m.
4. Sensitivity setting procedure
4.1 Calibration The equipment should be set for a depth range of 250mm by manipulating the depth control knob suitably.
Each division, therefore, shall correspond to 25 mm. 4.2 Test Rail
The sensitivity of the ultrasonic equipment shall be set with the help of a standard AT welded rail piece of 1.5 m length having a simulated flaw at standard locations as shown in Fig. 1
4.3 Alignment of probes The alignment of normal and 700 probes fitted with the trolley may be checked by placing the rail on the test
rail using water/oil as a couplant and ensuring that the probes travel long the axis of the rail.
4.4 Sensitivity setting for 700 probes
4.4.1 Place trolley on the test rails shown in Fig. 1. Keep the switches of all the probes in off position and turn the potentiometer knobs of all the probes to 50% of teier highest working range.
4.4.2 Switch on only 700 forward probe and move the equipment towards the drilled holes in the railhead. When the probe is just in the reflecting range, a pulse corresponding to the hole shall
appear on the screen, which during onward traveling shall show higher amplitude. The pulse shall appear moving from right to left. The equipment should be progressively moved forward till
136
maximum height of the pulse is obtained. At this location the height of the pulse shall be
adjusted to 60% of full screen height by suitably manipulation of the gain knob. 4.4.3 The forward probe shall be switched off and the 70% backward probe shall now be switched on.
In this case a flaw signal shall appear moving from left to right. The signal height in this position
shall also be adjusted to 60% of full screen height. This can be accomplished through suitable manipulation of relevant potentiometer.
4.4.4 The sensitivity setting for the normal probe has to be done while keeping all other probes in off position. Switch on only the normal probe and bring it above 3mm die hole of the test rail. Manipulate the potentiometer control knob to obtain echo height of 60% of full screen height at 1.0 division horizontal scale.
4.4.5 800 probe shall be connected to the socket available in the ultrasonic equipment. The selectors, which may be set to single crystal mode. Move the probe towards the 3mm die hole drilled in the AT Weld and manipulate knobs to obtain a 60% full screen height on the CRT.
5. Criteria for defect classification 5.1 Any flaw signal obtained by normal probe of 40% height or more shall be treated as a defective AT welded
joint. Any flaw signal obtained from the normal probe either from the we or the foot location shall also be a cause for rejection of the AT weld.
5.2 In the case of lack of fusion, inclusion, blow holes etc. In the railhead, moving signal shall be obtained while testing the 700 probe. The position of onset of the signal and its corresponding range on the horizontal screen as well as their maximum amplitude shall be recorded.
A welded joint showing the moving signal of 40% or more of the full screen height shall be considered as a defective welded joint.
5.3 800 probe shall be placed on the flange at a suitable distance (1mm approx.) corresponding to Position „L‟ in fig. 2. Such that ultrasonic waves are directed towards the weld. The probe shall thereafter
be moved slowly in a zigzag pattern towards at weld. A welded joint showing a flaw echo of 40% vertical height or more with the stipulated gain setting shall be treated as a defective welded joint. Similar testing shall be carried out from “C” and “U” region as shown in fig. 2. in these cases also the criteria for rejection shall remain the same.
6. The defective joints based on the criteria mentioned at clause 5 shall not be allowed to remain in service and cropped, re-welded and tested again. This execution shall be done by the contractor free of cost. The
re-welded joints shall be scanned ultrasonically again with the same set of acceptance criteria to ensure freedom from any harmful defects.
137
SPECIFICATION FOR TRACK BALLAST
{As per correction slip no.4 issued by Rly.Bd.ltr.No.2006/CE-II/MB/2 dt.10.06.2016 is also incorporated
in Para 2.3.4, Para 5 and addition of new Annexure-IV}
1. SCOPE : RDSO specification for track ballast GE 1 June 2004 with all correction slips upto date
shall be applicable. These specifications will be applicable for stone ballast to be used for all
types of sleepers on normal track, turnouts, tunnels and deck slabs etc on all routes.
2. DETAILED SPECIFICATIONS:
2.1 GENERAL
2.1.1 Basic Quality: Ballast should be hard durable and as far as possible angular along edges/corners,
free from weathered potions of parent rock, organic impurities and inorganic residues.
2.1.2 Particle shape: Ballast should be cubical in shape as far as possible. Individual pieces should not
be flaky and should have generally flat faces with not more than two rounded/ sub rounded faces.
2.1.3 Mode of manufacture: Ballast for all BG main lines and running lines, except on „E' routes but
including 'E' special routes, shall be machine crushed. For other BG lines and MG/NG routes
planned/sanctioned for conversion, the ballast shall preferably be machine crushed. Hand broken
ballast can be used in exceptional, cases with prior approval of Chief Track Engineer/CAO/C.
Such approval shall be obtained prior invitation of tenders.
On other MG & NG routes not planned/sanctioned for conversion hand broken ballast can be
used for which no approval shall be required.
2.2 PHYSICAL PROPERTIES
2.2.1 Ballast sample should satisfy the following physical properties in accordance with IS: 2386 Pt
IV-1963 when tested as per the procedure given in Annexure- I & II.
BG,MG & NG planned/sanctioned for NG & MG (other than those
conversion planned for conversion)
Aggregate Abrasion value 30% Max* 35% Max
Aggregate Impact value 20% Max* 30% Max * In exceptional cases, on technical and/or economic grounds relax-able upto 35% and 25% respectively by CTE in open line and CAO/C for construction projects. The relaxation in
Abrasion and Impact values shall be given prior to invitation of tender and should be incorporated in the Tender document.
2.2.2 The „Water Absorption' tested as per IS 23S6 Pt.III-1963 following the procedure given in Annexure-III should not be more than 1 %. This test however, to be prescribed at the discretion of CE/CTE in open line and CAO(C) for construction projects.
2.3 SIZE AND GRADATION 2.3.1 Ballast should satisfy the following size and gradation:
a) Retained on 65mm Sq.mesh sieve 5% Maximum
b) Retained on 40mm Sq.mesh sieve 40 % - 60%
c) Retained on 20mm Sq.mesh sieve*. Not less than 98 % for machine crushed
Not less than 95 % for hand broken * For machine crushed ballast only.
2.3.2 Oversize ballast i) Retention on 65mm square mesh sieve.
A maximum of 5% ballast retained on 65mm sieve shall be allowed without deduction in payment.
In case ballast retained on 65mm sieve exceeds 5% but does not exceed 10%, payment
138
at 5% reduction in contracted rate shall be made for the full stack. Stacks having more than 10 % retention of ballast on 65mm sieve shall be rejected.
ii) In case ballast retained on 40mm square mesh sieve (machine crushed case only) exceeds 60% limit prescribed in 2.3.1 (b) above, payment at the following reduced rates shall be made for the full stack in addition to the reduction worked out at i) above.
5% reduction in contracted rates if retention on 40mm square mesh sieve is between 60% (excluding) and 65% (including).
10% reduction in contracted rates if retention on 40mm square mesh sieve is between 65% (excluding) and 70% (including).
In case retention on 40mm square mesh sieve exceeds 70%, the stack shall be rejected.
iii) In case of hand broken ballast supply, 40mm sieve analysis may not be carried out. The executive may however ensure that the ballast is well graded between 65mm and 20mm size.
2.3.3. Under size Ballast: The Ballast shall be treated as undersize and shall be rejected if:-
i) Retention on 40mm Sq Mesh sieve is less than 40%.
ii) Retention on 20mm square mesh sieve is less than 98%(for machine crushed) or
95% (for hand broken).
2.3.4. Sieve Analysis of Ballast - 2.3.4.1 The test sieves used for sieve analysis shall conform to the specifications given
in Annexure-IV. 2.3.4.2 While carrying out sieve analysis, the screen shall not be kept inclined, but held
horizontally and shaken vigorously. The pieces of ballast retained on the screen can be turned with hand to see if they pass through but should not be pushed through the sieve.
2.3.4.3 The percentage passing through or retained on the sieve shall be determined by weight. The weighing equipment used shall NOT have least count more than 100 grams.
3 CONDITIONS FOR SUBMISSION OF TENDER: NIL 4. METHOD OF MEASUREMENT:
4.1 STACK MEASUREMENT: Stacking shall be done on a neat, plain and firm ground with good drainage. The height of stack shall not be less than 1m except in hilly areas where it may be 0.55m. Top width of stack shall not be less than 1.0m. Top of stack shall be kept parallel to the ground plane. The side slopes of stack should not be flatter than 1.5:1 (Horizontal: Vertical) Cubical content of each stack shall normally be not less than 30 cum in plain areas and 15 cum in hilly areas.
4.2 Wagon Measurement In case of ballast supply taken by direct loading into wagons, a continuous white line should be painted inside the wagon to indicate the level to which the ballast should be loaded. The cubical content in cubic meter corresponding to white line should also be painted on both sides outside the wagon.
In addition to painted line, mentioned in para 4.2.1, short pieces of flats ("cut pieces of tie bars
or otherwise) with cubical contents punched shall be welded at the center of all the four sides
as permanent reference. In case the supply is taken in general service wagon, actual 4.3 Shrinkage Allowance :- Payment snail be made for the gross measurements either in stacks or
139
in stacks or in wagons without any deduction for shrinkage/voids. However, when ballast
supply is made in wagons, shrinkage upto 8 % shall be permitted at destination while verifying
the booked quantities by the consignee.
5. SAMPLING AND TESTING :
5.1 General :-
5.1.1 The samples shall be drawn with due diligence and adequate precaution so that they represent
the true nature and condition of the ballast.
5.1.2 Being a heterogeneous material, the gradation of ballast loaded in wagons and / or dumped /
inserted in the track may not remain same as that initially checked in stacks, due to lifting,
loading, transportation, unloading etc.. Similarly in case of direct loading into wagons, the
gradation of ballast at destination may not remain same as that at source, due to loading,
transportation etc.. Therefore, the samples from wagons and track are not representative
samples as far as gradation is concerned. Even in the same stack, results of two checks may
not be same.
5.1.3 The samples from a stack taken after lapse of a long period of stacking are not representative
samples of the ballast initially supplied in the stack, due to settling down of smaller size particles in voids underneath, dirt / dust getting accumulated in the stack, rains etc..
5.2 Sampling Frequency :- In order to ensure supply of uniform qualify of ballast, the following
norms shall be followed in respect of sampling, testing and acceptance.
5.2.1 On supply of the first 100 cum, the test for size and gradation, abrasion value impact value and
water absorption (if prescribed) shall be carried out by Railway. Further supply shall be
accepted only after this ballast satisfies the specifications for these tests. Railway reserves the
right to terminate the contract as per GCC at this stage itself in case the ballast supply falls to
confirm with any of these specifications.
5.2.2 Subsequent test shall be carried out as follows :-
Type of tests Supply in stacks Supply in Wagons
(a) Size and
Gradation Tests
One for each
100cum or part
thereof in any stack
One for each 100 cum or
part thereof for quanti ty
to be loaded in wagons.
(b) Abrasion Value,
Impart value and Water Absorption
Value (*)
One Test for every 2000 cum
(*) These tests shall be done for the purpose of monitoring qualify during supply. In case of the
test results not being as per the prescribed specifications at any stage, further supplies shall be
suspended till suitable corrective action is taken and supplies ensured as per specifications. The above tests may be carried out more frequently, at the discretion of Railway.
5.2.3 All tests for Abrasion Value, Impact Value and Water Absorption should be got done through
approved laboratories or Railway‟s own laboratories (list of these laboratories shall be
mentioned in the tender document). These tests, subsequent to award of contract, shall be done
at Railway‟s cost.
5.3 Supply of ballast in Stacks :-
5.3.1 Sampling procedure :-
i. At the time of formation of stacks, sufficient care should be taken to ensure that there is
sufficient space around the stack to facilitate movement of JCB / Power equipments. The
length and width of each stack shall be kept in such a way that every part of the stack is
accessible to the JCB or Power Equipment, to be deployed for drawing “Samples”.
ii. In case of ballast supply in stacks, three “Samples” each of 0.3-0.5 cum values, one sample
each from two sides and one sample from top after removing outer layer (150-200 mm) should
be collected from stack for every 100 cum or part thereof, by JCB or other suitable Power
140
Equipment.
iii. The location (in plan) and depths of sampling points shall be varied for different “Samples”
and different stacks in a lot.
iv. “Gross Sample” should be prepared by thoroughly mixing the three “Samples” collected as in
(ii) above, using JCB bucket or any other suitable Power Equipment, on a clean, flat and hard
surface.
Note :- In exceptional cases of site specific constraints, approval of competent authority
(Engineer-in-charge) shall be taken prior to invitation of tender, for using manual means for
collection and mixing of “Samples”, and this should be incorporated in the Tender Document.
v. A “Test Sample” of value 0.027 cum shall be drawn from each of the “Gross Sample”, by the
method described in Para 5.3.1 (vi), for carrying out Size & Gradation tests.
vi. Method for drawing “Test Sample” : The ballast in “Gross Sample” shall be scooped into a
cone shaped pile by taking care to drop each scoopful exactly over the same spot. After the
cone is formed, it shall be flattened by pressing the top of cone with a smooth surface. Then, it
is cut into quarters by two lines which intersect at right angles at the centre of the cone. The bulk of the sample is reduced by rejecting any two diagonally opposite quarters. The
remaining ballast shall be mixed and “test sample” shall be drawn for testing. After drawing
“test sample” test left over ballast of “Gross Sample” shall be dumped back in the stack.
vii. In case clean, flat and hard surface is not available then a tarpaulin or any other suitable sheet
may be used on a flat surface for mixing, drawing and sieve analysis of samples.
5.3.2 In case of stacks of values more than 100 cum, more than one “Test Samples” will be tested for
Size & Gradation. In such cases, the sieve analysis results of all the “Test Samples” shall
individually conform to following gradation, for acceptance / rejection of the whole stack :
i. Retention on 20mm Sq.Mech Sieve shall not be less than 98% for machine crushed
ballast (not less than 95% for hand broken ballast)
ii. Retention on 40mm Sq.MEch Sieve shall be between 40 to 70%.
iii. Retention on 65mm Sq.MEch Sieve shall not be more than 10%.
The full payment / reduced payment for the whole stack, as given in Para 2.3 of the
“Specifications for Track Ballast (IRS-GE-1, June-2004), shall be decided based on the
average of the sieve analysis results of all the “Test Samples” for a stack.
5.4 Supply of ballast in Heaps for loading directly in Wagons
5.4.1 Sampling Procedure :- Samples of ballast shall be collected from heaps of ballast proposed to
be loaded into the wagons. For this, the contractor shall inform Officer / Engineer-in-charge in
writing sufficiently in advance before placement of rake, about the locations of ballast heaps
from where it is to be loaded into wagons. Officer / Engineer-in-charge shall decide the
location of heaps from which sampling is to be done, judiciously covering the nature quantity
of ballast to be loaded in the rake.
5.4.2. Based on the approx. quantity of ballast to be loaded in the rake, methodology for sampling of
ballast to be followed shall be the same as in Para-5.3.1 and 5.3.2 above.
6. CESS SUPPLY :- 6.1 For ballast collection along with Cess & its running out instruction as given in para 267 of
IRPWM shall be adhered to. 6.2 Stacking area should be level, firm and with good drainage. Written permission for stacking shall
be certified by XEN/AXEN (test checked at items by Dy. CE(C)) on the ballast passing register. Each stack shall be so formed that ratio of longer to smaller side does not exceed 2.5 except for areas where there is constraint of land width in which case the ratio upto 3.5 may be permitted. The height of stack shall not be less than 1.0m except in hilly areas where it may be 0.5m. The height of stack shall not be more than 2.0m the side slopes of stack should not be less than 30 cum in plain areas and 15 cum in hilly areas.
141
6.3 The plots for ballast stacks should be selected by SSE/JE in-charge and approved by XEN/AXEN
and should be on level ground and at such locations from where lifting and leading of the ballast
into the truck required minimum effort. The supply contractor should level the area at his own
cost before stacking the ballast.
6.4 The quantity of ballast required in stretches of 100m length should be properly assessed and shall
usually be 2.455 cum per track meter for straight plain sections (without yards & curves). Extra
ballast required for curved lengths and yard lengths shall be advised in advance to the contractor. 6.5 In case of cess supply, cess supply sketch similar to depot sketch shall be drawn by SE/JE in-
charge of the section. The diagram shall reflect all the stacks available on the section clearly indicating the following by difference colour/hatching. (i) Stacks measured on that date and yet to be paid for, (ii) Stacks measured earlier not yet disturbed, (i) Stacks measured earlier and already disturbed, and (ii) Stacks where the supply is in progress.
ANNEXURE-I
Aggregate Abrasion Value (Based on IS: 2386 Part IV-1963) 1. Apparatus 1.1 The abrasion test for track ballast shall be carried out using Los-Angles Machine as per fig. 1. 1.2 The abrasive charge shall consist of 12 nos. cast iron or steel spheres approx. 48mn dia and each
weighing between 390 and 445 gm ensuring total weight of charge as 5,000 ± 25 gm. 1.3 IS sieves of sizes 50mm, 40mm, 25nun and 1.70mm.
1.4 Drying Oven
2. Test Sample
2.1 The test sample of 10,000gm shall consist of clean ballast conforming to the following grading: • Passing 50mm and retained on
40mm square mesh sieve 5,000 gm @ • Passing 40mm and retained on
25mm square mesh sieve 5,000 gm@ @ tolerance of ± 2 % permitted. 2.2 The sample shall be dried in oven at 100 - 110
0C to a constant weight and weighed (Weight
'A'). 3. Test Procedure
The test samples and the abrasive charge shall be placed in the Los-Angeles abrasion testing
machine and the machine rotated at a speed of 20-33 revolutions/minute for 1000 revolutions. At the completion of test, the material shall be discharged and sieved through 1.70mm IS sieve.
4. Analysis and reporting of the Result
The material coarser than 1.70mm IS sieve shall be washed, dried in oven at 100 - 110°C to a constant weight and weighed (weight B).
The proportion of loss between weight "A" and weight "B" of the test sample shall be expressed as a percentage of the original weight of the test sample. This value shall be reported as :-
A-B Aggregate Abrasion Value = -------------------------- X 100
A
*****
142
ANNEXURE-II Aggregate impact value (Based on 1S: 2386 Part IV-1963)
1. Apparatus :- The apparatus shall consist of the following
a) Impact testing machine conforming to IS: 2386 part IV-1963 as per ig 2. IS Sieve of sizes 12.5mm, 10mm and 2.36 mm. b) A cylindrical metal measure of 75mm dia & 50mm depth. c) A tamping rod 10mm circular cross section and 230mm length, rounded at one end. d) Drying Oven
2. Test Sample 2.1 The test sample shall be prepared out of track ballast so as to conform to following grading:
- Passing I2.5mm IS sieve 100% - Retention 10mm IS sieve 100%
2.2 The sample shall be oven dried for 4 hours at a temperature of 100-1100C & cooled.
2.3 The measure shall be filled about one -third full with the prepared aggregate and tamped with 25 strokes of the tamping rod. A further similar quantity of aggregate shall be added and a further tamping of 25 strokes given. The measure shall finally be filled to overflowing, tamped 25 times and the surplus aggregate struck off, using and tamping rod as a straight edge. The net weight of the aggregate in the measure shall be determined to the nearest gm {weight 'A').
3. Test Procedure 3.1 The cup of impact testing machine shall be fixed firmly in the position on the base of the machine
and the whole of the test sample placed in it and compacted by 25 strokes of the tamping rod. 3.2 The hammer shall be raised 380mm above the upper surface of the aggregate in the cup and
allowed to fall freely on to the aggregate. The test sample shall be subjected to a total of 15 such blows, each being delivered at an interval of not less than one second.
4. Analysis and Reporting of the result 4.1 The sample shall be removed and sieved through 2.36mm IS sieve. The fraction passing through
shall be weighed (Weight „B‟). The fraction retained on the sieve shall also be weighed (Weight „C‟) and if the total weight (B+C) is less than the initial weight (Weight „A‟) by more than one gm, the result shall be discarded and fresh test made.
4.2 The ratio of the weight of the fines formed to the total sample weight shall be expressed as a percentage. Aggregate Impact Value = (B/A) X 100
4.3 Two such tests shall be carried out and the mean of the results shall be reported to me nearest whole number as the Aggregate Impact Value of the tested material.
-//*//-
ANNEXURE-III
Water Absorption (Based on IS; 2386 Part 111-1963)
1. Apparatus :- The apparatus shall consist of the following : - a) Wire Basket- Perforated electroplated or plastic coated, with wire hangers for
suspending it from the balance. b) Water tight - container for suspending the basket. c) Dry soft Absorbent cloth 75x45 cm size 2 nos. d) Shallow Tray of minimum 650 square cm area. e) Airtight container of capacity similar to basket. f) Drying Oven.
2. Test Sample :- A sample of not less than 2000gm shall be used.
3. Test Procedure 3.1 The sample shall be thoroughly washed to remove finer particle and dust, drained and then
143
placed in the wire basket and immersed in distilled water at a temperature between 22-32cC.
After immersion the entrapped air shall be removed by lifting the basket and allowing it to drop 25 times in 25 seconds. The basket and sample shall remain immersed for a period of 24 ± 1/2hours afterwards.
The basket and aggregate shall then be removed from the water, allowed to drain for few
minutes, after which the aggregate shall be gently emptied from the basket on to one of dry
clothes and gently surface dried with the cloth transferring it to second dry cloth when the first
will remove no further moisture. The stone aggregate shall be spread on the second cloth and
exposed to atmosphere (away & from direct sunlight) until it appears to be completely surface
dry. The aggregate then shall be weighed (Weight 'A').
The aggregate shall then be placed in an oven at a temperature 100 - 110°C for 24 hours. It shall then be removed from oven, cooled and weighed (weight ‟B‟).
4. Analyses and Reporting of the Result Water Absorption = {(A-B)/ B} x l00
4.1 Two such tests snail be made and individual and mean results shall be reported.
*****
144
Annexure-IV
Specification of Test Sieves used for Sieve Analysis of Ballast
1. The test sieves shall be perforated plate sieve type with square holes / apertures, mounted on a
frame. The test sieves are designated by the nominal size of holes / apertures.
2. Material of Perforated Plate :- The perforated plate for test sieves shall be manufactured from
Brass Sheet or Steel Sheet or Stainless Steel Sheet or Galvanized Steel Sheet or Electroplated Steel
Sheet.
3. Plate Thickness :- The thickness of plate used for making test sieve and the tolerance permitted for
this shall be as following :-
For 65mm Square Mesh Sieve - 3mm (Plus 1.0mm Minus 0.5mm)
For 40mm Square Mesh Sieve - 2mm (Plus Minus 0.5mm)
For 20mm Square Mesh Sieve - 2mm (Plus Minus 0.5mm)
4. Arrangement of Holes / Apertures :- The square holes / apertures of size “W” in the perforated
plate shall be arranged at Pitch “P” as per the sketch given below :-
W p
w
5. Sieve Opening Size, Pitch of Openings and tolerances :- The nominal size of individual hole /
aperture at mid-section (W), the Pitch of holes / apertures (P) and permissible tolerance for them
shall be as under :-
Test Sieve of
Square Mesh
size
W P
Nominal
Size
Tolerance Distance Tolerance
65 mm 65 mm (±) 1.5 mm 80 mm (+) 12.0 mm
(-) 8.0 mm
40 mm 40 mm (±) 1.5 mm 50 mm (+) 7.5 mm
(-) 5.0 mm
20 mm 20 mm (±) 1.0 mm 25 mm (+) 4.0 mm
(-) 2.5 mm
6. Sieve Frame :- The frame of test sieves shall be manufactured from Hardwood or Steel sheet or
Brass sheet. The internal size of the frame (i.e. clear size of perforated plate mounted on frame)
shall not be less than 100cm in length, 70cvm in breadth and 10cm in height on sides.
7. Marking on test sieves :- A label shall be fixed to the frame of each sieve, legibly marked with
following information :-
i. Nominal Aperture Size,
ii. Material of perforated plate,
iii. Material of sieve frame,
iv. Maker‟s Name or Trademark, and
v. An Identification Number for the sieve.
146
AGREEMENT FOR WORKS
CONTRACT AGREEMENT No. Dt. .
Articles of Agreement made this ________day of______________2017 between the President of India acting through the Railway Administration hereinafter called the "Railway" of the one part and _________________________________________________ hereinafter called the "Contractors" of the other part.
WHEREAS the Contractor has agreed with the Railway for the performance of the work of “
As per NIT “
Set-forth in the schedule hereto annexed upon the General Conditions of Contract and the Specifications of the Central Railway and the special conditions and special specifications, if any and in conformity with the drawings hereunto annexed and whereas the performance of the said work is an act in which the public are interested.
Now this indenture witnessed that in consideration of the payments to be made by the Railway, the contractor will duly perform the said works in the said schedule set forth and shall execute the same with great promptness, care and accuracy in a workman like manner to the satisfaction of the Railway and will complete the same in accordance with the said specifications and said drawings of conditions of contract on or before the _______ day of ________________ and will maintain the said works for a period of ______________ calendar months from the certified date of their completion and will observe, fulfill and keep all the conditions therein mentioned (which shall be deemed and taken to be part of this contract as if the same had been fully set forth herein) and the Railway do hereby agree that if the Contractor shall duly perform the said works in the manner aforesaid and observe and keep the said terms and conditions, the Railway will pay or cause to be paid to the contractor for the said works onto final completion thereof the amount due in respect thereof at the rates specified in the schedule hereto annexed.
Chief Engineer (Const.), Central Railway, CSTM
For & On behalf of the President of India Date: ____________
Contractors Signature & Address …………………………………..
………………………………….. Signature of witnesses :
with address
1) ____________________ 2) ____________________
*****END OF TENDER DOCUMENT*****