ITD CEMENTATION INDIA LIMITED - BSE
-
Upload
khangminh22 -
Category
Documents
-
view
1 -
download
0
Transcript of ITD CEMENTATION INDIA LIMITED - BSE
Preliminary Placement Document
Subject to Completion
Not for circulation
Private and confidential
Serial No. ___
ITD CEMENTATION INDIA LIMITED
ITD Cementation India Limited was incorporated in the Republic of India on June 24, 1978 as a limited company under the Companies Act, 1956 with corporate identification
number L61000MH1978PLC020435. For details with respect to change of name, please see section “General Information” beginning on page 193.
Registered Office: National Plastic Building, A-Subhash Road, Paranjape B Scheme, Vile Parle (East), Mumbai, Maharashtra, 400057;
Tel: +91 22 6693 1600; Fax: +91 22 6693 1627/28
Website: www.itdcem.co.in Email:[email protected]
ITD Cementation India Limited (the “Company” or “Issuer”) is issuing [●] equity shares of face value ₹1 each (the “Equity Shares”) at a price of ₹[●] per Equity Share,
including a premium of ₹ [●] per Equity Share, aggregating to ₹[●] lakhs(the “Issue”).
ISSUE IN RELIANCE UPON CHAPTER VIII OF THE SECURITIES AND EXCHANGE BOARD OF INDIA (ISSUE OF CAPITAL AND DISCLOSURE
REQUIREMENTS) REGULATIONS, 2009, AS AMENDED (THE “SEBI ICDR REGULATIONS”) AND SECTION 42 OF THE COMPANIES ACT, 2013 AND
THE RULES MADE THEREUNDER.
THIS ISSUE AND THE DISTRIBUTION OF THIS PRELIMINARY PLACEMENT DOCUMENT IS BEING MADE TO QUALIFIED INSTITUTIONAL
BUYERS AS DEFINED UNDER THE SEBI ICDR REGULATIONS (“QIBs”) WHO IS AN IDENTIFID PERSON (DEFINED LATER) IN RELIANCE UPON
CHAPTER VIII OF THE SEBI ICDR REGULATIONS AND SECTION 42 OF THE COMPANIES ACT, 2013, READ WITH RULE 14 OF THE COMPANIES
(PROSPECTUS AND ALLOTMENT OF SECURITIES) RULES, 2014. THIS PRELIMINARY PLACEMENT DOCUMENT IS PERSONAL TO EACH
PROSPECTIVE BUYER AND DOES NOT CONSTITUTE AN OFFER OR INVITATION OR SOLICITATION OF AN OFFER TO THE PUBLIC OR TO ANY
OTHER PERSON OR CLASS OF INVESTORS WITHIN OR OUTSIDE INDIA OTHER THAN TO QIBs. THIS PRELIMINARY PLACEMENT DOCUMENT
WILL BE CIRULATED ONLY TO SUCH QIBs WHOSE NAMES ARE RECORDED BY OUR COMPANY PRIOR TO MAKING AN INVITATION TO
SUBSCRIBE TO EQUITY SHARES.
YOU MAY NOT AND ARE NOT AUTHORIZED TO (1) DELIVER THIS PRELIMINARY PLACEMENT DOCUMENT TO ANY OTHER PERSON; OR (2)
REPRODUCE THIS PRELIMINARY PLACEMENT DOCUMENT IN ANY MANNER WHATSOEVER. ANY DISTRIBUTION OR REPRODUCTION OF THIS
PRELIMINARY PLACEMENT DOCUMENT IN WHOLE OR IN PART IS UNAUTHORIZED. FAILURE TO COMPLY WITH THIS INSTRUCTION MAY
RESULT IN A VIOLATION OF THE SEBI ICDR REGULATIONS OR OTHER APPLICABLE LAWS OF INDIA AND OTHER JURISDICTIONS.
Invitations, offer and subscription of the Equity Shares shall only be made pursuant to this Preliminary Placement Document together with the Application Form, the
Confirmation of Allocation Note and the Placement Document. See the chapter titled “Issue Procedure” beginning on page 141. The distribution of this Preliminary Placement
Document or the disclosure of its contents without our Company’s prior consent to any person other than Qualified Institutional Buyers (as defined in the SEBI ICDR
Regulations) and persons retained by Qualified Institutional Buyers to advise them with respect to their purchase of the Equity Shares is unauthorized and prohibited. Each
prospective investor, by accepting delivery of this Preliminary Placement Document, agrees to observe the foregoing restrictions and not to make copies of this Preliminary
Placement Document or any documents referred to in this Preliminary Placement Document.
INVESTMENTS IN EQUITY SHARES INVOLVE A DEGREE OF RISK AND PROSPECTIVE INVESTORS SHOULD NOT INVEST IN THIS ISSUE UNLESS
THEY ARE PREPARED TO RISK LOSING ALL OR PART OF THEIR INVESTMENT. PROSPECTIVE INVESTORS ARE ADVISED TO CAREFULLY
READ THE CHAPTER TITLED “RISK FACTORS” BEGINNING ON PAGE 29 BEFORE MAKING AN INVESTMENT DECISION IN THIS ISSUE. EACH
PROSPECTIVE INVESTOR IS ADVISED TO CONSULT ITS OWN ADVISORS ABOUT THE PARTICULAR CONSEQUENCES TO IT OF AN INVESTMENT
IN THE EQUITY SHARES PROPOSED TO BE ISSUED PURSUANT TO THIS PRELIMINARY PLACEMENT DOCUMENT.
Our Company’s Equity Shares are listed on the BSE Limited (the “BSE”) and the National Stock Exchange of India Limited (the “NSE”) (the BSE and the NSE collectively
the “Stock Exchanges”). The closing price of the outstanding Equity Shares on the BSE and the NSE on January 24, 2018 was ₹ 210.80 and ₹ 210.55 per Equity Share,
respectively. We have received in-principle approval under Regulation 28 of the SEBI Listing Regulations to list our Equity Shares from the BSE and the NSE on January 24,
2018. Applications will be made for the listing of the Equity Shares offered through this Preliminary Placement Document on the Stock Exchanges. The Stock Exchanges
assume no responsibility for the correctness of any statements made, opinions expressed or reports contained herein. Admission of the Equity Shares to trade on the Stock
Exchanges should not be taken as an indication of the merits of the business of our Company or the Equity Shares.
OUR COMPANY HAS PREPARED THIS PRELIMINARY PLACEMENT DOCUMENT SOLELY FOR PROVIDING INFORMATION IN CONNECTION
WITH THE PROPOSED ISSUE.
A copy of this Preliminary Placement Document (which includes disclosures prescribed under Form PAS-4 (as defined hereinafter) has been delivered to the Stock Exchanges.
A copy of the Placement Document (which will include disclosures prescribed under Form PAS-4 (as defined hereinafter) will be filed with the Stock Exchanges. Our Company
shall also make the requisite filings with the Registrar of Companies, Mumbai (the “RoC”) and the Securities and Exchange Board of India (“SEBI”) within the stipulated
period as required under the Companies Act, 2013 and the Companies (Prospectus and Allotment of Securities) Rules, 2014.
This Preliminary Placement Document has not been reviewed by SEBI, the Reserve Bank of India (the “RBI”), the Stock Exchanges, the RoC or any other regulatory
or listing authority. The Equity Shares offered in this Issue have not been recommended or approved by SEBI, nor does SEBI guarantee the accuracy or adequacy
of this Preliminary Placement Document. This Preliminary Placement Document has not been and will not be registered as a prospectus with any Registrar of
Companies in India, will not be circulated or distributed to the public in India or any other jurisdiction and will not constitute a public offer in India or any other
jurisdiction. This Preliminary Placement Document will be circulated or distributed to Qualified Institutional Buyers (as defined in the SEBI ICDR Regulations),
only and will not constitute an offer to any other class of investors in India or any other jurisdiction. The placement of Equity Shares proposed to be made pursuant
to this Preliminary Placement Document is meant solely for QIBs on a private placement basis and is not an offer to the public or to any other class of investors.
The information on our Company’s website or any website directly or indirectly linked to our Company’s website or the websites of the Book Running Lead Manager or its
affiliates does not form part of this Preliminary Placement Document and prospective investors should not rely on such information contained in, or available through, such
websites.
The Equity Shares being offered and sold in this Issue have not been and will not be registered under the U.S. Securities Act of 1933, as amended (“U.S. Securities Act”), or
any state securities laws of the United States and may not be offered, sold or delivered within the United States except pursuant to an exemption from, or in a transaction not
subject to, the registration requirements of the U.S. Securities Act and applicable state securities laws in the United States. Accordingly, the Equity Shares are being offered
and sold outside the United States in “offshore transactions” (as defined under Regulation S under the U.S. Securities Act ("Regulation S")) in accordance with Regulation S
and the applicable laws of the jurisdictions where those offers and sales are made. For a description of these and certain further restrictions on offers, sales and transfers of the
Equity Shares and distribution of this Preliminary Placement Document, see “Notice to Investors”, “Distribution and Solicitation Restrictions” and “Transfer Restrictions”
beginning on pages 1, 153 and 159, respectively.
This Preliminary Placement Document is dated January 24, 2018.
SOLE BOOK RUNNING LEAD MANAGER
ICICI Securities Limited
Th
is P
reli
min
ary
Pla
cem
ent
Do
cum
ent
is n
ot
com
ple
te a
nd m
ay b
e ch
anged
. W
e m
ay n
ot
sell
any s
ecuri
ties
des
crib
ed h
erei
n o
r ac
cept
an o
ffer
to b
uy s
uch
sec
uri
ties
unti
l th
is P
reli
min
ary P
lace
men
t D
ocu
men
t is
del
iver
ed i
n f
inal
fo
rm.
Th
is P
reli
min
ary
Pla
cem
ent
Docu
men
t is
not
an o
ffer
to s
ell
any s
ecuri
ties
and i
s not
soli
citi
ng a
n o
ffer
to s
ubsc
ribe
for
or
buy s
ecuri
ties
in a
ny j
uri
sdic
tion w
her
e su
ch o
ffer
or
sale
is
not
per
mit
ted
.
TABLE OF CONTENTS
NOTICE TO INVESTORS .................................................................................................................................... 1
REPRESENTATIONS BY INVESTORS .............................................................................................................. 3
OFFSHORE DERIVATIVE INSTRUMENTS ...................................................................................................... 8
DISCLAIMER CLAUSE OF THE STOCK EXCHANGES ................................................................................. 9
ENFORCEMENT OF CIVIL LIABILITIES ....................................................................................................... 10
CERTAIN CONVENTIONS, CURRENCY PRESENTATION AND FINANCIAL DATA ................................ 11
INDUSTRY AND MARKET DATA .................................................................................................................... 12
FORWARD-LOOKING STATEMENTS ............................................................................................................ 13
EXCHANGE RATES ........................................................................................................................................... 15
DEFINITIONS AND ABBREVIATIONS ........................................................................................................... 16
DISCLOSURE REQUIREMENTS UNDER FORM PAS-4 PRESCRIBED UNDER THE COMPANIES ACT,
2013 ...................................................................................................................................................................... 21
SUMMARY OF THE ISSUE ............................................................................................................................... 23
SUMMARY OF BUSINESS ................................................................................................................................ 25
SUMMARY OF FINANCIAL INFORMATION ................................................................................................ 26
RISK FACTORS .................................................................................................................................................. 29
MARKET PRICE INFORMATION .................................................................................................................... 52
USE OF PROCEEDS ........................................................................................................................................... 55
CAPITALIZATION STATEMENT..................................................................................................................... 56
CAPITAL STRUCTURE ..................................................................................................................................... 57
DIVIDEND POLICY ........................................................................................................................................... 59
MANAGEMENT’S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS OF
OPERATIONS ..................................................................................................................................................... 60
SUMMARY OF KEY DIFFERENCES BETWEEN INDIAN GAAP AND IND AS ........................................ 86
INDUSTRY .......................................................................................................................................................... 93
OUR BUSINESS ................................................................................................................................................ 102
REGULATIONS AND POLICIES .................................................................................................................... 122
BOARD OF DIRECTORS AND SENIOR MANAGEMENT .......................................................................... 130
PRINCIPAL SHAREHOLDERS ....................................................................................................................... 138
ISSUE PROCEDURE ........................................................................................................................................ 141
PLACEMENT .................................................................................................................................................... 152
DISTRIBUTION AND SOLICITATION RESTRICTIONS ............................................................................. 153
TRANSFER RESTRICTIONS ........................................................................................................................... 159
INDIAN SECURITIES MARKET ..................................................................................................................... 162
DESCRIPTION OF THE EQUITY SHARES ................................................................................................... 166
TAXATION ....................................................................................................................................................... 171
LEGAL PROCEEDINGS ................................................................................................................................... 177
INDEPENDENT ACCOUNTANTS .................................................................................................................. 192
GENERAL INFORMATION ............................................................................................................................. 193
FINANCIAL STATEMENTS ............................................................................................................................ 194
DECLARATION ................................................................................................................................................ 301
DECLARATION IN ACCORDANCE WITH FORM PAS - 4 ......................................................................... 302
1
NOTICE TO INVESTORS
Our Company has furnished and accepts full responsibility for all of the information contained in this Preliminary
Placement Document and to the best of its knowledge and belief, having made all reasonable enquiries, we confirm
that this Preliminary Placement Document contains all information with respect to our Company, its Subsidiary
and the Equity Shares, which is material in the context of this Issue. The statements contained in this Preliminary
Placement Document relating to our Company, its Subsidiary and the Equity Shares are, in all material respects,
true and accurate and not misleading. The opinions and intentions expressed in this Preliminary Placement
Document with regard to our Company, its Subsidiary and the Equity Shares are honestly held, have been reached
after considering all relevant circumstances, are based on information presently available to us, and on reasonable
assumptions. There are no other facts in relation to our Company, its Subsidiary and the Equity Shares, the
omission of which would, in the context of this Issue, make any statement in this Preliminary Placement Document
misleading in any material respect. Further, all reasonable enquiries have been made by our Company to ascertain
such facts and to verify the accuracy of all such information and statements.
The Book Running Lead Manager ("BRLM") has made reasonable inquiries but has not separately verified all
the information contained in this Preliminary Placement Document (financial, legal or otherwise). Accordingly,
neither the BRLM nor any of its shareholders, employees, legal counsels, officers, directors, representatives,
agents or affiliates makes any express or implied representation, warranty or undertaking, and no responsibility
or liability is accepted by the BRLM, or by any of its shareholders, employees, legal counsels, officers, directors,
representatives, agents or affiliates as to the accuracy or completeness of the information contained in this
Preliminary Placement Document or any other information supplied in connection with the issue of the Equity
Shares or their distribution. Each person receiving this Preliminary Placement Document acknowledges that such
person has neither relied on the BRLM nor on any of its shareholders, employees, legal counsels, officers,
directors, representatives, agents or affiliates or on any person affiliated with the BRLM in connection with its
investigation of the accuracy of such information, representation or its investment decision, and each such person
must rely on its own examination of our Company, its Subsidiary and the merits and risks involved in investing
in the Equity Shares issued pursuant to the Issue.
No person is authorized to give any information or to make any representation not contained in this Preliminary
Placement Document and any information or representation not so contained must not be relied upon as having
been authorized by or on behalf of our Company or the BRLM. The delivery of this Preliminary Placement
Document at any time does not imply that the information contained in it is correct as of any time subsequent to
its date.
The distribution of this Preliminary Placement Document or the disclosure of its contents without the prior consent
of our Company to any person, other than QIBs specified by the Book Running Lead Manager or its
representatives, and those retained by such QIBs to advise them with respect to their purchase of the Equity Shares
is unauthorised and prohibited. Each prospective investor, by accepting delivery of this Preliminary Placement
Document, agrees to observe the foregoing restrictions and to make no copies of this Preliminary Placement
Document or any documents referred to in this Preliminary Placement Document.
The Equity Shares to be issued pursuant to the Issue have not been approved, disapproved or recommended
by any regulatory authority in any jurisdiction including the U.S. Securities and Exchange Commission,
any other federal or state authorities in the United States the securities authorities of any non-United States
jurisdiction or any other United States or non-United States regulatory authority. No authority has passed
on or endorsed the merits of the Issue or the accuracy or adequacy of this Preliminary Placement
Document. Any representation to the contrary may be a criminal offence in the United States and may be
a criminal offence in other jurisdictions.
The Equity Shares have not been and will not be registered, listed or otherwise qualified in any other
jurisdiction outside India and may not be offered or sold, and Bids may not be made by persons in any
jurisdiction, except in compliance with the applicable laws of such jurisdiction.
The Equity Shares have not been and will not be registered under the U.S. Securities Act, or any state
securities laws of the United States and unless so registered may not be offered, sold or delivered within the
United States except pursuant to an exemption from, or in a transaction not subject to, the registration
requirements of the U.S. Securities Act and applicable U.S. state securities laws. Accordingly, the Equity
Shares are only being offered and sold outside the United States in offshore transactions in reliance on
Regulation S and the applicable laws of the jurisdictions where those offers and sales are made. For a
2
description of these and certain further restrictions on offers, sales and transfers of the Equity Shares and
distribution of this Preliminary Placement Document, see “Distribution and Solicitation Restrictions” and
“Transfer Restrictions” beginning on pages 153 and 159, respectively.
This Preliminary Placement Document does not constitute, and may not be used for or in connection with, an offer
or solicitation by anyone in any jurisdiction in which such offer or solicitation is not authorized or to any person
to whom it is unlawful to make such offer or solicitation. In particular, no action has been taken by our Company
and the BRLM which would permit an offering of the Equity Shares or distribution of this Preliminary Placement
Document in any country or jurisdiction, other than India, where action for that purpose is required. Accordingly,
the Equity Shares in this Issue may not be offered or sold, directly or indirectly, and neither this Preliminary
Placement Document nor any other Issue related materials in connection with the Equity Shares, may be
distributed or published in or from any country or jurisdiction, except under circumstances that will result in
compliance with any applicable rules and regulations of any such country or jurisdiction. The Equity Shares are
being offered and sold outside India only in accordance with the restrictions described under the sections titled
“Distribution and Solicitation Restrictions” and “Transfer Restrictions” beginning on pages 153 and 159,
respectively.
The information contained in this Preliminary Placement Document has been provided by our Company and other
sources identified herein. Distribution of this Preliminary Placement Document to any person other than the
investors specified by the BRLM or its representatives, and those persons, if any, retained to advise such investor
with respect thereto, is unauthorised, and any disclosure of its contents, without prior written consent of our
Company, is prohibited. Any reproduction or distribution of this Preliminary Placement Document, in whole or
in part, and any disclosure of its contents to any other person is prohibited. The distribution of this Preliminary
Placement Document and the issue of the Equity Shares in certain jurisdictions may be restricted by law.
Any reproduction or distribution of this Preliminary Placement Document in the United States, in whole or in
part, and any disclosure of its contents to any other person is prohibited.
In making an investment decision, prospective investors must rely on their own examination of our Company, its
Subsidiary and the terms of this Issue, including the merits and risk involved. Investors should not construe the
contents of this Preliminary Placement Document as business, investment, legal, tax, accounting or investment
advice. Investors should consult their own counsel and advisors as to business, legal, tax, accounting and related
matters concerning this Issue. In addition, neither our Company nor the BRLM is making any representation to
any investor, purchaser, offeree or subscriber of such Equity Shares pursuant to this Issue, regarding the legality
of an investment in the Equity Shares in this Issue by such investor, purchaser, offeree or subscriber under
applicable legal, investment or similar laws or regulations. Each such investor, subscriber, offeree or purchaser of
the Equity Shares in this Issue is deemed to have acknowledged, represented and agreed that they are eligible to
invest in India and in our Company under Indian law, including Chapter VIII of the SEBI ICDR Regulations and
Section 42 of the Companies Act, 2013, and that it is not prohibited by SEBI or any other statutory, regulatory or
judicial authority in India or any other jurisdiction from buying, selling or dealing in the securities or otherwise
accessing the capital markets in India including the Equity Shares. Each subscriber of the Equity Shares in this
Issue also acknowledges that it has been afforded an opportunity to request from our Company and review
information relating to our Company and the Equity Shares.
This Preliminary Placement Document contains summaries of certain terms of certain documents, which
summaries are qualified in their entirety by the terms and conditions of such documents. All references herein to
“you” or “your” is to the prospective investors of the Issue.
The information on our Company's website, www.itdcem.co.in, or any website directly or indirectly linked to our
Company's website or the website of the BRLM or its affiliates does not constitute or form part of this Preliminary
Placement Document. Prospective investors should not rely on such information contained in, or available
through, such websites.
3
REPRESENTATIONS BY INVESTORS
References herein to "you" or "your" in this section are to the prospective investors in this Issue. By bidding for
and/or subscribing to any Equity Shares under this Issue, you are deemed to have represented, warranted and
acknowledged to our Company and the BRLM, as follows:
You are a QIB as defined under Regulation 2(1)(zd) of the SEBI ICDR Regulations, and not excluded
pursuant to Regulation 86(1)(b) of the SEBI ICDR Regulations, having a valid and existing registration
under applicable laws and regulations of India, and undertake to acquire, hold, manage or dispose of any
Equity Shares that are allocated to you for the purposes of your business in accordance with Chapter VIII
of the SEBI ICDR Regulations, the Companies Act and all other applicable laws, including reporting
obligations;
You are authorized to consummate the subscription of the Equity Shares in this Issue in compliance with
all applicable laws and regulations;
You are eligible to invest in India under the applicable law, including the Foreign Exchange Management
(Transfer or Issue of Security by a Person Resident Outside India) Regulations, 2000 (“FEMA 20”) and
any notifications, circulars or clarifications issued thereunder, and have not been prohibited by SEBI or
any other regulatory authority, statutory authority or otherwise, from buying, selling or dealing in
securities;
If you are not a resident of India, but a QIB or you are an Eligible FPI (as defined hereinafter) or an FII
(including a sub-account other than a sub-account which is a foreign corporate or a foreign individual)
or an FVCI, in each case having a valid and existing registration with the SEBI under the applicable laws
in India or a multilateral or bilateral development financial institution, and are eligible to invest in India
under applicable law, including the Foreign Exchange Management (Transfer or Issue of Security by a
Person Resident Outside India) Regulations, 2000, as amended, and any notifications, circulars or
clarifications issued thereunder, and have not been prohibited by the SEBI or any other regulatory
authority, from buying, selling or dealing in securities;
You will make all necessary filings with appropriate regulatory authorities, including RBI, as required
pursuant to applicable laws;
If you are allotted Equity Shares pursuant to this Issue, you shall not, for a period of one year from the
date of Allotment, sell the Equity Shares so acquired, except on the floor of the Stock Exchanges, see the
chapter titled “Transfer Restrictions” beginning on page 159;
You have made, or been deemed to have made, as applicable, the representations set forth under the
chapters titled “Distribution and Solicitation Restrictions” and “Transfer Restrictions” beginning on
pages 153and 159, respectively;
You are aware that the Equity Shares have not been, and will not be, registered through a prospectus with
ROC, under the Companies Act (as defined hereunder), the SEBI ICDR Regulations or under any other
law in force in India. This Preliminary Placement Document has not been verified or affirmed by the
SEBI, RBI, the Stock Exchanges, RoC or any other regulatory or listing authority and is intended only
for use by QIBs. This Preliminary Placement Document has been filed with the Stock Exchanges and
will be displayed on the websites of our Company and the Stock Exchanges. Our Company shall make
the requisite filings with the RoC and the SEBI within the stipulated period as required under the
Companies Act, 2013 and the Companies (Prospectus and Allotment of Securities) Rules, 2014;
You are aware that additional requirements would be applicable if you are in jurisdictions other than
India, as set forth under sections “Distribution and Solicitation Restrictions” and “Transfer Restrictions”
of Preliminary Placement Document and you are entitled to acquire the Equity Shares under the laws of
all relevant jurisdictions and that you have all necessary capacity and have obtained all necessary
consents and authorities to enable you to commit to your participation in this Issue and to perform your
obligations in relation thereto (including, without limitation, in the case of any person on whose behalf
you are acting, all necessary consents and authorities to agree to the terms set out or referred to in this
Preliminary Placement Document) and will honour such obligations;
4
You confirm that, either: (i) you have not participated in or attended any investor meetings or
presentations by our Company or our agents ("Company Presentations") with regard to our Company
or the Issue; or (ii) if you have participated in or attended any Company Presentations: (a) you understand
and acknowledge that the BRLM may not have knowledge of the statements that our Company or our
agents may have made at such Company Presentations and are therefore unable to determine whether the
information provided to you at such Company Presentations may have included any material
misstatements or omissions and accordingly you acknowledge that the BRLM has advised you not to
rely in any way on any information that was provided to you at such Company Presentations, and (b)
confirm that, to the best of your knowledge, you have not been provided any material information that
was not publicly available;
Neither our Company nor the BRLM or their respective shareholders, directors, officers, employees,
counsel, representatives, agents or affiliates are making any recommendation to you or advising you
regarding the suitability of any transactions that you may enter into in connection with the Issue. Your
participation in this Issue is on the basis that you are not and will not be a client of the BRLM. Neither
the BRLM nor any of their shareholders, directors, officers, employees, counsel, representatives, agents
or affiliates do not have any duty or responsibility to you for providing the protection afforded to its
clients or customers or for providing advice in relation to the Issue and is in no way acting in a fiduciary
capacity;
You are aware and understand that the Equity Shares are being offered only to QIBs and are not being
offered to the general public. Further, you are aware and understand that the allotment of the Equity
Shares shall be on a discretionary basis at the discretion of our Company in consultation with the BRLM;
You have made, or been deemed to have made, as applicable, the representations set forth under
"Distribution and Solicitation Restrictions" and "Transfer Restrictions" beginning on pages 153and
159,respectively;
You have been provided a serially numbered copy of this Preliminary Placement Document and have
read this Preliminary Placement Document in its entirety; including, in particular, the chapter titled "Risk
Factors" beginning on page 29;
That in making your investment decision, (i) you have relied on your own examination of our Company,
its Subsidiary and the terms of this Issue, including the merits and risks involved, (ii) you have made and
will continue to make your own assessment of our Company, its Subsidiary, the Equity Shares and the
terms of this Issue, (iii) you have relied upon your own investigations and resources in deciding to invest
in the Equity Shares, (iv) you have consulted with your own independent counsel and advisors or
otherwise have satisfied yourself concerning, without limitation, the effects of local laws, including any
applicable securities law and (v) you have relied solely on the information contained in this Preliminary
Placement Document and no other disclosure or representation by our Company or any other party and
(vi) you have received all information that you believe is necessary or appropriate or relevant in order to
make an informed investment decision in respect of our Company and the Equity Shares;
You are aware that the pre-issue and post-issue shareholding pattern of our Company will be filed by our
Company with the Stock Exchanges, and if you are Allotted more than 5% of the Equity Shares in the
Issue, our Company shall be required to disclose your name and the number of the Equity Shares allotted
to you to the Stock Exchanges and the Stock Exchanges will make the same available on their websites
and by subscribing to this Issue, you consent to such disclosures; also, if you are a top ten shareholder in
our Company, our Company will be required to make a filing with the RoC within 15 days of the change,
as per provisions of Section 93 of the Companies Act, 2013;
Neither the BRLM nor any its shareholders, directors, officers, employees, counsel, representatives,
agents or affiliates, have provided you with any tax advice or otherwise made any representations
regarding the tax consequences of the Equity Shares (including but not limited to this Issue and the use
of the proceeds from the Equity Shares). You will obtain your own independent tax advice from a
reputable service provider and will not rely on the BRLM or any of its shareholders, directors, officers,
employees, counsel, representatives, agents or affiliates when evaluating the tax consequences in relation
to the Equity Shares (including but not limited to this Issue and the use of the proceeds from the Equity
Shares). You waive, and agree not to assert, any claim against our Company, the BRLM, or any of their
shareholders, directors, officers, employees, counsel, representatives, agents or affiliates with respect to
5
the tax aspects of the Equity Shares or as a result of any tax audits by tax authorities, wherever situated;
If you are acquiring the Equity Shares to be issued pursuant to this Issue, for one or more managed
accounts, you represent and warrant that you are authorised in writing by each such managed account to
subscribe to the Equity Shares for each managed account and to make (and you hereby make) the
representations, warranties, acknowledgements and agreements herein for and on behalf of each such
account, reading the reference to "you" to include such accounts;
You are not a promoter of our Company, as defined under Section 2(69) of the Companies Act, 2013 and
the SEBI ICDR Regulations, and are not a person related to the Promoter or to group companies of the
Promoter, either directly or indirectly and your Bid does not directly or indirectly represent the Promoter
or Promoter Group or persons related to the Promoter of our Company or to group companies of the
Promoter of our Company;
You have no rights under any shareholders' agreement or voting agreement with the Promoter or persons
related to the Promoter, no veto rights or right to appoint any nominee director on the Board of Directors
of our Company other than such rights acquired in the capacity of a lender not holding any Equity Shares
of our Company, which shall not be deemed to be a person related to the Promoter;
You have no right to withdraw your Bid after the Bid/Issue Closing Date (as defined hereinafter);
You are eligible, including without any limitation under any applicable law or regulation, to apply for
and hold the Equity Shares allotted to you together with any Equity Shares held by you prior to this Issue.
You further confirm that your aggregate holding upon such issue of the Equity Shares shall not exceed
the level permissible, as per any applicable law or regulation;
The Bids submitted by you would not eventually result in triggering a tender offer under the Securities
and Exchange Board of India (Substantial Acquisition of Shares and Takeovers) Regulations, 2011, as
amended (the "Takeover Code");
To the best of your knowledge and belief, together with other QIBs in the Issue that belong to the same
group or are under common control as you, the allotment under the present Issue shall not exceed 50%
of the Issue. For the purposes of this representation: (a) the expression 'belong to the same group' shall
derive meaning from the concept of 'companies under the same group' as provided in sub-section (11) of
Section 372 of the Companies Act, 1956 (the "Companies Act"); and (b) "control" shall have the same
meaning as is assigned to it by Regulation 2(1)(e) of the Takeover Code;
You are aware that in-principle approvals for listing and admission of the Equity Shares under Regulation
28 of the SEBI Listing Regulations have been applied for with the Stock Exchanges and application for
final listing and trading approval shall be made only after allotment of Equity Shares. There can be no
assurance that such final approvals for listing and trading in the Equity Shares will be obtained in time,
or at all. Our Company shall not be responsible for any delay or non-receipt of such final approvals or
any loss arising from such delay or non-receipt;
You are aware and understand that the BRLM has entered into a Placement Agreement with our
Company whereby the BRLM has, subject to the satisfaction of certain conditions set out therein, agreed
to manage the Issue and use reasonable efforts to procure subscriptions for the Equity Shares on the terms
and conditions set forth therein;
That the contents of this Preliminary Placement Document are exclusively the responsibility of our
Company and that neither the BRLM nor any person acting on its behalf has, or shall have, any liability
for any information, representation or statement contained in this Preliminary Placement Document or
any information previously published by or on behalf of our Company and will not be liable for your
decision to participate in this Issue based on any information, representation or statement contained in
this Preliminary Placement Document or otherwise. By accepting a participation in this Issue, you agree
and confirm that you have neither received nor relied on any other information, representation, warranty
or statement made by or on behalf of the BRLM or our Company or any other person and, to the greatest
extent permitted by law, neither the BRLM nor our Company nor any other person will be liable for your
decision to participate in this Issue based on any other information, representation, warranty or statement
that you may have obtained or received, whether contained in this Preliminary Placement Document or
6
otherwise;
As stated in the preceding clause herein, the only information you are entitled to rely on, and on which
you have relied on, in committing yourself to acquire the Equity Shares is contained in this Preliminary
Placement Document, such information being all that you deem necessary to make an investment
decision in respect of the Equity Shares. You have neither received nor relied on any other information
given or representations, warranties or statements made by the BRLM (including any view, statement,
opinion or representation expressed in any research published or distributed by the BRLM or their
respective affiliates or any view, statement, opinion or representation expressed by any staff (including
research staff) of the BRLM or its affiliates) or our Company and the BRLM or any of their respective
shareholders, directors, officers, employees, counsels, advisors, representatives, agents or affiliates will
not be liable for your decision to accept an invitation to participate in this Issue based on any other
information, representation, warranty or statement;
You agree to indemnify, keep indemnified and hold our Company and the BRLM and their respective
officers, directors, affiliates, associates and representatives harmless from any and all costs, claims,
liabilities and expenses (including legal fees and expenses) arising out of or in connection with any breach
of the representations and warranties in this section and the chapters titled "Distribution and Solicitation
Restrictions" and "Transfer Restrictions" beginning on pages 153and 159, respectively. You agree that
the indemnity set forth in this paragraph shall survive the resale of the Equity Shares by or on behalf of
the managed accounts;
That our Company, the BRLM, and their respective affiliates and others will rely on the truth and
accuracy of the foregoing representations, warranties, acknowledgements and undertakings, which are
irrevocable;
You understand that the BRLM does not have any obligation to purchase or acquire all or any part of the
Equity Shares purchased by you in this Issue or to support any losses directly or indirectly sustained or
incurred by you for any reason whatsoever in connection with this Issue, including non-performance by
our Company of any of our respective obligations or any breach of any representations or warranties by
our Company, whether to you or otherwise;
That each of the representations, warranties and acknowledgements set out above shall continue to be
true and accurate at all times up to and including the allotment of the Equity Shares and the listing and
commencement of trading of Equity Shares, wherever the context may require.
You agree that any dispute arising in connection with this Issue will be governed by and construed in
accordance with the laws of India, and the courts in Mumbai, India shall have exclusive jurisdiction to
settle any disputes applicable which may arise out of or in connection with this Preliminary Placement
Document and the Placement Document;
You understand that the Equity Shares have not been and will not be registered under the U.S. Securities
Act or with any securities regulatory authority of any state of the United States, and accordingly, may
not be offered, sold or delivered within the United States, except pursuant to an exemption from, or in a
transaction not subject to, the registration requirements of the U.S. Securities Act, and that the Equity
Shares are only being offered and sold outside the United States in offshore transactions in reliance on
Regulation S of the U.S. Securities Act;
You are, at the time the Equity Shares are purchased, located outside the United States (within the
meaning of Regulation S), and you are not an affiliate of the Company or a person acting on behalf of
the Company or such an affiliate;
You are not acquiring or subscribing for the Equity Shares as a result of any directed selling efforts (as
defined in Regulation S) and you understand and agree that offers and sales are being made only outside
the United States in offshore transactions in reliance on Regulation S;
You have made, or been deemed to have made, as applicable, the representations, warranties,
acknowledgments and agreements set forth in this section and in “Distribution and Solicitation
Restrictions” and “Transfer Restrictions” on pages 153 and 159, respectively; and
7
You are purchasing the Equity Shares in an offshore transactions meeting the requirements of Rule 903
or 904 of Regulation S and you shall not offer, sell, pledge or otherwise transfer such Equity Shares
except in an offshore transaction complying with Regulation S or pursuant to any other available
exemption from registration under the U.S. Securities Act and in accordance with all applicable securities
laws of the states of the United States and any other jurisdiction, including India.
8
OFFSHORE DERIVATIVE INSTRUMENTS
Subject to compliance with all applicable Indian laws, rules, regulations, guidelines and approvals in terms of
Regulation 22 of the SEBI FPI Regulations (as defined hereinafter), FPIs (which includes FIIs), other than
Category III Foreign Portfolio Investor (as defined hereinafter) and unregulated broad based funds, which are
classified as Category II foreign portfolio investor (as defined under the SEBI FPI Regulations) by virtue of their
investment manager being appropriately regulated, may issue, subscribe or otherwise deal in offshore derivative
instruments (as defined under the SEBI FPI Regulations as any instrument, by whatever name called, which is
issued overseas by an FPI against securities held by it that are listed or proposed to be listed on any recognised
stock exchange in India, as its underlying) (all such offshore derivative instruments are referred to herein as "P-
Notes") directly or indirectly, only in the event that (i) such offshore derivative instruments are issued only in
favour of those entities which are regulated by any appropriate foreign regulatory authorities in the countries of
their incorporation; and (ii) such offshore derivative instruments are issued after compliance with ‘know your
client’ norms. An FPI is also required to ensure that no issue or transfer of any offshore derivative instrument is
made by or on behalf of it to any persons that are not regulated by an appropriate foreign regulatory authority.
P-Notes have not been and are not being offered or sold pursuant to this Preliminary Placement Document. Neither
this Preliminary Placement Document nor the Placement Document contains or will contain any information
concerning P-Notes, or the issuer(s) of any such P-Notes, including, without limitation, any information regarding
any risk factors relating thereto.
Any P-Notes that may be issued are not securities of our Company and do not constitute any obligations of, claims
on, or interests in our Company. Our Company has not participated in any offer of any P-Notes, or in the
establishment of the terms of any P-Notes, or in the preparation of any disclosure related to any P-Notes. Any P-
Notes that may be offered are issued by, and are solely the obligations of, third parties that are unrelated to our
Company. Our Company does not make any recommendation as to any investment in P-Notes and does not accept
any responsibility whatsoever in connection with any P-Notes.
Any P-Notes that may be issued are not securities of the BRLM and do not constitute any obligations of, or claims
on, the BRLM. Affiliates of the BRLM which are FPIs may purchase, to the extent permissible under law, the
Equity Shares in this Issue, and may issue P-Notes in respect thereof.
Prospective investors interested in purchasing any P-Notes have the responsibility to obtain adequate
disclosure as to the issuer(s) of such P-Notes and the terms and conditions of any such P-Notes from the
issuer(s) of such P-Notes. Neither SEBI nor any other regulatory authority has reviewed or approved any
P-Notes or any disclosure related thereto. Prospective investors are urged to consult with their own
financial, legal, accounting and tax advisors regarding any contemplated investment in P-Notes, including
whether P-Notes are issued in compliance with applicable laws and regulations.
9
DISCLAIMER CLAUSE OF THE STOCK EXCHANGES
As required, a copy of this Preliminary Placement Document has been submitted to each of the Stock Exchanges.
The Stock Exchanges do not in any manner:
(1) warrant, certify or endorse the correctness or completeness of any of the contents of this Preliminary
Placement Document;
(2) warrant that our Company's Equity Shares issued pursuant to this Issue will be listed or will continue to
be listed on the Stock Exchanges; or
(3) take any responsibility for the financial or other soundness of our Company, its Promoter, its management
or any scheme or project of our Company;
The filing of this Preliminary Placement Document should not for any reason be deemed or construed to mean
that this Preliminary Placement Document has been cleared or approved by the Stock Exchanges. Every person
who desires to apply for or otherwise acquires any Equity Shares of our Company pursuant to this Issue may do
so pursuant to an independent inquiry, investigation and analysis and shall not have any claim against the Stock
Exchanges whatsoever by reason of any loss which may be suffered by such person consequent to or in connection
with such subscription/acquisition, whether by reason of anything stated or omitted to be stated herein or for any
other reason whatsoever.
10
ENFORCEMENT OF CIVIL LIABILITIES
Our Company is a public limited company incorporated under the laws of India and its shares are listed on the
Stock Exchanges. The Board of Directors of our Company comprises eight (8) Directors out of which 3 are Indian
citizens, 4 are citizens of Thailand and 1 Director is a citizen of Sweden. Most of our senior managerial personnel
and executive officers of our Company are residents of India and a substantial portion of the assets of such persons
and of our Company are located in India. As a result, it may be difficult or may not be possible for investors to
effect service of process upon our Company or such persons outside India or to enforce judgments obtained against
such parties outside India.
Recognition and enforcement of foreign judgments is provided for under Section 13 and Section 44A of the Code
of Civil Procedure, 1908 (the “Civil Code”) on a statutory basis. Section 13 of the Civil Code provides that a
foreign judgment shall be conclusive regarding any matter directly adjudicated upon between the same parties or
parties litigating under the same title, except:
(a) where the judgment has not been pronounced by a court of competent jurisdiction;
(b) where the judgment has not been given on the merits of the case;
(c) where it appears on the face of the proceedings that the judgment is founded on an incorrect view of
international law or a refusal to recognize the law of India in cases to which such law is applicable;
(d) where the proceedings in which the judgment was obtained were opposed to natural justice;
(e) where the judgment has been obtained by fraud; or
(f) where the judgment sustains a claim founded on a breach of any law than in force in India.
Under the Civil Code, a court in India shall, upon the production of any document purporting to be a certified
copy of a foreign judgment, presume that the judgment was pronounced by a court of competent jurisdiction,
unless the contrary appears on record.
India is not a signatory to any international treaty in relation to the recognition or enforcement of foreign
judgments. However Section 44A of the Civil Code provides that where a foreign judgment has been rendered by
a superior court (within the meaning of such Section), in any country or territory outside India which the
Government has by notification declared to be a reciprocating territory, it may be enforced in India by proceedings
in execution as if the judgment had been rendered by the relevant court in India. However, Section 44A of the
Civil Code is applicable only to monetary decrees not being of the same nature as amounts payable in respect of
taxes, other charges of a like nature or of a fine or other penalties and does not include arbitration awards.
A few countries like the United Kingdom of Great Britain and Northern Ireland, Republic of Singapore and Hong
Kong, amongst others, have been declared by the Central Government to be reciprocating territories for the
purposes of Section 44A and do not include arbitration awards.
A judgment of a court in a country which is not a reciprocating territory may be enforced only by a suit upon the
judgment and not by proceedings in execution. Such a suit must be filed in India within three years from the date
of the foreign judgment in the same manner as any other suit filed to enforce a civil liability in India. It is unlikely
that a court in India would award damages on the same basis as a foreign court if an action was brought in India.
Furthermore, it is unlikely that an Indian court would enforce foreign judgments if that court were of the view that
the amount of damages awarded was excessive or inconsistent with the public policy of India. Further, any
judgment or award for payment of amounts denominated in a foreign currency would be converted into Rupees
on the date of such judgment or award and not on the date of payment. A party seeking to enforce a foreign
judgment in India must obtain approval from the RBI to execute such a judgment or to repatriate outside India
any amount recovered, and we cannot assure that such approval will be forthcoming within a reasonable period
of time, or at all, or that conditions of such approvals would be acceptable. It is unlikely that an Indian court would
enforce foreign judgments that would be contrary to or in violation of Indian law. We cannot assure you that
Indian courts and/or authorities would not take a longer amount of time to adjudicate and conclude similar
proceedings in their respective jurisdictions.
11
CERTAIN CONVENTIONS, CURRENCY PRESENTATION AND FINANCIAL DATA
Certain Conventions
In this Preliminary Placement Document, unless the context otherwise indicates or implies, references to ‘you’,
‘your’, ‘offeree’, ‘purchaser’, ‘subscriber’, ‘recipient’, ‘investors’, ‘prospective investors’, ‘QIBs’ and ‘potential
investor’ are to the prospective investors of the Equity Shares to be issued pursuant to the Issue. References to the
‘Company’, or ‘Issuer’ ‘our Company’ are to ITD Cementation India Limited, and references to ‘we’, ‘our’ or
‘us’ are to ITD Cementation India Limited and its Subsidiaries. All references in this Preliminary Placement
Document to “India” are to the Republic of India, to the “Government” or the “Central Government” are to the
Government of India and to any “State Government” are to the relevant state government in India. All references
herein to the “U.S.” or the “United States” are to the United States of America and its territories and possessions.
Currency Presentation
In this Preliminary Placement Document, all references to "Rupees", "₹", “Re.” and "Rs." are to the currency of
India. All references to "U.S. dollars", "dollars", "$", "USD" and "US$" are to the currency of the United States
of America. All references to IDR are to the currency of Indonesia. References to the words "Lakh" or "Lacs"
mean "100 thousand", the word "million" means "10 lacs", the word “crore” means “10 million” and the word
"billion" means "1,000 million".
Financial Data
Unless stated otherwise, the financial data in this Preliminary Placement Document is derived from our
consolidated financial statements. Our fiscal year commences on January 1 of each year and ends on December
31 of the same year, so all references to a particular “fiscal year” or “Fiscal” are to the 12 month period ended on
December 31 of that year. Our audited consolidated financial statements for the financial years December 2016,
December 2015 and December 2014 (the “Audited Consolidated Financial Statements”) have been prepared
by our Company in accordance with Indian GAAP. Our Company has adopted Ind AS prescribed under section
133 of the Companies Act, 2013 for the quarters ended 31 March 2017, 30 June 2017 and 30 September 2017;
and the year to date results for the periods 1 January 2017 to 30 June 2017 and 1 January 2017 to 30 September
2017 (the “Unaudited Consolidated Financial Results”) that appear in this Preliminary Placement Document
have been prepared in accordance with Ind AS prescribed under Section 133 of the Companies Act, 2013.
Accordingly, the degree to which the Audited Consolidated Financial Statements included in this Preliminary
Placement Document will provide meaningful information is entirely dependent on the reader’s level of familiarity
with the respective accounting practices.
Any reliance by persons not familiar with Indian accounting practices on the financial disclosures presented in
this Preliminary Placement Document should accordingly be limited. For details of key differences between
Indian GAAP and Ind AS, see “Summary of Key Differences between Indian GAAP and Ind AS” beginning on
page 86.
In this Preliminary Placement Document, certain monetary amounts have been subject to rounding adjustments;
accordingly, figures shown as totals in certain tables may not be an arithmetic aggregation of the figures which
precede them.
12
INDUSTRY AND MARKET DATA
Information regarding markets, market size, market share, market position, growth rates and other industry data
pertaining to our Company's business contained in this Preliminary Placement Document consists of
estimates/forecasts based on data reports compiled by professional organisations and analysts, on data from
recognized industry sources, other external sources, and on our Company's knowledge of the markets in which
our Company operates. The statistical information included in this Preliminary Placement Document has been
reproduced from various trade, industry and Government publications and websites. Our Company confirms that
such information and data has been accurately reproduced, and that as far as we are aware and are able to ascertain
from information published by third parties, no facts have been omitted that would render the reproduced
information inaccurate or misleading.
This data is subject to change and cannot be verified with complete certainty due to limits on the availability and
reliability of the raw data and other limitations and uncertainties inherent in any statistical survey. In many cases,
there is no readily available external information (whether from trade or industry associations, Government bodies
or other organisations) to validate market related analysis and estimates, so our Company have relied on internally
developed estimates.
None of our Company, the BRLM or any of their affiliates and advisors or any other person connected with the
Issue has independently verified this information and neither our Company nor the BRLM make any
representation regarding the accuracy or completeness of such data. Industry sources and publications generally
state that the information contained therein has been obtained from sources believed to be reliable, but their
accuracy, completeness and underlying assumptions are not guaranteed and their reliability cannot be assured and
accordingly, investment decisions should not be based on such information. Industry sources and publications are
also prepared based on information as of specific dates and may no longer be current or reflect current trends.
Accordingly, the BRLM and we do not take any responsibility for the data, projections, forecasts, conclusions or
any other information contained in this section. Certain information contained herein pertaining to prior years is
presented in the form of estimates as they appear in the respective reports/ source documents. The actual data for
those years may vary significantly and materially from the estimates so contained. Similarly, while our Company
believes its internal estimates to be reasonable, such estimates have not been verified by any independent source
and our Company cannot assure potential investors as to their accuracy.
The extent to which the market and industry data used in this Preliminary Placement Document is meaningful
depends on the reader’s familiarity with and understanding of the methodologies used in compiling such data.
13
FORWARD-LOOKING STATEMENTS
Certain statements contained in this Preliminary Placement Document that are not statements of historical facts
constitute ‘forward-looking statements’. These statements express views of the management of our Company and
expectations based upon certain assumptions regarding trends in the Indian and international financial markets
and regional economies, the political climate in which our Company operates and other factors. Prospective
investors can identify forward-looking statements by the use of forward-looking terminology, including the words
“aim”, “anticipate”, “believes”, “continue”, “can”, "could", "estimates", "expects", "intends", "may", "will",
"plans", "objective", "potential", "project", "pursue", "shall", "will likely result", "will continue", "will achieve",
"is likely" or "should" or, in each case, their negative or other variations or comparable terminology or by
discussions of strategies, plans, objectives, goals, future events or intentions. All statements regarding our
Company's expected financial condition and results of operations, business plans projects under execution, orders-
in-hand and prospects are forward-looking statements. These forward-looking statements include statements as to
our Company's business strategy, revenue and profitability and other matters discussed in this Preliminary
Placement Document regarding matters that are not historical facts. They appear in a number of places throughout
this Preliminary Placement Document and include statements regarding the intentions, beliefs or current
expectations of our Company concerning, among other things, the results of operations, financial condition,
liquidity, prospects, growth, strategies and dividend policy of our Company and the industry in which we operate.
By their nature, forward-looking statements contained in this Preliminary Placement Document (whether made
by our Company or any third party) are predictions and involve known and unknown risks and uncertainties
because they relate to events, and depend on circumstances, and assumptions and other factors that may cause the
actual results, performance or achievements of our Company to be materially different from any future results,
performance or achievements expressed or implied by such forward-looking statements or other projections.
Forward-looking statements are not guarantees of future performance. Our Company's actual results of operations,
financial condition, liquidity, dividend policy and the development of the industry in which we operate may differ
materially from the impression created by the forward-looking statements contained in this Preliminary Placement
Document. In addition, even if the results of operations, financial condition, liquidity and dividend policy of our
Company and the development of the industry in which we operate are consistent with the forward-looking
statements contained in this Preliminary Placement Document, those results or developments may not be
indicative of results or developments in subsequent periods.
Important factors that could cause actual results and property valuations to differ materially from our expectations
include, but are not limited to, the following:
the growth of the infrastructure sector and the availability of infrastructure financing in India;
the extent to which our projects qualify for percentage of completion revenue recognition;
our ability to manage our growth effectively;
costs and availability of equipment and materials;
cost overruns, delays and disruptions in completion of projects;
outcome of legal or regulatory proceedings to which we, are a party to or might become involved in;
changes in government policies, laws and regulations that apply to our customers, infrastructure and
increasing competition in and the conditions of our customers, infrastructure and construction industry;
changes in political and social conditions in India;
our ability to compete effectively, particularly in new markets and business lines;
potential mergers, acquisitions or restructurings;
changes in the foreign exchange control regulations in India
other factors discussed in this Preliminary Placement Document, including "Risk Factors" on page 29and
general economic, political, social and business conditions in India.
Additional factors that could cause actual results, performance or achievements to differ materially include, but
are not limited to, those discussed under “Risk Factors”, “Management’s Discussion and Analysis of Financial
Condition and Results of Operations” and “Our Business” beginning on pages 29,60and 102respectively. These
forward-looking statements speak only as of the date of this Preliminary Placement Document. Our Company and
the BRLM expressly disclaim any obligation or undertaking to release publicly any updates or revisions to any
forward-looking statement contained herein to reflect any changes in our Company's expectations with regard
thereto or any change in events, conditions or circumstances on which any such statements are based.
The forward-looking statements contained in this Preliminary Placement Document are based on the beliefs of
the management of our Company, as well as the assumptions made by, and information currently available to, the
14
management of our Company. Although our Company believes that the expectations reflected in such forward-
looking statements are reasonable at this time, we cannot assure investors that such expectations will prove to be
correct. Given these uncertainties, investors are cautioned not to place undue reliance on such forward-looking
statements. In any event, these statements speak only as of the date of this Preliminary Placement Document or
the respective dates indicated in this Preliminary Placement Document and our Company undertakes no obligation
to update or revise any of them, whether as a result of new information, future events, changes in assumptions or
changes in factors affecting these forward looking statements or otherwise. If any of these risks and uncertainties
materialise, or if any of our Company's underlying assumptions prove to be incorrect, our Company's actual results
of operations or financial condition could differ materially from that described herein as anticipated, believed,
estimated or expected. All subsequent written and other forward-looking statements attributable to our Company
in this Preliminary Placement Document are expressly qualified in their entirety by reference to these cautionary
statements.
15
EXCHANGE RATES
Fluctuations in the exchange rate between the Rupee and foreign currencies will affect the foreign currency
equivalent of the Rupee price of the Equity Shares on the Stock Exchanges. These fluctuations will also affect the
conversion into foreign currencies of any cash dividends paid in Rupees on the Equity Shares.
The following table sets forth information with respect to the exchange rates between the Rupee and the U.S.
dollar (in ₹ per US$ 1.00), for the periods indicated. The exchange rates are based on the reference rates released
by the RBI, which are available on the website of the RBI. No representation is made that any Rupee amounts
could have been, or could be, converted into U.S. dollars at any particular rate, the rates stated below, or at all.
(₹ per US$1.00)
Period End Average(1) High(2) Low(3)
Fiscal Year Ended:
December 31, 2017 63.93 65.12 68.23 63.63
December 31, 2016 67.95 67.213 68.78 66.18
December 31, 2015 66.33 64.15 67.04 61.41
Quarter Ended:
December 31, 2017 63.93 64.74 65.55 63.93
September 30, 2017 65.36 64.29 65.76 63.63
June 30, 2017 64.74 64.46 65.04 64.00
Month ended:
December 31, 2017 63.93 64.24 64.54 63.93
November 30, 2017 64.43 64.86 65.52 64.41
October 31, 2017 64.77 65.08 65.55 64.76
September 30, 2017 65.36 64.44 65.76 63.87
August 31, 2017 64.02 63.97 64.24 63.63
July 31, 2017 64.08 64.46 64.81 64.08
Source: www.rbi.org.in
(1) Represents the average of the official rate for each working day of the relevant period;
(2) Maximum of the official rate for each working day of the relevant period;
(3) Minimum of the official rate for each working day of the relevant period.
Note: In case of holidays, the exchange rate on the last traded day of the month has been considered as the rate
for the period end
On January 19, 2018 the exchange rate (the RBI reference rate) was ₹ 63.72 to US$ 1.00.
No representation is made that the Rupee amounts actually represent such amounts in U.S. dollars or could have
been or could be converted into U.S. dollars at the rates indicated, any other rates, or at all.
16
DEFINITIONS AND ABBREVIATIONS
Unless otherwise defined or the context otherwise indicates or requires, certain capitalized terms used in this
Preliminary Placement Document have the meanings set forth below. References to any legislation, act or
regulation shall, unless the context otherwise requires, be to such legislation, act or regulation as amended as on
the date of this Preliminary Placement Document:
Term Description
ITD Cementation India Limited /
We / Us / Issuer /the Company /
our Company
Unless the context otherwise indicates or implies, refers to ITD
Cementation India Limited, a public limited company incorporated
under the Companies Act, 1956 and having its registered office at
National Plastic Building, A-Subhash Road, Paranjape B Scheme, Vile
Parle (East), Mumbai, Maharashtra, 400057
Articles / Articles of Association The articles of association of our Company, as amended from time to
time
Auditors Walker Chandiok & Co LLP (formerly Walker, Chandiok & Co),
Chartered Accountants, the statutory auditors of our Company.
Board of Directors / Board The Board of Directors of our Company or a duly constituted committee
thereof
Committee The Committee duly constituted by the Board of Directors
Corporate Office The corporate office of our Company located at National Plastic
Building, A-Subhash Road, Paranjape B Scheme, Vile Parle (East),
Mumbai, Maharashtra, 400057
Director(s) The Director(s) of our Company
Equity Shares / Shares The equity shares of our Company of face value of ₹ 1 each
Joint Venture(s) 1. ITD Cemindia JV where our Company’s share is 80%;;
2. ITD – ITD Cem JV where our Company’s share is 49%;
3. ITD – ITD Cem JV (Consortium of ITD – ITD Cementation)
where our Company’s share is 40%;
4. ITD Cem Maytas Consortium where our Company’s share is
95%;
5. CEC – ITD Cem – TPL JV where our Company’s share is 40%.
Memorandum / Memorandum of
Association
The memorandum of association of our Company, as amended from
time to time
Promoter Italian-Thai Development Public Company Limited, Thailand
Promoter Group Unless otherwise the context requires, the Promoter group of our
Company in accordance with the definition provided in Regulation
2(1)(zb) of the SEBI ICDR Regulations
QIP Committee The QIP committee of the Board of Directors described in the chapter
titled “Board of Directors and Senior Management” beginning on
page 130
Registered Office The registered office of our Company located at National Plastic
Building, A-Subhash Road, Paranjape B Scheme, Vile Parle (East),
Mumbai, Maharashtra, 400057
Registrar of Companies / RoC The Registrar of Companies, Mumbai
Subsidiary Subsidiary of the Company, as defined under section 2(87) of the
Companies Act, namely, i.e. ITD Cementation Projects India Limited
Issue related Terms
Term Description
Allocated or Allocation The allocation of Equity Shares following the determination of the Issue Price
to QIBs on the basis of Application Forms submitted by such QIBs, after
consulting with the BRLM and in compliance with Chapter VIII of the SEBI
ICDR Regulations
Allottee(s) Successful Bidders to whom Equity Shares are issued and allotted pursuant
to the Issue
Allot or Allotted or
Allotment
The issue and allotment of Equity Shares pursuant to this Issue
17
Term Description
Application or Bid Indication of interest from a QIB, including all revisions and modifications of
interest as provided by them, to subscribe for a specified number of Equity
Shares in this Issue on the terms set out in the Application Form to our
Company
Application Form or Bid
cum Application Form
The form, including all revisions and modifications thereto, pursuant to which
a QIB submits an Application
Bidder
Any prospective investor, being a QIB, who makes a Bid pursuant to the terms
of the Preliminary Placement Document and the Application Form
Bidding / Issue Period The period between the Bid/Issue Opening Date and Bid/Issue Closing Date,
inclusive of both dates, during which prospective Bidders can submit Bids
Book Running Lead
Manager/BRLM
ICICI Securities Limited
BSE BSE Limited
CDSL Central Depository Services (India) Limited
CAN or Confirmation of
Allocation Note
Note or advice or intimation to successful Bidders confirming Allocation of
Equity Shares to such successful Bidders after determination of the Issue
Price and requesting payment for the entire applicable Issue Price for all
Equity Shares Allocated to such successful Bidders
Closing Date On or about [●], 2018, the date on which the Allotment is expected to be made
Cut-off Price The price determined by our Company after consulting with the BRLM at or
above the Floor Price net of such discount as approved in accordance with
SEBI ICDR Regulations
Eligible FPIs FPIs that are eligible to participate in the Issue and does not include qualified
foreign investors and Category III Foreign Portfolio Investors (who are not
eligible to participate in the Issue)
Escrow Agreement The Escrow Agreement dated January 24, 2018 by and between our
Company, Escrow Bank and the BRLM in relation to the Issue
Escrow Bank Axis Bank Limited
Escrow Cash Account/
Escrow Account
The non-interest bearing, no-lien, escrow bank account without any cheque
or overdraft facilities opened by our Company with the Escrow Bank under
the arrangement between our Company and the Escrow Bank for receiving
the share application amount from the successful Bidders
Floor Price ₹ 213.20 per Equity Share, calculated in accordance with Regulation 85 of
the SEBI ICDR Regulations. Under the SEBI ICDR Regulations, the Issue
Price cannot be lower than the Floor Price subject to discount of not more
than 5% on the Floor Price which may be considered by our Company
Issue The offer, issue and allotment of [●] Equity Shares to QIBs, pursuant to
Chapter VIII of the SEBI ICDR Regulations and the provisions of Companies
Act, 2013 and Private Placement Provisions
Issue Closing Date or Bid
Closing Date
[●], 2018, the date on which our Company (or the BRLM on behalf of our
Company) shall cease to accept Application Forms
Issue Opening Date or Bid
Opening Date
January 24, 2018, the date on which our Company (or the BRLM on behalf
of our Company) shall commence acceptance of Application Forms
Issue Price The price per Equity Share of ₹[●]
Issue Size The issue of issuing [●] Equity Shares of face value of ₹1 each at a price of ₹
[●] per Equity Share aggregating ₹ [●] lakh.
NSDL The National Securities Depository Limited
NSE The National Stock Exchange of India Limited
Pay-in Date The last date specified in the CAN for payment of application monies by the
QIBs.
Placement Agreement The Placement Agreement dated January 24, 2018 entered between our
Company and the BRLM
Placement Document The placement document to be issued by our Company in accordance with
Chapter VIII of the SEBI ICDR Regulations and Section 42 of the Companies
Act, 2013 and the rules thereunder
Preliminary Placement
Document
The preliminary placement document issued in accordance with Chapter VIII
of the SEBI ICDR Regulations and Section 42 of the Companies Act, 2013
and the rules thereunder
18
Term Description
QIB or Qualified
Institutional Buyer
Any Qualified Institutional Buyer as defined under Regulation 2(1) (zd) of
Chapter VIII of the SEBI ICDR Regulations and the rules thereunder.
QIP Qualified Institutions Placement under Chapter VIII of the SEBI ICDR
Regulations
Regulation S Regulation S, as defined under the U.S. Securities Act
Relevant Date January 24, 2018 i.e. date of the meeting of the QIP Committee duly
authorised by the Board of Directors deciding to open the Issue
SCRA Securities Contracts (Regulation) Act, 1956 as amended from time to time
SCRR Securities Contracts (Regulation) Rules, 1957 as amended from time to time
SCR(SECC) Regulations Securities Contracts (Regulation) (Stock Exchanges and Clearing
Corporations) Regulations, 2012 as amended from time to time
SEBI The Securities and Exchange Board of India
SEBI Act The Securities and Exchange Board of India Act, 1992 as amended from time
to time
SEBI FPI Regulations Securities and Exchange Board of India (Foreign Portfolio Investors)
Regulations, 2014 as amended from time to time
SEBI ICDR Regulations The Securities and Exchange Board of India (Issue of Capital and Disclosure
Requirements) Regulations, 2009, as amended from time to time
SEBI Listing Regulations SEBI (Listing Obligations and Disclosure Requirements), Regulations, 2015,
as amended from time to time
SEBI Prohibition of Insider
Trading Regulations
SEBI (Prohibition of Insider Trading) Regulations, 2015 as amended from
time to time
Stock Exchanges BSE and NSE
Systemically Important
NBFCs
Systemically Important NBFC as defined under Regulation 2(1)(zla) of the
SEBI ICDR Regulations
STT Securities Transaction Tax
Takeover Code Securities and Exchange Board of India (Substantial Acquisition of Shares
and Takeovers), 2011
U.S. Securities Act The United States Securities Act of 1933 as amended
Business and Industry Related Terms
Terms Description
BOQ Bill of Quantities
BMRCL Bangalore Metro Rail Corporation Limited
DNV Det Norske Veritas
EPC Engineering, procurement and construction
HVAC Heating, ventilation and air conditioning
IT Information Technology
ISO The International Organization of Standardization
MRTS Mass Rapid Transit System
Conventional and General Terms
Terms Description
AGM Annual General Meeting
AIF Alternate Investment Funds(as defined under the Securities and Exchange
Board of India (Alternative Investment Fund) Regulations, 2012) registered
with the SEBI under applicable laws in India
CAGR Compounded Annual Growth Rate
Chapter VIII Refers to Chapter VIII of the SEBI ICDR Regulations that deals with
Qualified Institutions Placement and as amended from time to time
Civil Code or Code The Code of Civil Procedure, 1908 of India, as amended from time to time
Companies Act Companies Act, 1956, as amended or the Companies Act, 2013, as amended
as applicable
Companies Act, 1956 Companies Act, 1956, as amended and the rules made thereunder (without
reference to the provisions thereof that have ceased to have effect upon
notification of the Notified Sections)
19
Terms Description
Companies Act, 2013 Companies Act, 2013, as amended and the rules made thereunder, to the extent
in force pursuant to notification of the Notified Sections
CSR Corporate Social Responsibility
Depositories Act The Depositories Act, 1996 as amended from time to time
Depository A depository registered with SEBI under the SEBI (Depositories and
Participant) Regulations, 1996 as amended from time to time
Depository Participant A depository participant as defined under the Depositories Act
DIN Director Identification Number
EGM Extraordinary General Meeting
EOM Emphasis of Matters
FDI
Foreign Direct Investment in an Indian company, in accordance with
applicable law
FEMA
The Foreign Exchange Management Act, 1999 as amended from time to time
and the Regulations framed thereunder
FEMA Regulations The Foreign Exchange Management (Transfer or Issue of Security by a Person
Resident Outside India) Regulations, 2000 as amended from time to time
FII
Foreign Institutional Investor as defined under Section 2(1)(g) the SEBI FPI
Regulations, 2014, and registered as such with SEBI
FII Regulations
Securities and Exchange Board of India (Foreign Institutional Investors)
Regulations, 1995 as amended from time to time
Financial Year or Fiscal
Year or Fiscal or FY
A period of twelve months ending December 31 of that particular year apart
from in the Industry Section where it would mean a period of twelve months
ending March 31, unless otherwise stated
Form PAS-4 Form PAS-4 as prescribed under the Companies (Prospectus and Allotment
of Securities) Rules, 2014
FPI Foreign Portfolio Investors, as defined under Regulation 2(1)(h) of the
Securities And Exchange Board of India (Foreign Portfolio Investors)
Regulations, 2014
FVCI Any foreign venture capital investor (as defined under the Securities and
Exchange Board of India (Foreign Venture Capital Investors) Regulations,
2000, as amended) registered with the SEBI under applicable laws in India
GAAP Generally Accepted Accounting Principles
GDP Gross Domestic Product
GoI or Government Government of India, unless otherwise specified
GST Goods and Services Tax
ICAI The Institute of Chartered Accountants of India
IFRS International Financial Reporting Standards
Income Tax Act or IT Act The Income Tax Act, 1961 as amended from time to time
Ind AS Indian Accounting Standards
India The Republic of India
Indian GAAP Generally accepted accounting principles followed in India
KMP Key Managerial Personnel
Lakh/ Lac/Lacs One hundred thousand
LTCG Long Term Capital Gain
Minimum Wages Act Minimum Wages Act, 1948as amended from time to time
Mutual Fund
A mutual fund registered with SEBI under the Securities and Exchange Board
of India (Mutual Funds) Regulations, 1996 as amended from time to time
Non-Resident Indian(s) or
NRI
Non-Resident Indian as defined under FEMA
Notified Sections Sections of the Companies Act, 2013 that have been notified by the
Government of India
PAN Permanent Account Number
PAT Profit after tax
PBT Profit before tax
PPP Public Private Partnership
Portfolio Investment
Scheme/PIS
The portfolio investment scheme of RBI specified in Schedule 2 of the Foreign
Exchange Management (Transfer or Issue of Security by a Person Resident
Outside India) Regulations, 2000 as amended from time to time
20
Terms Description
Private Placement
Provisions
Section 42 of the Companies Act, 2013, read with Rule 14 of the Companies
(Prospectus and Allotment of Securities) Rules, 2014
₹ or Re. or Rs. or Rupees or
INR
Indian Rupee
RBI The Reserve Bank of India
STCG Short Term Capital Gain
State Any state in the Republic of India
State Government Government of a State
Takeover Code The Securities and Exchange Board of India (Substantial Acquisition of
Shares and Takeovers) Regulations, 2011 as amended from time to time
UK United Kingdom of Great Britain and Northern Ireland
USA or U.S. United States of America
$ or U.S. dollar or USD or
US$
The currency of the United States
VCF A venture capital fund as defined under the erstwhile Securities and Exchange
Board of India (Venture Capital Funds) Regulations, 1996
21
DISCLOSURE REQUIREMENTS UNDER FORM PAS-4 PRESCRIBED UNDER THE COMPANIES
ACT, 2013
The table below sets out the disclosure requirements as provided in Form PAS-4 and the relevant pages in this
Preliminary Placement Document where these disclosures, to the extent applicable, have been provided.
Sr.
No.
Disclosure Requirements Relevant Page of
this Preliminary
Placement
Document
1. GENERAL INFORMATION
a. Name, address, website and other contact details of our Company indicating both
Registered Office and corporate office
Cover Page and
193
b. Date of incorporation of our Company 193
Business carried on by our Company and its subsidiary with the details of branches
or units, if any.
102
c. Brief particulars of the management of our Company. 130
d. Names, addresses, DIN and occupations of the Directors. 130
e. Management’s perception of risk factors 29
f. Details of default, if any, including therein the amount involved, duration of default
and present status, in repayment of:
i) Statutory dues; NIL
ii) Debentures and interest thereon; NIL
iii) Deposits and interest thereon; and NIL
iv) Loan from any bank or financial institution and interest thereon. NIL
g. Names, designation, address and phone number, email ID of the nodal/ compliance
officer of our Company, if any, for the private placement offer process.
367
2. PARTICULARS OF THE OFFER
a. Date of passing of board resolution. 193
b. Date of passing of resolution in the general meeting, authorising the offer of
securities.
193
c. Kinds of securities offered (i.e. whether share or debenture) and class of security. 23
d. Price at which the security is being offered including the premium, if any, along with
justification of the price.
23
e. Name and address of the valuer who performed valuation of the security offered. Not applicable
f. Amount which our Company intends to raise by way of securities. 55
g. Terms of raising of securities:
i) Duration, if applicable; Not Applicable
ii) Rate of dividend; Not Applicable
iii) Rate of interest; Not Applicable
iv) Mode of payment; and Not Applicable
v) Repayment. Not Applicable
h. Proposed time schedule for which the offer letter is valid. 17
i. Purposes and objects of the offer. 55
j. Contribution being made by the Promoter or directors either as part of the offer or
separately in furtherance of such objects.
55
k. Principle terms of assets charged as security, if applicable. Not Applicable
3. DISCLOSURES WITH REGARD TO INTEREST OF DIRECTORS, LITIGATION ETC
i) Any financial or other material interest of the directors, Promoter or key managerial
personnel in the offer and the effect of such interest in so far as it is different from
the interests of other persons.
133 and 137
ii) Details of any litigation or legal action pending or taken by any Ministry or
Department of the Government or a statutory authority against any promoter of the
offeree company during the last three years immediately preceding the year of the
circulation of the offer letter and any direction issued by such Ministry or
Department or statutory authority upon conclusion of such litigation or legal action
shall be disclosed.
190
iii) Remuneration of Directors (during the current year and last three financial years). 133
iv) Related party transactions entered during the last three financial years immediately 83
22
Sr.
No.
Disclosure Requirements Relevant Page of
this Preliminary
Placement
Document
preceding the year of circulation of offer letter including with regard to loans made
or, guarantees given or securities provided.
v) Summary of reservations or qualifications or adverse remarks of auditors in the last
five financial years immediately preceding the year of circulation of offer letter and
of their impact on the financial statements and financial position of our Company
and the corrective steps taken and proposed to be taken by our Company for each of
the said reservations or qualifications or adverse remark.
73
vi) Details of any inquiry, inspections or investigations initiated or conducted under the
Companies Act or any previous company law in the last three years immediately
preceding the year of circulation of offer letter in the case of company and all of its
subsidiaries. Also if there were any prosecutions filed (whether pending or not) fines
imposed, compounding of offences in the last three years immediately preceding the
year of the offer letter and if so, section-wise details thereof for our Company and
all of its subsidiaries.
190
vii) Details of acts of material frauds committed against our Company in the last three
years, if any, and if so, the action taken by our Company.
190
4. FINANCIAL POSITION OF THE COMPANY
a. The capital structure of our Company in the following manner in a tabular form:
(i)
(a)
The authorised, issued, subscribed and paid up capital (number of securities,
description and aggregate nominal value);
57
(b) Size of the present offer; and 23
(c) Paid up capital: 57
(A) After the offer; and 57
(B) After conversion of convertible instruments (if applicable); Not Applicable
(d) Share premium account (before and after the offer). 57
(ii) The details of the existing share capital of the issuer company in a tabular form,
indicating therein with regard to each allotment, the date of allotment, the number
of shares allotted, the face value of the shares allotted, the price and the form of
consideration.
57
Provided that the issuer company shall also disclose the number and price at which
each of the allotments were made in the last one year preceding the date of the offer
letter separately indicating the allotments made for considerations other than cash
and the details of the consideration in each case.
58
b. Profits of our Company, before and after making provision for tax, for the three
financial years immediately preceding the date of circulation of offer letter.
25
c. Dividends declared by our Company in respect of the said three financial years;
interest coverage ratio for last three years (Cash profit after tax plus interest paid /
interest paid).
59
d. A summary of the financial position of our Company as in the three audited balance
sheets immediately preceding the date of circulation of offer letter.
25
e. Audited Cash Flow Statement for the three years immediately preceding the date of
circulation of offer letter.
72
f. Any change in accounting policies during the last three years and their effect on the
profits and the reserves of our Company.
83
5. A DECLARATION BY THE DIRECTORS THAT
a. Our Company has complied with the provisions of the Act and the rules made
thereunder.
302
b. The compliance with the Act and the rules does not imply that payment of dividend
or interest or repayment of debentures, if applicable, is guaranteed by the Central
Government.
c. The monies received under the offer shall be used only for the purposes and objects
indicated in the Offer letter.
23
SUMMARY OF THE ISSUE
The following is a general summary of the terms of the Issue. This summary should be read in conjunction with,
and is qualified in its entirety by, the more detailed information appearing elsewhere in this Preliminary
Placement Document, including under the chapters titled “Risk Factors”, “Use of Proceeds”, “Issue
Procedure”, “Placement” and “Description of the Equity Shares” beginning on pages 29,55,141,152 and 166.
Issuer ITD Cementation India Limited
Face value ₹ 1 per Equity Share
Issue Price per Equity Share [●]
Issue Size The issue of up to [●] Equity Shares of face value of ₹1 each at a price
of ₹ [●] per Equity Share including a premium of ₹ [●] per Equity Share
aggregating to ₹ [●] lakh.
A minimum of 10 % of the Issue Size i.e. [●] Equity Shares shall be
available for Allocation to Mutual Funds only, and [●] Equity Shares
shall be available for Allocation to all QIBs, including Mutual Funds. If
no Mutual Fund is agreeable to take up the minimum portion mentioned
above, such minimum portion or part thereof may be Allotted to other
eligible QIBs.
Date of Board Resolution
authorizing the Issue
September 21, 2017
Date of Shareholders’ Resolution
authorizing the Issue
December 12, 2017
Floor Price ₹ 213.20 per Equity Share, calculated in accordance with Regulation 85
of the SEBI ICDR Regulations subject to a discount of not more than
five per cent on the Floor Price in accordance with the approval of the
Equity Shareholders accorded on December 12, 2017 and Regulation
85(1) of the SEBI ICDR Regulations.
Equity Shares issued and
outstanding immediately prior to
the Issue
15,51,57,900 Equity Shares at a face value of ₹1per share.
Equity Shares issued and
outstanding immediately after
the Issue
[●] Equity Shares at a face value of ₹1 per share.
Eligible Investors QIBs as defined in regulation 2(1) (zd) of the SEBI ICDR Regulations
and Chapter VIII of the SEBI ICDR Regulations , who are outside of the
United States acquiring Equity Shares in an offshore transaction in
reliance on Regulation S, and to whom this Preliminary Placement
Document and the Application Form is delivered by the BRLM in
consultation with our Company, at their sole discretion and who are
eligible to bid and participate in this Issue and QIBs not excluded
pursuant to Regulation 86(1) (b) of the SEBI ICDR Regulations.
For further details, see the chapters titled “Issue Procedure” and
“Transfer Restrictions” beginning on pages 141 and 159, respectively.
Listing (i) Applications for approval, in terms of Regulation 28 (1) of the SEBI
Listing Regulations with the Stock Exchanges were made and (ii) the
application for final listing and trading approval, for listing and
admission of the Equity Shares and for trading on the Stock Exchange,
will be made only after Allotment of the Equity Shares in the Issue.
Issue Procedure The Issue is being made only to QIBs in reliance on Section 42 of the
Companies Act, 2013, read with Rule 14 of the Companies (Prospectus
and Allotment of Securities) Rules, 2014 and Chapter VIII of the SEBI
ICDR Regulations. For further details, see the chapter titled “Issue
Procedure” beginning on page 141.
Transferability Restrictions The Equity Shares being allotted pursuant to this Issue shall not be sold
for a period of one year from the date of Allotment, except if sold on the
floor of the Stock Exchange. For further details, see the chapter
“Transfer Restrictions” beginning on page 159.
24
Ranking The Equity Shares being issued pursuant to the Issue are subject to the
provisions of our Memorandum and Articles of Association and shall
rank pari passu in all respects with the existing Equity Shares, including
with respect to dividend rights. Shareholders will be entitled to dividends
and other corporate benefits, if any, declared by us after the Closing
Date, in compliance with the Companies Act, 2013. Shareholders may
attend and vote in shareholders’ meetings in accordance with the
provisions of the Companies Act, 2013. Please see the chapter titled
“Description of the Equity Shares” beginning on page 166.
Use of Proceeds The gross proceeds of the Issue are expected to be approximately ₹ [●]
lakh. The net proceeds from the Issue, after deducting fees, commissions
and expenses of the Issue, will be approximately ₹ [●] lakh. For further
details, please see the chapter titled “Use of Proceeds” beginning on
page 55.
Risk Factors For a discussion of certain risks in connection with an investment in the
Equity Shares, please see the chapter titled “Risk Factors” beginning on
page 29.
Closing Date The Allotment is expected to be made on or about [●] (the “Closing
Date”).
Pay-In date Last date specified in the CAN sent to the successful Bidders for
payment of application money
Security codes: ISIN:INE686A01026
BSE Scrip Code: 509496
NSE Symbol: ITDCEM
25
SUMMARY OF BUSINESS
We are one of the leading civil engineering, contracting and construction organizations providing integrated
design, engineering, procurement and construction services, for over eight decades, for infrastructure development
projects in India. Our current business covers major infrastructure areas including maritime structures, highways,
bridges and flyovers, urban infrastructure projects/mass rapid transit systems, specialist engineering works,
hydroelectric power projects, tunnels and dams, irrigation projects, industrial civil works, airports and civil works
of water and waste water projects.
Our focus areas, in relation to civil engineering, for providing design, engineering, procurement and construction
services under each segment are as follows:
Urban infrastructure/
MRTS Construction of civil and building structures for mass rapid transportation
systems (“MRTS”)
Construction of tunnels, underground railway stations and installation of
track;
Construction of integrated passenger terminals and allied services at
airports.
Maritime Structures Construction of jetties, dolphins and service platforms;
Construction of quay, berths on concrete and steel piles as well as solid
gravity type wharf structures;
Construction of ship lift, dry dock, wet basin (in complete marine
condition) and inclined berth;
Break water and piled approach trestles;
Steel pipes (vertical and raker), bored cast in-situ pile;
Undersea ground improvement;
Dredging and land reclamation;
Coastal erosion protection and rock bund.
Hydroelectric power
projects, tunnels, dams and
irrigation projects
Construction of concrete and masonry dams, micro tunnelling, earth fill
embankments, irrigation canal structures and hydro tunnels;
Construction of hydroelectric power stations.
Industrial structures and
buildings Construction of plant buildings for power, steel, refineries and fertilizer
sectors;
Civil works for water treatment and water intake systems;
Buildings for educational institutions, hospitals, shopping malls and IT
parks.
Specialist Engineering Foundation and specialist works including geotechnical investigations,
piling, diaphragm walling, sand wicks / band drains, vibro-floatation stone
columns / vibro compaction, drilling and grouting, rock / soil anchors,
colcrete, gunite / shotcrete, grouted mattress, repairs, tube heading and
box pushing.
Highways, bridges and
flyovers Construction of roads, bridges and flyovers.
Our segment wise revenue in the last 3 (three) Fiscal Years 2016, 2015 and 2014 is presented as under:
(` in lakh)
Name of the Division Fiscal Year 2016 Fiscal Year 2015 Fiscal Year 2014
Urban Infrastructure / MRTS 25,440 38,641 34,488
Maritime structures 1,72,302 1,47,400 53,020
Hydroelectric power projects, tunnels and
dams and irrigation projects
20,638 16,776 9,549
Industrial structures and buildings 22,283 25,375 8,389
Specialist Engineering 26,404 32,028 32,832
Highways, bridges and flyovers 41,790 46,650 32,964
26
SUMMARY OF FINANCIAL INFORMATION
The following selected information is extracted from and should be read in conjunction with our unaudited
financial statements for the quarters ended 31 March 2017, 30 June 2017 and 30 September 2017 and the year to
date results for the periods 1 January 2017 to 30 June 2017 and 1 January 2017 to 30 September 2017 in
accordance with Ind AS and our audited financial statements and notes thereto as at and for the twelve months
period ended December 31, 2016, December 31, 2015 and December 31, 2014 prepared in accordance with Indian
GAAP, each included elsewhere in this Preliminary Placement Document. You should refer to “Management’s
Discussion and Analysis of Financial Condition and Results of Operations” beginning on page 60 for further
discussion and analysis of the financial statements of our Company. The financial information included in this
Preliminary Placement Document does not reflect our Company’s results of operations, financial position and
cash flows in the future and our Company’s past results are not a guarantee of its future operating performance.
SUMMARY OF CONSOLIDATED BALANCE SHEET
(₹ in lakh)
Particulars As at 31st
December
2016
As at 31st
December
2015
As at 31st
December
2014
EQUITY AND LIABILTIES
Shareholders’ Funds
Share capital 1,551.58 1,551.58 1,551.58
Reserves and surplus 53,520.39 49,269.85 55,230.22
55,071.97 50,821.43 56,781.80
Non-Current Liabilities
Long-term borrowings 4,062.13 1,178.81 4,038.61
Long-term provisions 902.13 694.56 563.24
4,964.49 1,873.37 4,601.85
Current Liabilities
Short-term borrowings 37,105.85 56,211.69 68,119.53
Trade Payables 41,719.51
- Total outstanding dues of Micro Enterprises
and Small Enterprises
758.85 - -
- Total outstanding dues of creditors other than
Micro Enterprises and Small Enterprises
63,208.08 75,429.28 -
Current maturity of long term borrowings 5131.01 2,684.22 -
Other current liabilities 46,996.70 55,837.61 47,150.32
Short-term provisions 2,544.04 1,621.57 1,110.97
1,55,744.53 1,91,784.37 1,58,100.33
Total 2,15,780.99 2,44,479.17 2,19,483.98
ASSESTS
Non-Current Assets
Fixed Assets
- Tangible assets 38,184.36 34,898.52 33,525.83
- Capital work-in-progress 560.20 267.22 328.36
Deferred tax assets (net) 2,756.42 4,423.39 1,485.13
Long term loans and advances 27,518.73 22,167.51 16,595.77
Long term Trade receivables 2,863.37 2,863.37 2,863.37
Other non-current assets - 23.79 27.54
71,883.08 64,643.80 54,826.00
Current Assets
Current Investments 0.26 0.26 0.26
Inventories 84,567.21 1,17,538.07 1,13,125.22
Trade receivables 26,482.29 30,917.17 41,285.81
Cash and bank balances 18,509.82 14,760.26 2,718.20
Short term loans and advances 14,298.79 16,500.51 7,512.74
Other current 39.54 119.10 15.75
1,43,897.91 1,79,835.37 1,64,657.98
Total 2,15,780.99 2,44,479.17 2,19,483.98
27
SUMMARY OF CONSOLIDATED STATEMENT OF PROFIT AND LOSS
(₹ in lakh)
Particulars
Year
ended
December
31st 2016
Year
ended
December
31st, 2015
Year
ended
December
31st, 2014
REVENUE
Contract revenue 3,08,856.02 3,06,870.03 1,71,242.31
Other operating income 103.98 224.87 652.29
Other income 2,522.16 2,217.41 1,849.47
Total revenue 3,11,482.16 3,09,312.31 1,73,744.07
EXPENSES
Cost of materials consumed 73,225.93 80,945.83 64,392.02
Sub-contract expenses 1,32,999.85 1,29,588.37 40,260.28
Employees benefits expense 25,380.31 22,240.69 19,363.89
Finance costs 11,652.27 13,771.36 13,550.37
Depreciation expenses 4,494.45 3,665.05 4,270.88
Other expenses 56,368.55 55,162.40 38,770.92
Total Expenses 3,04,121.36 3,05,373.70 1,80,608.36
Profit/ (loss) before exceptional item and tax 7,360.80 3,938.61 (6,864.29)
Exceptional items - (12,397.19) 9,553.25
Profit/(loss) before tax 7,360.80 (8,458.58) 2,688.96
Tax expenses
Current tax (3,455.44) (265.37) (964.52)
Less: Minimum alternative tax 2,550.83 720.23
Earlier year tax adjustments 21.55 (131.83) 132.69
Deferred tax (charge)/credit (1,666.97) 2,925.02 (635.93)
Net profit/(loss) for the year 4,810.77 (5,930.76) 1,941.43
Earning/(loss) per equity share of Rs 1 each
Basic and diluted 3.10 (3.82) 1.51
SUMMARY OF CONSOLIDATED CASH FLOW
(₹ in lakh)
Particulars Year ended
December 31,
2016
Year ended
December 31,
2015
Year ended
December 31,
2014
Cash and cash equivalents at the beginning of year 8,382.74 2,495.33 2,395.93
Net cash generated from operating activities 35,918.55 46,505.52 4,363.60
Net cash used in investing activities (637.09) (10,409.08) (3,835.69)
Net cash used in financing activities (25,575.65) (30,209.03) (428.51)
Net increase in cash and cash equivalents 9,705.81 5,887.41 99.40
Cash and cash equivalents at the end of year 18,088.55 8,382.74 2,495.33
SUMMARY OF CONSOLIDATED PROFIT AND LOSS STATEMENT FOR THE NINE MONTHS
ENDED SEPTEMBER 30, 2017
(₹ in lakhs)
Particulars Nine months ended September 30, 2017
Income from operations 148,559.88
Other Income 2,020.15
Total Income 1,50,580.03
Expenses
Cost of material consumed 42,804.29
Subcontracting expenses 33,086.43
Employee benefits expense 19,126.59
Depreciation and amortization expense 4,127.54
Finance costs 6,574.49
Other expenses 34,251.80
28
Particulars Nine months ended September 30, 2017
Total expenses 1,39,971.14
Profit before tax and share of profit/ (loss) of joint
ventures
10,608.89
Share of profit/ (loss) of joint venture (1,471.17)
Profit before tax 9,137.72
Tax expenses
Current income tax 5,639.03
Deferred income tax (2,028.20)
Total tax expense 3,610.83
Profit for the period 5,526.89
Other comprehensive income
Item not to be reclassified subsequently to profit or loss
- Profit/ (loss) on fair value of defined benefit plans (517.90)
- Income tax effect on above 179.24
Income tax relating to items that will not be reclassified to
profit or loss
-
Other comprehensive income for the period , net of tax (338.66)
Total comprehensive income for the period, net of tax 5,188.23
29
RISK FACTORS
This offering and an investment in Equity Shares involve a degree of risk. You should carefully consider the risks
described below as well other information contained in this Preliminary Placement Document before making an
investment decision. If anyone or some combination of the risks described below actually occurs, our business,
prospects, financial condition, results of operation and cash flows could adversely affect, the trading price of our
shares could decline and you may lose all or part of your investment. Unless specified in the risk factors below,
we are not in a position to quantify the financial implications of any of the risks mentioned below. We have
described the risks and uncertainties that our management believes are material but the risks set out in this
Preliminary Placement Document may not be exhaustive or complete and additional risks and uncertainties not
presently known to us, or which we currently deem to be immaterial, may arise or may become material in the
future.
This section should be read together with chapters titled “Management’s Discussion and Analysis of Financial
Condition and Results of Operations”, “Industry Overview” and “Our Business” beginning on pages 60, 86and
102, respectively, as well as the financial statements, including the notes thereto, and other financial information
included elsewhere in this Preliminary Placement Document. This Preliminary Placement Document also
contains forward-looking statements that involve risks and uncertainties. Our results could differ materially from
such forward-looking statements as a result of certain factors including the considerations described below and
elsewhere in this Preliminary Placement Document. Additional risks not described below or not currently known
to us or that we currently deem immaterial may also adversely affect the market price of our Equity Shares. In
making an investment decision, prospective investors must rely on their own examination of our Company and
the terms of the Issue including the merits and the risks involved. Investors should consult tax, financial and legal
advisors about the particular consequences of an investment in the Issue.
INTERNAL RISKS AND RISKS ASSOCIATED WITH OUR BUSINESS.
1. A case has been registered against one of our employees and a professional consultant, under the
Prevention of Corruption Act, 1988 by the Anti-Corruption Bureau, Andhra Pradesh. An adverse
order in the matter is likely to affect our Company’s reputation which in turn may affect our ability to
procure contracts in future, or potentially result in cancellation of our existing orders by our
customers, thereby impacting our revenues.
On January 12, 2018, one of our employees holding the designation of Deputy Manager (Accounts) and
a professional consultant were arrested under the Prevention of Corruption Act, 1988 on the allegations
of bribing an Additional Commissioner (State Tax), Enforcement Wing, Commercial Tax Department,
Andhra Pradesh and are under judicial custody. A case under the Prevention of Corruption Act, 1988 has
been registered by the Anti-Corruption Bureau, Andhra Pradesh against the said employee and a
professional consultant and the matter is currently under investigation. While our Company is internally
investigating the aforesaid matter, a conviction of our employee and / or a professional consultant in the
matter may affect the reputation of our Company which in turn may affect our ability to procure contracts
in future, or potentially result in cancellation of our existing offers by our customers, thereby impacting
our revenues.
For further details on this please refer to the section titled ‘Potential Litigation against our Company’ in
the chapter titled ‘Legal Proceedings’ on page 190.
2. Our Company relies on construction contracts awarded by our clients for our revenues, which may be
subject to variation in the scope of work by these clients. Any cost, if not reimbursed by our client,
incurred in excess of our contract value or anticipated revenues due to such restructuring or
renegotiation could reduce our profits.
Our Company relies on construction contracts awarded by our clients for our revenues. In many of the
contracts our Company may have limited ability to negotiate the terms of contracts which means that the
terms in such contracts tend to favour the client. Further, any client may change the scope of a contract
including but not limited to changes in designs at its discretion which may lead to additional costs. While
we may have price escalation clauses in most of our contracts, any change in costs related to construction
may not be fully compensated by our clients, which would impact our margins.
3. Our Company may not be selected for any of the projects for which we may have submitted a bid and
we may end up incurring significant costs in preparation and submission of such a failed bid.
30
There are certain proposed projects for which we have or may in future submit financial bids. We
generally incur significant costs in the preparation and submission of such bids, which are one-time costs.
We cannot assure that our bids, when submitted or if already submitted, would be accepted. Further,
there may be delays in the bid selection process owing to a variety of reasons which may be outside
our control and our bids, once selected, may not always translate into an order within the expected time
frame. Any failure to win the bids may lead to loss of costs incurred in submitting the bids which may in
turn lead affect our financial results.
4. Our Company operates in a highly competitive market. If we are unable to bid for and win engineering
construction projects, both large and small, or compete with competitors, we could fail to
increase, or maintain, our volume of order intake and our results of operations may be materially
adversely affected.
Our Company faces competition from other market players, which is determined by size, nature,
complexity and location of projects, proximity of materials to the local market, the availability
of subcontractors, construction workers and local economic conditions. Some of our Company’s
competitors may have greater resources in specific areas like capital, labour, equipment, technology,
marketing or other resources and at times may apply those resources and capabilities more successfully
than our Company. Further, our competitors may bid more aggressively owing to which we may not be
selected for such bids and our revenues in future may be impacted. Further, our ability to bid for and win
projects is dependent on a number of factors including our ability to show experience in executing large
projects and to demonstrate that we have strong engineering capabilities in executing technically
complex projects. We face competition from other bidders in a similar position to us looking
for suitable joint venture partners with whom to partner in order to meet the pre-qualification
requirements. For many large construction contracts and infrastructure development projects, we
may not always meet the pre-qualification criteria on a standalone basis. If we are unable to partner
with other players, we may lose the opportunity to bid for and therefore fail to increase or maintain its
volume of new construction contract orders or new projects. There can be no assurance that we can
continue to effectively compete with our competitors in the future, and failure to compete effectively
may have an adverse effect on our business, financial condition, cash flows and results of operations.
5. Delays in completion of our current and future projects and cost overrun could have adverse effect on
our business prospects and results of operations.
We have faced delays in completion of certain of our projects and may face delays in completion for
certain of our projects which are under execution. Typically, our projects are subject to specific
completion schedule requirements. The scheduled completion targets for our projects are estimates and
are subject to delays as a result of, among other things, unforeseen engineering problems, force majeure
events, issues arising out of right of way, unavailability of financing, unanticipated cost increases or
changes in scope and inability in obtaining certain client and / or government approvals. We also provide
performance guarantees to our clients which may be invoked if we are unable to complete projects within
a specified time frame and such guarantees may be extended owing to any change in such timelines.
Failure to adhere to contractually agreed timelines could lead to forfeiture of security deposits, payment
of liquidated damages and / or our performance guarantees being invoked. There can be no assurance
that our projects will be completed within the specified time frame. We cannot assure you that all
potential liabilities that may arise from delays or that any damages, that maybe claimed for such delays
from clients or any third party, would be adequate to cover losses resulting there from.
Further, any delay in completing construction contracts would result in the total cost of a construction
contract to exceed the original estimates. Such delays and cost overruns may adversely affect our
business and results of operations.
6. A significant part of our Company's business transactions are with government entities or agencies
which present particular risks.
A significant part of our Company’s business is dependent on development projects undertaken by
government entities or agencies.
There could be delays in projects with these authorities and institutions due to changes in government
policies or initiatives, changes in budgetary allocation or other approvals or inadequate funds with
31
government/government organisations. Our Company also faces the risk of non- payment or delay in the
collection of receivables from government owned or controlled entities and financial institutions. Our
Company's operations involve significant working capital requirements and a non-payment or delayed
collection of receivables could significantly adversely affect our Company's financial condition, liquidity
and results of operations.
Government contracts generally also contain unilateral termination provisions in favour of the
government. In the event that one or more of our Company's material contracts is terminated, our business
and results of operations may be adversely affected.
In addition, documentary closure or completion of government contracts, including the release of
performance guarantees and final acceptance notices, generally takes a significant amount of time and is
subject to material delays, which also adversely affects our Company's financial condition and results of
operations.
7. We are dependent on our suppliers for adequate and timely supply of key raw materials at competitive
rates and generally do not enter into any long term supply contracts with our suppliers. If our
Company is unable to procure the requisite quantities of construction materials in time and at
commercially acceptable prices, the performance of its financial results and business prospects could
be adversely affected.
Our Company purchases significant amount of raw materials, including steel, cement, bentonite,
admixture, aggregates, sand, binding wires, bentonite powder etc. for its construction operations. While
our Company maintains relations with many different suppliers in order to avoid risks of unavailability
of resources, any unavailability of such resources could materially disrupt our Company’s operations. In
addition, the unavailability of resources and fluctuations in costs of raw materials could significantly
affect our operating costs and consequently reduce our profitability. Accordingly, we cannot assure you
that we would be able to procure raw materials in a timely manner and at competitive prices or that we
will not be affected in the event of any shortfall of supply since we do not have any definitive
arrangements with our suppliers, which may adversely affect our business. If, for any reason, our primary
suppliers of raw materials curtail or discontinue their delivery of such materials to us in the quantities we
need and at prices that are competitive, our reputation and ability to meet our material requirements for
our projects could be impaired, our construction schedules could be disrupted and our business could
suffer. The contracts entered into by our Company with its clients normally include clauses permitting
us to recover the cost of escalations in the price of materials and labour. However, such variation clauses
normally link the additional amounts which our Company can recover to levels of increase in specified
published indices. We cannot assure you that the additional amounts which our Company should recover
from clients in respect of the increased cost of materials and labour will be the full amount of such
increased costs borne by us.
Further, the prices and supply of these and other raw materials depend on factors not under our control,
including general economic conditions, competition, production levels, transportation costs and import
duties. Revenues, costs and profits will often vary from original estimates due to factors such as changes
in project conditions, fluctuations in costs of construction materials, variations in labour and equipment
costs and weather conditions. These risks, which are inherent in the construction industry, may result in
profits being different from those estimated and may result in decreased profitability or even losses in
affected projects. Although we normally provide a margin in our estimates for increases in labour and
material costs and other contingencies, significant cost overruns may still occur, and could adversely
affect our business, results of operations and profitability.
8. Our projects and revenues are geographically concentrated in Maharashtra, Karnataka and West
Bengal. Consequently, we are exposed to risks emanating from economic, regulatory and other
changes in these states which we may not be able to successfully manage and which in turn may have
an adverse effect on our revenues, cash flows, profits and financial condition.
While we enjoy a nationwide presence, our operations and revenues are geographically concentrated in
Maharashtra, Karnataka and West Bengal. Our Company’s projects in the aforesaid regions accounted
for 85% of the Order Book as at September 30, 2017. Our business is, therefore, significantly dependent
on the general economic and market conditions in these regions in which we operate and respective state
and local government policies relating to our industry. Should there be a regional slowdown in
infrastructure, maritime activities or economic activity or any adverse regulatory development in these
32
areas or any developments that would make undertaking the relevant projects economically less
profitable, the growth of our business, our financial condition, our cash flows and results of operations
could suffer.
9. Statutory auditors of our Company have included certain qualifications/ observations and Emphasis
of Matters (“EOMs”) paras in their respective audit reports of our Company.
The statutory auditors of our Company have included certain qualifications, observations and EOMs in
their respective audit reports of our Company in the last five financial years immediately preceding this
Preliminary Placement Document, including with respect to the Companies (Auditor‘s Report) Order,
2012, 2013, 2014, 2015 and 2016 as applicable, which are discussed in our standalone and consolidated
financial information. If we are required to restate the accounts for any reason including due to
accounting standards or regulatory requirements or otherwise, we may be required to readjust all of the
receivables and other items specified in these qualifications which may result in loss for the subsequent
period or we will be unable to meet our financial covenants/obligations. Further, there can be no
assurance that our auditors will not qualify their opinion in the future. For further details and management
responses to each of these qualifications and / or EOMs, please refer to the “Financial Statements” and
“Management's Discussion and Analysis of Financial Condition and Results of Operations” on page
194and 60 respectively.
10. We are involved in certain legal and other proceedings. An adverse outcome in such proceedings may
have an adverse effect on our financials.
The nature of the business segments that we operate in are such that, from time to time we have been,
and expect to continue to be subject to legal proceedings and claims in the ordinary course of our
business, particularly relating to liability claims and dispute under customer contracts. We are currently
involved in certain legal proceedings in India. These legal proceedings are pending at different levels of
adjudication before various courts and tribunals. Details of the total number of material proceedings
pending by and against us are mentioned below:
Material Litigations filed against our Company:
Nature of cases/ claims Number of cases outstanding
Civil Matters 69
Criminal Matters 6
Tax Matters Nil
* To the extent quantifiable.
x
Material Litigations filed by our Company:
Nature of cases/claims Number of cases outstanding
Civil Matter 9
Criminal Matter 1
Tax Matter 30
We can give no assurance that these legal proceedings will be decided in our favour and we may incur
significant expenses and management time in such proceedings and may have to make provisions in our
financial statements, which could increase our expenses and liabilities. If any new developments arise,
for example, rulings against us by the appellate courts or tribunals, we may face losses and may have to
make provisions in our financial statements, which could increase our expenses and our liabilities. If
such claims are determined against us, there could be an adverse effect on our reputation, business,
financial condition and results of operations, which could adversely affect the trading price of our Equity
Shares.
For further details of these legal proceedings, please refer to chapter titled “Legal Proceedings”
beginning on page 177.
11. We have experienced losses and negative cash flows in earlier Fiscals 2014, 2015 and 2016 and may
experience such losses and / or negative cash flows in the future. An inability to generate sufficient
cash flows in the future may adversely affect our business operations and financial performance.
33
We had losses and negative net cash flows from our operating, investing & financing activities in Fiscal
2016, Fiscal 2015 and Fiscal 2014 on a consolidated basis, the details of which are provided below.
Further our Company has also suffered losses in the past, the details of which are provided below.
(₹ in lakh)
Particulars Fiscal 2016 Fiscal 2015 Fiscal 2014
Net cash generated from operating activities N.A.# N.A.# N.A.#
Net cash used in investing activities (637.09) (10,409.08) (3,835.69)
Net cash used in financing activities (25,575.65) (30,209.03) (428.51)
Net profit/(loss) for the year N.A.# (5,930.76) N.A.# # Indicates positive cash flows
Cash flow is a key financial indicator of cash generated from operations to meet our capital expenditure,
pay dividends, repay loans and make new investments without raising finance from external resources.
An inability to generate sufficient cash flows in the future may adversely affect our business operations
and financial performance.
12. In the recent past, we had reached a onetime settlement with a statutory agency for settlement of all
awards received, claims under consideration, at various forums which was written off in our books of
accounts.
In the year 2015, we had entered into a definitive agreement with a statutory agency pursuant to which
both parties agreed to settle all awards received, claims under consideration at various forums, pending
disputes and amounts outstanding in the Company’s and relevant joint venture’s books of account under
trade receivables and unbilled work-in-progress in respect of all the contracts executed by our Company
and the relevant joint venture. Pursuant to this settlement the Company including its share in Joint
Venture had accounted for the resultant loss on the settlement of ₹12,397.19 lakh which had been
disclosed as an exceptional item in Fiscal 2015 and written off during the Fiscal 2015. We cannot assure
you that our Company will not enter into any such similar arrangement in the future as well to settle
outstanding disputes with its clients and that such settlements will not adversely affect our financial
results.
13. There has been a variation in the end use of proceeds as compared to the objects of the issue stated in
the previous rights issue offer document.
In respect of the rights issue of Equity Shares by our Company in September 2006, it had in the offer
document projected deployment of ` 767.55 lakh towards payment of security deposit towards procuring
capital equipment operating lease / hire purchase and ` 150.00 lakh towards meeting expenses of the
rights issue. The proceeds of the rights issue were partly utilized to meet the said objectives, however a
sum of ` 274.11 lakh and ` 77.45 lakh remained unutilized as on December 31, 2006 and since our
Company did not foresee any immediate requirement as mentioned above, we obtained shareholders’
approval to utilize this amount towards any one or more of the objects of the said rights issue.
Subsequently, pursuant to the shareholders resolution passed at the annual general meeting held on April
27, 2007, the aforesaid sum of ` 274.11 lakh and ` 77.45 lakh were utilized by our Company towards
meeting the working capital requirements in the financial year 2007.
14. Changes in the scope of work may result in disputes, which could have a material and adverse impact
on the profits from that project.
In certain cases, we may be required to perform additional work on a project that is beyond the stated
scope of the contract. We may not receive any remuneration for the same, or payments in respect of the
same may be delayed or may not be commensurate with the quantum of work performed, which may
have a material adverse effect on our profits. Further, in certain contracts we may be required to execute
modified work order as directed by the client who may not have been agreed upon at the time of execution
of the contract. This process may result in disputes and may result in delayed or inadequate payments.
This could have an adverse effect on our profits.
15. Our Company has significant indebtedness and the conditions and restrictions imposed on us by our
financing agreements could adversely affect our ability to conduct our business.
34
As of September 30, 2017, our Company had total borrowings of ₹52,698.07 lakh on a consolidated
basis, which includes short-term borrowings of `45,540.64 lakh, other borrowings (representing current
maturities of long term borrowings) of `5,159.53 lakh and long-term borrowings of `1,997.90 lakh. In
respect of various agreements entered into by our Company with the lenders, we are bound by certain
restrictive covenants. A majority of these covenants are specific to the conduct of our Company and our
Company is required to obtain written consent from the lenders in relation to certain actions/matters,
amongst others, including entering into any scheme of amalgamation or merger/demerger/reconstruction,
declaration of any dividends if there are any arrears in making any payment of amount(s) due to our
lender(s), entering into any arrangement for settlement of litigation for any such amount which would
have a material adverse effect on our Company, not to change/vary our constitution, name, location of
the unit, product line, technical process and machinery and godown not to have any banking account or
borrowing arrangements, not to make any changes to the general nature or scope of the business from
that carried on by our Company, formulate any scheme of amalgamation or merger or reconstruction,
effect any adverse changes in our Company’s capital structure, make any drastic changes in its
management set-up, approach capital markets for mobilizing resources either in the form of debtor
equity, approach prepayment of the outstanding principal amount of the facility on full or in part before
the due date, before creating any further security/ collateral/ personal or corporate guarantee which is
more favourable to such lender/ bank than the terms agreed to amongst others. Such restrictions or
limitations may adversely limit our Company's operations and financial flexibility, and adversely affect
its business, results of operations and financial condition.
Further, our short term borrowings are repayable on demand. In the event that the lenders of such loans
call in these loans, alternative sources of financing may not be available on commercially reasonable
terms, or at all. Any such unexpected demand for repayment may materially and adversely affect our
Company’s cash flows, business, financial condition, results of operations and cash flows.
16. Our contingent liabilities that have not been provided for in our financial statements may have an
adverse impact our financial condition.
The table below sets out our consolidated contingent liabilities (as disclosed in our audited financial
statements in prepared in accordance with Indian GAAP) that have not been provided for, as of December
31, 2016.
Particulars Amount
(` in Lacs)
Guarantees given by banks in respect of contracting commitments in the
normal course of business
43,094.03
The Company has a number of claims on customers for price escalation and/
or variation in contract work. In certain cases which are currently under
arbitration, the customers have raised counter – claims. The Company has
received legal advice that none of the counter – claims are legally tenable.
Accordingly, no provision is considered necessary in respect of these
counter claims.
21,743.22
Sales tax matters pending in appeals 6,311.74
Income tax matters pending in appeals 1,933.07
Excise matter pending in appeal 51.70
Any or all of these contingent liabilities may become actual liabilities. In the event that any of these
contingent liabilities materialises, our business, results of operations, prospects, cash flows and financial
condition may be adversely affected.
17. Our working capital requirements may increase in future depending on the requirements of the
projects under execution. If we are unable to generate sufficient cash flows to allow us to make
required payments on our debt or fund working capital requirements, there may be an adverse effect
on our results of operations.
Some of our contracts under execution have high working capital requirements. In many cases,
significant amounts of working capital are required to finance the purchase of materials and the
performance of engineering, construction and other work on such contracts before payments are received
35
from clients. The actual amount and timing of our future capital requirements may differ from estimates
of, inter alia, unforeseen delays or cost overruns, unanticipated expenses, regulatory changes, economic
conditions, design changes, weather related delays, technological changes and additional market
developments and new opportunities.
Our working capital requirements may increase if, under certain contracts, payment terms do not include
advance payments or such contracts have payment schedules that shift payments toward the end of a
project or otherwise increase our working capital burden. In addition, our working capital requirements
have increased in recent years because we have undertaken a growing number of projects within a similar
timeframe and due to the growth of our Company’s business generally. We have in the past experienced
delays in receipt of our dues from clients; all of these factors may result, or have resulted, in increase in
our working capital needs.
It is customary in the industry in which we operate to provide bank guarantees in favour of clients to
secure obligations under contracts. These may extend, wholly or partly, during the contract period and
even after the date of completion of the contract for an additional period of up to six to twelve months.
If we are unable to provide sufficient collateral to secure such bank guarantees, our ability to enter into
new contracts or obtain adequate supplies could be limited. Providing security to obtain bank guarantees
increases our working capital needs. We may not be able to continue obtaining new bank guarantees, on
commercially acceptable terms or at all, to match our business requirements. This may have a material
adverse effect on our business, results of operations and financial condition.
18. Failure to adhere to agreed contractual conditions with clients could adversely affect our reputation
and/or expose us to financial liabilities.
Our Company’s contracts are subject to specific requirements on timelines, quality and other conditions
with appropriate contractual remedies to be imposed by the client for non-performance of our obligations.
Any default of these obligations unless accepted by the client/s could lead to rescinding the contract
either by the client causing damage to our reputation and / or affect the financial outcomes. Alternatively,
our Company may also choose to rescind a contract in case of any default made by our client and / or for
the non-performance of their obligations which may in turn cause damage to our reputation and / or affect
our financial results.
19. Any downgrading of our Company’s debt ratings could impact our ability in future to raise finance
on favorable terms or at all, which in turn could adversely affect our business, financial condition and
results of operations.
As at September 30, 2017, our Company had total borrowings of ₹52,698.07 lakh on a consolidated
basis, which includes short-term borrowings of `45,540.64 lakh, other borrowings (representing current
maturities of long term borrowings) of `5,159.53 lakh and long-term borrowings of `1,997.90 lakh. Our
Company’s long-term debt is rated by CARE Rating as ‘CARE A1’ and short term debt is rated by CARE
Rating as ‘CARE A / CARE A1’. While, the rating of the Company continues to derive strength from
proven track record in construction industry, healthy order improvement combined with improved
financial matrix of the Company, we cannot assure you that the debt rating will not be revised in future.
Any failure to service our indebtedness, maintain the required security interests, compliance with a
requirement or otherwise perform our obligations under our financing agreements could lead to a
termination of one or more of our credit facilities, penalties and acceleration of amounts due under such
facilities which may lead to downgrading of our Company’s debt ratings which could impact our ability
to raise finance in future on favourable terms or at all and in turn adversely affect our business, financial
condition and results of operations.
20. We have preferred claims on some of our clients towards compensation of additional costs and / or
time in respect of work performed by us for such clients which we consider recoverable in accordance
with the terms and conditions of the respective contracts. In the event we are unable to realise amounts
recoverable and considered in our revenues for the period to date, the same would adversely affect our
financial condition.
In some of the contracts performed/under completion by us, we have encountered additional costs and
overrun in time. We have preferred claims on the corresponding clients and the same are in several stages
of dispute resolution, arbitration and in courts. Based on probable recovery against these claims and in
line with the accounting policies followed by us, we have recognised revenues and margins in our
36
financial results for the period to date. Denials or prolonged delays in the realisation of the amounts
recognised or enforcement of counterclaims against us on these claims would adversely affect our
financial results and cash flows.
21. We are exposed to various risks at our sites which could result in additional liabilities and/or costs to
us.
Our operations are subject to several hazards such as risk of equipment failure, work accidents that may
cause injury and loss of life, severe damage to and /or destruction of property and equipment and / or
environmental damage.
During the provision of our engineering and construction services, we undertake liabilities relating to
design, engineering, materials, workmanship, construction and maintenance during defect liability period
etc. Claims from the client could arise for a perceived default of our obligations. We provide our
competitive bids after considering reasonable and assessed costs towards performance of contractual
obligations including where considered necessary and where mandated, specific insurance coverage.
Where the risk mitigation through appropriate insurance coverage or provision of assessed costs for
complying with its obligations is found insufficient, we may be called upon to compensate the claimant/s
for such costs which were not assessed or insured against or provided for and could affect the financial
condition and have a material adverse effect on our business. In case of any failure by us in the actual
execution of these obligations, we would be liable to claims alleging default of the obligation.
22. Obsolescence, destruction, theft, breakdowns of our assets or failure to repair or maintain the same
may adversely affect our business, cash flows, financial condition and results of operations.
We own/ take on lease a fleet of equipment and tools including modern equipment for flyover
construction, concrete production and movement, maritime gantries, modern hydraulic piling plant and
associated equipment (together “Owned/ Leased Assets”). To maintain our capability to undertake large
and complex projects, we seek to purchase/ lease equipments built with the latest technologies and
knowhow and keep them readily available for our construction activities through careful and periodic
repairs and maintenance. However, we cannot assure you that we will be immune from the associated
operational risks such as the obsolescence of our Owned/ Leased Assets, destruction, theft or major
equipment breakdowns or failures or delays to repair or maintain our Owned/ Leased Assets, which may
result in their unavailability, project delays, cost overruns and even defaults under our contracts.
Our recent experience indicates that clients are increasingly developing larger, more technically complex
projects in the infrastructure sector. To meet our clients’ needs, we will need to regularly update existing
technology and acquire or develop new technology for our engineering and infrastructure services in a
cost effective manner. In addition, rapid and frequent technology and market demand changes can often
render existing technologies and equipment obsolete, requiring substantial new capital expenditures
and/or write-downs of assets. Our failure to anticipate or to respond adequately to changing technical,
market demands and/or client requirements could adversely affect our business, financial condition and
results of operation.
Obsolescence, destruction, theft or breakdowns of our Owned/ Leased Assets may significantly increase
our asset purchase cost and the depreciation of our assets, as well as change the way our management
estimates the useful life of our assets. In such cases, we may not be able to acquire new assets or repair
the damaged assets in time or at all, particularly where our assets are not readily available from the market
or requires services from original asset manufacturers. Some of our major assets or parts may be costly
to replace or repair. We may experience significant price increases due to supply shortages, inflation,
transportation difficulties or unavailability of bulk discounts. Such obsolescence, destruction, theft,
breakdowns, repair or maintenance failures or price increases may not be adequately covered by the
insurance policies availed by our Company and may have an adverse effect our business, cash flows,
financial condition and results of operations.
23. Our Promoter is engaged in the same line of business as our Company and has also undertaken in
the past some projects independently in India
Our Promoter, Italian-Thai Development Public Company Limited is engaged in the business of
construction which is in the same line of business as our Company. Further, our Promoter has undertaken
37
construction projects independently in India. In such instances there could be a conflict of interest
between our Company and our Promoter. There can be no assurance that such conflict of interest will
not have an adverse impact on our operations and financial performance.
24. Presently in certain cases, we depend on the experience and track record of our Promoter in the
infrastructure sector in qualifying for and in the execution of projects in specific sectors such as
airports, mass rapid transit systems and water projects in joint venture with our Promoter. Our
inability to continue with this arrangement may adversely affect our business and results of
operations.
In select cases of infrastructure projects where the pre-qualification requires a financial and technical
track record, we draw upon the experience and track record of our Promoter in the infrastructure sector
in qualifying, bidding and execution of these large projects. Our business and growth depends upon our
Promoter and our inability in continuing this arrangement may adversely affect our business and
operations.
25. We deploy a large workforce at our project sites and staff at offices. Demands and / or group activity
by any of these groups including work stoppages and other forms of industrial action could result in
delays and additional costs affecting our operating results
As of September 30, 2017, we employed a staff of 1,953 employees. In addition, we have a large number
of site based staff, piece rate and temporary contract labour on our project sites.
We have not experienced any major disruption in our work in the past. However, there can be no
assurance that we will not experience future major disruptions to our operations due to disputes or other
problems with our work force, which may adversely affect our business and results of operations. The
number of contract labourers varies from time to time based on the nature and extent of work contracted.
Contract labourers engaged at the project sites are governed by minimum wages regulations that are fixed
by local government authorities. Any upward revision of wages required by such governments to be paid
to such contract labourers, or offer of permanent employment or the unavailability of the required number
of contract labourers, may adversely affect our business and results of operations. We also enter into
contracts with independent contractors to complete specified assignments. Non-compliance with any
prevalent labour laws by such independent contractors may result in penalties and/or expose our
Company to other consequential risks which we may not be able to recover from such independent
contractors in all cases.
26. The failure of a joint venture partner to perform its obligations could impose additional financial and
performance obligations resulting in reduced profits or, in some cases, significant losses from the joint
venture.
We presently enter and may continue to enter into various joint ventures with other companies as part of
our business. As on September 30, 2017, Company’s share in joint venture projects under execution
amounts to 48% of our total order book. The success of these joint ventures depends on the satisfactory
performance by our joint venture partners and fulfilment of their obligations. If our joint venture partners
fail to perform these obligations satisfactorily, the joint venture may be unable to perform adequately or
deliver its contracted services. In this case, we may be required to make additional investments and/or
provide additional services to ensure the adequate performance and delivery of the contracted services
because we are subject to joint and several liabilities as a member of the joint venture in a number of
projects. These additional obligations could result in reduced profits or, in some cases, losses for us. The
inability of a joint venture partner to continue with a project due to financial or legal difficulties could
mean that we would bear increased and possibly sole responsibility for the completion of the project and
bear a concomitant increase in the financial risk of the project. In addition, partners in our joint ventures
may:
be unable or unwilling to fulfil their obligations, whether of a financial nature or otherwise;
take actions contrary to our instructions or requests or contrary to a joint ventures’ policies and
objectives;
fail to provide timely financial and operating data in order to comply with periodic reporting
obligations to clients, lenders or as required by law;
take actions that are not acceptable to regulatory authorities;
38
have financial difficulties; or
have disputes with us.
The aforesaid factors may adversely affect our business and results of operations.
27. We may be unable to pre-qualify to bid on certain larger projects on our own and if we are unable to
forge alliances with third parties, we may be precluded from bidding for those large projects, which
could have an adverse effect on our growth prospects and operations.
Our ability to bid for and win major projects is dependent on our ability to demonstrate our experience,
engineering capabilities in executing technically complex projects and our financial resources and/or
ability to access funds. In selecting contractors for major projects, clients generally limit the tender to
contractors they have pre-qualified based on several criteria including financial strength, experience in
successful execution of similar and comparable projects, technical capabilities, plant and equipment,
quality and safety performance records and ability to provide guarantees and bonds.
Based on these qualifying parameters, projects are then bid on competitive basis amongst organisations
who meet the above criteria. International engineering and construction companies now participate
actively in the Indian market and are likely to leverage their overseas experience and financial strengths
in meeting the above criteria and bid competitively for these large projects.
Our ability to bid for and win such projects is dependent on our ability to qualify and competitively quote
for such large projects. Consequently any deficiencies in these areas are likely to influence the business
operations and results from operations.
Moreover our competitors with greater financial resources and greater economies of scale than us may
be able to prequalify in their own right and/or attract a joint venture partner more easily than us. In cases
where we are unable to forge an alliance with appropriate companies to meet pre-qualification
requirements, we may lose out on opportunities to bid, which could have an adverse effect on our growth
prospects and operations.
28. On fixed-price, lump sum or item-rate contracts, we are exposed to increases in the cost of construction
materials, fuel, and equipment.
Under fixed-price or lump sum contracts, we typically agree to a fixed price for providing civil
construction for the part of the project contracted to us.
Under these contracts, additional costs associated with cost increases in construction materials, fuel,
equipment, and materials are borne by us, unless these contracts contain price escalation clauses.
Similarly, we bear the additional cost associated with quantities of construction materials, fuel,
equipment and materials exceeding estimates and assumptions. The prices and supply of these
construction materials depend on factors beyond our control, including general economic conditions,
competition, production levels, transportation costs and import duties. Some of our construction contracts
either contain limited or no price escalation clauses covering these additional costs.
Under item-rate contracts, we agree to provide certain construction activities at a rate specified in the
relevant bill of quantity, or “BOQ”. The BOQ is an estimate of the quantity of activities involved and
these quantities may be varied by the parties during the course of the project. Although the additional
costs associated with actual quantities exceeding estimated quantities may not pass to our Company
entirely, we however, bear the risk associated with actual costs for construction activities exceeding the
agreed upon rate, unless these item-rate contracts contain price escalation clauses.
For fixed-price or lumpsum or item-rate contracts, we may bear additional cost if actual expenses vary
substantially from the assumptions underlying its bid and forecasted budget for reasons related to the
following:
unancticipated changes in engineering design of the project;
drawings and technical information provided by the clients, and on which bids were based, and not
accurate. We typically do not have recourse to clients for errors and omissions in drawings and
technical information provided by them. Under the terms of many contracts, we are deemed to accept
any risk associated with inadequacies, errors or omissions in such drawings and technical
39
information;
unforeseen design and engineering construction conditions, site and geological conditions, resulting
in delays and increase costs;
inability by the client to obtain requisite environmental and other approvals;
delays associated with the delivery of equipment and materials to the project site;
unanticipated increases in equipment costs;
delays caused by local and seasonal weather conditions; and
suppliers or sub-contractors failure to perform their obligations in a timely
As fixed price or lump sum and item-rate contracts also tend to be fixed-time contracts, we bear the risk
of unanticipated delays other than for force majeure events.
Unanticipated costs or delays in performing part of a contract and/or unanticipated increases in the price
of construction materials, fuel, equipment, and materials can have a compounding effect by increasing
costs of performing other parts of the contract. There may also be a higher risk of delay created by the
fact that construction contracts are sometimes divided into multiple parts to be simultaneously performed
by us and joint venture partners.
These risks generally inherent to the construction industry may result in lower profits than originally
estimated and may result in reduced profitability or losses on our projects
29. Increase in interest rates may materially impact our results of operations.
Our business requires a significant amount of working capital to finance the purchase of construction
materials, submission of earnest money deposit and other work on our infrastructure projects before
payment is received from clients. We also avail term loans to meet our capital expenditure requirements,
which carry a high interest rate.
Increases in interest expense may have an adverse effect on our results of operations and financial
condition. Our current debt facilities carry interest at variable rates as well as fixed rates with the
provision for periodic reset of interest rates. As of December 31, 2016, a major portion of our
indebtedness was subject to variable interest rates.
Although we may decide to engage in interest rates hedging transactions or exercise the rights available
to our Company to terminate the current debt financing arrangement on the respective reset dates and
enter into new financing arrangements. There can be no assurance that we will be able to raise funds or
do so on commercially reasonable terms or at all.
30. Our Promoter has interests in our Company other than reimbursement of expenses incurred or normal
remuneration or benefits.
Our Promoter is interested in our Company to the extent of their shareholding in our Company and
royalty fees for the use of the ‘ITD’ trademark. Further our Promoter may also be deemed to be interested
to the extent of any dividend payable to them or other distributions in respect of the Equity Shares.
The Promoter is also interest to the extent of their share in the Joint Ventures which our Company has
entered into with our Promoter. For more details, see the section titled “Related Party Transactions”
beginning at page 125.
31. While the post issue shareholding of the Promoter in our Company will fall below 51%, our Promoter
will continue to retain majority control in our Company after the Issue, which will allow it to influence
the outcome of matters submitted to shareholders for approval.
Pursuant to Articles 111A, 137 and 146 of the Articles of Association, so long as our Promoter holds not
less than 26% of the total paid-up Equity Share capital of our Company it has the right to appoint not
exceeding one-third of the total number of Directors of our Company and to remove such persons from
office, appoint and remove the Managing Director(s) and appoint or remove the Chairman of the Board.
As of December 31, 2017, our Promoter owned approximately 51.63 % of our share capital. Please see
section titled "Principal Shareholders" on page 143. Owing to the right of the Promoter enshrined in the
40
Articles of Association and their majority stake, the Promoter may be in a position to influence decisions
relating to our business and the outcome of matters submitted to shareholders for approval. In addition,
for so long as the Promoter continues to exercise significant control over our Company, it may influence
the material policies of our Company in a manner that could conflict with the interests of our other
shareholders.
32. Invocation of performance guarantees issued in relation to one of our projects could adversely affect
our financial condition.
We are required to provide performance guarantee to the owner of the project during the construction
period which may extend until the end of the defects liability period. Performance risk refers to the risk
that the work is not executed according to specifications laid out in the contract, which may lead to
triggering the encashment of the performance guarantee. Defects liability periods typically extend to one
year after completion of a project. All of our projects are covered by guarantees, some of which are
substantial and include performance guarantees, which are provided as security for any monetary loss
suffered by the client up to the amount of such guarantees in the event of any failure on our part to ensure
the satisfactory execution and completion of various awarded projects in line with contractual
specifications. In the event of any performance related issues or if contractual obligations are not
completed as per scheduled time then the financial or performance guarantees provided maybe invoked,
thus exposing us to additional and increased financial liabilities. As at December 31, 2016, the
outstanding guarantees given by banks in respect of our contracting commitments in normal course of
business amounted to ₹ 43,094.03 lakhs and on behalf of our joint ventures amounted to ₹ 48,651.00
lakhs. Further, during the year ended December 2013, one of our clients has invoked bank guarantees
amounting to ` 9,200.00 lakh. Subsequently, our Company amicably settled the matter with the client
and our Company has recommenced work on the project. A call on one or more of these guarantees could
adversely affect our financial results, will deplete our finances and lead to a liquidity crunch and a call
on our performance guarantee may harm our reputation and limit our capability to attract new projects.
33. We recognise revenue based on the “Percentage of Completion Method” of accounting on the basis
of the stage of completion and its revenues may fluctuate significantly from period to period.
Our Company recognises revenue generated from its construction contracts on the “Percentage of
Completion Method” as per the applicable accounting standard. The stage of completion of a contract is
determined by the proportion that contract costs incurred for work performed upto the reporting date bear
to the estimated total contract costs. Percentage of completion is determined on the basis of cost incurred.
Contractual liquidated damages, payable for delays in completion of contract work or for other causes,
are accounted for as costs when such delays and causes are attributable to the Company or when deducted
by the client.
In the event of any change in law that requires a change in the method of revenue recognition, our
Company’s financial results may be adversely affected. For example with effect January 1, 2017 the
revenues of only those joint venture where our Company exercises control (as defined under Ind AS) are
consolidated pursuant to adoption of Ind AS. For the details of the method of revenue recognition, see
the section titled “Management’s Discussion and Analysis of Financial Conditions and Results of
operations — Significant Accounting Policies” at page 114 and “Summary of key differences between
Indian GAAP and Ind AS” at page 86.
34. Our statements regarding our work in hand may not be representative of our future results.
Our Company defines order book as anticipated revenues from the uncompleted portion of existing
contracts as of a certain date. The order book amount does not necessarily indicate future earnings related
to the performance of that work. Further, our order book also includes our share of the order book of the
joint ventures where our Company does not exercise control (as defined under Ind AS) which are not
consolidated pursuant to adoption of Ind AS. Our inability to complete the projects within anticipated
timelines and/or achieve expected margins and/or performance targets, could reduce our profit or cause
us to incur a loss. Future earnings related to the performance of the work in the order book may not
necessarily be realised. Although projects in the order book represent business that our Company
considers firm, cancellations or scope adjustments may occur. Due to possible changes in project scope
and schedule, our Company cannot predict with certainty when or whether projects in its order book will
be performed and generate revenue. Further certain contracts which are part of the order book may get
delayed or cancelled interalia on account of non-achievement of financial closure of the project by the
41
client. In addition, even where a project proceeds as scheduled, it is possible that contracting parties may
default and fail to pay amounts owed or dispute the amounts owed to our Company. There may also be
delays associated with collection of receivables from clients. Any delay, cancellation or payment default
could materially harm our cash flow position, revenues or profits.
35. We have entered into transactions with related parties.
Our Company has in the course of our business entered into transactions with related parties, including
our Promoter. For detailed information on our related party transactions, see the section titled “Related
Party Transactions” beginning at page 125. Further, our business will continue to involve transactions
with such related parties, in the future.
36. We depend on sub-contractors for timely and successful completion of certain parts of our projects
and failure on the part of our sub-contractors to perform their obligations in a timely manner or at all
could adversely affect our ability to complete projects in a timely manner at commercially viable terms.
We depend on sub-contractors for timely and successful completion of certain part of our projects and
failure on the part of our sub-contractors to perform their obligations in a timely manner or at all could
adversely affect our ability to complete projects in a timely manner at commercially viable terms or at
all, which in turn could subject us to time and cost overruns, defaults under the contracts for such projects
and loss of revenue and profitability.
We assign work to various subcontractors to assist us depending on the area, type, duration and size of
our projects.Weattempttoensurethattheservicesperformedbyoursubcontractorsareofahigh standard as full
responsibility to the customer for all construction projects rests with us (although the subcontractor is
responsible to us for its work). There is no assurance that the quality of work performed by such
subcontractors will always be of a sufficiently high standard. Further, the use of subcontractors exposes
us to various risks over which we may have little or no control, including the possibility that a
subcontractor may fail or otherwise become unable to perform or complete projects, or that projects may
otherwise be delayed or defective.
Even when our Company sub-contracts work, it remains responsible for the sub-contracted work which
means clients still have recourse to our Company for actions, omissions and defects by sub-contractors.
In some cases, our Company may not receive guarantees or indemnities from sub-contractors as to timely
completion, cost overruns, or additional liabilities which means that it assumes the risk of delayed or
reduced payments, liquidated damages or penalty amounts, or contract termination by the client. Our
Company also assumes liability for defects in connection with any work done by sub-contractors. Hence,
any failure on the part of our sub-contractors to perform their obligations in a timely manner or at all
could adversely affect our operations, financial condition and cash flows.
37. We maintain a workforce based upon current and anticipated workloads. If we do not receive future
contract awards or if these awards are delayed, we could incur significant costs.
The estimates of future performance depend on, among other things, whether and when we will receive
certain new contract awards. We maintain a workforce based upon current and anticipated workloads.
The strength of our workforce as on September 30, 2017 is 1,953 employees. While our estimates are
based upon our best judgement, these estimates may change based on account of changes in the available
information. In case of large-scale projects where timing is often uncertain, it is particularly difficult to
predict whether or when we will receive a contract award. The uncertainty of contract awards and timing
can present difficulties in matching the workforce size with the contract needs. If an expected contract
award is delayed or not received, we would incur expenses due to maintaining under-utilised staff and
facilities that would have the effect of reducing our profits.
38. We depend on machinery and equipment to implement our projects. We order these machinery and
equipment from various parts of the world. Any manufacturing defect or poor maintenance systems
of the machinery may cause strain on our machinery and lead to delays in implementation of our
projects.
We depend on machinery and equipment to implement our projects. We order these machinery and
equipment from various parts of the world. Any manufacturing defect or poor maintenance systems of
the machinery may cause strain on our machinery and lead to delays in implementation of our projects
42
and loss of performance. In addition, technology advancements could result in lower future utilization of
equipment, which may have an adverse impact on our business, operations and profitability.
39. During the tenure of the project, the creditworthiness of our clients may weaken, which may affect
their paying capacity and may lead to delays in our payments.
One of the risks associated with construction companies, such as ours, is the credit worthiness and the
paying capacity of the clients. If the client does not have adequate funds, it could delay our projects or
even lead to cancellation of the project. Moreover, we may or may not get any compensation if payments
due to us are delayed, which may have an adverse effect on our liquidity.
40. Demand for our services is dependent on growth in infrastructure and general economic conditions.
Demand for our services is largely dependent on general economic conditions, growth in infrastructure
and economic cycle. Our business is also directly affected by changes in government spending and capital
expenditures by our clients. Any change or downturn that leads to decreased spending on construction
projects including privately funded infrastructure projects, could adversely affect our business and our
results of operations.
41. Contracts awarded to us by government entities are based on standard forms and may contain terms
that favour the government entity.
A major part of our business is dependent on government projects and we sign construction contracts
with such government entities as the client. We have limited ability to negotiate the terms of these
contracts resulting in many terms in such agreements favouring the client. In certain contracts we believe
the present risks to our business are:
non availability of clear dispute resolution mechanisms other than the courts;
to the extent defects in site or geological conditions are unforeseen or latent from our investigations,
design and engineering prior to submitting a bid, we may have to bear the risks associated with such
defects and may not have any recourse to the client;
in many cases, though the client has the discretion to grant time extension and reimburse related
costs, this cannot be enforced by us; and
even though there are contractual recourses available in the contract, the government entity may
have the right to terminate the contract, at any time after serving us with notice.
42. Delays in the acquisition of land by the GoI and/or state government may adversely affect the timely
performance of our obligations under construction contracts leading to disputes with our clients and
corresponding results from operations.
Mainly for our road, irrigation and metro rail projects, our clients are typically required under the
respective contract agreements to arrange the acquisition or lease of, or secure rights of way over tracts
of land for the project from landowners including private persons. Delays by our clients to acquire or
lease or secure rights of way over land may lead to substantial disputes under respective contracts. Similar
delays in land acquisition could delay the construction activities and consequently delay the completion
of these projects. This may lead to disputes and delay in realising our costs and affect our financial and
operating results.
43. Delays associated with collection of receivables from our clients may adversely affect our business and
results of operations.
We have experienced delays in the collection of receivables from our clients due to various reasons. As
of September 30, 2017, the trade receivables stands at ` 26,944.23 lakh, out of which an amount of
`2,863.37 lakh is expected to be realised after a period of 12 (twelve) months.
We may require additional working capital if we are unable to recover our claims on time due to
disagreements or disputes with clients leading to protracted contractual dispute resolution processes
including arbitration and court proceedings which could result in substantial delays in receipt of
corresponding payments where work may have been performed and/or costs incurred. These may result
in increase in the amount of our receivables and short-term borrowings.
43
The construction business involves significant working capital requirements and delay in collection of
receivables could adversely affect our liquidity and financial results.
44. Inability to handle expansion of our business operations or the delayed provision of required resources
by our Company for such expansion could impact our operations and adversely affect our financial
results.
In order to participate in the growth in the infrastructure industry and consequently expand our
operations, we need to augment our organisation, systems and controls commensurate with the size and
nature of business. This growth may pose significant challenges and demands on our management,
financial and other resources. Our ability to successfully implement our business plan would depend on
adequate systems and resources and we will need to continuously develop and improve our financial,
internal accounting and management controls, reporting systems and procedures to grow and expand our
business.
Inability of our Company to provide these key resources or recover our claims in a timely manner would
seriously impact our operations, growth and financial results.
45. Risks associated with execution of large and complex engineering and construction contracts that may
be secured by us.
The current infrastructure market is evolving towards large and complex projects with significant risks
being passed on to the contractor. We provide competitive bids for large infrastructure projects after
assessment of costs and associated risks on these complex projects. However, as a result of various
conditions prevailing during execution of these projects, the estimated financial outcomes may not
materialise.
46. Given the long-term nature of infrastructure projects, we face development and
implementation/completion risk.
A key element of our strategy is to extend our business of infrastructure development. Typically,
infrastructure development projects involve agreements that are long-term in nature.
The implementation of infrastructure projects involves substantial capital expenditure and other risks
associated with major projects, such as cost overruns, delays in implementation and damages payable
therefor, technical and economic viability and changes in market conditions, fixed capital commitments
over a long period of time, any of which may have a material adverse effect on the results of operations
and profitability of our Company.
Further although our Company builds contingencies into our expected total project costs, there can be no
certainty that such contingencies will be sufficient to fund any such costs. Any project delays or cost
overruns on our projects could have a material adverse effect on the results of operations of our Company.
In addition, any project delays or cost overruns could lead to an early termination of the relevant project
contract by our clients.
47. We execute construction projects through unincorporated joint ventures.
Some of our projects are being executed through unincorporated joint ventures with other companies.
These unincorporated joint ventures are not separate legal entities and the liabilities incurred by such
unincorporated joint ventures would be shared jointly and severally by the members of such joint venture
entities. While cross indemnification is usually available between the joint venture members, we could
be exposed to liabilities arising out of defaults by our joint venture member.
48. The nature of our construction business exposes us to liability claims and contract disputes.
We are involved in large projects where default or inadequacies in design, construction or systems
failures can result in injury or damage to third parties. We could face claims for damages if a project
suffers from defects in the quality of our design, engineering or construction. While we maintain
insurance in accordance with industry standards, there can be no assurance that such insurance will be
sufficient to cover liabilities resulting from claims. Any liability in excess of our insurance limits or any
44
loss arising out of uninsured risks could result in additional costs which could affect our financial results.
Further, in the event a client raises a dispute regarding our performance, it may delay or withhold our
payments which, in turn, would affect our financial results.
49. Our operations are sensitive to weather conditions and adverse weather conditions could affect our
business and results of operations
We operate at multiple sites all over the country where we are exposed to risks arising from force majeure
events including, among others, rain, floods, earthquake, landslides and other natural calamities. These
could cause reduced productivity, cessation, evacuation and other hazards and to the extent the losses are
not recoverable from the client under the respective contract and/or our insurance policies, they may
result in additional expenses on the affected projects and may adversely affect our financial condition
and results of operation.
50. Our infrastructure-related contracts and projects carry risks that may not be fully covered by
insurance policies to cover our economic losses. Further some of our, shorter duration contracts, may
not be insured.
Infrastructure-related projects carry a variety of risks that could be due to technical, legal, financial and
other reasons, which may materialise during the execution of the project. Not all of the risks may be
insurable or possible to insure on commercially reasonable terms. Although for most of our Contracts,
our Company has insurances that are customary for construction projects in India, the insurances,
however, may not provide adequate coverage in certain circumstances such as change in value of
contract(s) and is subject to certain deductibles, exclusions and limits on coverage. Should an uninsured
loss or a loss in excess of insured limits occur, our financial results could be affected.
51. Inability to attract, recruit and retain skilled personnel could adversely affect our business and results
of operations.
In the construction business, we are dependent on our key management personnel, including skilled
project management personnel for setting our current operations and sustainable business growth, which
are crucial to our success and business strategy. Similarly, we are dependent on the availability of a large
pool of contract labour. Our ability to meet current and future business growth opportunities depends on
our ability to attract, recruit and retain experienced, talented and skilled professionals as well as the
availability of a sufficient pool of contract labour to execute construction contracts. Due to the current
limited pool of skilled personnel, competition for senior management, functional specialists including
commercial and finance professionals, and engineers in our industry is intense. We may also need to
increase our pay structures and other employee benefit schemes to attract and retain such personnel,
which could affect our profit margins. Further, there can be no assurance that increased salaries will
result in a lower rate of attrition. The loss of the services of our directors, senior management or other
key personnel or our inability to recruit or train a sufficient number of experienced personnel or our
inability to manage the attrition levels in different employee categories may have an adverse effect on
our operations, financial results and business prospects.
52. We could be adversely affected if we fail to keep pace with technical and technological developments
in the construction industry.
The construction industry is now venturing into larger and more complex projects with major
international companies seeking to enter into the Indian market. Arising from the nature of projects and
international competition, the requirement of technology, operating processes as well as compression of
completion schedules would require our Company to continuously anticipate and keep pace with these
changes. While we have integrated management systems in place including continuous improvement
processes, our inability to continuously improve on our operating competencies could erode our
efficiencies and adversely affect our growth and results from operation.
53. We are subject to operational hazards and other risks that could expose us to material liabilities, loss
in revenues and increased costs.
Our business is subject to hazards inherent in providing construction services, such as risk of equipment
failure, work accidents, fire or explosion, including hazards that may cause injury and loss of life, severe
damage to and destruction of property and equipment, and environmental damage.
45
We may also be subject to claims resulting from defects arising from workmanship, procurement and/or
construction services provided by it within the warranty periods, which generally is for upto 12 months
from the completion of work. Actual or claimed defects in equipment procured and/or construction
quality could give rise to claims, liabilities, costs and expenses, relating to loss of life, personal injury,
damage to property, equipment and facilities, pollution, inefficient operating process, loss of production
or suspension of operations. Our policy of covering these risks through contractual limitations of liability,
indemnities and insurance may not always be effective.
54. Our assets have been charged under various financing agreements. A default under any of the
financing agreements may compel the bank or financial institution to sell the asset to recover its loan,
which may lead to fewer assets available to us to avail further bank facilities, which may affect our
financial condition, cash flow and results of operations.
We maintain bank facilities and term loans with banks and other financial institutions to provide us with
general working capital and operational flexibility in connection with our business. We also receive funds
from banks and other financial institutions pursuant to infrastructure project specific loans.
In the event of a default by us on our financing agreements, our charged assets could be seized, leaving
us with fewer assets with which to operate our business, adversely affecting our business prospects.
Further, under our financing agreements a cross default would also constitute an event of default thus.
Any default in fulfilling our obligations to any lender will trigger the cross default obligations with the
other lenders. This could also result in us having difficulty obtaining further working capital finance from
these or other lenders given our lack of substantial additional security capable of being charged and affect
financial condition, cash flows and results of operations.
55. Our flexibility in managing our operations is limited by the regulatory environment in which we
operate.
The infrastructure sector in India, particularly in relation to maritime, road, and port industries, is highly
regulated. Our businesses are regulated by various authorities and state governments, including the
Ministry of Shipping, Road Transport and Highways, the NHAI, state governments and the GoI.
To conduct our infrastructure development business, we must obtain various licences, permits and
approvals. Even when we obtain the required licences, permits and approvals, our operations are subject
to continued review and the governing regulations and their implementation are subject to change. We
cannot assure that we will be able to obtain and comply with all changes in the governing regulations. If
we fail to comply with all applicable regulations or if the regulations governing our infrastructure
development business or their implementation change, we may incur increased costs or be subject to
penalties, which could disrupt their operations and adversely affect our financial results and business
prospects.
The regulatory framework, which consists of regulations and directives issued by government entities,
has changed significantly in recent years and their impact and ramifications are still unclear. We expect
that certain additional reforms, including change of the current regulatory bodies and existing legal
framework, will take place in the next few years. See the section titled “Regulations and Policies”
beginning at page 128.
Further we are subject to the corporate, taxation and other laws in effect in India which require continued
monitoring and compliances. The introduction of additional government control or newly implemented
laws and regulations and our ability to make corresponding adjustments, may result in a material adverse
effect on our business, results of operations and financial condition and our future expansion plans in
India. In particular, decisions taken by regulators concerning economic policies or goals that are
inconsistent with our interests, could adversely affect our results of operations. While we will take
adequate measures, we cannot assure you that we will be able to timely adapt to new laws, regulations
or policies that may come into effect from time to time with respect to the infrastructure projects
specifically and regulatory regime in general. These laws and regulations and the way in which they are
implemented and enforced may change from time to time and there can be no assurance that future
legislative or regulatory changes will not have an adverse effect on our business, results of operations,
financial condition and cash flows.
46
RISKS RELATING TO OUR EQUITY SHARES AND THE ISSUE
1. Applicants to the Issue are not allowed to withdraw their bids after the Bid/Issue Closing Date.
In terms of the SEBI ICDR Regulations, applicants in this Issue are not allowed to withdraw their Bids
after the Bid/Issue Closing Date. The allotment of Equity Shares in this Issue and the credit of such
Equity Shares to the applicant’s demat account with depository participant could take approximately
seven days and up to ten days from the Bid/Issue Closing Date. However, there is no assurance that
material adverse changes in the international or national monetary, financial, political or economic
conditions or other events in the nature of force majeure, material adverse changes in our Company's
business, results of operation or financial condition, or other events affecting the applicant’s decision to
invest in the Equity Shares, would not arise between the Bid/Issue Closing Date and the date of allotment
of Equity Shares in this Issue. The occurrence of any such events after the Bid/Issue Closing Date could
also impact the market price of the Equity Shares. The applicants shall not have the right to withdraw
their Bids in the event of any such occurrence without the prior approval of the SEBI. Our Company may
complete the allotment of the Equity Shares even if such events may limit the applicants’ ability to sell
the Equity Shares after the Issue or cause the trading price of the Equity Shares to decline.
2. Investors in the Equity Shares may not be able to enforce a judgment of a foreign court against our
Company, its directors and key managerial personnel.
Majority of our directors and key managerial personnel are residents of India and all or substantial portion
of our assets are located in India. As a result, it may be difficult for investors outside India to effect
service of process upon us, our directors, executive officers or such experts in countries outside India,
including the United States, or enforce, in Indian courts, judgments obtained in foreign courts, against us
or such persons or entities. See “Enforcement of Civil Liabilities” beginning on page 10.
3. After this Issue and till Allotment, the price of our Equity Shares may be volatile.
The Issue Price will be determined by us in consultation with the BRLM, based on Bids received in
compliance with Chapter VIII of the SEBI ICDR Regulations, and it may not necessarily be indicative
of the market price of the Equity Shares after this Issue is completed. The trading price of our Equity
Shares may fluctuate after this Issue and Allotment due to a variety of factors, including our results of
operations and the performance of our business, competitive conditions, general economic, political and
social factors, the performance of the Indian and global economy and significant developments in India’s
fiscal regime, volatility in the Indian and global securities market, performance of our competitors, the
Indian financial services industry and the perception in the market about investments in the financial
services industry, changes in the estimates of our performance or recommendations by financial analysts
and announcements by us or others regarding contracts, acquisitions, strategic partnerships, joint
ventures, or capital commitments. Due to which the market value of an investor’s investment may
fluctuate
In addition, if the stock markets in general experience a loss of investor confidence, the trading price of
our Equity Shares could decline for reasons unrelated to our business, financial condition or operating
results. The trading price of our Equity Shares might also decline in reaction to events that affect other
companies in our industry even if these events do not directly affect us. Each of these factors, among
others, could adversely affect the price of our Equity Shares. There can be no assurance that an active
trading market for the Equity Shares will be sustained after this Issue, or that the price at which the Equity
Shares have historically traded will correspond to the price at which the Equity Shares are offered in this
Issue or the price at which the Equity Shares will trade in the market subsequent to this Issue.
4. Conditions in Indian stock exchanges may affect the price or liquidity of the Equity Shares.
The Indian stock exchanges have, in the past, experienced substantial fluctuations in the prices of their
listed securities. The Indian stock exchanges have experienced problems that, if they continue or recur,
could affect the market price and liquidity of the securities of Indian companies, including the Equity
Shares. Problems in the past included temporary exchange closures to manage extreme market volatility,
broker defaults, settlement delays and strikes by brokers. In addition, the governing bodies of the Indian
stock exchanges have from time to time imposed restrictions on the trading of certain securities and
limitations on price movements and margin requirements. Furthermore, disputes have occurred from
time to time between listed companies, stock exchanges and other regulatory bodies, which in some cases
47
may have had a negative effect on market sentiment.
5. There may be less company information available in Indian securities markets than in securities
markets in certain other countries.
There is a difference between the level of regulation, disclosure and monitoring of the Indian securities
markets and the activities of investors, brokers and other participants in markets in the United Kingdom,
the United States and certain other economies. The SEBI is responsible for monitoring, ensuring and
improving disclosure and other regulatory standards for the Indian securities markets and has issued
regulations and guidelines on disclosure requirements, insider trading and other matters. Investors may,
however, have access to less information about our business, results of operations and financial
conditions, on an on-going basis, than investors would have in the case of companies subject to reporting
requirements of certain other countries.
6. There is no guarantee that the Equity Shares issued pursuant to this Issue will be listed on the Stock
Exchanges in a timely manner.
In accordance with Indian law and regulations and the requirements of the Stock Exchanges, in principle
and final approvals for listing and trading of the Equity Shares issued pursuant to this Issue will not be
applied for or granted until after the Equity Shares have been issued and allotted. Approval for listing
and trading will require all relevant documents authorising the issuing of Equity Shares to be submitted.
Accordingly, there could be a failure or delay in listing the Equity Shares on the Stock Exchange. If there
is a delay in obtaining such approvals, we may not be able to credit the Equity Shares allotted to the
investors to their depository participant accounts or assure ownership of such Equity Shares by the
investors in any manner promptly after the Closing Date. In any such event, the ownership of the
investors over Equity Shares allotted to them and their ability to dispose of any such Equity Shares may
be restricted. For further information on issue procedure, see “Issue Procedure” beginning on page 141.
7. Investors may be subject to Indian taxes arising out of capital gains on the sale of the Equity Shares.
Under current Indian tax laws and regulations, capital gains arising from the sale of equity shares in an
Indian company are generally taxable in India. Any gain realised on the sale of listed Equity Shares on a
Stock Exchange held for more than 12 months will not be subject to capital gains tax in India if Securities
Transaction Tax (“STT”) has been paid on the transaction. STT will be levied on and collected by a
domestic Stock Exchange on which the Equity Shares are sold. Any gain realised on the sale of equity
shares held for more than 12 months to an Indian resident, which are sold other than on a recognised
Stock Exchange and on which no STT has been paid, will be subject to long term capital gains tax in
India. Further, any gain realised on the sale of listed Equity Shares held for a period of 12 months or less
will be subject to short term capital gains tax in India. Capital gains arising from the sale of the Equity
Shares will be exempt from taxation in India in cases where the exemption from taxation in India is
provided under a treaty between India and the country of which the seller is resident. Generally, Indian
tax treaties do not limit India‘s ability to impose tax on capital gains. As a result, residents of other
countries may be liable for tax in India as well as in their own jurisdiction on a gain upon the sale of the
Equity Shares.
8. SEBI operates an index-based market-wide circuit breaker. Any operation of a circuit breaker may
adversely affect a shareholder's ability to sell, or the price at which it can sell, the Equity Shares at a
particular point in time.
We are subject to an index-based market-wide circuit breaker generally imposed by SEBI Indian stock
exchanges. This may be triggered by an extremely high degree of volatility in the market activity (among
other things). The percentage limit on our circuit breaker is set by the stock exchanges based on the
historical volatility in the price and trading volume of the Equity Shares. The stock exchanges do not
inform us of the percentage limit of the circuit breaker from time to time, and may change it without our
knowledge. This circuit breaker effectively limits the upward and downward movements in the price of
the Equity Shares. Due to the existence of this circuit breaker, there can be no assurance that shareholders
will be able to sell the Equity Shares at their preferred price or at all at any particular point in time.
9. Any future issuance of Equity Shares may dilute the shareholding of investors and any future sales of
Equity Shares by our major shareholders may adversely affect the trading price of the Equity Shares.
48
The future issuance of Equity Shares by our Company, or the disposal of Equity Shares by any of our
major shareholders, including by the Promoter, lenders that have received a pledge of our Equity Shares
as security and are seeking to enforce such security, or the perception that such issuance or sales may
occur, may significantly affect the trading price of the Equity Shares. Except for the restrictions described
in the sections “Placement” and “Description of the Shares”, there is no restriction on our ability to
issue Equity Shares or the ability of any of our shareholders to dispose of, pledge or otherwise encumber
their Equity Shares, and there can be no assurance that we will not issue Equity Shares or that our
shareholders will not dispose of, pledge or otherwise encumber their Equity Shares. Future issuances of
Equity Shares may dilute the shareholding of the investors and may adversely affect the trading price of
the Equity Shares. Subject to applicable law, such securities may also be issued at prices below the then
market price of the Equity Shares.
10. An investor will not be able to sell any of the Equity Shares subscribed in this Issue other than on a
recognised Indian stock exchange for a period of 12 months from the date of Allotment of the Equity
Shares.
Our Company’s Equity Share are currently listed on the BSE and the NSE. Pursuant to the SEBI ICDR
Regulations, for a period of 12 months from the date of the Allotment of the Equity Shares under this
Issue, QIBs subscribing to the Equity Shares may only sell their Equity Shares through Stock Exchange
mechanism and may not enter into any off market trading in respect of these Equity Shares. Further,
allotment to FVCIs, VCFs and AIFs are subject to applicable rules and regulations, including in relation
to lock-in. We cannot be certain that these restrictions will not have an impact on the price and liquidity
of the Equity Shares.
11. The ability of the investors to sell Equity Shares that they acquire in this Issue is restricted by the
transfer restrictions set forth in the Preliminary Placement Document.
No actions have been taken by our Company in order to permit a public offering of the Equity Shares in
any jurisdiction including India. The Equity Shares are subject to restrictions on transferability and resale.
The investors are required to observe these restrictions, which are set forth in this Preliminary Placement
Document under the section titled ‘Transfer Restrictions’ beginning on page 159. Our Company We will
not be obligated to recognize any acquisition, transfer or resale of the Equity Shares made other than in
compliance with the restrictions set forth herein
12. Since our Equity Shares are quoted in Indian Rupees in India, investors may be subject to potential
losses arising out of exchange rate risk on the Indian Rupee and risks associated with the conversion
of Indian Rupee proceeds into foreign currency.
Foreign investors are subject to currency fluctuation risk and convertibility risk since the Equity Shares
are quoted in Indian Rupees on the Indian stock exchanges on which they are listed. Dividends on the
Equity Shares will also be paid in Indian Rupees. In addition, investors that seek to sell Equity Shares
will have to obtain approval from RBI, unless the sale is made on one of the Stock Exchanges or in
connection with an offer made under the Takeover Code. The volatility of the Indian Rupee against the
U.S. Dollar and other currencies subjects investors who convert funds into Indian Rupees to purchase
our Equity Shares to currency fluctuation risks.
13. Sales of our securities by the existing shareholders may lower the prices of shares.
The market price of our Equity Shares could decline as a result of sale of our Equity Shares or the
perception that such sale could occur in the future. Sale of Equity Shares by existing shareholders may
also make it more difficult for the investors to sell equity shares in the future.
RISKS RELATING TO INDIA AND ABROAD
1. Public companies in India, including our Company, are required to prepare financial statements
under IFRS or Ind AS. The transition to Ind AS in India is very recent and still unclear and our
Company may be negatively affected by such transition.
Public companies in India, including our Company, are required to prepare annual and interim financial
statements under Indian Accounting Standard 101 “First-time Adoption of Indian Accounting Standards
(“Ind AS”). On January 2, 2015, the Ministry of Corporate Affairs, Government of India (the “MCA”)
49
announced the revised roadmap for the implementation of IndAS (on a voluntary as well as mandatory
basis) for companies other than banking companies, insurance companies and non-banking finance
companies through a press release (the “Press Release”). Further, on February 16, 2015, the MCA has
released the Companies (Indian Accounting Standards) Rules, 2015 (the “Ind AS Rules”) which has
come into effect from April 1, 2015. The Ind AS Rules provide for voluntary adoption of Ind AS by
companies in fiscal 2015. Ind AS will be required to be implemented on a mandatory basis by companies.
The timing of such mandatory implementation depends inter alia on the net worth of the companies and
whether the company has securities listed or not. In preparing their first annual financial statements under
Ind AS, companies in India, including ourselves, will be required to prepare annual as per Indian
Accounting Standard 101 “First-time Adoption of Indian Accounting Standards. The recognition and
measurement principles of Ind AS (including IND AS 101) will also be applicable in the preparation of
our interim financial results. Further, from January 1, 2017 onwards, our Company has prepared its
financials as per Ind AS. For further discussion on effect of adoption of Ind AS on our Company’s results,
please refer ‘Summary of key differences between Indian GAAP and Ind AS’ on page 86.
There is not yet a significant body of established practice on which to draw informing judgments
regarding its implementation and application. Additionally, Ind AS differs in certain respects from IFRS
and Indian GAAP and therefore financial statements prepared under Ind AS may be substantially
different from financial statements prepared under IFRS and Indian GAAP. There can be no assurance
that our financial condition, results of operation, cash flow or changes in shareholders’ equity will not be
presented differently under Ind AS than under Indian GAAP or IFRS. When we adopt Ind AS reporting,
we may encounter difficulties in the ongoing process of implementing and enhancing our management
information systems. There can be no assurance that the adoption of Ind AS by us will not adversely
affect its results of operation or financial condition and hence the financials of the current financial year
will not be comparable to the financials of the previous financial year.
2. Our business and activities may be regulated by the Competition Act, 2002.
The Competition Act, 2002, as amended ("Competition Act"), was enacted for the purpose of preventing
practices having an adverse effect on competition in India and has mandated the Competition
Commission of India ("CCI") to regulate such practices. Under the Competition Act, any arrangement,
understanding or action, whether formal or informal, which causes or is likely to cause an appreciable
adverse effect on competition in India is void and may result in substantial penalties. Any agreement
among competitors which directly or indirectly determines purchase or sale prices, directly or indirectly
results in bid rigging or collusive bidding, limits or controls production, supply, markets, technical
development, investment or the provision of services, or shares the market or source of production or
provision of services in any manner, including by way of allocation of geographical area or types of
goods or services or number of customers in the relevant market or any other similar way, is presumed
to have an appreciable adverse effect on competition in the relevant market in India and shall be void.
The Competition Act also prohibits the abuse of dominant position by any enterprise. Further, if it is
proved that any contravention committed by a company took place with the consent or connivance or is
attributable to any neglect on the part of, any director, manager, secretary or other officer of such
company, that person shall be guilty of the contravention and may be punished. It is unclear as to how
the Competition Act and the CCI will affect the business environment in India.
Consequently, all agreements entered into by us may fall within the purview of the Competition Act.
Further, the CCI has extraterritorial powers and can investigate any agreements, abusive conduct or
combination occurring outside India if such agreement, conduct or combination has an appreciable
adverse effect on competition in India. The applicability of any provision of the Competition Act, or any
enforcement proceedings initiated by the CCI, or any adverse publicity that may be generated due to
scrutiny or prosecution by the CCI or if any prohibition or substantial penalties are levied under the
Competition Act, may adversely affect our business, results of operations and prospects.
3. Changing laws, rules and regulations and legal uncertainties, including adverse application of tax
laws and regulations, may adversely affect our business and financial performance.
Our business and financial performance could be adversely affected by unfavourable changes in or
interpretations of existing, or the promulgation of new laws, rules and regulations applicable to us and
our business. Please refer to "Regulations and Policies" on page 122 of this Preliminary Placement
Document for details of the laws currently applicable to us.
There can be no assurance that the Government of India may not implement new regulations and policies
50
which will require us to obtain approvals and licenses from the Government of India and other regulatory
bodies or impose onerous requirements and conditions on our operations. Any such changes and the
related uncertainties with respect to the applicability, interpretation and implementation of any
amendment to, or change to governing laws, regulation or policy in the jurisdictions in which we operate
may have a material adverse effect on our business, financial condition and results of operations. In
addition, we may have to incur expenditures to comply with the requirements of any new regulations,
which may also materially harm our results of operations. Any unfavourable changes to the laws and
regulations applicable to us could also subject us to additional liabilities.
The application of various Indian tax laws, rules and regulations to our business, currently or in the
future, is subject to interpretation by the applicable taxation authorities. If such tax laws, rules and
regulations are amended, new adverse laws, rules or regulations are adopted or current laws are
interpreted adversely to our interests, the results could increase our tax payments (prospectively or
retrospectively) and/or subject us to penalties.
Further, the Government of India has implemented the Goods and Services Act, 2017 with effect from
July 1, 2017 that combines taxes and levies by the central and state Governments into a unified rate
structure. While the Government of India and other state governments have announced that all committed
incentives will be protected following the implementation of the GST, given that the said act has been
notified recently and is still in the process of implementation, which may be affected by any disagreement
between certain state governments, which may create uncertainty. Any such future increases or
amendments may affect the overall tax efficiency of companies operating in India and may result in
significant additional taxes becoming payable.
4. We are subject to stringent labour laws and trade union activity. Our business may be affected due to
disputes with our labours/employees.
The various geographies in which we operate have stringent labour legislation that protects the interests
of workers, including legislation that sets out detailed procedures for discharge of employees and dispute
resolution and imposes financial obligations on employers upon employee layoffs. As a result of such
stringent labour regulations, it is difficult for us to maintain flexible human resource policies, discharge
employees or downsize, which may adversely affect our business, financial condition and results of
operations.
In addition to our permanent employees we also employ labour for execution of our projects and the
number of contract labourers may vary from time to time depending on the nature and quantum of work
involved. There is no trade union for the Company’s full-time employees. We cannot assure you that any
disputes, work stoppages or strikes will not arise in the future. Increases in our labour costs and future
disputes with our employees could adversely affect our business, financial condition or results of
operations.
5. Terrorist attacks, communal disturbances, civil unrest, piracy and other acts of violence or war
involving India and other countries or the occurrence of natural or man-made disasters may adversely
affect the financial markets and our business.
The occurrence of natural disasters, including hurricanes, floods, tsunamis, earthquakes, tornadoes, fires,
explosions, pandemic disease and man-made disasters, including acts of terrorism and military actions,
may adversely affect our financial condition or results of operations. Terrorist attacks and other acts of
violence or war may negatively affect the Indian markets on which our Equity Shares trade and also
adversely affect the worldwide financial markets. These acts may also result in a loss of business
confidence, and adversely affect our business. In addition, any deterioration in relations between India
and its neighbouring countries might result in investor concern about stability in the region, which may
adversely affect the price of our Equity Shares.
The potential impact of a natural disaster such as the H5N1 "avian flu" virus, or H1N1, the swine flu
virus, MERS (Middle East Respiratory Syndrome), Zika, the mosquito virus, on our results of operations
and financial position is speculative, and would depend on numerous factors. Although the long-term
effect of such diseases cannot currently be predicted, previous occurrences of avian flu, swine flu, MERS
and Zika had an adverse effect on the economies of those countries in which they were most prevalent.
In the case of any of such diseases, should the virus mutate and lead to human-to-human transmission of
the disease, the consequence for our business could be severe. An outbreak of a communicable disease
51
in India or in the particular region in which we have projects would adversely affect our business and
financial conditions and the result of operations. We cannot assure prospective investors that such events
will not occur in the future or that our business, results of operations and financial condition will not be
adversely affected.
Some states in India have also witnessed civil unrest including communal disturbances in recent years
and it is possible that future civil unrest as well as other adverse social, economic and political events in
India may have a negative impact on us. Such incidents may also create a greater perception that
investment in Indian companies involves a higher degree of risk and may have an adverse impact on our
business and the price of our Equity Shares.
6. Any downgrading of India’s debt rating by an independent agency may harm our ability to raise debt
financing.
Any adverse revisions to India’s credit ratings for domestic and international debt by international rating
agencies may adversely affect our ability to raise additional financing and the interest rates and other
commercial terms at which such additional financing is available. This may have an adverse effect on
our capital expenditure plans, business and financial performance.
7. Foreign investors are subject to foreign investment restrictions under Indian law that limits our ability
to attract foreign investors, which may adversely impact the market price of our Equity Shares.
Under the foreign exchange regulations currently in force in India, transfers of shares between non-
residents and residents are freely permitted (subject to certain exceptions) if they comply with the pricing
and reporting requirements specified by the RBI. If the transfer of shares is not in compliance with such
pricing or reporting requirements and does not fall under any of the exceptions, then the prior approval
of the RBI will be required. Additionally, shareholders who seek to convert Rupee proceeds from a sale
of shares in India into foreign currency and repatriate that foreign currency from India which will require
a no objection or a tax clearance certificate from the income tax authority. We cannot assure you that
any required approval from the RBI or any other Government agency can be obtained on any particular
terms or at all.
8. We or other intermediaries may be required to withhold U.S. tax on payments made on the Equity
Shares to certain non-U.S. financial institutions after December 31, 2016.
Under certain provisions of the U.S. Internal Revenue Code (commonly referred to as “FATCA”), we
may be subject to a 30% U.S. withholding tax on certain payments we receive unless we enter into an
agreement (an “FFI agreement”) with the U.S. Internal Revenue Service (the “IRS”) pursuant to which
we may be required to report to the IRS, information about any of our “United States accounts” and
comply with certain procedures to be determined by the IRS. We may enter into such an agreement with
the IRS and thereby become a participating foreign financial institution (“participating FFI”) unless we
otherwise become eligible for an exemption (e.g., pursuant to an intergovernmental agreement between
the United States and India). The U.S. Treasury Department and the IRS recently issued regulations that
implement certain provisions of FATCA. Under FATCA and the regulations, if we enter into an FFI
agreement, we (or another intermediary that is a participating FFI) may be required, pursuant to our FFI
agreement, to withhold 30% U.S. withholding tax from any payment made on the Equity Shares after
December 31, 2016, to the extent the payment is considered to be a “foreign pass thru payment,” but
only if such payment is made to a “foreign financial institution” (which is broadly defined for this purpose
and in general includes investment vehicles) that is not a participating FFI. Under current regulations,
the term “foreign pass thru payment” is not defined and it is not yet clear whether or to what extent
payments on the Equity Shares will be treated as “foreign pass thru payments”. Holders of Equity Shares
should consult their own tax advisors regarding the application of FATCA to an investment in the Equity
Shares and their ability to obtain a refund of any amounts withheld under FATCA. The above is based
on our understanding of FATCA, which is complex new legislation, and its application to us is uncertain
at this time.
52
MARKET PRICE INFORMATION
Our Equity Shares are listed and traded on BSE and NSE. The stock market data presented below is given for the
BSE and the NSE separately. As of the date of this Preliminary Placement Document, 15,51,57,900 Equity Shares
of ₹ 1 each were issued; 15,51,57,900 Equity Shares of ₹ 1 each were paid up and outstanding.
The following tables set forth the reported high, low, the number of Equity Shares traded and the total trading
volume on the dates on which such high and low prices were recorded and the average closing prices of the Equity
Shares, on the BSE and the NSE during the fiscal years ended 2017, 2016 and 2015.
NSE
Fisca
l
High
(₹)
Date of
high
Number of
Equity
Shares
traded on
the date of
high
Total
turnove
r on
date of
high (₹
lakh)
Low
(₹)
Date of
low
Numbe
r of
Equity
Shares
traded
on the
date of
low
Total
turnove
r on
date of
low
(₹lakh)
Averag
e of
Closing
Prices
during
the
Period
(₹)
Total
number of
Equity
Shares
traded in
the period
Total
Turnover
in the
period
In number In ₹ lakh
2017 218.95 Decembe
r 28,
2017
142,611 310.54 147.65 August
9, 2017
243,651 368.29 174.04 55,607,946 98,618.38
2016 163.95 August
10, 2016
1,910,123 2,808.55 83.10 Februar
y 12,
2017
83,455 73.37 128.33 44,647,903 58,217.54
2015 896.70 August 6,
2015
147,742 1,226.08 59.50 August
25,
2015
157,568 111.13 461.09 26,653,158 60,484.01
Source: www.nseindia.com
* Average of the daily closing price
(1) High is based on the daily Closing price. In case the price is the same on 2 dates then the date on which the
volume is higher has been considered.
(2) Low is based on the daily Closing price. In case the price is the same on 2 dates then the date on which the
volume is higher has been considered.
BSE
Fiscal High
(₹)
Date of
high
Number
of
Equity
Shares
traded
on the
date of
high
Total
turnover
on date of
high
(₹lakh)
Low
(₹)
Date
of low
Number
of
Equity
Shares
traded
on the
date of
low
Total
turnover
on date
of low
(₹lakh)
Average
of
Closing
Prices
during
the
Period
(₹)
Total
number of
Equity
Shares
traded in
the period
Total
Turnover
in the
period
In number In ₹ lakh
2017 218.35 Decembe
r 28,
2017
15,473 33.59 148.10 Augus
t 9,
2017
196,071 294.26 173.74 14,918,043 27,088.44
2016 165.00 August
10, 2016
374,510 558.70 83.30 Februa
ry 12,
2016
12,900 11.30 128.16 8,684,073 11,203.53
2015 890.00 August
6, 2015
32,226 266.79 61.00 Augus
t 25,
2015
50,492 36.70 460.45 7,863,796 18,903.86
Source: www.bseindia.com
* Average of the daily closing price
(1) High is based on the Daily Closing price. In case the price is the same on 2 dates then the date on which the
volume is higher has been considered.
(2) Low is based on the Daily Closing price. In case the price is the same on 2 dates then the date on which the
volume is higher has been considered.
(iii) The following tables set forth the reported high, low, the number of Equity Shares traded and the total
53
trading volume on the dates on which such high and low prices were recorded and the average closing
prices of the Equity Shares, on the NSE and the BSE during the last six months:
NSE
Mon
th
year
High
(₹)
Date
of
high
Number of
Equity
Shares
traded on
date of
high
Total
turnover
on date of
high
(₹lakh)
Low
(₹)
Date of
low
Number
of Equity
Shares
traded on
date of
low
Total
turnover
on date of
low
(₹lakh)
Averag
e of
Closing
Prices
for the
Period
(₹)
Total Equity Shares
traded in the period
(In figures) (In ₹ in
lakh)
Dec
- 17
218.95 Dece
mber
28,
2017
142,611 310.54 202.00 December
19, 2017
63,877 129.55 207.08 6,172,038 12,774.52
Nov
-17
235.20 Nov
emb
er
13,
2017
1,078,018 2,337.64 179.50 November
2, 2017
809,616 1,488.67 201.59 94,84,523 18,966.81
Oct-
17
182.75 Octo
ber
31,
2017
956,926 1,691.21 164.50 October
23, 2017
103,102 171.95 170.58 3,746,514 6,444.76
Sep-
17
182.50 Sept
emb
er
15,
2017
882,092 1,528.11 159.50 September
19, 2017
500,969 825.37 168.24 5,575,326 9,373.94
Aug
-17
168.00 Aug
ust
18,
2017
98,618 159.58 146.50 August 9,
2017
243,651 368.29 159.70 3,291,501 5,220.34
Jul-
17
179.95 July
7,
2017
134,281 236.48 160.45 July 24,
2017
180,492 293.68 169.32 3,395,944 5,769.75
Source: www.nseindia.com
* Average of the daily closing price
(1) High is based on the daily Closing price. In case the price is the same on 2 dates then the date on which the
volume is higher has been considered.
(2) Low is based on the daily Closing price. In case the price is the same on 2 dates then the date on which the
volume is higher has been considered.
BSE
Mo
nth
yea
r
High
(₹)
Date of
high
Numbe
r of
Equity
Shares
traded
on date
of high
Total
turnov
er on
date of
high
(₹lakh)
Low (₹) Date of
low
Number
of
Equity
Shares
traded
on date
of low
Total
turnov
er on
date of
low
(₹lakh)
Avera
ge of
Closin
g
Prices
for the
Period
(₹)
Total Equity Shares
traded in the period
(In figures) (In ₹ in
lakh)
De
c-
17
218.35 Decembe
r 28,
2017
15,473 33.59 201.20 Decembe
r 19,
2017
19,442 39.34 206.69 3,827,176 7,854.55
No
v-
17
234.9 Novemb
er 13,
2017
118,117 260.67 179.35 Novemb
er 2,
2017
47,271 87.04
201.20 1,930,425 3,947.42
Oct
-17
183.00 October
31, 2017
47,682 85.53 164.00 October
23, 2017
4,626 7.70 36197
6
620.40 620.40
54
Mo
nth
yea
r
High
(₹)
Date of
high
Numbe
r of
Equity
Shares
traded
on date
of high
Total
turnov
er on
date of
high
(₹lakh)
Low (₹) Date of
low
Number
of
Equity
Shares
traded
on date
of low
Total
turnov
er on
date of
low
(₹lakh)
Avera
ge of
Closin
g
Prices
for the
Period
(₹)
Total Equity Shares
traded in the period
(In figures) (In ₹ in
lakh)
Sep
-17
181.40 Septemb
er 15,
2017
108,667 188.27 160.10 Septemb
er 1,
2017
12,456 20.23 167.76 614,728 1,038.27
Au
g-
17
167.00 August
1, 2017
3,729 6.13 146.55 August
9, 2017
196,071 294.26 159.40 1,076,162 1,675.86
Jul-
17
179.30 July 3,
2017
40,961 72.17 160.40 July 24,
2017
27,602 44.89 169.08 378,277 644.82
Source: www.bseindia.com
* Average of the daily closing price
(1) High is based on the daily Closing price. In case the price is the same on 2 dates then the date on which the
volume is higher has been considered.
(2) Low is based on the daily Closing price. In case the price is the same on 2 dates then the date on which the
volume is higher has been considered.
(i) The following table sets forth the market price on the Stock Exchanges on September 22, 2017, the
first working day following the approval of the Board of Directors for the Issue:
BSE NSE
Date Open High
Low
Close
Traded
Volum
e
(No. of
Shares)
Turno
ver
(₹ in
lakh)
Open
High
Low
Close
Trade
d
Volum
e
(No. of
Shares
)
Turnove
r
(₹in
lakh)
September
22, 2017 165.55 167.25 164.50 165.65 18,677 30.95 169.00 169.05 164.20 166.45 105,247 174.92
Source: www.nseindia.com, www.bseindia.com
55
USE OF PROCEEDS
The gross proceeds from the Issue will be ₹ [●] lakh. The net proceeds from the Issue after deducting fees,
commissions and expenses of approximately ₹ [●] lakh, will be approximately ₹ [●] lakh (“Net Proceeds”).
Subject to compliance with applicable laws and regulations, our Company has undertaken to use the net proceeds
of the Issue to meet its long term working capital and capital expenditure requirements, in connection with the
Company’s business ventures including but not limited to investments by way of equity participation in special
purpose vehicle(s), in joint ventures / consortiums with various parties, repayment of debts, general corporate
purposes and for such other purposes as may be permitted by applicable laws.
The Net Proceeds are not proposed to be utilised towards any specific project. Accordingly, the disclosure
requirements under para 8(a) (b) and (c) of Schedule XVIII the SEBI ICDR Regulations are not applicable.
In accordance with the decision of our Company’s Board, our Company’s management will have the flexibility
in deploying the net proceeds received by our Company from the Issue. Pending utilization of proceeds of the
issue as described above, if any, the Company intends to temporarily invest the funds in high quality, interest/
dividend bearing instruments, including deposits with Banks and investment in liquid and debt mutual funds for
the applicable period in compliance with the applicable laws and regulations, as approved by the Board in
accordance with the investment policy and applicable laws.
Neither our Promoter nor our Directors will make any financial contribution either as part of the Issue or separately
in furtherance of the objects of the Issue.
56
CAPITALIZATION STATEMENT
Our authorized capital is ₹ 7,500 lakh divided into ₹ 3,000 lakh Equity Shares of ₹ 1 each and ₹450 lakh
Preference Shares of ₹10 each. As of the date of this Preliminary Placement Document 15,51,57,900 Equity Shares
of ₹ 1 each were paid up and outstanding.
The following table sets forth our Company’s capitalisation and total debt, on a consolidated basis, as on
December 31, 2016, and as adjusted to give effect to the Issue. This table should be read with the chapter titled
“Management’s Discussion and Analysis of Financial Condition and Results of Operations” and other
financial information contained in the chapter titled “Financial Statements” beginning on pages 60 and 194,
respectively.
(₹in lakh)
Particulars As at 31 December 2016 As at 31 December 2016, as
adjusted for the Offering*
As per Consolidated
Financial
Statements
As per Consolidated
Financial
Statements
Short Term Borrowings (A) 37,105.85 []
Long Term Borrowings (B) 4,062.13 []
Current Maturities of Long Term Borrowings (C) 5,131.01 []
Total Long Term Borrowings (D=B+C) 9,193.14 []
Total Borrowings (E=A+D) 46,298.99 []
Shareholder’s Funds: []
- Share Capital (F) 1,551.58 []
- Securities Premium (G) 45,556.44 []
- Reserves and Surplus (H) 7,963.95 []
Total Shareholders' Funds (I=F+G+H)
(excluding borrowed funds)
55,071.97 []
Total Capitalisation (J=E+I) 101,370.96 []
Debt - equity ratio: (K=D/I) 0.17 []
Debt - equity ratio: (L=E/I) 0.84 []
Notes:
1. Shareholder’s fund represents the sum of Share Capital, Securities Premium, Reserves and Surplus as
mentioned in the table herein above, which included includes the general reserve and the profit or loss.
2. Total borrowings represent the sum of Short Term Borrowings, Long Term Borrowings and Current
Maturities of Long Term Borrowings
*Will be inserted once the Issue Price is determined
57
CAPITAL STRUCTURE
The share capital of our Company, as on the date of this Preliminary Placement Document is set forth below:
No. Particulars Amount (In ₹lakh)
Aggregate nominal value
A. Authorised Share Capital
30,00,00,000 Equity Shares of ₹ 1 each 3,000.00
4,50,00,000 Preference Share of ₹ 10 each 4,500.00
B. Issued Share Capital before the Issue
15,51,57,900 Equity Shares of ₹ 1 each 1,551.83
C. Subscribed and Paid – up Share Capital before the Issue
15,51,57,900 Equity Shares of ₹ 1 each 1,551.58
D. Present Issue in terms of this Preliminary Placement
Document(a)
Issue of [●] Equity Shares of ₹ 1 each [●]
D. Issued, Subscribed and Paid-Up Share Capital after the Issue
[●] Equity Shares of ₹1 each [●]
E. Securities Premium Account
Before the Issue 45,556.44
After the Issue(b) [●]
Notes:
(a) The Issue has been authorised by the Board of Directors vide a resolution passed at its meeting held on
September 21, 2017 and by the shareholders of our Company vide a special resolution passed pursuant to
sections 42 and 62(1)(c) of the Companies Act through postal ballot on December 12, 2017.
(b) The Securities Premium Account after the Issue is calculated net of adjustments for estimated issue expenses
of approximately ₹ [●].
NOTES TO THE CAPITAL STRUCTURE
1. History of Equity Share Capital of our Company
The history of the equity share capital of our Company is provided in the following table:
Date of Issue/
Allotment Shares
Face
Value
(`)
Issue
Price
(`)
Consideration Mode of
Allotment
Identity of
Allottees
Number %
July 20, 1978 100 0.00 10 10 Cash Subscription
to the MOA
CCL* and
others
February 12,
1980
3,92,000 3.40 10 10 Cash Public Issue UTI, GIC,
Employees,
Directors
and Public
February
12,1980
4,08,000 3.54 10 10 Other than cash Amalgamati
on Scheme
CCL
May 16, 1984 4,80,060 4.17 10 - Other than cash Bonus Issue CCL and
Public
November 1,
1994
12,80,160 11.12 10 - Other than cash Bonus Issue CCL and
Public
March 10,
1998
20,46,198 17.77 10 200 Cash Rights Issue CCL and
Public
November 5, 3 0.00 10 200 Cash Rights Issue Public
58
Date of Issue/
Allotment Shares
Face
Value
(`)
Issue
Price
(`)
Consideration Mode of
Allotment
Identity of
Allottees
Number %
1999
March 6, 2003 40 0.00 10 200 Cash Rights Issue Public
November 13,
2006
11,51,539 10.00 10 490 Cash Rights Issue ITD and
Public
December 31,
2007
57,57,690 50.00 10 425 Cash Rights Issue ITD and
Public
September 4,
2014
40,00,000 34.73 10 360 Cash By way of a
qualified
institutional
placement
Qualified
Institutiona
l Buyers
Pursuant to the approval of the members at the 37th Annual General Meeting of the Company held on May 13,
2015 to the sub-division of the Equity Shares of the Company, each Equity Share of nominal face value of ₹10
each was sub-divided to 10 (ten) Equity Share of ₹1 each. The effective date for the said sub-division was 24
August 2015.
Total 15,51,57,900
*The Cementation Company Limited, U.K
2. Equity Shares issued for consideration other than cash by our Company
In the last one year preceding the date of this Preliminary Placement Documents, our Company has not
issued any Equity Shares for consideration other than cash.
59
DIVIDEND POLICY
Under the Companies Act, an Indian company may pay dividend only upon a recommendation by its board of
directors and approval by a majority of its shareholders at the annual general meeting. As permitted by the Articles
of Association of our Company, the Board declares and pays interim dividends. Under the Companies Act, a
company may pay dividends only out of its profits in the year in which the dividend is declared or out of the
undistributed profits or reserves of prior fiscal years or out of both.
The following table sets forth details regarding the dividend paid by our Company on the Equity shares for Fiscal
Years 2016, 2015 and 2014:
Particulars Year ended
December 31, 2016
Year ended
December 31,
2015
Year ended
December 31,
2014
Face Value of Equity Share (₹ per share) 1.00 1.00 10.00
Dividend per equity Share (in ₹) 0.30 Nil Nil
Total Dividend declared (₹ in lakhs) 465.47 Nil Nil
Dividend Distribution Tax on above (₹
in lakhs)
94.76 Nil Nil
Rate of Dividend (%) 30.00 Nil Nil
Approved by the shareholders on 11 May 2017 Not applicable Not applicable
Future Dividends
Our Company has a divdend distribution policy in compliance with Regulation 43A of the SEBI LODR
Regulations which mandates the top 500 listed companies based on market capitalization calculated as on March
31 of every financial year to formulate a dividend distribution policy. The policy has been approved by the Board
of Directors of the Company in its meeting held on November 9, 2016 and is applicable from the financial year
ended December 31, 2016.
For a summary of certain Indian tax consequences of dividend distributions to shareholders, see the chapter titled
“Taxation” beginning on page 171.
60
MANAGEMENT’S DISCUSSION AND ANALYSIS OF FINANCIAL CONDITION AND RESULTS OF
OPERATIONS
You should read the following discussion of our financial condition and results of operations together with our
Audited Consolidated Financial Statements for the Fiscal 2016, 2015 and 2014 and the consolidated unaudited
financial results for the nine months ended September 30, 2017 including the notes thereto and reports thereon,
each included in this document. You should also read “Risk Factors”, and “Forward Looking Statements” on
pages 29 and 13, both of which discuss a number of factors and contingencies that could affect our financial
condition, results of operations and cash flows. The amounts derived from the Audited Consolidated Financial
Statements included herein are presented in ₹ lakh, which is the manner in which the numbers are presented in
our financial statements for Fiscal 2016, Fiscal 2015 and Fiscal 2014. The figures disclosed herein for the nine
months ended September 30, 2017 are based on consolidated unaudited financial results, which was filed with
the Stock Exchanges under the SEBI Listing Regulations. As per the option given to our Company under
Regulation 33 of the SEBI Listing Regulations, our Company opted to publish the standalone and consolidated
unaudited financial results for the nine months ended September 30, 2017. All information in relation to the nine
months ended September 30, 2017 and September 30, 2016 is given on a consolidated basis. Unless stated
otherwise, all information in relation to Fiscal 2015, 2016 and 2017 is given on a consolidated basis.
Our Audited Consolidated Financial Statements have been prepared in accordance with Indian GAAP. Since
January 1, 2017, we have been required to prepare our financial statements in accordance with Ind AS. Ind AS is
different in many respects from Indian GAAP. See “Risk Factors— Significant differences exist between Indian
GAAP and Ind AS, which may be material to investors’ assessments of our financial condition” on page 29. For
the purpose of this chapter, we have relied on numbers prepared in accordance with Indian GAAP for the Fiscal
2016.
Our fiscal ends on December 31 of each year. Accordingly, all references to a particular fiscal year are to the 12
months ended December 31 of that year.
Overview:
We are one of the leading civil engineering, contracting and construction organizations providing integrated
design, engineering, procurement and construction services, for over eight decades, for infrastructure development
projects in India. Our current business covers major infrastructure areas including maritime structures, highways,
bridges and flyovers, urban infrastructure projects/mass rapid transit systems, specialist engineering works,
hydroelectric power projects, tunnels and dams, irrigation projects, industrial civil works, airports and civil works
of water and waste water projects.
Our focus areas, in relation to civil engineering, for providing design, engineering, procurement and construction
services under each segment are as follows:
Urban infrastructure/
MRTS Construction of civil and building structures for mass rapid transportation
systems (“MRTS”)
Construction of tunnels, underground railway stations and installation of
track;
Construction of integrated passenger terminals and allied services at
airports.
Maritime Structures Construction of jetties, dolphins and service platforms;
Construction of quay, berths on concrete and steel piles as well as solid
gravity type wharf structures;
Construction of ship lift, dry dock, wet basin (in complete marine
condition) and inclined berth;
Break water and piled approach trestles;
Steel pipes (vertical and raker), bored cast in-situ pile;
Undersea ground improvement;
Dredging and land reclamation;
Coastal erosion protection and rock bund.
Hydroelectric power
projects, tunnels, dams and
irrigation projects
Construction of concrete and masonry dams, micro tunnelling, earth fill
embankments, irrigation canal structures and hydro tunnels;
Construction of hydroelectric power stations.
61
Industrial structures and
buildings Construction of plant buildings for power, steel, refineries and fertilizer
sectors;
Civil works for water treatment and water intake systems;
Buildings for educational institutions, hospitals, shopping malls and IT
parks.
Specialist Engineering Foundation and specialist works including geotechnical investigations,
piling, diaphragm walling, sand wicks / band drains, vibro-floatation stone
columns / vibro compaction, drilling and grouting, rock / soil anchors,
colcrete, gunite / shotcrete, grouted mattress, repairs, tube heading and
box pushing.
Highways, bridges and
flyovers Construction of roads, bridges and flyovers.
A. Basis of preparation and Principles of Consolidation
i. Basis of Preparation of Consolidated Financial Statements
The Consolidated Financial Statements have been prepared to comply in all materials respects with the
accounting standards notified by the Companies (Accounting Standards) Rules, 2006 read with Rule 7
to the Companies (Accounts) Rules 2014 in respect of Section 133 of the Companies Act, 2013. The
consolidated financial statements are prepared under the historical cost convention, on an accrual basis
of accounting.
The accounting policies applied are consistent with those used in the previous year.
The consolidated financial statement comprises the financial statements of ITD Cementation India
Limited (“the Holding Company”) and its subsidiary (the Holding Company and its subsidiary together
referred to as “the Group”) and unincorporated jointly controlled entities.
ii. Principles of Consolidation
The consolidated financial statements have been prepared on the following basis:
a. The financial statements of the Holding Company and its subsidiary company have been
consolidated on a line by line basis by adding together the book values of like items of assets,
liabilities, income and expenses, after eliminating intra-group balances/ transactions and
elimination of resulting unrealized profits in accordance with Accounting Standard (‘AS’) - 21
‘Consolidated Financial Statements’ notified by the Companies (Accounting Standards) Rules,
2006 read with Rule 7 to the Companies (Accounts) Rules 2014 in respect of Section 133 of the
Companies Act, 2013.
b. The Interests in Joint Ventures which are in the nature of unincorporated jointly controlled
entities have been consolidated by using the proportionate consolidation method on a line by
line basis by adding together the book values of like items of assets, liabilities, income and
expenses, after eliminating intra-group balances/ transaction and elimination of resulting
unrealized profits in accordance with AS 27 - ‘Financial Reporting of Interests in Joint
Ventures’ notified by the Companies (Accounting Standards) Rules, 2006 read with Rule 7 to
the Companies (Accounts) Rules 2014 in respect of Section 133 of the Companies Act, 2013.
c. Consolidated financial statements are prepared using uniform policies for like transaction and
other events in similar circumstances and are presented, to the extent possible, in the same
manner as the Company’s separate financial statements.
d. Notes to the consolidated financial statements, represents notes involving items which are
considered material and are accordingly duly disclosed. Materiality for the purpose is assessed
in relation to the information contained in the consolidated financial statement. Further,
additional statutory information disclosed in separate financial statements of the subsidiary and/
or a parent having no bearing on the true and fair view of the consolidated financial statement
has not been disclosed in the consolidated financial statements.
62
e. The difference between the cost to the Group of investment in subsidiary and joint ventures and
the proportionate share in the equity of the investee company as at the date of the acquisition of
stake is recognized in the consolidated financial statements as goodwill or capital reserve, as
the case may be. Goodwill arising on consolidation is tested for impairment annually.
B. Accounting estimates
The preparation of the consolidated financial statements in conformity with generally accepted
accounting principles requires management to make estimates and assumptions that affect the reported
amounts of assets and liabilities and disclosure of contingent liabilities as at the date of consolidated
financial statements and the results of operation during the reported year. Although these estimates are
based upon management’s best knowledge of current events and actions, actual results could differ from
these estimates which are recognised in the year in which they are determined
C. Fixed assets
Tangible assets are stated at cost, less accumulated depreciation and impairment losses, if any. Cost
comprises the purchase price and any attributable cost of bringing the asset to its working condition for
its intended use. Borrowing costs relating to acquisition of fixed assets which takes substantial period of
time to get ready for its intended use are also included to the extent they relate to the period till such
assets are ready to be put to use.
Subsequent expenditures related to an item of tangible asset are added to its book value only if they
increase the future benefits from the existing asset beyond its previously assessed standard of
performance.
Capital work in progress represents expenditure incurred in respect of capital projects under development
and are carried at cost. Cost includes related acquisition expenses, construction cost and other direct
expenditure.
D. Depreciation on tangible fixed assets
i. Depreciation on tangible assets is provided on straight line basis at useful life prescribed in Schedule II
to the Companies Act, 2013 on a pro-rata basis. However, certain class of plant and machinery are
depreciated on the useful life different from the useful life prescribed in Schedule II to the Companies
Act, 2013 having regard to useful life of those assets in construction projects based on the management’s
experience of use of those assets which is in line with industry practices.
ii. Leasehold improvements are amortized over the lease period or useful life whichever is lower.
iii. Depreciation for additions to/deductions from, owned assets is calculated pro rata from/to the day of
additions/deductions.
iv. In case of Joint Ventures, depreciation on fixed assets is provided on straight-line method at the rates
determined as per the useful lives of the respective assets and the life of the project.
E. Impairment of assets
The carrying amounts of the Company’s assets are reviewed at each balance sheet date if there is any
indication of impairment based on internal/external factors. An impairment loss is recognized whenever
the carrying amount of an asset exceeds its recoverable amount. The recoverable amount is the greater
of the assets net selling price and its value in use. Impairment loss is recognized in the Statement of Profit
and Loss or against revaluation surplus where applicable beyond the carrying value that would have
prevailed by charging usual depreciation if there was no impairment.
A previously recognized impairment loss is increased or reversed depending on changes in
circumstances. However, the carrying value after reversal is not increased beyond the carrying value that
would have prevailed by charging usual depreciation if there was no impairment.
F. Investments
63
Investments, which are readily realizable and intended to be held for not more than one year from the
date on which such investments are made, are classified as current investments. All other investments
are classified as non-current investments.
Current investments are carried in the consolidated financial statements at lower of cost or fair value
determined on an individual investment basis. Non-current investments are carried at cost and provision
for diminution in value is made to recognize a decline other than temporary in the value of the
investments.
On disposal of an investment, the difference between its carrying amount and net disposal proceeds is
charged or credited to the Statement of Profit and Loss.
G. Inventories
i. Construction materials are valued at cost. Cost is determined on a first-in, first-out method and comprises
the purchase price including duties and taxes (other than those subsequently recoverable by the Company
from the taxing authorities).
ii. Tools and equipment are stated at cost less the amount amortized. Tools and equipment are amortized
over their estimated useful lives ranging from 3 to 10 years. Cost is determined by the weighted average
method.
iii. Machinery spares that are of regular use are charged to the statement of profit and loss as and when
consumed.
iv. Unbilled work in progress: Work done remaining to be certified/billed is recognized as unbilled work in
progress provided it is probable that they will be recovered in the accounts. The same is valued at the
realizable value.
H. Revenue recognition
i. On contracts
Revenue from construction contracts is recognized on the basis of percentage completion method. The
stage of completion of a contract is determined by the proportion that contract costs incurred for work
performed up to the reporting date bear to the estimated total contract costs. Contract revenue earned in
excess of certification has been classified as “Unbilled work-in-progress” and certification in excess of
contract revenue has been classified as “Amount due to customer” under “Other current liabilities” in the
consolidated financial statements.
Amounts recoverable in respect of the price and other escalation, bonus claims adjudication and variation
in contract work required for performance of the contract to the extent that it is probable that they will
result in revenue.
In addition, if it is expected that the contract will make a loss, the estimated loss is immediately provided
for in the books of account. Contractual liquidated damages, payable for delays in completion of contract
work or for other causes, are accounted for as costs when such delays and causes are attributable to the
Company or when deducted by the client.
ii. Accounting for Joint Venture Contracts
Revenue from long term construction contracts executed in unincorporated joint ventures under work
sharing arrangements is recognized on the same basis as similar contracts independently executed by the
Company.
iii. Service Income
Service income is accounted on accrual basis in accordance with the terms of agreement with the parties.
iv. Insurance Claims
64
Insurance claims are recognized as income based on certainty of receipt.
v. Interest Income and other income
Interest and other income are accounted for on accrual basis except where the receipt of income is
uncertain in which case it is accounted for on receipt basis.
I. Advances from customers, progress payments and retention
Advances received from customers in respect of contracts are treated as liabilities and adjusted against
progress billing as per terms of the contract.
Progress payments received are adjusted against amount receivable from customers in respect of the
contract work performed.
Amounts retained by the customers until the satisfactory completion of the contracts are recognised as
receivables. Where such retention has been released by customers against submission of bank guarantees,
the amount so released is adjusted against receivable from customers and the value of bank guarantees
is disclosed as a contingent liability.
J. Foreign currency transactions
i. Initial Recognition
Foreign currency transactions are recorded in the reporting currency, by applying to the foreign currency
amount the exchange rate between the reporting currency and the foreign currency at the date of the
transaction.
ii. Conversion
Foreign currency monetary items are reported using the closing rate. Non-monetary items which are
carried in terms of historical cost denominated in a foreign currency are reported using the exchange rate
at the date of the transaction.
iii. Exchange Differences
Exchange differences arising on the settlement of monetary items or on reporting company’s monetary
items at rates different from those at which they were initially recorded during the year, or reported in
previous consolidated financial statements, are recognized as income or as expenses in the year in which
they arise
iv. Forward Exchange Contracts not intended for trading or speculation purposes
The premium or discount arising at the inception of forward exchange contracts is amortized as expense
or income over the life of the contract. Exchange differences on such contracts are recognized in the
statement of profit and loss in the year in which the exchange rates change. Any profit or loss arising on
cancellation or renewal of forward exchange contract is recognized as income or as expense for the year.
K. Employee benefits
i. Defined benefit plan
In terms of the Guidance on implementing Accounting Standard (AS) 15 - Employee Benefits, issued by
the Accounting Standards Board of the Institute of Chartered Accountants of India, the Provident Fund
set up by the Company is treated as a defined benefit plan. This is administered through trusts of the
Company. The Company has to meet the interest shortfall, if any. Accordingly, the contribution paid or
payable and the interest shortfall, if any, is recognized as an expense in the period in which services are
rendered by the employee. Further, the pattern of investments for investible funds is as prescribed by the
Government. Accordingly, other related disclosures in respect of provident fund have not been made.
65
Further Company has defined benefit plans for post-employment benefits in the form of Gratuity. The
Company has taken an insurance policy under the Group Gratuity Scheme with the insurance company
to cover the Gratuity Liability. The liability for Defined Benefit Plans is provided on the basis of
valuations, as at the Balance Sheet date, carried out by an independent actuary.
The obligations are measured as the present value of estimated future cash flows discounted at rates
reflecting the prevailing market yields of Indian Government securities as at the Balance Sheet date for
the estimated term of the obligations. The estimate of future salary increases considered takes into
account the inflation, seniority, promotion and other relevant factors.
The expected rate of return of plan assets is the Company’s expectation of the average long-term rate of
return expected on investments of the fund during the estimated term of the obligations. Plan assets are
measured at fair value as at the Balance Sheet date. The actuarial valuation method used by independent
actuary for measuring the liability is the Projected Unit Credit method.
ii. Defined contribution plan
The certain employees of the Company are also participant in the superannuation plan, employee state
insurance scheme and Labour Welfare Fund scheme which is a defined contribution plan. The Company
has no obligations to the Plan beyond its contributions. The company’s contributions to Defined
Contribution Plans are charged to the Statement of Profit and Loss as incurred.
iii. Other employee benefits
The Company treats accumulated leave expected to be carried forward beyond twelve months, as long-
term employee benefit for the measurement purposes. Such long-term compensated absences are
provided for based on the actuarial valuations using the projected unit credit method at the period end.
Accumulated leave which is expected to be utilized within next 12 months, is treated as short-term
employee benefit. Actuarial gains and losses in respect of the defined benefit plans are recognized in the
Statement of Profit and Loss in the period in which they arise.
L. Earnings Per Share
Basic earnings per share is calculated by dividing the net profit or loss after tax for the year attributable
to equity shareholders by the weighted average number of equity shares outstanding during the year. The
number of shares used in computing diluted earnings per share comprises the weighted average number
of shares considered for deriving basic earnings per share and also the weighted average number of shares
which could have been issued on conversion of all dilutive potential equity shares.
M. Taxation
Current Tax
Provision for current tax is recognized based on the estimated tax liability computed after taking credit
for allowances and exemptions in accordance with the Income Tax Act, 1961.
Minimum Alternative Tax (MAT) credit is recognized as an asset only when and to the extent there is
convincing evidence that the company will pay normal income tax during the specified period. In the
year in which the MAT credit becomes eligible to be recognized as an asset in accordance with the
recommendations contained in Guidance Note issued by the Institute of Chartered Accountants of India,
the said asset is created by way of a credit to the Statement of Profit and Loss and shown as MAT Credit
Entitlement. The Company reviews the same at each balance sheet date and writes down the carrying
amount of MAT Credit Entitlement to the extent there is no longer convincing evidence to the effect that
Company will pay normal Income Tax during the specified period.
Deferred Tax
Deferred tax assets and liabilities are recognized for the future tax consequences attributable to timing
differences between the financial statements’ carrying amounts of existing assets and liabilities and their
respective tax basis. Deferred tax assets and liabilities are measured using the enacted tax rates or tax
rates that are substantively enacted at the balance sheet dates. The effect on deferred tax assets and
66
liabilities of a change in tax rates is recognized in the period that includes the enactment date. Where
there is unabsorbed depreciation or carry forward losses, deferred tax assets are recognized only if there
is virtual certainty supported by convincing evidence that they can be realized against future taxable
profits. Other deferred tax assets are recognized only to the extent there is reasonable certainty of
realization in the future. Such assets are reviewed at each balance sheet date to reassess realization.
Timing differences originating and reversing during the tax holiday period are not considered for the
purpose of computing deferred tax assets and liabilities.
N. Leases
Leases, where the lessor effectively retains substantially all the risks and benefits of ownership of the
leased term, are classified as operating leases. Operating lease payments are recognized as an expense in
the Statement of Profit and Loss account on a straight-line basis over the lease term.
O. Provisions and Contingent Liabilities
A provision is recognized when the Company has a present obligation as a result of past events and it is
probable that an outflow of resources will be required to settle the obligation, in respect of which a
reliable estimate can be made. Provisions are not discounted to their present value and are determined
based on management’s best estimates required to settle the obligation at the Balance Sheet date. These
are reviewed at each Balance Sheet date and adjusted to reflect the current best estimates.
Contingent Liabilities are disclosed in respect of possible obligations that arise from past events, whose
existence would be confirmed by the occurrence or non-occurrence of one or more uncertain future
events not wholly within the control of the Company.
Contingent assets are neither recognized nor disclosed in the consolidated financial statements.
P. Cash and Cash Equivalent
Cash and cash equivalents comprise of cash at bank and cash in hand. The Company considers all highly
liquid investments with an original maturity of three month or less from date of purchase, to be cash
equivalents.
Summary of Consolidated Audited Profit and Loss Account
The following table sets out our income statement:
(₹ in lakh)
Particulars Year ended
December 31, 2016
Year ended
December 31, 2015
Year ended
December 31,
2014
Amount Amount Amount
REVENUE
Contract revenue 3,08,856.02 3,06,870.03 1,71,242.31
Other operating income 103.98 224.87 652.29
Other Income 2,522.16 2,217.41 1,849.47
Total revenue 3,11,482.16 3,09,312.31 1,73,744.07
EXPENSES
Cost of materials consumed 73,225.93 80,945.83 64,392.02
Sub-contract expense 1,32,999.85 1,29,588.37 40,260.28
Employees benefits expense 25,380.31 22,240.69 19,363.89
Finance costs 11,652.27 13,771.36 13,550.37
Depreciation expenses 4,494.45 3,665.05 4,270.88
Other expenses 56,368.55 55,162.40 38,770.92
Total Expenses 3,04,121.36 3,05,373.70 1,80,608.36
Profit/ (Loss) before exceptional item
and tax
7,360.80 3,938.61 (6,864.29)
Exceptional items - (12,397.19) 9,553.25
Profit/(loss) before tax 7,360.80 (8,458.58) 2,688.96
Tax expense
67
Particulars Year ended
December 31, 2016
Year ended
December 31, 2015
Year ended
December 31,
2014
Amount Amount Amount
Current tax (3,455.44) (265.37) (964.52)
Less: Minimum alternative tax credit
entitlement
2,550.83 - 720.23
Earlier year tax adjustments 21.55 (131.83) 132.69
Deferred tax (charge)/ credit (1,666.97) 2,925.02 (635.93)
Net profit/ (loss) for the year 4,810.77 (5,930.76) 1,941.43
Earnings/ (loss) per equity share of ₹1
each
Basic and diluted 3.10 (3.82) 1.51
Fiscal 2016 compared to Fiscal 2015
Contract Revenue
Our contract revenue for the year December 31, 2016 was ₹ 3,08,856.02 lakh as against ₹ 3,06,870.03 lakh for
the previous year recording an marginal increase of 0.65% due increase in revenue from maritime work.
Other Operating Income
Our other operating income for the year December 31, 2016 was ₹ 103.98 lakh as against ₹ 224.87 lakh for the
previous year recording a reduction of 53.76% due to decline in service income received by providing plant and
equipments on lease basis.
Other Income
Our other income for year ended December 31, 2016 was ₹ 2,522.16 lakh compared to previous year’s income of
₹ 2,217.41 lakh. This increase was primarily as a result of increase in the interest received on the bank deposits,
income tax refund, and sales tax refund and also due to write back of excess cost provisions of previous year.
Expenditures:
Cost of material consumed
The cost of material consumed for the year December 31, 2016 was ₹ 73,552.93 lakh, indicating a decline of
9.13% over previous year’s figure of ₹ 80,945.83 lakh. This decline was mainly due to completion of certain
major material intensive contracts.
Sub-contract expense
The sub-contract expense for the year December 31, 2016 was ₹ 1,32,999.85 lakh, indicating an increase of 2.63%
over previous year’s figure of ₹ 1,29,588.37 lakh which was due to significant progress in the new projects
undertaken by the Company.
Employee benefit expenses
The employee benefit expenses increased by 14.12% to ₹25,380.31 lakh in fiscal 2016 from ₹22,240.69 lakh in
fiscal 2015. This increase was primarily due to increase in manpower and increase in salaries and wages and
contribution to provident and other funds.
Finance Cost
Our finance cost for fiscal 2016 were ₹ 11,652.27 lakh, decreased by 15.39% from previous year’s figure of ₹
13,771.36 lakh. This decrease was primarily due to decrease in borrowings which led to reduction in interest
expenses towards cash credit facilities and working capital demand loan, long term loan and buyer’s credit.
Depreciation expenses
68
Our depreciation expenses for the year ended December 31, 2016 was ₹ 4,494.45 lakh vis-à-vis previous year’s
figure of ₹ 3,665.05 lakh. Increase in depreciation is on account of major addition of new plant and equipment’s
during the year.
Other Expenses
Our other expenses increased by 2.19% to ₹ 56,368.55 lakh in Fiscal 2016 from ₹ 55,162.40 lakh in Fiscal 2015.
This is primarily because of increase in the provisions for doubtful debts, fuel cost and repairs and maintenance
cost toward the plants and machinery and provision for foreseeable losses.
Profit/ (Loss) before tax
Our Company earned a profit before tax of ₹ 7,360.80 lakh over previous year’s loss of ₹ 8,458.58 lakh (after
exceptional item of ₹12,397.19 lakh) for the year ended December 31, 2016 on a consolidated basis.
Tax expenses
Our provision for current taxes increased to ₹ 3,455.44 lakh for the Fiscal 2016 from ₹ 265.37 lakh for fiscal 2016
due to increase in profit before tax.
Net profit / (loss) for the year
For the year ended December 31, 2016, the Company on a consolidated basis incurred net profit of ₹ 4,810.77
lakh over previous year’s loss of ₹ 5,930.76 lakh.
Fiscal 2015 compared to Fiscal 2014
Contract Revenue
Our contract revenue for the year December 31, 2015 was ₹ 3,06,870.03 lakh as against ₹ 1,71,242.31 lakh for
the previous year recording an increase of 79.20% mainly due to increase in revenue from most of the divisions,
especially from the maritime structure division.
Other Operating Income
Our other operating income for the year December 31, 2015 was ₹ 224.87 lakh as against ₹ 652.29 lakh for the
previous year recording a reduction of 65.53 % due to decline in service income received by providing plant and
equipments on lease basis.
Other Income
Our other income for year ended December 31, 2015 was ₹ 2,217.41 lakh compared to previous year’s income of
₹ 1,849.47 lakh. This increase was primarily as a result of increase in the interest received on the bank deposits,
insurance claims and sale of fixed assets.
Expenditures:
Cost of material consumed
The cost of material consumed for the year December 31, 2015 was ₹ 80,945.83 lakh , an increase of 25.71% over
previous year’s figure of ₹ 64,392.02 lakh. This increase is due to increase in revenue.
Sub-contract expense
The sub-contract expense for the year December 31, 2015 was ₹ 1,29,588.37 lakh, an increase of 221.88% over
previous year’s figure of₹ 40,260.28 lakh. This increase is mainly due to increase in revenue from the subcontract
intensive projects.
Employee benefit expenses
69
The employee benefit expenses increased by 14.86% to ₹ 22,240.69 lakh in Fiscal 2015 from ₹ 19,363.89 lakh in
Fiscal 2014. This increase was primarily as a result of increase in manpower and increase in salaries and wages
and contribution to provident and other funds.
Finance Cost
Our finance cost for Fiscal 2015 were ₹ 13,771.36 lakh, increase from previous year’s figure of ₹ 13,550.37 lakh.
This increase was primarily as a result of increase interest expenses on advance from customers.
Depreciation expenses
Our depreciation expenses for the year ended December 31, 2015 was ₹ 3,665.05 lakh vis-à-vis previous year’s
figure of ₹ 4,270.88 lakh. Decrease in depreciation is on account of change in method of depreciation from WDV
to SLM.
Other Expenses
Our other expenses increased by 42.28% to ₹ 55,162.40 lakh in Fiscal 2015 from ₹ 38,770.92 lakh in Fiscal 2014.
This increase is primarily because of increase in the provisions for doubtful debts, plant hire cost, sales tax and
service tax on works contracts and labour cess.
Profit/ (Loss) before tax
Our Company, on a consolidated basis, incurred a loss of ₹ 8,458.58 lakh (after exceptional item of ₹12,397.19
lakh) over the previous year’s profit of ₹ 2,688.96 lakh (after exceptional income of ₹9,553.25 lakh) for the year
ended December 31, 2015.
Tax expenses
Our provision for current taxes decreased to ₹ 265.37 lakh for the Fiscal 2015 from ₹ 964.52 lakh for fiscal 2014
due to loss in profit before tax.
Net profit / (loss) for the year
For the year ended December 31, 2016, the Company on a consolidated basis incurred net loss of ₹ 5,930.76 lakh
over previous year’s profit of ₹ 1,941.43 lakh.
Components of our Revenue and Expenses on a Consolidated Basis
Components of our Revenue
The components of our revenue also expressed as a percentage of our total revenue, as reflected in our
Consolidated audited financial statements for Fiscal 2016, 2015 and 2014 is as follows:
(₹ in lakh)
COMPONENTS OF OUR REVENUE
Particulars Year ended December
31, 2016
Year ended December 31,
2015
Year ended December
31, 2014
Amount
As % of
Total
Revenue
Amount
As % of
Total
Revenue
Amount As % of
Total
Revenue
A. Contract Revenue 3,08,856.02 99.16 3,06,870.03 99.21 1,71,242.31 98.56
B. Other Operating
Income
Service income from
unincorporated joint ventures
103.98 0.03 224.87 0.07 652.29 0.38
Total Revenue from Other
Operating Income (B)
103.98 0.03 224.87 0.07 652.29 0.38
C. Other Income
Interest:
70
COMPONENTS OF OUR REVENUE
Particulars Year ended December
31, 2016
Year ended December 31,
2015
Year ended December
31, 2014
Amount
As % of
Total
Revenue
Amount
As % of
Total
Revenue
Amount As % of
Total
Revenue
On bank deposits 1,179.20 0.38 408.15 0.13 131.04 0.08
On income tax refund 184.44 0.06 52.55 0.02 320.88 0.18
On sales tax refund 204.12 0.07 - - -
From customer on settlement - - 81.01 0.03 222.89 0.13
Others 9.96 - 41.43 0.01 18.30 0.01
Other non-operating income:
Profit on sale of fixed assets
(net)
- - 815.02 0.26 - -
Exchange gain (net) 43.82 0.01 20.62 0.01 - -
Sundry balances written back 310.09 0.10 235.81 0.08 132.13 0.08
Provisions no longer required,
written back
209.34 0.07 - - - -
Excess provisions of prior
year written back
- - - - 176.95 0.10
Insurance claim 34.87 0.01 175.49 0.06 - -
Miscellaneous Income 346.32 0.11 387.33 0.13 846.92 0.49
Total Revenue from Other
Income (C)
2,522.16 0.81 2,217.41 0.72 1,849.47 1.06
Total Revenue (A+B+C) 3,11,482.16 100 3,09,312.31 100 1,73,744.07 100
Revenue
Our total revenue comprises of revenue from operations carried out by our Company and its Subsidiary and
unincorporated jointly controlled entities and other income.
Contract Revenue
Our contract revenue comprises of revenue generated from contracts entered by our Company and its
unincorporated jointly controlled entities for construction and engineering of various projects under its diverse
business segments.
Other Operating Income
Our income from other operating income comprises of services provided to unincorporated joint ventures for the
use of equipment on lease.
Other Income
Income from other income comprises of interest received on bank deposits, income tax refund, sales tax refund,
and payments made by the customers on settlement. Further is also comprises of other non-operating income such
as profit on sale of fixed assets, exchange gain, sundry balances written back, bad debts recovered, excess
provisions of prior years’ written back, insurance claim and miscellaneous income.
Components of our Expenses
The components of our expenses also expressed as a percentage of our total expenses, as reflected in our
Consolidated audited financial statements for Fiscal 2016, 2015 and 2014 is as follows:
71
(₹ in lakh)
COMPONENTS OF OUR EXPENSES
Particulars Year ended December 31,
2016
Year ended December 31,
2015
Year ended December 31,
2014
Amount
As % of
Total
Income
Amount
As % of
Total
Income
Amount As % of
Total
Income
A. Cost of Material
Consumed
73,225.93 23.51 80,945.83 26.17 64,392.02 37.06
B. Sub-Contract Expenses 1,32,999.85 42.70 1,29,588.37 41.90 40,260.28 23.17
C. Employees Benefits
Expenses
Salaries and wages 22,948.89 7.37 19,993.94 6.46 17,648.07 10.16
Contribution to gratuity 589.18 0.19 725.28 0.23 359.44 0.21
Contribution to provident and
other funds
1,715.76 0.55 1,386.83 0.45 1,278.92 0.74
Staff welfare expenses 126.48 0.04 134.64 0.04 77.46 0.04
Total Employees Benefits
Expenses (C)
25,380.31 8.15 22,240.69 7.19 19,363.89 11.15
D. Finance Costs
Interest Expenses:
Cash credit facilities and
working capital demand loan
4,243.23 1.36 6,411.07 2.07 9,069.73 5.22
Long term loan 716.67 0.23 1,000.77 0.32 1,149.08 0.66
Commercial papers 1,668.62 0.54 1,386.18 0.43 -
Advances from customers 1,721.52 0.55 1,814.37 0.59 940.89 0.54
Letter of credit 368.82 0.12 378.44 0.12 155.07 0.09
Buyer’s credit - - 5.15 - 17.84 0.01
Others 56.49 0.02 123.09 0.04 118.13 0.07
Other Borrowing Costs:
Applicable net loss on foreign
currency transactions and
transition
- - 55.71 0.02 204.93 0.12
Bank charges and guarantee
commission
2,876.92 0.92 2,596.58 0.84 1,894.70 1.09
Total Finance Cost
Expenses (D)
11,652.27 3.74 13,771.36 4.45 13,550.37 7.80
E. Depreciation Expenses 4,494.45 1.44 3,665.05 1.18 4,270.88 2.46
F. Other Expenses
Plant hire expenses 6,082.02 1.95 5,995.35 1.94 4,848.76 2.79
Power and Fuel 8,164.42 2.62 7,097.04 2.29 7,057.98 4.06
Sales tax on work contracts 7,857.93 2.52 8,146.71 2.63 5,396.99 3.11
Travelling expenses 1,014.96 0.33 926.17 0.30 890.64 0.51
Tools and equipment 2,038.01 0.65 1,740.02 0.56 1,025.41 0.59
Foreseeable loss 970.08 0.31 231.96 0.07 1,329.73 0.77
Site transport and conveyance 2,691.16 0.86 2,559.47 0.81 2,856.71 1.64
Repair and maintenance:
Plant and machinery 1,256.70 0.40 646.13 0.21 528.07 0.30
Others 188.35 0.06 323.81 0.10 196.91 0.11
Insurance 1,351.17 0.43 1,323.74 0.43 849.59 0.49
Professional fees 1,487.44 0.48 2,501.78 0.81 2,356.09 1.36
Rent 2,808.51 0.90 2,759.49 0.89 2,709.79 1.56
Consumption of spares 2,144.76 0.69 1,821.82 0.59 1,287.58 0.74
Security charges 1,226.05 0.39 1,308.67 0.42 990.34 0.57
Temporary site installations 592.81 0.19 834.75 0.27 449.19 0.26
Postage and telephone 230.77 0.07 214.01 0.07 200.27 0.12
Auditor remuneration 105.20 0.03 84.40 0.03 75.46 0.04
Provision for doubtful debts 2,050.07 0.66 1,367.65 0.44 673.69 0.39
72
COMPONENTS OF OUR EXPENSES
Particulars Year ended December 31,
2016
Year ended December 31,
2015
Year ended December 31,
2014
Amount
As % of
Total
Income
Amount
As % of
Total
Income
Amount As % of
Total
Income
Provision for doubtful
deposits
2.74 - 50.22 0.02 47.33 0.03
Rates & taxes 295.98 0.10 86.14 0.03 135.76 0.08
Water charges 798.35 0.26 704.61 0.23 370.22 0.21
Printing and stationery 168.46 0.05 161.50 0.05 137.01 0.08
Infotech expenses 265.58 0.09 294.52 0.10 200.66 0.12
Service tax 7,707.82 2.47 9,794.14 3.17 1,300.51 0.75
Labour cess 2,797.65 0.90 1,851.04 0.60 876.66 0.50
Exchange loss (net) - - - - 114.74 0.07
Director’s sitting fees 8.90 - 6.05 - 2.75 -
CSR Expenses - - 19.74 0.01 12.87 0.01
Loss on sale of fixed assets 74.58 0.02 - - 20.03 0.01
Miscellaneous expenses 1,988.08 0.64 2,311.47 0.75 1,829.18 1.05
Total Other Expenses (E) 56,368.55 18.10 55,162.40 17.83 38,770.92 22.31
Total Expenses
(A+B+C+D+E)
3,04,121.36 97.64 3,05,373.70 98.73 1,80,608.36 103.95
Expenses
Our expenses comprises of cost of material consumed, sub-contract expenses, employees benefits expenses,
finance costs, depreciation expense and other expenses.
Cost of materials consumed
Cost of materials consumed comprises of steel, cement, bentonite, admixture, aggregates, sand, binding wires,
bentonite powder etc.
Sub-contract expense
Sub-contract expenses comprises of costs relating to supply of labourers, cutting, bending and welding of
reinforcement steel, staging shuttering and de-shuttering work, concreting work, earth feeling, tree cutting, steel
cutting and cage making etc.
Employee benefit expense
The employee benefit expenses comprise of salaries and wages paid to the employees and workers by our
Company, contribution towards gratuity and provident funds and staff welfare expenses.
Finance Cost
Our finance cost comprises of interest expenses on our borrowing and debt facilities and other borrowing costs
like loan processing costs and other finance costs of lenders. Our finance costs accounted for 3.74%, 4.45% and
7.80% of our total revenue for Fiscal 2016, 2015 and 2014 respectively.
Summary of Cash Flow
Below is the table of selected information from our Company’s consolidated audited statement of cash flows for
the Fiscals 2016, 2015 and 2014:
(₹ in lakh)
Particulars Fiscal 2016 Fiscal 2015 Fiscal 2014
Cash and cash equivalents at the beginning of year 8,382.74 2,495.33 2,395.93
Net cash generated from operating activities 35,918.55 46,505.52 4,363.60
Net cash used in investing activities (637.09) (10,409.08) (3,835.69)
Net cash used in financing activities (25,575.65) (30,209.03) (428.51)
73
Particulars Fiscal 2016 Fiscal 2015 Fiscal 2014
Net increase in cash and cash equivalents 9,705.81 5,887.41 99.40
Cash and cash equivalents at the end of year 18,088.55 8,382.74 2,495.33
Operating Activities
For Fiscal 2016, we had a profit before taxation of ₹7,360.80 lakh. Our operating profit before working capital
changes was ₹23,926.32 lakh primarily as a result of adjustments for finance costs of ₹11,652.27 lakh and
depreciation of ₹4,494.45 lakh which were partially offset by interest income of ₹1,189.16 lakh, sundry balances
written back of ₹310.09 lakh and prior years provisions written back of ₹209.34 lakhs. However, net cash
generated from operations was ₹15,658.38 lakh as a result of working capital adjustments, including a ₹32,970.86
lakh decrease in inventories, ₹2,384.81 lakhs decrease in trade receivables, ₹438.35 lakh increase in loans and
advances and ₹19,258.94 lakh decrease in trade payables and other current liabilities. We also paid ₹3,666.15
lakh in direct taxes.
For Fiscal 2015, we had a loss before taxation of ₹8,458.58 lakh. Our operating profit before working capital
changes was ₹21,292.48 lakh primarily as a result of adjustments for finance costs of ₹13,771.36 lakh and
depreciation of ₹3,665.05lakh and bad debts written off on one time settlement with client of ₹12,397.17 lakh
which were partially offset by interest income of ₹449.58 lakh and sundry balances written back of ₹235.81 lakh
and profit on sale of fixed assets of ₹815.02 lakh. However, net cash generated from operations was ₹27,716.73
lakh as a result of working capital adjustments, including a ₹4,412.85 lakh increase in inventories, ₹3,396.19 lakh
increase in trade receivables, ₹12,266.25 lakh increase in loans and advances and ₹47,792.02 lakh increase in
trade payables and other current liabilities. We also paid ₹2,503.69 lakh in direct taxes.
For Fiscal 2014, we had a profit before taxation of ₹2,688.96 lakh. Our operating profit before working capital
changes was ₹11,239.23 lakh primarily as a result of adjustments for finance costs of ₹13,550.37 lakh,
depreciation of ₹4,270.88 lakh and provisioning for doubtful debts of ₹673.69 lakh which were partially offset by
interest income of ₹149.70 lakh and sundry balances written back of ₹132.13 lakh and depreciation written back
of ` 9,553.25 lakh. However, net cash used for operations was ₹7,496.79 lakh as a result of working capital
adjustments, including a ₹17,442.63 lakh increase in inventories, ₹4,664.43 lakh increase in trade receivables,
₹4,051.90 lakh increase in loans and advances and ₹18,662.17 lakh increase in trade payables and other current
liabilities. We received ₹621.16 lakh in direct taxes.
Investing Activities
In Fiscal 2016, the net cash used in our investing activities was ₹637.09 lakh. This primarily reflected ₹8,008.44
lakh used in purchase of fixed assets and ₹6,364.14 lakh received as proceed from fixed deposit with bank and
1,275.61 lakh received as interest income.
In Fiscal 2015, the net cash used in our investing activities was ₹10,409.08 lakh. This primarily reflected
₹5,862.62lakh used in purchase of fixed assets and ₹6,372.42 lakh in fixed deposit with bank and ₹344.88lakhs
received as interest income and ₹1,258.21 lakh received from sale of fixed assets.
In Fiscal 2014, the net cash used in our investing activities was ₹3,835.69 lakh. This primarily reflected ₹4,912.77
lakh used in purchase of fixed assets and ₹795.89 lakh received as proceed from fixed deposit with bank and
₹161.69 lakh received as interest income and ₹342.37 lakh received from sale of fixed assets.
Financing Activities
In Fiscal 2016, our net cash used in financing activities was ₹25,575.65 lakh. This reflected mainly ₹19,105.84
lakh in respect of repayments of short term borrowings and proceeds, net of repayment of ₹5,330.11 lakh from
long term borrowings. We have used ₹11,799.21 lakh to pay interest.
In Fiscal 2015, our net cash used in financing activities was ₹30,209.03 lakh. This reflected mainly ₹11,907.84
lakhs in respect of repayments of short term borrowings and ₹4,550.10 lakh in respect of repayment of long term
borrowings. We have used ₹13,749.82 lakh to pay interest.
In Fiscal 2014, our net cash used in financing activities was ₹428.51 lakh. This reflected mainly ₹13,999.05 lakh
74
proceeds from issue of share capital through QIP and ₹402.81lakh in respect of repayment of short term
borrowings. We have used ₹13,874.75 lakh to pay interest and paid dividend along with tax of ₹134.23 lakh.
Summary of reservations or qualifications or adverse remarks or EOMs in the Auditors’ report in the last
five Financial Years immediately preceding the year of filing this Preliminary Placement Document.
Except the following, our Auditors have not made any reservations or qualifications or adverse remarks or EOMs
in their reports in the last five Financial Years and the relevant quarters immediately preceding the year of filing
this Preliminary Placement Document.
Fiscal
Year
Summary of EOM Management Response
2017 September 30, 2017:
We draw attention to Note 6 to the unaudited
standalone and unaudited consolidated
Statement which describes the uncertainty
related to recoverability of non-current trade
receivables and unbilled work in progress
(other non-current financial assets)
aggregating ₹2,863.37 lakhs and ₹8,677.57
lakhs respectively outstanding as at 30
September 2017, representing various
claims recognised during the earlier period
based on the terms and conditions implicit in
the contracts. The Company has assessed the
recoverability of these claims, being
technical in nature and subject matter of
litigation, based on the contractual terms and
legal opinions from independent counsel.
On the basis of such assessment,
management is of the opinion that the claims
are tenable and would be realized in full and
accordingly no adjustments have been made
in the Statement.
Non-current trade receivables as at September
30, 2017 include variation claims of ₹ 309 lakhs
for which the Company had received an
arbitration award in its favour which has
subsequently been upheld by an order of the
District Court. The customer has challenged this
Court Order. However, based on the above
arbitration award, Court Order and legal
opinion, management is reasonably confident of
recovery of these amounts.
Non-current trade receivables and Unbilled
work-in-progress (other non-current financial
assets)as at September 30, 2017 includes ₹
1,139.96 lakhs and ₹ 2,755.80 lakhs
respectively, for a contract which was rescinded
by the Company and Non-current trade
receivables and Unbilled work-in-progress
(other non-current financial assets) as at
September 30, 2017 includes ₹ 1,414.41 lakhs
and ₹ 5,921.77 lakhs respectively, in respect of
another contract where the Company received a
notice from the customer withdrawing from the
Company the balance works to be executed
under the contract for which the Company has
also issued guarantees aggregating ₹ 1,497.13
lakhs. The Company has made claims against
the customers to recover these amounts and has
initiated legal action. Based upon legal opinions
received, the management is reasonably
confident of recovery of these amounts of Non-
current trade receivables and Unbilled work-in-
progress (other non-current financial assets) and
consequently no changes have been made to the
values and classification of these amounts in the
results.
June 30, 2017:
We draw attention to Note 6 to the unaudited
standalone and unaudited consolidated
Statement which describes the uncertainty
related to recoverability of non-current trade
receivables and unbilled work in progress
(other current financial assets) aggregating
₹2,863.37 lakhs and ₹8,677.57 lakhs
respectively outstanding as at 30 June 2017,
Non-current trade receivables as at June 30,
2017 include variation claims of ₹ 309 lakhs for
which the Company had received an arbitration
award in its favour which has subsequently been
upheld by an order of the District Court. The
customer has challenged this Court Order.
However, based on the above arbitration award,
Court Order and legal opinion, management is
75
Fiscal
Year
Summary of EOM Management Response
representing various claims recognised
during the earlier period based on the terms
and conditions implicit in the contracts. The
Company has assessed the recoverability of
these claims, being technical in nature and
subject matter of litigation, based on legal
opinions from independent counsel. On the
basis of such assessment, management is of
the opinion that the claims are tenable and
would be realized in full and accordingly no
adjustments have been made in the
Statement.
reasonably confident of recovery of these
amounts.
Non-current trade receivables and Unbilled
work-in-progress (other current financial assets)
as at June 30, 2017 includes ₹ 1,139.96 lakhs
and ₹ 2,755.80 lakhs respectively, for a contract
which was rescinded by the Company and Non-
current trade receivables and Unbilled work-in-
progress (other current financial assets) as at
June 30, 2017 includes ₹ 1,414.41 lakhs and ₹
5,921.77 lakhs respectively, in respect of
another contract where the Company received a
notice from the customer withdrawing from the
Company the balance works to be executed
under the contract for which the Company has
also issued guarantees aggregating ₹ 1,497.13
lakhs. The Company has made claims against
the customers to recover these amounts and has
initiated legal action. Based upon legal opinions
received, the management is reasonably
confident of recovery of these amounts of Non-
current trade receivables and Unbilled work-in-
progress (other current financial assets) and
consequently no changes have been made to the
values and classification of these amounts in the
results.
March 31, 2017:
We draw attention to Note 6 to the unaudited
standalone and unaudited consolidated
Statement which describes the uncertainty
related to recoverability of non-current trade
receivables and unbilled work in progress
(other current financial assets) aggregating
₹2,863.37 lakhs and ₹8,677.57 lakhs
respectively outstanding as at 31 March
2017, representing various claims
recognised during the earlier period based
on the terms and conditions implicit in the
contracts. The Company has assessed the
recoverability of these claims, being
technical in nature and subject matter of
litigation, based on legal opinions from
independent counsel. On the basis of such
assessment, management is of the opinion
that the claims are tenable and would be
realized in full and accordingly no
adjustments have been made in the
Statement.
Non-current trade receivables as at March 31,
2017 include variation claims of ₹309 lakhs for
which the Company had received an arbitration
award in its favour which has subsequently been
upheld by the District Court. The customer has
challenged this Court Order. However, based on
the above arbitration award, Court Order and
legal opinion, management is reasonably
confident of recovery of these amounts.
Non-current trade receivables and Unbilled
Work-in-progress (other current financial
assets) as at March 31, 2017 includes ₹ 1,139.96
lakhs and ₹ 2,755.80 lakhs respectively, for a
contract which was rescinded by the Company
and Non-current trade receivables and Unbilled
Work-in-progress (other current financial
assets) as at March 31, 2017 includes ₹ 1,414.41
lakhs and ₹ 5,921.77 lakhs respectively, in
respect of another contract where the Company
received a notice from the customer
withdrawing from the Company the balance
works to be executed under the contract for
which the Company has also issued guarantees
aggregating ₹ 1,497.13 lakhs. The Company has
made claims against the customers to recover
these amounts and has initiated legal action.
Based upon legal opinions received, the
management is reasonably confident of recovery
76
Fiscal
Year
Summary of EOM Management Response
of these amounts of Non-current trade
receivables and Unbilled Work-in-progress
(other current financial assets) and consequently
no changes have been made to the values and
classification of these amounts in the results.
2016 We draw attention to Note 38 to the standalone
financial statements and Note 37 to the
consolidated financial statements which
describes the uncertainty related to
recoverability of long-term trade receivables
and unbilled work in progress aggregating to
₹2,863.37 lakhs (31 December 2015:
₹2,863.37 lakhs) and ₹8,677.57 lakhs (31
December 2015: ₹8,677.57 lakhs)
respectively, outstanding as at 31 December
2016, representing various claims recognised
during the earlier period based on the terms
and conditions implicit in the contracts. These
claims being technical in nature and being
subject matter of litigation, the Company has
assessed the recoverability of these claims
based on legal opinion from an independent
counsel. On the basis of such assessment,
management is of the opinion that the claims
are tenable and would be realized in full and
accordingly no adjustments have been made in
the consolidated financial statements. Our
opinion on the consolidated financial
statements is not modified in respect of these
matters.
Long-term trade receivables at 31 December
2016 include variation claims of ₹309 lakhs for
which the Company had received an arbitration
award in its favour which has subsequently been
upheld by the District Court. The customer has
challenged this Court Order. However, based on
the above arbitration award, Court Order and
legal opinion, management is reasonably
confident of recovery of these amounts.
Long-term trade receivables and unbilled work-
in-progress at 31 December 2016 include
₹1,139.96 lakh and ₹2,755.80 lakh in respect of
a contract which has been rescinded by the
Company and long-term trade receivables and
unbilled work-in-progress as at 31 December
2016 includes ₹1,414.41 lakh and ₹5,921.77
lakh respectively, in respect of another contract
where the Company has received a notice from
the customer withdrawing from the Company
the balance works to be executed under the
contract for which the Company has also issued
guarantees aggregating ₹1,497.13 lakh. The
Company has made claims against the customer
to recover these amounts and has initiated legal
action. Based upon legal opinion received,
management is reasonably confident of recovery
of these amounts of long term trade receivable
and unbilled work-in-progress and consequently
no changes have been made to the values and
classification of these amounts in the financial
statements.
2015 As stated in Note 37 to the standalone financial
statements and Note 36 to the consolidated
financial statements, the Company’s trade
receivables and unbilled work in progress as at
31 December 2015 include amounts
aggregating ₹3,033 lakhs (31 December 2014:
₹2,655 lakhs) and ₹479 Lakhs (31 December
2014: ₹1,584 lakhs) respectively, being
considered as good and recoverable by the
management. These amounts are presently
under negotiation with the customers or
subject matter of litigation. In the absence of
external balance confirmations from the
customers or other alternative audit evidence
to corroborate management’s assessment of
recoverability of these balances and having
regard to the age of these receivables, we are
unable to comment on the extent to which
these balances are recoverable and
consequential impact, if any, on the
accompanying standalone financial statements
Trade receivables and Unbilled Work-in-
progress as at 31 December 2015 include
amounts aggregating ₹3,033 lakhs and ₹479
lakhs respectively, which have been outstanding
for a substantial period of time. The Company
has been actively negotiating for recovery and
also pursuing
legal action of the balance receivables. In view
thereof, management is reasonably confident of
their recovery.
77
Fiscal
Year
Summary of EOM Management Response
and consolidated financial statements.
We draw attention to Note 38 to the standalone
financial statement and Note 37 to the
consolidated financial statements which
describes the uncertainty related to
recoverability of long-term trade receivables
and unbilled work in progress aggregating to
₹2,863 lakhs (31 December 2014: ₹2,863
lakhs) and ₹8,678 lakhs (31 December 2014:
₹8,678 lakhs) respectively, outstanding as at
31 December 2015, representing various
claims recognised during the earlier period
based on the terms and conditions implicit in
the contracts. These claims being technical in
nature and being subject matter of litigation,
the Company has assessed the recoverability
of these claims based on legal opinion from an
independent counsel. On the basis of such
assessment, management is of the opinion that
the claims are tenable and would be realized in
full and accordingly no adjustments have been
made in the consolidated financial statements.
Our opinion is not modified in respect of these
matters.
Long-term trade receivables at 31 December
2015 include variation claims of ₹309 lakh for
which the Company had received an arbitration
award in its favour which has subsequently been
upheld by the District Court. The customer has
challenged this Court Order. However, based on
the above arbitration award, Court Order and
legal opinion, management is reasonably
confident of recovery of these amounts.
Long-term trade receivables and unbilled work-
in-progress at 31 December 2015 include ₹1,140
lakh and ₹2,756 lakh respectively, in respect of
a contract which has been rescinded by the
Company and long-term trade receivables and
unbilled work-in-progress as at 31 December
2015 includes ₹1,414 lakh and ₹5,922 lakh
respectively, in respect of another contract
where the Company has received a notice from
the customer withdrawing from the Company
the balance works to be executed under the
contract for which the Company has also issued
guarantees aggregating ₹1,497 lakh. The
Company has made claims against the customer
to recover these amounts and has initiated legal
action. Based upon legal opinion received,
management is reasonably confident of recovery
of these amounts of long term trade receivable
and unbilled work-in-progress and consequently
no changes have been made to the values and
classification of these amounts in the financial
statements.
2014 As stated in Note 36 to the standalone financial
statements and Note 35 to the consolidated
financial statements, the company’s trade
receivables and unbilled work in progress as at
31 December, 2014 include amounts
aggregating ₹2,655 lakhs and ₹1,584 lakhs
respectively, being considered as good and
fully recoverable by the management. These
amounts are presently under negotiation with
the customers. In the absence of external
balance confirmations from the customers or
other alternative audit evidence to corroborate
management’s assessment of recoverability of
these balances and having regard to the age of
these receivables, we are unable to comment
on the extent to which these balances are
recoverable and the consequential impact, if
any, on the accompanying standalone financial
statements and consolidated financial
statements
Trade receivables and Unbilled Work-in-
progress as at 31 December 2014 include
amounts aggregating ₹2,655 lakhs and ₹1,584
lakhs respectively, which have been outstanding
for a substantial period of time. The Company
has been actively negotiating for speedy
recovery of the balance receivables. In view
thereof, management is reasonably confident of
their recovery.
We draw attention to Note 37 to the standalone
financial statements and Note 36 to the
consolidated financial statements regarding
long-term trade receivables, trade receivables
and unbilled work in progress aggregating to
Trade receivables as at 31 December 2014
representing variation claims and interim work
bills recognized by the Company aggregating
₹6,842 lakh. These claims are presently under
various stage of litigations. Considering
78
Fiscal
Year
Summary of EOM Management Response
₹2,863 lakhs (31 December 2013: ₹Nil),
₹8,521 lakhs (31 December 2013: ₹11,099
lakhs) and ₹25,467 lakhs (31 December 2013:
₹25,507 lakhs) respectively, outstanding as at
31 December 2014, representing various
claims recognised during the earlier period
based on the terms and conditions implicit in
the contracts. These claims being technical in
nature and being subject matter of arbitration/
litigation, the Company has assessed the
recoverability of these claims based on
recommendation of Dispute Resolution Board,
awards received from Arbitration Tribunal,
High Court orders received and legal opinion
from Annual an independent counsel. On the
basis of such assessment, management is of
the opinion that the claims are tenable and
would be realized in full and accordingly no
adjustments have been made in the Financial
Statement. Our opinion is not qualified in
respect of these matters.
favorable arbitration awards, claims under
consideration at various forums, past experience
of the Company and based on the legal opinion
received, the management is reasonably
confident of recovery of these amounts and are
expected to be realised within next twelve
months.
Trade receivables as at 31 December 2014
include ₹696 lakh relating to price escalation
claims which are disputed by the customer. The
Company has received an arbitration award in
its favour which has subsequently been upheld
by the High Court. The customer has challenged
this High Court order. However, based on the
above arbitration award, High Court order and
legal opinion, management is reasonably
confident of recovery of these amounts and are
expected to be realised within next twelve
months.
Long term trade receivables as at 31 December
2014 include variation claims of ₹309 lakh for
which the Company had received an arbitration
award in its favour which has subsequently been
upheld by the District Court. The customer has
challenged this Court Order. However, based on
the above arbitration award, Court Order and
legal opinion, management is reasonably
confident of recovery of these amounts.
Long term trade receivables and unbilled work-
in-progress as at 31 December 2014 include ₹
1,140 lakh and ₹2,756 lakh respectively, in
respect of a contract which has been rescinded
by the Company and long term trade receivable
and unbilled work-in-progress as at 31
December 2014 include ₹1,414 lakh and ₹5,922
lakh respectively, in respect of another contract
where the Company has received a notice from
the customer withdrawing from the Company
the balance works to be executed under the
contract; for which the Company has also issued
guarantees aggregating ₹1,497 lakh .The
Company has made claims against the customer
to recover these amounts and has initiated legal
action. Based upon legal opinion received,
management is reasonably confident of recovery
of these amounts of long term trade receivable
and unbilled work-in-progress and consequently
no changes have been made to the values and
classification of these amounts in the financial
statements.
Trade receivables and unbilled work in progress
as at 31 December 2014 includes ₹983 lakh and
₹16,789 lakh respectively in respect of certain
road contracts which are executed by the
79
Fiscal
Year
Summary of EOM Management Response
Company. The Company has made claims on
the customer for recovery of these amounts.
Based on the contract terms and legal opinion
obtained, the management is reasonably
confident of recovery of these amounts and are
expected to be realised within next twelve
months.
We draw attention to Note. 38 to the
standalone financial statements which
describe the uncertainty related to the
recoverability of short-term advances
aggregating to ₹6,819 lakhs to ITD Cemindia
JV, Company’s Joint Venture. The
recoverability of these advances is majorly
dependent on the Joint Venture’s ability to
realize the outstanding dues from its customer
which are presently under litigation.
Short term Loans and advances as at 31
December 2014 include ₹6,819 lakhs on account
of advances to ITD Cemindia JV, Company’s
joint venture. These amounts will be refunded
by the joint venture on receipt of money from its
customer. The joint venture had recognized
various claims during earlier period based on the
terms and conditions implicit in the contract,
which are presently under various stage of
litigations. Considering favorable arbitration
award, pending claims at various forums and
based on independent legal opinion,
management is reasonably confident of recovery
of these advances.
We draw attention to Note 37 to the
consolidated financial statements which
describes the uncertainty related to the
recoverability of group’s share of trade
receivables and unbilled work in progress
aggregating to ₹2,076 lakhs and ₹2,394 lakhs,
respectively, in ITD Cemindia JV, company’s
joint venture, outstanding as at 31 December
2014, representing various claims recognized
during the earlier periods based on the terms
and conditions implicit in the contracts. These
claims being technical in nature and being
subject matter of arbitration/ litigation, the
management of the group has assessed the
recoverability of these dues based on
recommendation of Dispute Resolution Board,
awards received from Arbitration Tribunal and
legal opinion from an independent counsel.
Pending the ultimate outcome of these matters
which is presently unascertainable, no
adjustments have been made in the
accompanying consolidated financial
statements. Our opinion is not qualified in
respect of this matter.
Trade receivables and unbilled work-in-
progress as at 31 December 2014 include
Company's share of ₹2,076 lakh and ₹2,394 lakh
respectively, in respect of a joint venture,
representing escalation and variation claims
recognized by the joint venture. These claims
are presently under various stages of litigation.
Considering favorable arbitration awards,
claims under consideration at various forums
and based on the legal opinion received, the
management is reasonably confident of recovery
of these amounts and are expected to be realised
within next twelve months.
2013 We draw attention to Note 36 to the standalone
financial statements and Note 35 to the
consolidated financial statements regarding
trade receivables and unbilled work in
progress aggregating to ₹11,099 lakh (31
December 2012: ₹8,727 lakh) and ₹25,507
lakh (31 December 2012: ₹8,686 lakh)
respectively, outstanding as at 31 December
2013, representing various claims recognised
during the earlier period based on the terms
and conditions implicit in the contracts. These
claims being technical in nature and being
Trade receivables as at 31 December 2013
include variation claims recognised by the
Company aggregating ₹2,769 lakhs which are
disputed by the customer. Out of this claims
amounting to ₹2,258 lakh are a subject matter of
arbitration. The Company has received
arbitration award in its favour in respect of the
balance amount of ₹511 lakhs which have since
been challenged by the customer. Based on the
legal opinion from Company's counsel in the
matter, the management is reasonably confident
of recovery of these amounts.
80
Fiscal
Year
Summary of EOM Management Response
subject matter of arbitration/ litigation, the
Company has assessed the recoverability of
these claims based on recommendation of
Dispute Resolution Board, awards received
from Arbitration Tribunal, High Court orders
received and legal opinion from an
independent counsel. On the basis of such
assessment, management is of the opinion that
the claims are tenable and would be realized in
full and accordingly no adjustments have been
made in the consolidated financial statements.
Our opinion is not modified in respect of these
matters
Trade receivables as at 31 December 2013
include ₹4,080 lakhs representing interim work
bills for work done which have not been
certified by customers beyond normal periods of
certification. The management is reasonably
confident of the certification and recovery of the
same progressively on these contracts based on
past experience of the Company, assessment of
work done and the fact that these amounts are
not disputed by the customer and based on the
legal opinion received on this matter.
Trade receivables as at 31 December 2013
include ₹1,140 lakhs relating to price escalation
claims which are disputed by the customer. The
Company has received an arbitration award in
its favour which has subsequently been upheld
by the High Court. The customer has challenged
this High Court order. However, based on the
above arbitration award, High Court order and
legal opinion, management is reasonably
confident of recovery of these amounts.
Trade receivables as at 31 December 2013
include variation claims of ₹309 lakhs for which
the Company had received an arbitration award
in its favour which has subsequently been
upheld by the District Court. The customer has
challenged this Court Order. However, based on
the above arbitration award, Court Order and
legal opinion, management is reasonably
confident of recovery of these amounts.
Trade receivables and unbilled work-in-
progress as at 31 December 2013 include ₹1,140
lakh and ₹2,756 lakh respectively, in respect of
a contract which has been rescinded by the
Company and trade receivable and unbilled
work-in-progress as at 31 December 2013
include ₹689 lakhs and ₹5,922 lakhs
respectively, in respect of another contract
where the Company has received a notice from
the customer withdrawing from the Company
the balance works to be executed under the
contract; for which the Company has also issued
guarantees aggregating ₹2,227 lakh . The
Company has made claims against the customer
to recover these amounts and has initiated legal
action. Based upon legal opinion received,
management is reasonably confident of recovery
of these amounts of trade receivable and
unbilled work-in-progress and consequently no
changes have been made to the values and
classification of these amounts in the financial
statements.
Trade receivables and unbilled work in progress
as at 31 December 2013 includes ₹972 lakhs and
81
Fiscal
Year
Summary of EOM Management Response
₹16,829 lakhs respectively in respect of certain
road contracts which are currently being
executed by the Company. The customer has
already granted two extensions of time and the
Company’s request for further extension is
under consideration. The Company has made
claims on the customer for recovery of these
amounts. Based on the contract terms and legal
opinion obtained, the management is reasonably
confident of recovery of these amounts.
2012 We draw attention to notes 36 to 40 to the
standalone financial statements and notes 35 to
39 to the consolidated financial statements
regarding trade receivables and un-billed work
in progress aggregating to ₹8,727 lakhs and
₹8,686 lakhs (31 December 2011: ₹8,288
lakhs and ₹8,686 lakhs) respectively,
outstanding as at 31 December 2012,
representing various claims recognised during
the earlier period based on the terms and
conditions implicit in the contracts. These
claims being technical in nature and being
subject matter of litigation, the Company has
assessed the recoverability of these claims
based on Dispute Resolution Board, awards
received from arbitration tribunal, high court
orders received and legal opinion from an
independent counsel. On the basis of such
assessment, management is of the opinion that
the claims are tenable and would be realized in
full accordingly no adjustments have been
made in these standalone financial statements
and consolidated financial statements
Trade receivables at 31 December 2012 include
variation claims recognised by the Company
aggregating ₹3,278 lakhs which are disputed by
the customer. Out of this claims amounting to
₹2,346 lakhs are a subject matter of arbitration.
The Company has received arbitration award in
its favour in respect of the balance amount of
₹932 lakhs which have since been challenged by
the customer. Considering the legal opinion
from Company’s counsel in the matter, the
management is reasonably confident of recovery
of these amounts.
Trade receivables as at 31 December 2012
include ₹ 3,384 lakhs representing interim work
bills for work carried out by the Company which
have not been certified by customers beyond
normal periods of certification. The
management is reasonably confident of the
certification and recovery of the same
progressively on these contracts based on past
experience of the Company, assessment of work
done and the fact that these amounts are not
disputed by the customer and based on the legal
opinion received on this matter.
Trade receivables at 31 December 2012 include
₹1,140 lakhs relating to price escalation claims
which are disputed by the customer. The
Company has received favourable verdict from
Dispute Redressal Board and also thereafter in
Arbitration in respect of these claims. The
Customer has appealed against the Arbitration
Award. Management is reasonably confident of
recovery of this amount based on the above and
independent legal opinion from eminent legal
counsel in the matter.
Trade receivables at 31 December 2012 include
variation claims of ₹309 lakhs for which the
Company had received an arbitration award in
its favour which has subsequently been upheld
by the District Court. The customer has
challenged this Court Order. However, based on
the above arbitration award, Court Order and
legal opinion, management is reasonably
confident of recovery of these amounts.
Trade receivables and Unbilled work-in-
82
Fiscal
Year
Summary of EOM Management Response
progress at 31 December 2012 include ₹616
lakhs and ₹2,757 lakhs in respect of a contract
which has been rescinded by the Company and
₹5,929 lakhs in respect of another contract
where the Company has received a notice from
the customer withdrawing from the Company
the balance works to be executed under the
contract; besides the Company has also issued
guarantees aggregating ₹2,227 lakhs. The
Company has made claims against the customer
to recover these amounts and has initiated legal
action. Based upon legal opinion received,
management is reasonably confident of recovery
of these amounts of work in progress and
consequently no changes have been made to the
values and classification of these amounts in the
financial statements.
Liquidity and Capital Resources
As of December 31, 2016, we had cash and bank balances of ₹18,509.82 lakh on consolidated basis. Cash and
bank balances consist of cash on hand and deposit accounts including fixed deposits. Our primary liquidity needs
have been to finance our operations, working capital needs, debt service and capital expenditures. We have
historically met our liquidity needs through a combination of borrowings, capital raising and internally generated
cash flows.
We expect to meet our working capital requirements primarily from the cash flows from our business operations
and working capital borrowings as may be required.
Our long-term liquidity requirements include acquisition of assets. Sources of funding our long-term liquidity
requirements include new loans, equity or debt issues.
Off-Balance Sheet Commitments and Arrangements
We do not have any off-balance sheet arrangements, derivative instruments, swap transactions or relationships
with affiliates or other unconsolidated entities or financial partnerships that would have been established for the
purpose of facilitating off-balance sheet arrangements.
Interest Coverage Ratio
The interest coverage ratio of our Company on a consolidated basis, which is the total of profit after tax plus
depreciation and finance cost for the year divided by finance cost for the last 3 (three) fiscals is as under:
Particular Fiscal 2016 Fiscal 2015 Fiscal 2014
Interest Coverage Ratio (on consolidated basis) 2.02 times 1.55 times 0.81 times
An analysis of reasons for the changes in significant items of income and expenditure is given hereunder:
Unusual or infrequent events or transactions
There have been no events to the best of our knowledge, other than as described in this Preliminary Placement
Document, which may be called “unusual” or “infrequent”.
Significant economic changes that materially affected or are likely to affect income from continuing operations
Other than as mentioned under the heading titled ‘Factors Affecting Results of Our Operations’ on page 194 in
this chapter, “Risk Factors” and “Regulations and Policies” on page 29 and page 122, respectively, to the best
83
knowledge of the management of our Company, there are no other significant economic changes that materially
affect or are likely to affect income from continuing operations.
Future changes in relationship between costs and income
Changes in revenues during the last three years are as explained in the part Fiscal 2016 compared to Fiscal 2015
and Fiscal 2015 compared to Fiscal 2014 in this chapter.
Status of any publicly announced new products or business segments
There are currently no publicly announced new products or business segments.
Seasonality of Business
Our business operations may be adversely affected by adverse weather conditions, which may require us to
evacuate personnel or curtail services, or lead to damage of equipment or facilities resulting in the suspension of
operations. Extreme temperature or weather fluctuations in areas in which our projects are executed, such as
during summer and monsoon seasons may impede us from executing projects efficiently and from effectively
utilizing resources. During periods of curtailed activity due to adverse weather conditions, we may continue to
incur overhead expenses, but our revenues from operations may be delayed or reduced.
Any significant dependence on a single or few suppliers or customers
While we are not dependent on any single raw material supplier/ customer, raw material supply and pricing can
be volatile due to a number of factors beyond our control, including global demand and supply, transportation and
labour costs, labour unrest, natural disasters, competition, import duties, tariffs and currency exchange rates, and
any unanticipated variation in any of these factors could have a material adverse effect on our operations.
Competitive Conditions
We face competition from existing and potential competitors which is common for any business. We have, over
a period of time, developed certain competitive strengths which have been discussed in the chapter titled “Our
Business” on page 102.
Transactions with related parties
For details in relation to the related party transactions entered by our Company during the last three Financial
Years, as per the requirements under “Accounting Standard 18 – Related Party Transactions” and as specified
under the Companies Act, 2013, see “Financial Statements” on page 194.
Changes in accounting policies during last three years and their effect on the profits and reserves of our
Company
Up to the period ended 30 September 2014, the Company had been accounting for depreciation on fixed assets
based on written down value method. Effective 1 October 2014, the Company has with retrospective effect
changed its method of providing depreciation on fixed assets from the ‘Written Down Value’ method to the
‘Straight Line’ method. Management believes that this change will result in more appropriate presentation and
will give a systematic basis of depreciation charge, representative of the time pattern in which the economic
benefits will be derived from the use of these assets. The Company has also carried out a technical evaluation to
assess the revised useful life of fixed assets. The change in the above accounting policy has resulted in a surplus
of ₹ 9,553.25 lakhs relating to the depreciation already charged upto the period ended 30 September 2014 which
has been disclosed as an exceptional item
Recent Financial Performance
The following discussion of the Company’s results of operations is based on the Unaudited Interim Financial
Statements of the Company for the nine months ended September 30, 2017. The consolidated unaudited financial
results for the nine months ended September 30, 2017 are not necessarily indicative of results of operations that
may be expected for the full year and do not reflect the financial results on a consolidated basis for the same
period. References to “we” and “our” in this section are to our Company.
84
The Ministry of Corporate Affairs notified the Companies (Indian Accounting Standards) Rules, 2015 on February
16, 2015 providing a roadmap for the implementation of Ind AS in a phased manner. The company has adopted
Indian Accounting standards (Ind AS) with transition date of January 1, 2017. Accordingly, the financial results
for the nine months ended September 30, 2017 have been prepared in accordance with the recognition and
measurement principles laid down in Ind AS, in terms of Regulation 33 of the SEBI (Listing Obligations and
Disclosure Requirements) Regulations, 2015 and SEBI Circular dated July 5, 2016. The Statutory Auditors has
given a limited review report for the nine months period ended September 30, 2017, as per Ind AS. Accounting
principles under Ind AS vary in many respects from accounting principles under Indian GAAP, and our Unaudited
Financial Statements prepared and presented in accordance with Ind AS are therefore not comparable to the
Audited Financial Statements or any of our other historical financial statements prepared under Indian GAAP.
The Unaudited Financial Results are also presented in a manner that is not comparable to the Audited Financial
Results. For further information, see “Certain Conventions, Currency Presentation and Financial Data” on page
11.
SUMMARY OF CONSOLIDATED PROFIT AND LOSS STATEMENT FOR THE NINE MONTHS
ENDED SEPTEMBER 30, 2017
(₹ in lakhs)
Particulars Nine months ended September 30, 2017
Income from operations 148,559.88
Other Income 2,020.15
Total Income 1,50,580.03
Expenses
Cost of material consumed 42,804.29
Subcontracting expenses 33,086.43
Employee benefits expense 19,126.59
Depreciation and amortization expense 4,127.54
Finance costs 6,574.49
Other expenses 34,251.80
Total expenses 1,39,971.14
Profit before tax and share of profit/ (loss) of joint ventures 10,608.89
Share of profit/ (loss) of joint venture (1,471.17)
Profit before tax 9,137.72
Tax expenses
Current income tax 5,639.03
Deferred income tax (2,028.20)
Total tax expense 3,610.83
Profit for the period 5,526.89
Other comprehensive income
Item not to be reclassified subsequently to profit or loss
- Profit/ (loss) on fair value of defined benefit plans (517.90)
- Income tax effect on above 179.24
Income tax relating to items that will not be reclassified to profit
or loss
-
Other comprehensive income for the period , net of tax (338.66)
Total comprehensive income for the period, net of tax 5,188.23
Unaudited Financial Results for Quarter ended September 30, 2017 and September 30, 2016 on a consolidated
basis are not comparable.
Significant Developments after December 31, 2016
To the best of our knowledge and belief, except as disclosed in this Preliminary Placement Document, no
circumstances have arisen since the date of the last audited financial statements contained in this Preliminary
Placement Document which materially affect or are likely to affect, the trading and profitability of our Company,
or the value of our assets or our ability to pay material liabilities within the next 12 months save and except what
is stated as under:
1. Enhancement in the value of existing Kalkeshwaram Project - Package No.17 - Investigation, Design
and execution of water conveyor system consisting of lined gravity canal, CM & CD works, tunnel from
₹ 66,748 lakh to ₹ 99,042 lakh.
85
2. We were selected as L1 bidders in projects worth ₹ 209,900 lakh.
3. As of September 30, 2017, our Company’s total borrowings has increased to ₹ 52,698.07 lakh on a
consolidated basis as per Ind AS to meet the working capital/capex requirements of the projects of the
Company and its Joint Ventures.
86
SUMMARY OF KEY DIFFERENCES BETWEEN INDIAN GAAP AND IND AS
The financial statements of Indian companies are prepared as per the Indian Accounting standards (Ind AS)
notified by the Ministry of Corporate Affairs with effect from 1st April 2016, with a transition date of 1st April,
2015. Ind AS 101- First-time Adoption of India Accounting Standards required that all Ind AS standards and
interpretations that are issued and effective for the first Ind AS financial statements which is for the year ended
March 31, 2017 for the Company, on a consolidated basis, be applied retrospectively and consistently for all
financial years presented.
The financial information included in the section - Financial Statements of the Company has been prepared on the basis of the Company‘s audited financial information were prepared in accordance with Indian GAAP. Many differences exist between Indian GAAP and Ind AS that might be material to our financial information. Ind AS have been made applicable in India with effect from April 1, 2016 in phased manner and same are applicable to our Company since January 1, 2017. The matters described below summarize certain key differences between Indian GAAP and Ind AS. No numerical reconciliation of the financial position and results of operations under Indian GAAP and under Ind AS have been included in the Preliminary Placement Document. Therefore, we are not in a position to state as to how our financial position and the results of operations would be impacted when computed under Ind AS.
In making an investment decision, investors must rely upon their own examination of the Company, the terms of
the offering and the financial information. Potential investors should consult their own professional advisors for
an understanding of the differences between Indian GAAP and Ind AS, and how those differences might affect
the financial information included in this Preliminary Placement Document. This is not an exhaustive list of
differences between Indian GAAP and Ind AS; rather, it indicates only those key differences which are considered
to be more relevant to the financial position and results of operations of the Company and does not cover all
differences regarding presentation, classification and disclosure requirement applicable under Indian GAAP and
Ind AS.
Ind AS
Standard
Particulars Treatment as per Indian GAAP Treatment as per Ind AS
Ind AS 1 Presentation of
Financial
Statements
Other Comprehensive Income:
Statement of Other Comprehensive
Income is not applicable under
Indian GAAP. Some items, such as
revaluation surplus, that are treated
as ‘other comprehensive income’
under Ind AS are recognised
directly under Reserves and Surplus
under Indian GAAP. There is no
concept of “other comprehensive
Income” under Indian GAAP.
Other Comprehensive Income:
The statement of profit and loss
and other comprehensive income
includes all items of income and
expense (i.e. all ‘non-owner’
changes in equity) including (a)
components of profit or loss and
(b) other comprehensive income
(i.e. items of income and
expense that are not recognised in
profit and loss as required or
permitted by other accounting
standards under Ind AS). An entity
is required to present all items of
income and expenses including
components of other
comprehensive income in a period
in a single statement of profit and
loss.
Statement of Change in Equity:
A statement of changes in equity is
currently not presented.
Movements in share capital,
retained earnings and other
reserves are to be presented in the
notes to accounts
Statement of Change in Equity:
The statement of changes in equity
includes the following
information:
total comprehensive income
for the period;
the effects on each
component of equity of
retrospective application or
retrospective restatement in
accordance with Ind AS 8;
87
Ind AS
Standard
Particulars Treatment as per Indian GAAP Treatment as per Ind AS
and
for each component of
equity, a reconciliation
between the opening and
closing balances, separately
disclosing each change.
Extraordinary items:
Extraordinary items are disclosed
separately in the statement of profit
and loss and are included in the
determination of net profit or loss
for the period. Items of income or
expense to be disclosed as
extraordinary should be distinct
from the ordinary activities and are
determined by the nature of the
event or transaction in relation to
the business ordinarily carried out
by an entity.
Extraordinary items:
Presentation of any items of
income or expense as
extraordinary is prohibited.
Change in Accounting Policies:
Under Indian GAAP, Changes in
accounting policies should be made
only if it is required by statute, for
compliance with an Accounting
Standard or for a more appropriate
presentation of the financial
statements on a retrospective basis
together with a disclosure of the
impact of the same in the current
year. If a change in the accounting
policy is expected to have a material
effect in the later periods, the same
should be appropriately disclosed.
Change in Accounting Policies:
Ind AS-1 requires retrospective
application of changes in
accounting policies by adjusting
the opening balance of each
affected component of equity for
the earliest prior period presented
and the other comparative
amounts for each period presented
as if the new accounting policy had
always been applied, unless
transitional provisions of an
accounting standard require
otherwise.
Dividends:
Schedule III requires disclosure of
proposed dividends in the notes to
accounts. However, as per the
requirements of AS 4, which
override the provisions of
Schedule III, dividends stated to be
in respect of the period covered by
the financial statements, which are
proposed or declared after the
balance sheet date but before
approval of the financial
statements will have to be recorded
as a provision. Further, as per
recent amendment in Accounting
Standards 4, dividends declared
subsequent to the balance sheet are
to be considered as a non-adjusting
event, which is similar to the Ind
AS requirement.
Dividends:
Liability for dividends declared to
holders of equity instruments are
recognised in the period when
declared. It is a non-adjusting
event, which is an event after the
reporting period that is indicative
of a condition that arose after the
end of the reporting period
Errors:
Prior period items are included in
determination of net profit or loss of
Errors:
Material prior period errors are
corrected retrospectively by
88
Ind AS
Standard
Particulars Treatment as per Indian GAAP Treatment as per Ind AS
the period in which the error
pertaining to a prior period is
discovered and are separately
disclosed in the statement of profit
and loss in a manner that the impact
on current profit or loss can be
perceived.
restating the comparative amounts
for prior periods presented in
which the error occurred or if the
error occurred before the earliest
period presented, by restating the
opening balance sheet.
Presentation of profit or loss
attributable to non-controlling
interests (minority interests):
Profit or loss attributable to
minority interests is disclosed as
deduction from the profit or loss for
the period as an item of income or
expense
Presentation of profit or loss
attributable to non-controlling
interests (minority interests):
Profit or loss attributable to non-
controlling interests and equity
holders of the parent are disclosed
in the statement of profit or loss
and Other comprehensive income
as allocations of profit or loss and
total comprehensive income for the
period.
Reclassification Under Indian GAAP, a disclosure is
made in financial statements that
comparative amounts have been
reclassified to conform to the
presentation in the current period
without additional disclosures for
the nature, amount and reason for
reclassification.
Ind AS requires, when
comparative amounts are
reclassified, the nature amount and
reason for reclassification to be
disclosed.
Ind AS 7 Statement of Cash
Flow
Under Indian GAAP, AS is silent
about inclusion of bank overdraft
in cash and cash equivalents.
Effect of changes in Bank overdraft
is included under financing
activities.
As per Ind AS 7, bank overdrafts
which are repayable on demand
form an integral part of an entity's
cash management, are included as
a component of cash and cash
equivalents.
Ind AS
11
Construction
Receipt
Under Indian GAAP, revenue from
Construction contract is recognized
with reference to stage of
completion of the contract activity
at the reporting date when outcome
of the construction contract is
estimated reliably. All expected
losses are immediately recognized
as expenses in statement of Profit &
Loss.
Revenue from Construction
contracts is recognized in similar
manner as in Indian GAAP. Only
difference is that Ind AS requires
consideration to be measured at
fair value.
Ind AS
12
Income taxes Deferred taxes are computed for
timing differences in respect of
recognition of items of profit or loss
Deferred taxes are computed
for all accounting base and the tax
base of assets and liabilities.
Also, any deferred tax impact on
the adjustment made to transition
to Ind AS is to be assessed and
should be given impact in
financial statements.
Ind AS
16
Depreciation Property, plant and equipment are
not required to be componentised as
per AS 10. However, companies
Property, plant and equipment are
separately. There is no concept of
minimum statutory depreciation
89
Ind AS
Standard
Particulars Treatment as per Indian GAAP Treatment as per Ind AS
Act requires the company to adopt
component accounting. The
Companies Act, 2013 sets out the
estimated useful lives of assets
based on the nature of the asset and
the useful life used for depreciation
ordinarily should not differ from the
useful life specifies in the
Companies Act, 2013. However a
different useful life may be used
based on technical analysis and
requires disclosure in financial
statements. Further, as per recent
amendment in Accounting
Standards 10, the standard is made
in line with the requirements Ind
AS.
under Ind AS.
Ind AS
17
Leases Indian GAAP requires lease
payments under an operating lease
shall be recognised as an expense on
a straight line basis over the lease
term unless another systematic basis
is more representative of the time
pattern of the user’s benefit.
Under Ind AS 17 straight lining of
operating lease is not required, if
the payments to the lessor are
structured to increase in line with
expected general inflation to
compensate for the lessor’s
expected inflationary cost
increases.
Ind AS
19
Employee
Benefits
All actuarial gains and losses are
recognised immediately in the
statement of profit and loss.
Actuarial gains and losses
representing changes in the
present value of the defined
benefit obligation resulting from
experience adjustment and effects
of changes in actuarial
assumptions are recognised in
other comprehensive income and
not reclassified to profit or loss in
a subsequent period.
Ind AS
21
Effects of changes
in Foreign
Exchange Rates:
Functional and
presentation
currency
Foreign currency is a currency
other than the reporting currency
which is the currency in which
financial statements are presented.
There is no concept of functional
currency.
Functional currency is the
currency of the primary economic
environment in which the entity
operates. Foreign currency is a
currency other than the functional
currency. Presentation currency is
the currency in which the financial
statements are presented.
Ind AS
32
Classification of
Equity and
Financial
Liabilities
Under Indian GAAP, financial
instruments are classified as a
liability or equity based on legal
form. Redeemable preference
shares will be classified as
Shareholders Funds. Preference
dividends are always recognized
similar to equity dividends and are
not treated as interest expense.
Under Ind AS, financial
instruments are classified as a
liability or equity according to the
substance of the contractual
arrangement (and not its legal
form) and the definitions of
financial liabilities and equity
instruments.
Dividends on financial
instruments classified as financial
liability are recognised as an
90
Ind AS
Standard
Particulars Treatment as per Indian GAAP Treatment as per Ind AS
interest expense in the statement
of profit or loss and other
comprehensive income.
Hence if preference shares meet
the definition of financial liability,
the dividend is treated as an
interest expense.
Ind AS
37
Provisions,
Contingent
Liabilities and
Contingent Assets
Discounting of liabilities is not
permitted and provisions are carried
at their full values.
When the effect of time value of
money is material, the amount of
provision is the present value of
the expenditure expected to be
required to settle the obligation.
The discount rate is a pre-tax rate
that reflects the current market
assessment of the time value of
money and risks specific to the
liability.
Ind AS
101
First Time
Adoption
There is no specific standard. Full
retrospective application would be
required.
Ind AS 101 gives guidance on
preparation of first Ind AS
financial statement. Ind AS grants
limited mandatory and voluntary
exemptions from full retrospective
application.
Ind AS
109
Financial Assets Financial assets are not defined in
Indian GAAP and no specific
guidance is provided. All assets are
measured and booked at their
transaction value.
All financial assets are
classified as measured at
amortised cost or measured at fair
value through profit and loss or
fair value through other
comprehensive income. All
equity investments are measured
at fair value with value changes
recognized in statement of Profit
and Loss except for those equity
investments for which the entity
has irrevocably elected to present
value changes in OCI.
Financial
Liabilities
Financial liabilities are not defined
in Indian GAAP and no specific
guidance is provided. The common
practice is to recognize financial
liability for consideration received
on its recognition. Subsequently,
interest is recognized at contractual
rate, if any.
Financial liabilities held for
trading are subsequently measured
at fair value through profit and
loss and all other financial
liabilities are measured at
amortised cost using the effective
interest method
Financial
guarantee contract
Under Indian GAAP, the financial
guarantee contracts (i.e. guarantees
given on behalf of subsidiary,
associate or joint venture
companies) are disclosed by way
of contingent liabilities in the
standalone financial statements of
the parent Company. Guarantees
given on behalf of associate and
joint venture companies are
Ind AS 109 requires all financial
guarantee contracts to be
recognized at fair value at
inception. The fair value of the
contract will be equal to the
amount of premium receivable (or
net present value of the
premium if the same is paid
over the period) determined on an
arm’s length basis.
91
Ind AS
Standard
Particulars Treatment as per Indian GAAP Treatment as per Ind AS
disclosed by way of contingent
liabilities in the consolidated
financial statements of the parent
Company.
Subsequently, the issuer measures
it at the higher of the amount of the
loss allowance determined and
(ii) the amount initially
recognised less, when
appropriate, the cumulative
amount of income recognised in
accordance with the principles of
Ind AS 18.
Financial
Instruments -
Provision for
doubtful debts
Under Indian GAAP, provisions are
made for specific receivables based
on circumstances such as. Credit
default of customer or disputes with
customers. An enterprise should
assess the provision of doubtful
debts at each period end which, in
practice, is based on relevant
information such as past
experience, actual financial
position and cash flows of the
debtors. Different methods are used
for making provisions for bad debts,
including ageing analysis and
individual assessment of
recoverability.
In addition to the specific
provisions under Indian GAAP,
under Ind AS, at each reporting
date, an entity shall assess
whether the credit risk on trade
receivables has increased
significantly since initial
recognition. When making the
assessment, an entity shall use the
Expected Credit Loss model to
provide for a loss allowance
over and above any provision for
doubtful debts in the profit and
loss statement. An entity shall
measure expected credit losses to
reflect the following:
An unbiased and
probability weighted
amount that is determined
by evaluating a range of
possible outcomes;
The time value of money;
and
Reasonable and support
able information that is
available without undue
cost or effort at the
reporting date about past
events, current conditions
and forecasts of future
economic conditions.
Ind AS
110/111
Subsidiary v.
Joint
Arrangements
Under Indian GAAP, a Company is
treated as a subsidiary Company if
the parent is holding more than 50%
of the equity/voting rights during
the year. Accordingly, the financial
statements of the parent and its
subsidiaries are consolidated on a
line by line basis by adding together
like items of assets, liabilities,
income and expenses. The
financial statement of Joint Venture
is consolidated on a proportionate
basis by adding together like items
of assets, liabilities, income and
expenses.
An investor controls an investee
when it is exposed, or has rights,
to variable returns from its
involvement with the investee and
has the ability to affect those
returns through its power over
the investee. Accordingly, the
financial statements of the parent
and its subsidiaries are
consolidated on line by line basis
by adding together like items of
assets, liabilities, income and
expenses. Joint arrangement is an
arrangement in which two or more
parties have joint control. Joint
control is contractually agreed
92
Ind AS
Standard
Particulars Treatment as per Indian GAAP Treatment as per Ind AS
sharing of control of an
arrangement which exists only
when decisions about the relevant
activities require unanimous
consent of the parties sharing
control. Based on legal form of
separate vehicle, terms of
contractual agreement and other
facts, joint arrangement shall be
classified either into joint venture
or joint operation. In case of joint
venture, equity method in
accordance with Ind AS 28 is
applied at the time of
consolidation.
93
INDUSTRY
The information in this section is derived from various publicly available sources, government publications and
other industry sources, including the August 2017 edition published by the India Brand Equity Foundation on
Roads, Railways, Power and Ports sector in India. Although we believe industry, market and government data
used in this section is reliable and that website data is as current as practicable, this information has not been
independently verified by us, the Book Running Lead Manager, or other advisors, and no representation is made
as to the accuracy of this information. Industry sources and publications generally state that the information
contained therein has been obtained from sources generally believed to be reliable, but their accuracy,
completeness and underlying assumptions are not guaranteed and their reliability cannot be assured, and
accordingly, investment decisions should not be based on such information. Certain data has been reclassified
for the purpose of presentation and much of the available information is based on best estimates, and should
therefore be regarded as indicative only and treated with appropriate caution. Certain financial and other
numerical amounts specified in this section have been subject to rounding adjustments; figures shown as totals
may not be the arithmetic aggregation of the figures which precede them. Statements in this section that are not
statements of historical fact constitute “forward-looking statements”. Such forward-looking statements are
subject to various risks, assumptions and uncertainties and certain factors could cause actual results or outcomes
to differ materially.
India is the world’s largest democracy by population and the Third largest economy in the world in terms of gross
domestic product (“GDP”) (purchasing power parity) after the United States and China (Source: CIA World
Factbook). It is one of the most attractive destinations for business and investment opportunities due to huge
manpower base, diversified natural resources and strong macro-economic fundamentals. The Indian economy
grew at an average of 7.1% in the Financial Year 2016-2017, slower than 8% as recorded in the previous year
2015-2016, due to the Government’s note ban decision.
INFRASTRUCTURE SECTOR IN INDIA
In developing countries, an essential requirement for economic growth and sustainable development is the
provision of efficient, reliable and affordable infrastructure services, such as water and sanitation, power, transport
and telecommunications. The availability of efficient infrastructure services is an important determinant of the
pace of market development and output growth, and, in addition, access to affordable infrastructure services for
consumption purposes serves to improve household welfare. Primarily, the sector includes the following:
Sr. No. Category Infrastructure Sub Sectors
1. Transport Roads and bridges
Ports
Shipyards
Inland Waterways
Airport
Railway Track, tunnels, viaducts, bridges, terminal infrastructure
including stations and adjoining commercial infrastructure
2. Energy Electricity Generation
Electricity Transmission
Electricity Distribution
Oil Pipelines
Oil/Gas/Liquefied Natural Gas (LNG) storage facility
Gas pipelines
3. Water and Sanitation Solid Waste Management
Water supply pipelines
Water treatment plants
Sewage collection, treatment and disposal system
Irrigation (dams, channels, embankments, etc.)
Storm Water Drainage System
Slurry Pipelines
4. Communication Telecommunication (fixed network)
Telecommunication towers
Telecommunication & Telecom Services
94
Sr. No. Category Infrastructure Sub Sectors
5. Social and Commercial
Infrastructure Education Institutions (capital stock)
Sports Infrastructure
Hospitals (capital stock)
Tourism infrastructure viz. (i) three-star or higher category classified
hotel located outside cities with population of more than 1 million,
(ii) ropeways and cable cars
Common infrastructure for Industrial Parks and other parks with
industrial activity such as food parks, textile parks, Special
Economic Zones, tourism facilities and agriculture markets
Post-harvest storage infrastructure for agriculture and horticultural
produce including cold storage
Terminal markets
Soil-testing laboratories
Cold Chain
Affordable Housing
(Source: Department of Economic Affairs, (Infrastructure Policy and Programme Section)
http://dea.gov.in/sites/default/files/Gazette Notification dated 17th October, 2017.pdf)
In this chapter, we shall discuss the following sub sectors of infrastructure sector in India:
Urban Infrastructure
Marine
Irrigation
Airports and
Roads and Railways
PROJECTED INVESTMENT IN INFRASTRUCTURE
Infrastructure sector is a key driver for the Indian economy. The sector is highly responsible for propelling India’s
overall development and enjoys intense focus from Government for initiating policies that would ensure time-
bound creation of world class infrastructure in the country. The Minister of Road Transport and Highways, and
Shipping, has announced the government’s target of Rs 25 trillion (US$ 376.53 billion) investment in
infrastructure over a period of three years, which will include Rs 8 trillion (US$ 120.49 billion) for developing 27
industrial clusters and an additional Rs 5 trillion (US$ 75.30 billion) for road, railway and port connectivity
projects.
Infrastructure sector includes power, bridges, dams, roads and urban infrastructure development. In 2016, India
jumped 19 places in World Bank's Logistics Performance Index (LPI) 2016, to rank 35th amongst 160 countries.
(Source: https://www.ibef.org/pages/37663)
URBAN INFRASTRUCTURE
Indian cities are growing rapidly. There is a need to direct growth in a planned manner with adequate attention to
the transport system at early stages in their development. Cities are witnessing fast growth in the number of
personal motor vehicles, with severe congestion and pollution being the most visible manifestation of the growth
in the number of motor vehicles. Efforts at remedying the situation will need to focus on improving the public
transport system. In several cities this would require implementation of Mass Transit systems such as metro rail,
bus rapid transit, light rail, etc.
Urban Rail, popularly referred to as Metro Rail, has seen substantial growth in India in the recent years. More
cities are experiencing the need for metro rail to meet their day-to-day mobility requirements. Most of the metro
rail projects have been financed by the central government in partnership with the state governments, while some
have been funded by the state governments either on their own or with private partnership. Metro rail projects
provide high capacity public transit and are capital intensive. However, considering the rapid urbanization and the
imminent need for enhancing mobility in cities through metro rail, it is imperative to explore alternative and
innovative sources of funds to supplement the budgetary resources. At the same time, it is also important to ensure
that the proposals are prepared and appraised in a comprehensive manner to enhance
urban mobility as well as the speed and quality of implementation of metro projects. It is in this context that the
95
need for a policy on metro rail has been felt necessary to ensure that such systems are decided upon and
implemented in the most sustainable manner from the social, economic and environmental perspectives.
The following are the prevalent broad models of financing metro rail in India:
a. The existing 50:50 Joint Venture model that is predominantly the major model available for the financing
and organization structure was started with Delhi Metro Rail Corporation and later followed in other
metros like Mumbai Line-3, Chennai, Bangalore, Nagpur, Lucknow, Kochi and Ahmedabad.
b. The second model is that of full funding by the central government. Examples of this model are the first
metro in the city of Calcutta (now Kolkata) by Indian Railways, followed by East-West corridor in
Kolkata being implemented on a 74:26 equity sharing between Ministry of Railways and Ministry of
Housing and Urban Affairs respectively.
c. The third model is that of complete funding by state government; examples are Metro rail in Jaipur and
Monorail in Mumbai.
d. The other model is the Public Private Partnership (PPP). Mumbai Metro Line- 1 and Hyderabad metro
rail have been taken up with Viability Gap Funding (VGF) from Government of India. The Rapid Metro
in Gurugram is an initiative of Government of Haryana where full funding is by the private
concessionaire.
(Source: http://moud.gov.in/upload/whatsnew/59a3f7f130eecMetro_Rail_Policy_2017.pdf)
Options of Mass Rapid Transit Systems (MRTS)
The mass transit systems in cities/ urban agglomeration can be broadly classified into the following 5 categories:
a. Busways and Bus Rapid Transit System;
b. Light Rail Transit;
c. Tramways:
d. Metro Rail;
e. Regional Rail
(Source: http://moud.gov.in/upload/whatsnew/59a3f7f130eecMetro_Rail_Policy_2017.pdf)
Choice of Metro Rail as a Mode of Mass Transit:
The choice of a particular MRTS will depend on a variety of factors like demand, capacity, cost and ease of
implementation. A BRT or LRT systems at grade may require linear pathway to be carved out of existing land if
additional space cannot be made available on the sideways and will reduce the space for other traffic depending
on the width of existing roads. LRTs and Tramways without horizontal separation will have reduced speed and
hence reduced capacity. The capacity of MRTS is generally denoted by passengers per hour per direction
(PPHPD). A BRTS typically has a capacity of 10,000-15,000 PPHPD on a single lane but can be enhanced with
additional lanes. Comparatively metro rail systems are able to carry much higher passenger volumes of 60,000
PPHPD and can go up to 80,000 PPHPD. Such rail based systems also generally provide rapid service, a higher
quality ride and service regularity due to grade separation.
(Source: http://moud.gov.in/upload/whatsnew/59a3f7f130eecMetro_Rail_Policy_2017.pdf)
PORTS / MARINE
Cargo Capacity is expected to increase to increase to 2,493.1 MMT in FY17. The Maritime Agenda 2010-20 has
a 2020 target of 3,200 MT of port capacity. By FY17, cargo capacity at major ports grew to 1,065 MMT in FY17,
from 965.36 MMT in FY16 implying a year-on-year growth of 10.32%.
India has 12 major ports and over 200 non-major ports with cargo traffic on the rise at both kinds of ports. In
H1FY18, major ports in India have handled 326.4 MMT of cargo traffic. In FY17, the 12 major ports in India
handled 647.43 (Million Tonnes) of cargo as compared to 606.37 (Million Tonnes) in FY16, showing a year-on-
year growth of 6.77 per cent.
96
(FY18*: Till September 2017)
The following graph illustrates cargo traffic handled at non-major ports in India (MMT):
(Source: http://ipa.nic.in/WriteReadData/Links/State-wise%20traffic%20handled%20at%20portsea7965ce-
8715-4924-8b9a-f3fd6e9d7a1a.pdf)
National Maritime Agenda
The National Maritime Agenda 2010–20 is aimed at the all-round development of the Indian maritime sector.
Following are some of the highlights of the agenda:
Focus on increasing capacity: To create a port capacity of around 3,200 MT to handle the expected traffic
of about 2,500 MT by 2020.
Proposed investments in major ports by 2020 are expected to total US$ 18.6 billion, while those in non-
major ports would be US$ 28.5 billion
World-class infrastructure: To implement full mechanization of cargo handling and movement at ports,
thereby bringing Indian ports on par with the best international ports in terms of performance and
capacity
Strategically building ports: To develop two major ports (one each on East and West coast) to promote
trade as well as two hub ports (one each on the West coast and the East coast) – Mumbai (JNPT), Kochi,
Chennai, and Visakhapatnam
Notable trends in the port sector in India:
Increasing private participation: Strong growth potential, favorable investment climate and sops provided by
state governments have encouraged domestic and foreign private players to enter the Indian ports sector. In
addition to the development of ports and terminals, the private sector has extensively participated in port logistics
services.
Setting up of port based SEZs: SEZs are being developed in close proximity to several ports, thereby providing
strategic advantage to industries within these zones. Plants being set up include:
Coal-based power plants to take advantage of imported coal
Steel plants and edible oil refineries
Specialist terminal based ports: Focus on terminals that deal with a particular type of cargo. This is useful for
handling specific cargo such as LNG that requires specific equipment and hence high capital costs. Forming
specialist terminals for such cargo results in optimal use of resources and increased efficiencies. Examples of
606.4 647.4
326.4
0
500
1000
FY16 FY17 FY18*
Cargo Traffic at Major Ports (MMT)
465.9 485.2
0
200
400
600
FY16 FY17
Cargo Traffic at Non-Major Ports (MMT)
97
specialist terminals: ICTT in Cochin, LNG terminal in Dahej Port.
Landlord port model: To promote private investments, the government has reformed the organizational model
of seaports
From: A ‘service port’ model where the port authority offers all the services.
To: A ‘landlord port’ model where the port authority acts as a regulator and landlord while port
operations are carried out by private companies
Ports to operate on Green energy: Government of India is targeting to make the country the first in the world
to operate all 12 major domestic government ports on renewable energy. The government plans to install almost
200 MW wind and solar power generation capacity by 2019 at the ports. The energy capacity could be ramped up
to 500 MW in future years.
(Source: https://www.ibef.org/download/Ports-October-2017.pdf)
IRRIGATION
Sustainable development and efficient management of water is an increasingly complex challenge in India.
Increasing population, growing urbanization, and rapid industrialization combined with the need for raising
agricultural production generates competing claims for water and good irrigation system. Additionally, as a result
of uncertain rainfall and a growing sense of an impending water crisis in the country, irrigation has become
essential in India.
The irrigation projects are classified into three categories viz. major, medium and minor. Projects which have a
cultivable command area (CCA) of more than 10,000 ha. are termed as major projects, those which have a CCA
of less than 10,000 ha. but more than 2,000 ha. are termed as medium projects and those which have a CCA of
2,000 ha or less are known as minor projects. In Annual Plan 2016-2017, there is a marginal decline in the plan
outlay in irrigation and flood control sector over the allocation from Rs. 831,434.06 lacs in 2015-2016 to Rs.
730,784.00 lacs for 2016-2017. An amount of Rs. 638,866.52 lacs is provided in the budget 2016-17 for the
projects under Major Irrigation and an amount of Rs..67,762.20 lacs is provided in budget 2016-17 for the Minor
Irrigation projects.
(Sources: http://www.apsdps.ap.gov.in/dp/downloads/Annual_Plan_2016_17.pdf)
AVIATION
The aviation industry’s potential in India is massive. India is set to become 3rd largest aviation market by 2020. In
FY17, airports in India witnessed domestic passenger traffic of about 205 million people. By 2020, passenger
traffic at Indian airports is expected to increase to 421 million from 264.99 million in 2016-17. Travel and tourism
are expected to contribute US$ 423.7 billion to GDP by 2026.
Investments totalling US$ 11.4 billion in the airport sector are expected to be made during the 12th Five Year
Plan (2012- 17); of these, private investments are expected to total US$ 9.3 billion. The government has been
encouraging private sector participation. Foreign investment up to 49 per cent is allowed under automatic route
in scheduled air transport service, regional air transport service and domestic scheduled passenger airline.
Notable Trends
Rising Private Participation: Currently, five international airports have been completed successfully under PPP
mode. Investment made by private sector during the 12th Five Year Plan (2012–17) is expected to increase by
69.1 per cent to US$ 9.3 billion over that during the 11th Five Year Plan. Four existing airports and two greenfield
projects will be offered on PPP basis which is expected to attract investments from private players.
Greater use of non-scheduled airlines: Rising business activity has led to higher demand for non-scheduled
airlines. As of July 2017, there are 112 operators (NSOP).
Focus on non-aeronautical revenue: Indian airports are emulating the SEZ-aerotropolis model to enhance
revenues; focus on revenues from retail, advertising, vehicle parking, etc.
Policy Initiative
Greater Focus on Infrastructure: GOI envisions airport infrastructure investment of US$ 11.4 billion under the
98
12th Five Year Plan (2012-17). The Indian government is planning to invest US$ 1.83 billion for development of
airport infrastructure along with aviation navigation services by 2026.
Liberalisation, Open sky policy: With the opening of the airport sector to private participation, six airports across
major cities are being developed under the PPP model. Currently 60 per cent of airport traffic is handled under
the PPP model, while the remaining 40 per cent is managed by the AAI. In May 2017, India and Spain signed an
MoU for cooperation in civil aviation industry. The MoU would spur greater trade, investment, tourism and
cultural exchanges between both the countries.
Taxes and Duties: 100 per cent tax exemption for airport projects for a period of 10 years is given. Indian aircraft
Manufacture, Repair and Overhaul (MRO) service providers are exempted completely from customs and
countervailing duties.
Budgetary support: In the Union Budget for FY17, Government of India, for the purpose of equity infusion has
earmarked US$ 255.86 million for Air India Limited. Also, a budget of about US$ 14.98 million has been allocated
to Airports Authority of India, of which US$ 4.29 million has been attributed towards Pakyong, Sikkim project.
The government has planned to allocate a sum of US$ 11.80 million to Directorate General of Civil Aviation to
implement various schemes.
(Sources: https://www.ibef.org/download/Aviation-October-20171.pdf)
ROAD TRASNPORT
Road transport is a critical infrastructure for the economic development of a country. It influences the pace,
structure and pattern of development. In India, road infrastructure is used to transport over 64.5% of total goods
and 90% of total passenger traffic. National highways comprise only 1.9% of network but carry 40% of traffic.
India has the second largest road networks in the world consisting of 5.21 million kilometers (km) consisting of
national highways, expressways, state highways, major district roads, other district roads and village roads with
the following distribution.
National Highways/Expressways 1,03,933 kms
State Highways 161,487 kms
Other Roads 52,07,044 kms
The following table states the distribution of national highways in terms of width:
Single lane/Intermediate lane 19,330 kms
Double lane 40,658 kms
Four lane/six lane/eight lane 19,128 kms
The Ministry of Road Transport and Highways has been entrusted with the responsibility for construction and
maintenance of national highways. All roads other than national highways in the states fall within the jurisdiction
of respective state governments.
(Source: https://www.ibef.org/download/Roads-October-2017.pdf)
Policy initiatives for the road sector
Support from the Union Budget: For the financial year 2016-17, NHAI has made budgetary provisions for a cess
of Rs. 24,107.35 crore and Rs. 7,475 crores as plough back of funds deposited by NHAI in Consolidated Fund of
India (CFI) against toll Collection, Revenue Share, Negative Grant & Premium. An additional budgetary support
of Rs. 1,140 crores for SARDP-NE & J&K projects, Rs. 1,326 crores for Eastern Peripheral Expressway and Rs.
1,128 crore for Grant for Maintenance and Repair for National Highways.
Rural Development: The Ministry has set up Left Wing Extremism (LWE) Division under Chief Engineer for
sanctioning and implementing the above programme through respective State Public Works Departments (PWDs).
As on 30th November, 2016, the detailed estimates for 5,422 km length have been sanctioned at an estimated cost
of Rs. 8,585 crore, out of which, works on 5,406 km length costing Rs. 8,497 crore have been awarded.
Development in 4,153 km length has been completed up to November, 2016 and cumulative expenditure incurred
so far is Rs. 5,964 crores.
Introduction of Hybrid Annuity Model (HAM): The HAM Model has been approved by the CCEA. As per the
99
model, 40% of the Project Cost is to be provided by the Government as ‘Construction Support’ to the private
developer during the construction period and the balance 60% will be paid as annuity payments over the operations
period along with interest on outstanding amount. The payable interest rate is linked to market rates (Bank
Rate+3.00%). There is separate provision for O&M payments by the Government to the concessionaire. The
private party does not have to bear the traffic and inflation risks.
Central Road Fund (CRF): During the year 2016-17 (up to December, 2016), 409 proposals involving a cost of
Rs. 5,693 crore have been approved for improvement of state roads under the CRF excluding the works approved
under the schemes.
International Support: The third meeting of the India-Japan Joint Working Group (JWG) in the Roads and Road
Transportation sector was held in New Delhi on 24.10.2016 under the Framework of Cooperation (FoC) signed
in September 2014 between India and Japan. In the meeting, the two delegations deliberated on collaboration in
the areas of construction of highways in mountainous regions, technologies for building bridges, road safety
measures and developing highway management systems.
(Source: Annual Report of Ministry of Road Transport and Highways 2016-2017
(http://morth.nic.in/showfile.asp?lid=2631))
RAIL TRANSPORT
India has the world’s fourth largest rail network (Source: https://www.ibef.org/download/Railways_-_October-
2017.pdf). The railways play a significant role in India’s transport sector. Indian Railways has 12,617 passenger
trains carrying over 23 million passengers daily. On the commercial front, 1,107.1 million tonnes of freight was
transported via trains in FY17. Up to August 2017, freight traffic stood at 466.82 million tonnes.
Strong Revenue Growth
The Indian Railways revenue has been the strongest over the years. During the Financial year 2007-2017, the
revenue has increased at a CAGR of 9.8 per cent to US$ 25.62 billion in FY17. The revenues from the sector are
estimated to reach to US$ 44.5 billion by the end of FY20. Overall, revenues are expected to expand at a CAGR
of 12.2 per cent during FY07-20.
The Indian Railways has attracted increasing foreign investment through strategic alliances with various countries
over the last few years.
Notable Trends in the railways sector
Demand for urban transport: There is a rapid increase in demand for urban mass transportation systems in the
country. Several metro rail projects are in progress to improve connectivity within cities; the Delhi Metro has
emerged as an internationally acclaimed venture. The central government inaugurated the Pune Metro Rail project
on December 24, 2016. The metro line would have 30 stations and the 1st phase would cover a distance of 31.25
km. The project is estimated to be completed at a cost of US$ 1.67 billion.
International Investment: Indian Railways has attracted increasing foreign investments through strategic
100
alliances with various countries over the last few years. Indian railways received foreign investments worth Rs
42,000 crore (US$ 6.59 billion) in May 2016 over two contracts with one European and one American company.
6 major global players have shown keen interest in developing ultra-high-speed trains in India.
High Speed Rails: In coordination with the Japanese government, a high speed passenger train corridor, between
Ahmedabad to Mumbai is being undertaken. Construction of the project is likely to commence in 2017. As part
of Railway Budget 2016-17, the government launched a new train “Mahamana Express” connecting Varanasi and
Delhi and is considering increasing the average speed of freight trains to 50 km/h and mail or express trains to 80
km/h by the end of 2020. In April 2017, the government announced intentions to develop 180 Kms Delhi-Rewari-
Alwar Regional Rapid Transport System with an investment of around US$5.5 billion. The project would enable
passengers to travel from Delhi to Alwar in just 104 mins.
Modernization/Technology: In October 2017, it was decided that modernization of 20 train stations will be
undertaken to create superior infrastructure and passenger facilities. Indian Railways is planning to launch an
integrated mobile application for availing all travel-related services such as hiring taxis, pre-ordering a meal,
requesting for porter services, lodging at a retiring room, etc. Indian Railways is considering introduction of
lightweight aluminium coaches in the rail network to reduce the travelling time between metropolis by 2018.
Manufacturing of Modern Linke Hofmann Busch coaches has started in 2017 in India. These coaches are equipped
with modern technology and can prevent capsizing during derailment.
Expanding Scope of Public Private Partnership (“PPP”): In December 2012, the Cabinet approved the new
policy of ‘participative models for rail-connectivity and capacity augmented projects’. The policy addressed the
issues of ownership of the railway line and repayment of investment.
Since the launch of the policy, railway authorities have received various proposals from private investors and have
already given approval (can now acquire land and begin construction) for four port connectivity projects, to ease
congestion. Indian Railways started the PPP mode of funding and has already awarded projects which amounted
to around US$ 1.73 billion in the first seven months of FY16. For FY17, PPP investment is estimated to reach
US$ 2.7 billion as per the revised estimates. In January 2017, Indian Railways has signed a JV agreement with
the Government of Jharkhand to develop the state’s railway infrastructure.
(Sources: https://www.ibef.org/download/Railways_-_October-2017.pdf)
THE INDIAN POWER SCENARIO
India is the third largest producer and fourth largest consumer of electricity in the world, with the installed power
capacity reaching 330.86 GW by November 2017. The country also has the fifth largest installed capacity in the
world. Wind energy is estimated to contribute 60 GW, and solar power is estimated to contribute 100 GW by
2022. The target for renewable energy has been increased to 175 GW by 2022.
The following table states the all India installed capacity (in MW) of power stations as on November 30, 2017:
Ownership Thermal Nuclear Hydro RES
(MNRE)
Total
Coal Gas Diesel Total
State 63,780.50 7,078.95 363.93 7,1223.38 0.00 29,858.00 1,976.90 1,03,058.27
Private 74,496.00 10,580.60 473.70 85,550.30 0.00 3,394.00 58,180.76 1,47,125.06
Central 54,695.00 7,490.83 0.00 62,185.83 6,780.00 11,711.42 0.00 80,677.25
Total 1,92,971.50 25,150.38 837.63 2,18,959.51 6,780.00 44,963.42 60,157.66 3,30,860.58
(Source: http://www.cea.nic.in/reports/monthly/installedcapacity/2017/installed_capacity-11.pdf)
Power Generation has grown rapidly over the years in India. Electricity Production in India stood at 1,160.1 BU
in FY17. The Country witnessed growth of around 4.72 per cent over the previous fiscal year. Over FY10–FY17,
electricity production in India grew at a CAGR of 7.03 per cent. The 12th Five Year Plan projects that, total
domestic energy production would reach 844 million tonnes of oil equivalent (MTOE) by 2021–22.
A total of 13,872 villages out of 18,452 un-electrified villages in India have been electrified up to June 30, 2017
as part of the target to electrify all villages by May 1, 2018.
Power is one of the key sectors attracting FDI inflows into India. From April 2000 to June 2017, India recorded
FDI of US$ 5.85 billion in non-conventional energy sector. New and renewable energy sector witnessed maximum
101
power generation capacity addition, since 2000. Power sector accounted for 3.44 per cent of total FDI inflows till
March 2017. Cumulative FDI inflows into the sector in April 2000–June 2017 were US$ 11.77 billion.
An increase in industrial activity coupled with increasing penetration, per-capita consumption and a growing
middle class and consumer base has led to a growth in demand for power. This growth has been supported by
various government policies. Some of the policy initiatives include the Electricity Act, 2003 which is a liberal
framework for generation, fuel supply agreements of power companies with Coal India Limited, development of
ultra-mega power projects and the National Tariff Policy, 2006, R-APDRP which was launched by Ministry of
Power with the purpose of reducing AT&T losses up to 15 per cent by upgradation of transmission and distribution
network, National Tariff Policy (2016). The National Tariff Policy for Electricity was amended by the Union
Government on 20 January, 2016. Special focus on renewable energy has been laid. In order to promote use of
renewable energy, solar Renewable Purchase Obligation (RPO) is proposed to increase to 8 per cent by 2022.
(Sources: https://www.ibef.org/download/Power-October-20171.pdf)
Hydroelectric Power
Hydro power is a renewable, economic and non-polluting source of energy. Hydro power stations have inherent
ability of quick starting, stopping and load variations offering operational flexibility and help in improving
reliability of power system. Hydro stations are the best choice for meeting the peak demand. The generation cost
is not only inflation free but reduces with time. Hydroelectric projects have long useful life extending over 50
years and help in conserving scarce fossil fuels. They also help in opening of avenues for development of remote
and backward areas. Development of hydro power resources is important for energy security of the country. It
takes about 10 years for developing a large size hydro project from planning to commissioning. The construction
period of a large hydro project after placement of Letter of Award for the main packages could span 5 years or
more. It is therefore necessary to prepare a long term plan of hydropower development covering at least 10 years
period. India has an estimated hydro potential of about 176,990 MW, out of which only 21.5% that is 38,160 MW
is commissioned.
(Source: http://www.eai.in/ref/ae/hyd/hyd.html)
Industrial civil works
Industrial civil works largely consist of plant, building, chimneys, silos, conveyers, furnace and administrator
buildings which form an integral part of the manufacturing capacities.
The last few years have been one of the toughest for Indian manufacturing sector. The slowdown was visible
through dramatic fall in the cumulative growthrate of eight core industries and of Index ofIndustrial Production
(IIP) over the last three years. The IIP registered a growth of 3.8 % in September, 2017 over the Index of
September, 2016. The growth for Index of Manufacturing, Mining and Electricity was 3.4 %, 7.9 % and 3.4 %
respectively during September, 2017.
(Sources: http://www.eaindustry.nic.in/iip/IIP_Highlights.pdf)
102
OUR BUSINESS
Some of the information contained in the following discussion, including information with respect to our plans
and strategies, contain forward-looking statements that involve risks and uncertainties. You should read the
chapter titled “Forward-Looking Statements” beginning on page 13 for a discussion of the risks and
uncertainties related to those statements and also the chapter titled “Risk Factors” beginning on page 29 for a
discussion of certain factors that may affect our business, financial condition or results of operations. Our actual
results may differ materially from those expressed in or implied by these forward-looking statements. Our fiscal
year ends on December 31 of each year, so all references to a particular Fiscal are to the twelve months period
ended December 31 of that year.
Overview
We are one of the leading civil engineering, contracting and construction organizations providing integrated
design, engineering, procurement and construction services, for over eight decades, for infrastructure development
projects in India. Our current business covers major infrastructure areas including maritime structures, highways,
bridges and flyovers, urban infrastructure projects/mass rapid transit systems, specialist engineering works,
hydroelectric power projects, tunnels and dams, irrigation projects, industrial civil works, airports and civil works
of water and waste water projects.
Our focus areas, in relation to civil engineering, for providing design, engineering, procurement and construction
services under each segment are as follows:
Urban infrastructure/
MRTS Construction of civil and building structures for mass rapid transportation
systems (“MRTS”)
Construction of tunnels, underground railway stations and installation of
track;
Construction of integrated passenger terminals and allied services at
airports.
Maritime Structures Construction of jetties, dolphins and service platforms;
Construction of quay, berths on concrete and steel piles as well as solid
gravity type wharf structures;
Construction of ship lift, dry dock, wet basin (in complete marine
condition) and inclined berth;
Break water and piled approach trestles;
Steel pipes (vertical and raker), bored cast in-situ pile;
Undersea ground improvement;
Dredging and land reclamation;
Coastal erosion protection and rock bund.
Hydroelectric power
projects, tunnels, dams and
irrigation projects
Construction of concrete and masonry dams, micro tunnelling, earth fill
embankments, irrigation canal structures and hydro tunnels;
Construction of hydroelectric power stations.
Industrial structures and
buildings Construction of plant buildings for power, steel, refineries and fertilizer
sectors;
Civil works for water treatment and water intake systems;
Buildings for educational institutions, hospitals, shopping malls and IT
parks.
Specialist Engineering Foundation and specialist works including geotechnical investigations,
piling, diaphragm walling, sand wicks / band drains, vibro-floatation stone
columns / vibro compaction, drilling and grouting, rock / soil anchors,
colcrete, gunite / shotcrete, grouted mattress, repairs, tube heading and
box pushing.
Highways, bridges and
flyovers Construction of roads, bridges and flyovers.
Our Competitive Strengths
We believe the following are our principal competitive strengths which we expect will continue to contribute to
the realization of our business strategy going forward including growth in our current areas of operation and areas
103
we plan to expand into.
Strong order book with diversified presence across segments, clients and geographies
Our Company’s total outstanding Order Book as on September 30, 2017 is ₹ 8,13,082 lakhs well diversified across
segments like Maritime Structures, Urban Infrastructure Projects/Mass Rapid Transit Systems, Hydroelectric
Power Projects, Tunnels and Dams, Irrigation Projects, Highways, Bridges and Flyovers, Industrial Structures and
Buildings and Specialist Engineering. These projects are geographically dispersed across various states in the
country. We are currently executing 67 projects across 14 states in India. Further, our clients comprise of
government organisations, port authorities, public sector undertakings, large private sector companies, state
boards amongst others. Through these segments, clients and geographic diversity, we are able to mitigate the
concentration risks associated with operations in specific segments, limited clientele and specific states in India.
Our operations are supported by our corporate headquarters in Mumbai and our area offices in Delhi, Kolkata and
Chennai.
Extensive experience and proven track record in the construction industry
We have executed several significant projects across the country and have developed competency in areas
including mass rapid transit systems, maritime construction, industrial civil works, airports, foundations including
piling of all types in different soil and geographic conditions, thereby positioning ourselves amongst the market
leaders in some of these areas.
We believe that our expertise and track record in implementation of projects provides us with significant
competitive advantages. Further this enables us to better position to deal with construction or implementation risk.
We further believe that our execution capabilities have witnessed a steady growth and we are able to execute a
diverse range of projects effectively. We believe that our experience has made us familiar with the risks associated
with undertaking projects in India, which has enabled us to bid for, negotiate agreement and execute our projects
more effectively and efficiently. We believe we have good working relationships with our suppliers, our
employees and sub-contractors. Such relationships facilitate the efficient execution of projects.
Further we believe we can meet the pre- qualification requirements for a large number of projects across various
segments, in terms of having the requisite experience, technical know-how, and financial resources, either in our
own accord or as a partner in a joint venture. Our Company believes that its credentials enable us to enter into
joint ventures and partnerships with reputable partners which, in turn, enable us to bid for large and complex
projects.
Established reputation for execution of large and complex infrastructure projects
Over the last eight decades of our presence in India, our Company has successfully completed large and complex
infrastructure projects like construction of integrated passenger terminal building at the Netaji Subhash Chandra
Bose Airport at Kolkata, various roads under the National Highway Development Program, tunnelling for the
Delhi Metro, piling wok for the Asia’s first stock exchange amongst others.
With the Indian economy expanding, projects in the infrastructure sector are also increasing in size and
complexity. In addition, increased funding in infrastructure development, from the private sector, is resulting in
projects being tendered to demanding schedules, design and execution methodologies. It also requires the
contracting organisation to have robust organisational methods in tendering and execution to meet demanding
schedules, to budget and to deliver international quality standards.
We believe we have skilled manpower and management, good organisational processes, professional approach to
risk and its containment all of which translates into our ability to manage multiple, large and complex projects.
Our Company is therefore well placed in this contracting environment and we believe this gives us the competitive
edge when compared to other construction companies.
Strong parentage that provides access to technology and experience
Our Promoter is one of the largest construction companies in Thailand and has contributed to the development of
Thailand’s infrastructure for over five decades. It has achieved significant success in this sector including
construction of integrated metro rail projects, airports, tunnels, highways, elevated expressways, bridges, railways
and buildings, e.g. Bangkok Mass Transit System, Suvarnabhumi airport, elevated corridor projects in Bangkok.
104
Our Promoter continually extends support in the execution of our business plan by providing access to its
technologies and know-how as well as deployment of skilled personnel wherever necessary. We, through our
Promoter, have access to major international design and engineering organisations and leading construction
groups to support pre-qualification and execution of major projects in the infrastructure sector. As on September
30, 2017, we have undertaken a total of 11 projects like BMRCL amongst others through joint ventures with our
Promoter where they have also helped us meet the pre – qualification criteria. We believe that this extensive
support from our Promoter, provides us with a competitive advantage when participating in large projects.
Utilization of different and varied technologies and availability of various specialized equipment
We own a fleet of equipment and tools including modern equipment for flyover construction, concrete production
and movement, maritime gantries, modern hydraulic piling plant and associated equipment. Additions to our fleet
of equipment and tools are carried out, based on project requirements and schedules to cater to the needs of various
project sites located pan India. We believe this provides us with strategic and competitive advantage in our
business. This access to modern technologies, processes and skills helps our Company, provide our clients with
comprehensive, value engineered solutions to meet varied civil engineering challenges, especially in areas of
ground engineering, piling, maritime construction and irrigation projects.
Professional and experienced senior management team and a highly skilled employee base
We believe that we have an experienced professional senior management team, supported by a capable and
talented pool of employees to maintain strategic direction, manage current operations and risk profile and meet
future business challenges, including the planned expansion and the addition of new businesses. It has been our
policy to induct and retain skilled and experienced human resources for all of our operations. As of September 30
2017, we have 1,953 permanent employees, including engineers, graduates and post graduates.
We have trained project management and corporate resources to support multiple large projects nationally and are
continuously working to enhance this large trained pool of human resources through training and development
and skill upgradation programs.
Quality control, health, safety and environment
We have developed integrated systems for management of quality, health, environment and safety and are keen
to maintain global standards on the same in our operations with a view to make us the preferred partner for project
developers.
Our commitment and compliance to these standards have enabled us to be one of the few construction companies
in India to be accredited by DNV, to certify our Company for the following standards:
ISO-9001:2008: Quality management systems standards;
OHSAS-18001:2007: Occupational health and safety management systems standards; and
ISO-14001:2004: Environmental management systems standards.
Our Business Strategies
Expand into infrastructure sector through participation in key projects on our own or in partnership with
companies with complimentary skill sets
As a natural extension to our construction operations, we are continuously evaluating opportunities for
participation on our own and/or with our Promoter and/or other developers in infrastructure activities where our
participation in sharing the development of the project would lead to significant new construction opportunities
on preferred terms. Our participation in select infrastructure projects would be based on a careful review of our
overall margins from these projects including the follow-on construction opportunity in comparison to the risks
therein.
We also intend to pursue projects in select sectors where we enjoy expertise and limited competition such as
Urban Infrastructure / MRTS and Maritime Structures. We also intend to undertake, on a selective basis, larger
and more complex projects.
Continue to enhance our core strengths such as execution capability with appropriate systems, processes and
on- site working
105
We believe that our ability to effectively manage projects in multiple geographic regions is crucial to ensure our
continued success as a recognized construction and project management company. We have in place an
experienced and well-qualified execution team, with skills in various fields, including civil, structural, electrical
and mechanical works. We intend to continuously strengthen our execution capabilities by adding to our existing
pool of engineers, attracting new graduates from leading engineering colleges in India, focus on team building
and facilitating continuous learning with in-house and external training opportunities. In addition, our support
groups in plant, inventory, procurement, marketing, finance, legal and safety are also continuously reviewed to
meet requirements of increasing project size, locations and complexity.
Expand areas of construction offering significant growth opportunities in the country
Our current areas of operation include mass rapid transit systems, maritime structures including construction of
jetties, dolphins and service platforms, dry dock, wet basin highways, bridges and flyovers including roads,
bridges and flyovers, specialist engineering works including stone columns, drilling and grouting piling,
diaphragm walling, hydroelectric power projects, tunnels and dams, industrial civil works and urban infrastructure
projects. Considering the opportunities being available in areas including airports, elevated roads, micro tunnelling
and waste water management, we have developed the necessary competencies and formed business development
teams focussed on converting these market opportunities. We believe this will help in diversifying our sources of
revenue and mitigate risks. In addition, we will be well positioned to benefit from increasing capital expenditures
in these sectors.
Further strengthen financial capabilities to take up major construction projects and infrastructure
development activities
In addition to requirements of past track record of similar projects, availability of bid capacity and other technical
criteria, project sponsors including government and private developers require adequate financial criteria to be
met by contractors bidding for their projects. These financial criteria includes net worth, availability of working
capital funds for a portion of the contract cost. We plan to focus on cash positive and margin accretive projects,
with faster claim realization and cost reduction through increasing efficiency.
The overall financial plan, of our Company, includes exploring possible avenues for participation in the
infrastructure development projects to position our Company to benefit from major infrastructural opportunities
that are emerging in the country in the medium to long term.
Consolidate position in infrastructure space
We believe that infrastructure will be a major driver for growth in the Indian construction industry in the
foreseeable future due to increased levels of government and private industry investment in infrastructure. Thus,
there will be numerous opportunities for infrastructure creation. In anticipation of the trend towards increased
infrastructure investment, we have developed skill sets across a diverse portfolio of infrastructure projects in
recent years, including construction of maritime structures, roads, bridges and flyovers, mass rapid transit systems,
hydroelectric power projects, water supply projects, water treatment projects, tunnels and dams. Our business plan
and growth is expected to come from increased infrastructure spending in growth sectors including industrial civil
works, airports, metro rails projects, elevated road, rail corridors, ports, major bridges and flyover. We have
leveraged and will continue to leverage on our wide ranging experience in the infrastructure segment to capitalize
on opportunities to win and execute diverse infrastructure projects. We intend to focus on on-time completion of
projects, endeavour towards an injury free environment and Continue to improve our quality and environment
standard. We intend to bid for and secure more complex and profitable infrastructure projects, as well as continue
to focus on those types of infrastructure projects that are within our core competence.
Improving our productivity and competitiveness
We intend to increase the efficiency and competitiveness of our operations by continuously investing in state of
the art construction machinery and equipment and related operating methods, in order to maximize efficiency of
labour, material and reduce our costs and the time taken to execute our projects. We also intend to continuously
improve our project management skills and control operating and overhead costs to maximize our operating
margins. To facilitate efficient and cost-effective decision-making, we intend to continue to strengthen our internal
systems. We believe that this will make us more efficient and also make us more competitive.
Development of human resources and skills enhancement
106
We believe that we have a professional work environment, participative leadership and management, which helps
us attract and retain key construction and engineering professionals who are well rated in the industry. We believe
that our ability to effectively manage projects in multiple geographic regions is crucial to our continued success
as a recognised infrastructure company at a national level. We have in place an experienced and well – qualified
execution team, with skills in various fields, required to handle a diverse project portfolio. We intend to
continuously add to our existing pool of engineers, attract fresh, young talent and facilitate continuous learning
with in-house and external training opportunities.
Pursuing select projects in international markets
Over the years, we have steadily and successfully increased our business portfolio catering to a range of
construction projects situated over diverse geographies in India. To diversify our business, we look forward to
further extend our business to other geographies such as Africa, Middle East and South East Asia, either by
ourselves or through joint ventures. For example, we had in the recent past submitted a bid for a maritime project
in Egypt. We intend to concentrate on projects and geographies where we can retain a competitive edge and seek
better margins.
Our Business
We are a company having capabilities in providing integrated design, engineering, and procurement and
construction services, for over eight decades, for infrastructure development projects in India. We are actively
expanding our engineering, procurement and construction operations into a wider variety of projects as well as in
terms of geography.
Order book
We define Order Book as:
“Order Book” means the Total Contract Value (as defined below) of all Existing Contracts of the Company (as
defined below) as of such date, minus any revenue already recognised by the Company of such Existing Contracts
up to and including such dates. “The Total Contract Value” and “Existing Contracts” of the Company are stated
below:
(a) “Total Contract Value” means the entire value of a project including price escalation, bonus claims
adjudication as per contractually agreed terms. Other claims or variations in the contract works are
included in contract value only when they have been accepted by the client.
(b) “Existing Contracts of the Company” includes the work order/letter of award/contracts entered into by
the Company and in case of Joint Ventures, the Company’s share of the Total Contract Value
The table below sets forth the Company's Order book as of September 30, 2017:
Segment
Order Book of the Company As a % of
total Order
Book
No. of
Projects
Total Contract Value
(₹ in lakh)
Urban infrastructure projects/mass rapid
transit systems
15 4,85,970 60
Maritime structures 15 2,08,932 26
Hydroelectric power projects, tunnels and
dams and irrigation projects 8 74,569 9
Industrial Structures and Buildings* 8 19,454 2
Specialist engineering works 17 12,933 2
Highways, bridges and works 4 11,224 1
Total 67 8,13,082 100
* Includes water and waste water
Apart from these, we are selected as L1 Bidder for one project as on September 30, 2017 worth Rs 209,900 lakh
and an addition of scope in one of the existing projects by Rs 32,290 lakh.
107
Order Book Break up – Client wise
Our Business Segments
Our segment wise revenue in the last 3 (three) Fiscal Years 2016, 2015 and 2014 is presented as under:
(₹in lakh)
Name of the Division Fiscal Year 2016 Fiscal Year 2015 Fiscal Year 2014
Urban Infrastructure / MRTS 25,440 38,641 34,488
Maritime structures 1,72,302 1,47,400 53,020
Hydroelectric power projects, tunnels and
dams and irrigation projects
20,638 16,776 9,549
Industrial structures and buildings 22,283 25,375 8,389
Specialist Engineering 26,404 32,028 32,832
Highways, bridges and flyovers 41,790 46,650 32,964
A detailed description of each of our services provided under each of our business segments is set forth below:
Urban Infrastructure / MRTS
In the Urban Infrastructure /Mass Rapid Transit Systems segment, our Company is primarily involved in the
construction of mass rapid transit systems. We have also ventured into construction of passenger terminals and
allied services at airports. Most of our completed and current projects are item-rate contracts which are undertaken
independently by us. We also execute some of our projects on a joint venture basis.
As of September 30, 2017, we have a total of 15 Urban Infrastructure / MRTS contracts in different stages of
construction underway, with an aggregate value of ₹ 4,85,970 lakh and contributing60% of the total Order Book
of our Company.
Below is a selection of some of our significant projects in the Urban Infrastructure / MRTS segment which are
currently being undertaken:
Name and Description of Project State Total Contract Value
(₹in lakh)
Construction of 7 (seven) stations for airport corridor of
Kolkata Metro Railway Line
West Bengal 38,505
Construction of 10 (ten) elevated metro stations for Nagpur
Metro Rail Project
Maharashtra 44,575
Design and construction of elevated viaduct of the Nagpur
Metro Rail Project
Maharashtra 37,217
Execution of Civil Engineering works for RCC box tunnel
for the Kolkata Metro Railways
Maharashtra 30,677
Construction of 8 (eight) elevated metro stations for the
Nagpur Metro Rail Project
Maharashtra 31,031
Design and construction of underground section for the
Kolkata Metro Railway
West Bengal 81,108*
Private ,
16%
Government, 25%
PSUs, 59%
As of September 30, 2017
108
Name and Description of Project State Total Contract Value
(₹in lakh)
Design and construction of underground section including 3
(three) underground stations for Mumbai metro rail project
Maharashtra 113,204*
Construction of elevated structures for Bangalore Metro
Railway
Karnataka 55,161
Construction of elevated structures for Bangalore Metro
Railway
Karnataka 54,704
Construction of elevated structures for Bangalore Metro
Railway
Karnataka 38,842
Construction of elevated structures for Bangalore Metro
Railway
Karnataka 40,909
*Denotes our Company’s share in respective joint venture projects
Maritime Structures
Under the Maritime Structures, our Company is primarily involved in the construction of jetties, dolphins and
service platforms, construction of quay, berths on concrete and steel piles as well as sold gravity type wharf
structures, construction of ship lift facility, dry dock, wet basin and inclined berth, building of jetties for handling
liquid and solid cargo, wharfs, berths and quays for handling of containers. In this area of operation, we provide
design, planning and execution of contracts using various equipments and technologies like steel piles, raker piles,
large diameter and deep concrete in-situ piles, deck and superstructure to international standards.
Most of our completed and current projects are item-rate contracts which are undertaken independently by us.
As of September 30, 2017, we had a total of 15 Maritime Structure contracts in different stages of construction
underway, with an aggregate value of ₹ 2,08,932 lakh and contributing 26% of the total Order Book of our
Company.
Below is a selection of some of our significant projects in the Maritime Structures segment which are currently
being undertaken:
Name and Description of Project State Total Value of
Contract
(₹in lakh)
Development of Marine Facilities at Karanja Port Maharashtra 61, 735
Civil works for oil berth at Jawahar Dweep Maharashtra 30,728
Dredging and reclamation works for development of container
terminal at Jawaharlal Nehru Port Trust
Maharashtra 257,494
Construction of multi-modal IWT terminal for Haldia West Bengal 51,736
Development of multi-purpose terminal by replacement of
exiting at Vishakhapatnam Port
Andhra Pradesh 16,766
Hydroelectric Power Projects, Tunnels and Dams and Irrigation Projects
In the Hydroelectric Power Projects, Tunnels and Dams and Irrigation Projects segment, our Company is primarily
involved in the construction of concrete, earth fill and rock fill dams and tunnels and construction of hydroelectric
power projects. Most of our completed and current projects are item-rate contracts which are undertaken
independently by us. We also execute some of our projects on a joint venture basis.
As of September 30, 2017, we have a total of 8 Hydroelectric Power Projects, Tunnels and Dams and Irrigation
Project contracts in different stages of construction underway with an aggregate value of ₹ 74,569lakh and
contributing 9% of the total Order Book of our Company.
Below is a selection of some of our significant projects in the Hydroelectric Power Projects, Tunnels and Dams
and Irrigation Project segment which are currently being undertaken:
(₹ in lakh)
109
Name and Description of Project State Total Value of
Contract
(₹ in lakh)
Construction of balance work of tunnels for Katra Dharam
Section in Jammu and Kashmir
Jammu and
Kashmir
26,112
Investigation Design and execution of water conveyor system
from Thipparam Reservoir to Gundureddipalli.
Andhra Pradesh 63,008
Industrial Structures and Buildings
In the Industrial Structures and Buildings segment, our Company is primarily involved in the construction of
metro station buildings and civil structures for refineries, petrochemicals, power, steel and fertilizer plants. Most
of our completed and current projects are item-rate contracts which are undertaken independently by us.
As of September 30, 2017, we have a total of 8 Industrial Structures and Buildings projects contracts in different
stages of construction aggregating to a total value of ₹ 19,454lakh and contributing 2% of the total Order Book of
our Company.
Below is a selection of some of our significant projects in the Industrial Structures and Buildings segment which
are currently being undertaken:
(₹ in lakh)
Name and Description of Project
State Total Value of
Contract
Civil, structural fabrication and erection, water supply, plumbing
electric, lightning and earthing and HVAC installation works for
CKCEC, Rath Chakra, Paradip
Odisha ₹14,370
Architectural Finishing, Plumbing, Tubewell, VAC, Electrical, Fire
Fighting Works For 6 Elevated Stations
West Bengal ₹ 9,611
Designing, Providing, Constructing, Erecting, Testing &
Commissioning of Intake Channel, Jackwell & Pump House,
Approach Bridge, Break Pressure Tank, Raw Water Pumping
Machinery With Transformer Substation & Power Connection to
Head Works under a water supply scheme
Maharashtra ₹ 8,675
Specialist Engineering
In the Specialist Engineering segment, our Company is primarily involved in the foundation and specialist works
including geotechnical investigations, piling, diaphragm walling, sand wicks / band drains, vibro-floatation stone
columns / vibro compaction, drilling and grouting, rock / soil anchors, colcrete, gunite / shotcrete, grouted
mattress, repairs, tube heading and box pushing. In addition, we have carried out several rehabilitation
assignments for protection and life enhancement of stressed dams and other structures through drilling, grouting
and anchor stressing and other engineering solutions. Most of our completed and current projects are item-rate
contracts which are undertaken independently by us.
As of September 30, 2017, we have 17 Specialist Engineering contracts in different stages of construction
aggregating to a total of ₹ 12,933lakh and contributing 2% of the total Order Book of our Company.
Below is a selection of some of our significant projects in the maritime structures segment which are currently
being undertaken:
(₹ in lakh)
Name and description of Project State Total Value
of Contract
Ground improvement works using vibrostoe column works for RMHS-II
project at Dharamtar for JSW Steel Limited
Maharashtra 5,168
Highways, Bridges and Flyovers
In the Highways, Bridges and Flyovers segment, our Company is primarily involved in the construction of roads,
bridges and flyovers. We are also executing an elevated road in a dense traffic zone as well as carrying out bridge
construction contracts for various clients. Most of our completed and current projects are item-rate contracts which
110
are undertaken independently by us. We also execute some of our projects on a joint venture basis.
As of September 30, 2017, we have 4 Highways, Bridges and Flyovers contracts in different stages of construction
underway aggregating to a total of ₹ 11,224 lakh and contributing to 1% of the total Order Book of our Company.
Below is a selection of some of our significant projects in the Highways, Bridges and Flyovers segment which are
currently being undertaken:
(₹ in lakh)
Name and Description of Project State Total Value of Contract
Railway bridges at Nashik Maharashtra 10,554
Our Joint Ventures
ITD-ITDCem JV ITD-ITDCem JV
(Consortium of
ITD-ITD
Cementation)
ITD Cem
Maytas
Consortium
ITD Cemindia JV CEC-ITD Cem-
TPL JV
Shareholders ITD Cem – 49%
ITD (Thailand) –
51%
ITD Cem – 40%
ITD (Thailand) –
60%
ITD Cem –
95%
Maytas Infra
Limited–5%
ITD Cem – 80%
ITD (Thailand) –
20%
Continental
Engineering
Corporation –
40%
ITD Cem – 40%
Tata Projects
Limited - 20%
Key projects Supply and
installation of
track work for
Bangalore
Metro
3 under ground
stations and
tunnels for
Kolkata Metro
– scope of
work
increased, new
order of
enhanced
work awaited
Design and
construction of
elevated
viaduct and 8
elevated
stations
(CC26) worth
54,600 lakhs
Design and
Construction
of Tunnels by
Shield TBM
under Delhi
MRTS Project
(CC32) worth
75,200 lakhs
Laying of
Water Trunk
Main from
Garden Reach
Water Works
Construction
of integrated
passenger
terminal
building at
Netaji Subas
Chandra Bose
(International)
airport in
Kolkata
Design and
execution
of water
conveyor
system for
government
of Andhra
Pradesh
Rehabilitation
and
Refurbishment
of Water
Works at Palta
and Garden
Reach.(KEIIP)
4 Nos. projects
-Construction
of elevated
structures
(viaduct &
stations) for
Bangalore
Metro Rail
Corporation
Limited
Design and
construction
of
underground
section
including 3
underground
stations at
Mumbai
111
ITD-ITDCem JV ITD-ITDCem JV
(Consortium of
ITD-ITD
Cementation)
ITD Cem
Maytas
Consortium
ITD Cemindia JV CEC-ITD Cem-
TPL JV
to Taratala
Valve Station
and Laying of
Sewer Line
along
Diamond
Harbour Road
by
Microtunelling
Method for
KEIIP worth
14,590 lakhs
Work in
Hand as on
Sept 30, 2017
(100%)
91,290 lakhs - 56,850 lakhs 2,34,030 lakhs 26,050 lakhs
Our Business Process
Participation in Projects
We are a civil engineering, contracting and construction organisation involved in securing and execution of
construction projects. Based on requirements in each case, we secure these projects as a main contractor, a member
of a consortium or joint venture or a subcontractor. We secure most of our contracts individually and in a few
cases under unincorporated joint ventures with our Promoter and/or partners. As a member of a consortium, the
scope of work and responsibility is shared within the consortium members and defined through appropriate
agreements. In the case of joint ventures, we enter into agreements which lay down the responsibilities and
obligations of each member of the joint venture. Generally, the members of the joint venture are jointly and
severally responsible to the client. For the execution of projects, we also engage subcontractors to perform part of
the work and provide personnel.
Tendering for projects is one of the key elements of our business. We place our bids on tenders based on
comprehensive estimation of the total cost required to perform the tender. We estimate the cost of a project prior
to submission of a bid based on the bill of quantity information provided by the client or based on the quantities
derived by us in case of design and build projects and our own experience in estimating such costs.
Our Contracts
A major portion of our current contracts are from government or governmental organisations for the execution of
infrastructure projects. These projects comprise of construction contracts based on client design or design and
build contracts or engineering, procurement and construction (“EPC”) contracts. We enter into these contracts
independently or in a joint venture or consortium with other partners, including our Promoter.
The different contract types typically used in the construction business falls into one or more combinations of the
following categories:
Lump-sum contracts provide for a single price for the total amount of work, subject to variations pursuant
to changes in the client's project requirements. In lump-sum contracts, the client supplies all the
information relating to the project, such as designs and drawings. Based on such information, we are
required to estimate the quantities of various items, such as raw materials, and the amount of work that
would be needed to complete the project, and then prepare a bill of quantities ("BOQ") to arrive at the
price to be quoted. We are responsible for the execution of the project based on the information provided
and technical stipulations laid down by the client at our quoted price.
Design and Build contracts provide for a single price for the total amount of work, subject to variations
pursuant to changes in the client's project requirements. In Design and Build contracts, the client supplies
conceptual information pertaining to the project and spells out the project requirements and
112
specifications. We are required to (i) appoint consultants to design the proposed structure, (ii) estimate
the quantities of various items that would be needed to complete the project based on the designs and
drawings prepared by our consultants and (iii) prepare a BOQ to arrive at the price to be quoted. We are
responsible for the execution of all aspects of the project described above at our quoted price.
Item-rate contracts are contracts where we need to quote the price of each item presented in a BOQ
furnished by the client. In item-rate contracts the client supplies all the information such as the design,
drawings and a BOQ. We are responsible for the execution of the project based on the information
provided and technical stipulations laid down by the client at our quoted rates for each respective item.
Percentage rate contracts require us to quote a percentage above, below or at par with the estimated cost
furnished by the client. In percentage rate contracts, the client supplies all the information such as design,
drawings and BOQ with the estimated rates for each item of the BOQ. We are responsible for the
execution of the project based on the information provided and technical stipulations laid down by the
client at our quoted rates, which are arrived at by adding or subtracting the percentage quoted by us above
or below the estimated cost furnished by the client.
Most contracts, irrespective of their type (i.e., lump-sum, item-rate, percentage rate, design-build, etc.) contain
price variation or escalation clauses that provide for either reimbursement by the client in the event of a variation
in the prices of key raw materials (for example, steel and cement) or a formula that splits the contract into pre-
defined components for materials, labour and fuel and/or links the escalation in amounts payable by the client to
pre-defined price indices published periodically by the RBI or the Government. Some contracts do not include
such price variation or escalation clauses. In those instances, we face the risk that the price of key raw materials
and other inputs will increase during the project execution period and we may be unable to pass on the increases
in such costs to the client.
Most of our contracts are awarded and carried out on a reimbursable unit item-rate basis where we are paid based
on the contracted rates for performing specified items of work, which reduces the risk of lower revenues resulting
from inaccurate cost estimates.
The projects we undertake are typically completed in an average of one to four years, including the defect liability
period. Most of our contracts provide for an advance payment of 5% to 10% of the overall contract price against
corresponding bank guarantee/s and progress payments on a monthly basis or at various stages of the project.
Many of our projects contain provisions allowing reimbursement against increase in the cost of critical inputs,
such as steel, cement, fuel and labour charges.
We typically provide security deposits and/or performance guarantees which normally range of 5% to 10% of the
contract value. The deposits and/or guarantees are provided by us either by way of irrevocable bank guarantees
or cash deposits or retention of a particular percentage of monthly progress payments by the client. Such security
deposits and performance guarantees are generally refunded partly at the completion of the project and the rest at
the end of the defect liability period.
Typically under all our contracts we are required to execute the project in a specified time period. When a project
is delayed through no fault of our own, the contracts usually provide that we would be granted suitable extensions.
The contracts also usually provide for liquidated damages to be paid by us in case of delays in the execution or
delays in achieving certain milestones including completion milestones during the execution of the project. In
case of delay or defective work done by us, the client has right to require us to rectify the defective work at our
cost including engagement of third party/ies for completion of the work and deduct additional costs or charges
incurred on such account from contract price payable to us.
Most contracts also require us to provide for appropriate insurance policies which would cover our works, plants
and machineries, workmen, vehicles and third party losses. Where these insurances are in place, the client incurs
no liability for costs recoverable from insurance including the deductible amounts which are to be borne by us.
When the costs for re-performance exceed the insurance proceeds, the same may have to be incurred by us.
Project-specific joint ventures
We may enter into joint ventures while bidding for certain projects. We generally bid for projects on a joint venture
basis with our Promoter and/or other partner(s) to enable us to obtain larger projects that require additional
qualifications and/or resources, such as financial strength, expertise, equipment, manpower or local content
resources.
113
In a project-specific joint venture, each member of the joint venture shares the risks and revenues of the project
according to a predetermined agreement. However, the members of the joint venture are jointly and severally
responsible to the client. In addition, in the event any member(s) of our joint ventures default on its or their duties
to perform, the other members would typically remain liable to our client for the completion of the project. Counter
indemnity agreements are made between the joint venture members to safeguard against losses or liabilities arising
from actions/omissions of other members.
The project-specific joint venture typically terminates at the completion of the defect liability period, at which
point the project-specific joint venture liquidates and dissolves. Currently, we have four joint ventures. For details
of our Joint Ventures, please refer to the chapter titled “Related Party Transactions” on page 125.
Project Lifecycle
Business Development
We bid for projects primarily through a competitive bidding process. The Government and other clients typically
advertise proposed projects in leading national newspapers or on their websites. Our business development
department regularly scans newspapers and websites to identify projects that could be of interest to us. We also
regularly interact with our private sector clients to look for any new or proposed projects. The business
development department evaluates bid opportunities and decides whether we should pursue a particular project
based on various factors, including the client's reputation and financial strength, the geographic location of the
project and the degree of difficulty in executing the project in such location, our current and projected workload,
the likelihood of additional work, the project's costs and our competitive advantage relative to other likely bidders.
Once we have identified projects that meet our criteria, we submit an application to the client according to the
procedures set forth in the advertisement.
Tendering
The process of bidding for a project usually involves a pre-qualification process either prior to the issue of bid
documents by the client or along with the valuation of the proposal presented by prospective bidders. Pre-
qualification applications generally require us to submit details about our organizational set-up, financial
parameters such as turnover, net worth and profit and loss history, employee information, plant and equipment
inventory, experience, technical ability and performance, reputation for quality, safety record, portfolio of
executed and ongoing projects and details of litigations and arbitrations in which we are involved. The client
evaluates our ability to bid and/or execute the project based on these criteria although price competitiveness of
the bid is usually the final selection criterion.
We endeavour to qualify for projects on our own in which we propose to bid. However if additional credentials
are required to qualify for a specific project, we may seek tie ups or project-specific joint ventures on a case to
case basis with other partners including our Promoter and using the combined credentials improve our chances to
pre-qualify and secure the project.
Once we pre-qualify for a project, the next step is to submit a techno-commercial and financial bid. For each bid
we may, depending on size of the project identify a bid manager to lead an estimation team consisting of members
drawn from other internal departments like estimation, planning, design and engineering, purchase, commercial
and contracts. The estimation team then carries out detailed study of the proposed project, visit the project site,
and study the technical, commercial conditions and other requirements of the client in detail.
This team in consultation with our management determines the bidding strategy depending upon the type of
project and contract. In case of unit-item rate bids involving only construction, the bids are based on the bill of
quantities, drawings, specifications etc. provided by the client, whereas in the event of bid for a design-build
project, we may appoint a competent consultant to design the project and provide us with drawings, quantities and
other details to enable us to further analyse the various aspects of the project for us to submit a more informed
bid/proposal. Similarly, a lump sum tender would entail quantity take-offs from the drawings supplied by the
clients.
Site visit and estimation
A site visit and study enables us to determine the access to the site, the local conditions among other things. A
local market survey is also usually conducted to assess the availability, and price of key construction resources
like materials, labour, plant and equipment and specialist subcontractors in the particular region, including sources
114
of key natural construction materials, their availability and quality of such material. The site visit also allows us
to determine the incidence and rates of local taxes and levies, such as sales tax or value added tax, octroi and cess.
Depending on the nature and magnitude of the work, project completion period and the various technical and other
requirements of the client, the estimation team prepares a broad construction methodology and wherever possible
detailed monthly programme with breakup of activities.
The estimation team then works out resource requirements, generally including the following parameters:
Plant and equipment – owned and / or hired,
Materials and services – quantum and period,
Human resource including skill requirements and
Other inputs
Resources required for various activities during project duration are planned depending on the quantum of the
activities to be executed each month as detailed in programme. Requirement of resources are based on work
content, our experience, guidelines derived from past data and trends available to the estimation team. The
resource requirement of the project is then compared against in-house availability prior to opting for external
sourcing. Human resources in the skill sets, numbers, period and special requirements are assessed for the project.
In order to bring the collective experience of our Company into the estimation process, inputs for tendering are
normally collated from specialist departments including plant, human resources, design and engineering,
procurement, finance, logistics, taxation, commercial and contracts. A statement detailing salient bid conditions
is usually prepared recording key tender conditions that may require management assessment. An analysis
covering techno-commercial, legal, financial and other project specific risks may be prepared for review by
management and where necessary and feasible taken up with the client for suitable change and / or development
of risk mitigation measures including additional costs, insurance or deviations to the tender.
Methodologies, costs and inputs that would be required for the execution of the project are assessed by the
estimation team in conjunction with the operating managers. This estimate is then taken up for approval by the
management within a well-defined delegation of authority matrix. Project details are usually spelt out with
assumptions, salient bid conditions, clarifications, deviations, assumptions along with the risk analysis and the
estimate is reviewed, modified and finalized by the management. In all this, we also consider key marketing inputs
including likely competition and assessment of our position, the overall business plan of our Company as well as
other parameters to arrive at the proposal to be made to the client.
Submission of bids
The approved proposal is then prepared for submission to the client in the format and as per the requirements of
the client. The marketing and sales department then proceeds with the submission process and follows through
the various steps required by the client in their process to decide on the successful agency for award of the project.
Where we are not successful in winning the project(s), an analysis of the reasons for the loss is done, if required,
by the marketing and sales department along with the estimation group and reviewed by management to examine
the causes and corrections, if necessary for future business development.
When the proposal is accepted by the client, it is usually communicated in the form of an acceptance letter to the
proposal submitted or a letter of intent followed by entering into contract agreements. We review in detail the
draft agreements proposed by the clients to ensure that it reflects our proposal and proceed to discuss with the
client on changes that may be necessary, if any, to reflect the understanding of the proposal submitted. The
execution of the awarded project is based on letter of intent/agreement which lays down the roles and
responsibilities of both the parties.
Construction
The receipt of letter of acceptance or letter of intent from the client signifies that we have been awarded the
contract. Upon receipt of the letter, we typically commence pre-construction activities, such as mobilising
resources viz. manpower, equipment, etc. and setting up site offices, stores and other ancillary facilities.
Construction activity typically commences once the client approves working designs, issues drawings and hands
115
over work front. Based on contract documents, a detailed schedule of construction activities is prepared. This
schedule identifies interim milestones, if any, stipulated in the contract with corresponding time schedules for
achieving these milestones. The project team also identifies and works with the purchase department in procuring
construction materials and services required for the construction.
The sequence of construction activities largely follows the construction schedule that is prepared initially, subject
to changes in scope requested by the client or as per project requirement.
Procurement
In construction business the cost of material generally comprises substantial portion of the total project cost;
consequently success in any project would depend on the adequate supply of requisite material during the tenure
of the contract. We have a separate department, which is responsible for procurement and logistics to ensure
timely availability of material at each of our project sites.
Upon award of a contract, the purchase department is provided with the project details along with the budgeted
rates for material, services and equipment. The material, services and equipment required for projects are
estimated by the project team and informed to the purchase department along with the schedule of requirements.
The ability to procure cost-effectively material, services and equipment on time and of the required quality and
quantity is essential for the successful execution of our projects. For this purpose, we have processes to continually
evaluate our existing vendors and also develop additional sources of supply for most of the materials, services and
equipment needed for our projects.
We have over the years developed relationships with a number of vendors for key materials, services
and equipment and have an extensive vendor database for the same. In addition, we also receive quotations for
materials required for the project at the time of bidding for the project. Based on the foregoing and the information
from the vendor base, the purchase department invites quotations for the required materials. Vendors are also
invited to negotiate before finalizing the terms and prices. The materials ordered are provided to the sites from
time to time as per requirements. We also maintain material procurement, tracking and control systems, which
enable monitoring of our purchases.
Integrated management system
We have an integrated management system in place which ensures seamless system of operation across our
Company and also helps us to track the physical and financial progress of work vis-à-vis the project schedule on
a daily basis with monthly management meetings held to review the project progress. Project personnel also hold
periodic review meetings with the client at project sites and also interact with off-site office personnel to discuss
the progress being made on the project and support requirements.
Dispatch of invoices
Project sites usually have commercial cell that is responsible for preparing and submitting periodic invoices to
the client. Joint measurements with the client's representative are taken on a periodic basis and interim invoices
are prepared on the basis of such measurements. These invoices are then sent to the client for certification and for
release of interim payments. This department is also responsible for verifying the bills prepared by our vendors
and subcontractors and forwarding the same to accounts department for further processing.
Administration of Contracts
All major projects have dedicated contracts engineers responsible for assisting the project manager in the contract
administration including detecting and reporting any variations/deviations to the agreed terms of the contract. The
contracts engineer in consultation with the contract department at the head office send appropriate notifications
as per terms of the contract to the client for remedial action.
Quality and safety measures
We generally have onsite testing facilities/laboratories manned by experienced personnel to ensure quality
assurance and quality control at the project.
We also deploy dedicated safety personnel at each site for ensuring safety compliance. Safety review meetings
116
are attended by our project personnel and subcontractors / agencies engaged by us at site and chaired by the project
manager. These review meetings are generally held on a monthly basis to improve safety performance.
Completion of the project
We consider a project to be "substantially complete" when it is ready to be handed over to the client. We then
along with the client jointly inspect the project to begin the process of handing over the project to the client. Once
satisfied, the client prepares a "substantial completion certificate", which signifies the commencement of the
defects liability period or the maintenance period (i.e., the period during which we are contractually bound to
rectify any defects arising out of construction, as per the contract). On completion of the defects liability period,
we request the client for release of any performance bonds or retention monies that may be outstanding.
Project Phases
The flowchart below presents broadly the various phases of a project.
Construction Risk Management
Contracting and construction business is exposed to a variety of risks. Assessing and managing risks is and
continues to be a critical function to our business. We have risk management processes in our Company to identify
and analyze the various risks and wherever possible, for us to manage it by appropriate mitigation measures thus
enabling us to improve our operations.
This process is usually done at two stages – at bidding stage and during the execution of the project. The risk areas
may be grouped into the following areas:
● Technical
The key elements reviewed under this may include client requirements, possible variation in the work
Prequalification
Submission of Proposal/Bid
Client Evaluation
Not Awarded
Loss Analysis
&
Corrective actions (if
Tender Preparation
- Site Visit & Study - Methodology & Programme - Resource identification - Risk analysis - Estimation - Formulate Proposal/Bid
Work Awarded
Letter of Acceptance
Signing of Agreement
Mobilisation
Execution
Execution Planning
Identify prospective projects
Suitability Review
Physical Completion
Defect Liability Period
Completion of Project
117
including possibility of additional works, technical and quality requirements, risks relating to the project
site viz. location, climate, geological, geotechnical challenges; methodology of construction; availability
of resources; requirement of special materials and/or equipment and/or specialists, expertise and
competency of associates and/or subcontractors and/or consultants, construction process. These are broad
heads and specific projects may have other risks that may be considered during the bidding and execution
stages.
● Legal
This may include a review of the risks, if any, arising from legal issues like the applicable law, joint-
ventures/association agreements, the contract terms and conditions, site clearances, the scope of our
involvement in the project, risk coverage required, defects liability requirements, permits, legal or
physical impossibility, dispute resolution procedures and force majeure conditions.
● Financial
In this area, risks that may be assessed include those arising from project funding, contract payment
schedule, project cash flow, financial arrangements with joint venture partners, associates, vendors,
subcontractors, contract guarantee requirements, insurance and coverage requirements are review under
this head.
● Public Exposure
As our projects have interaction with the public and have large manpower deployment, areas like
employee relations, labour relations, local management, contract/project specific requirements,
environment, compliance to statutory laws and regulations have a large role to play in the successful
execution of our projects. Hence these areas may be reviewed for possible risks.
These risks may then be analyzed for probability of occurrence and impact of occurrence and are then
reviewed by the management. Depending upon the situation, the management adopts suitable mitigation
methods. However, this system of risk analysis and mitigation may only reduce the likely risks through
timely detection and mitigation and also become aware of any residual risks after mitigation, if any, for
improving the operations and profitability of our projects.
Equipment
Our construction business requires timely mobilization of specialised and general plant and equipment, their
efficient operation at site and timely maintenance required to ensure their continued performance. Our Company
possesses an inventory of modern construction equipment that can be mobilized in accordance with requirement
on our projects. To enable an effective and efficient operation and timely maintenance of these at our various
project sites in India, we have centralized the management of this key resource.
Our current equipment’s include maritime gantries, conventional bored piling rigs and driven piling rigs to modern
piling equipment’s like tunnel boring machines, diesel and vibratory pile drivers, rotary equipment’s like
mechanical and hydraulic self-propelled hydraulic rigs; vibro floater, diaphragm walling equipment’s for
foundation/geotechnical works, equipment’s for road works including motor graders; dozers, large multi stage
stone crushers capacities; wet mix plants, batch type hot mix plants; wet mix macadam pavers, sensor pavers for
bituminous works and sensor pavers for concrete pavements, concrete kerb casting machines etc. Our concrete
production, transportation and placing fleet includes automated batching plants of various capacities, chilling
plant, transit mixers, remix cars, concrete pumps and placer boom. For tunneling operations we have our
specialized hauling systems and ventilation systems. Apart from these our other major plants include high capacity
electric generators, high capacity crawler cranes, tower cranes, tippers trucks, excavators of various capacities etc.
Our plant and equipment fleet is continually reviewed to meet our current and projected requirements.
Competition
In the construction industry, contracts are secured based on competitive bidding amongst eligible entities, which
includes other Indian companies, project specific joint ventures as well as international companies. Our
competition depends on whether the project is in the civil construction sector or the infrastructure sector. It also
depends on a host of other factors, such as the type of project, contract value and potential margins, the complexity
118
and location of the project, the reputation of the client and the risks relating to revenue generation. While service
quality, technical ability, performance record, experience, health and safety records and the availability of skilled
personnel are key factors in client decisions among competitors, price is often the deciding factor in most tender
awards.
While we are among the leading diversified construction companies in India with an all India presence and a track
record of several decades, we face competition in each of our areas of activity from our competitors in India like.
While we believe that the liberalization of the Indian economy creates attractive business opportunities for us, due
to the rising government expenditure on infrastructure and various policy initiatives for development of
infrastructure. We believe that we are well placed to face the competition and secure contracts given our strong
international parentage and good management systems backed by a skilled work force.
Offices
Note: The above map is not to scale and not intended to mean political map of India
Awards and Achievements
The awards and achievements received by our Company from our clients include the following:
On Safety
Certificate of Appreciation for successfully completing 1 million safe man-hours during construction of
SSNNL D-wall from Megha Engineering and Infrastructure Limited in the year 2017;
Certificate of Appreciation for successfully completing 2 million safe man-hour during construction of
marine facility at Karanja Creek from Karanja Terminal Logistic Private Limited in the year 2017;
Certificate of Achievement for best safety performance from JSW Steel Limited in the year 2017 ;
Certificate of Appreciation for outstanding performance by implementing good safety practices at
Bhamaaskhed water supply scheme from Bhamaaskhed Water Supply Scheme Project in the year 2017;
Certificate of Appreciation for successfully completing 3 million safe man-hours during work on CC-50
project in the year 2016;
Certificate of Appreciation for successfully completing 2.87 million safe man-hours during construction
of Container Terminal-4 from Adani Ports & Special Economic Zones Limited in the year 2016;
Certificate of Appreciation for successfully completing 2 million safe man-hours from Konkan Railway
Corporation Limited in the year 2016;
Certificate of Appreciation for successfully completing 5.2 million during New Umtru Hydro Electric
Project from Meghalaya Power Generation Corporation Limited in the year 2016;
Certificate of Appreciation for successfully completing 4.18 million safe man-hours during construction
of underground metro from Kolkata Metro Rail Corporation Limited in the year 2016;
Certificate of Appreciation for successfully completing 2.6 million safe man-hours from Adani Ennore
Container Terminal Private Limited in the year 2016;
119
Certificate of Appreciation for successfully completing 5 million safe man-hours from Rohit Surfactants
Private Limited in the year 2016;
Certificate of Appreciation for successfully completing 2 million injury free man-hours Delhi Metro in
the year 2016;
Certificate of appreciation for excellent performance in Occupational health, safety during construction
Coal Berth No.3 from Kamarjar Port Limited in the year 2016;
Certificate of Excellence for achieving 10 millions safe man-hours at LNG Terminal from GSPC LNG
in the year 2016;
Certificate of Excellence for valuable contribution and achievement of excellent safety standards at
ITPCL from HTG Limited in the year 2016;
Certificate of Appreciation for Safety Award from China Datang Technologies & Engineering India
Private Limited in the year 2016;
Certificate of appreciation for excellent performance in Occupational health, safety during construction
of EMC Bridge across intake channel – Mundra from PMC Projects (India) Private Limited in the year
2016;
Certificate of Appreciation for major contribution towards safe man-hours at CCPP/MAB construction
site from Reliance Industries Limited for the year 2015;
Certificate of Appreciation for implementing Safety practices in the work area from JSW in the year
2015;
Certificate of Appreciation for achieving 2 million safe hours during construction of container berth No.
3A,3B & 4A from JSW for the year 2015;
Certificate of Recognition for excellent contribution towards Best Safety Performance from TATA
Power in the year 2015;
Certificate of Appreciation for successfully completing 2.4 million safe man-hours from Kolkata Metro
Rail Corporation Limited for the year 2015;
Certificate of Appreciation for achievement in occupational safety and health from National Safety
Council of India in the year 2015;
Certificate of Appreciation for successfully completing one lakh safe hours during construction of
diaphragm wall from Bakeri in the year 2015;
Certificate of Appreciation for successfully completing one million safe hours from LNG Storage Tanks
Projects, Mundra in the year 2015;
Certificate of Appreciation for successfully completing 1.95 million injury free man-hours from
Archtech Consultants Private Limited in the year 2015;
Certificate of Appreciation for successfully completing 1.3 million safe man-hours during construction
of 7 metro stations from Kolkata Project Implementation Unit in the year 2015;
Certificate of Excellence for successfully completing 3 lakh safe man-hours during pilling and civil
works from TATA Consultancy Engineers Limited in the year 2015;
Safety Excellence Award during construction of polypropylene project from Thysenkrupp Industrial
Solutions Private Limited in the year 2015;
Certificate of Appreciation for successfully completing 1.5 million safe man-hours from Noida
Development Authority in the year 2015;
Safety Excellence Award in recognition of valuable contribution made in safe working environment as
well as best quality standards at DMRC Project Site (CC-23) in the year 2014;
Safety Excellence Award in recognition for outstanding contribution in the achievement of 10 lakh safe
hours from Lubrizol TempRite Compounding Unit, Dahej, Gujarat in the year 2014;
Letter of appreciation for significant contribution in implementing safety practices from Lavgan
Dockyard Limited;
Certificate of Appreciation for successfully completing One million safe man-hours during contract
package CC-50 in the year 2014;
Certificate of Appreciation for successfully completing Three million safe man-hours during
construction of Quay works for 330m Container Terminal Project;
Certificate of Appreciation for implementing good safety practices at TRL Eklehara Pumphouse from
Indiabulls in the year 2014;
Certificate of Excellence for safe working environment at PTA-10 Project site for bored cast in-situ piling
works by Hazira Manufacturing Division in the year 2014;
Certificate of Excellence for developing and implementing effective management systems and
procedures from National Safety Council of India in the year 2014.
On Quality
120
Certificate of Merit for outstanding concrete structure of Elevated Road from Vishwa Bharati School to
Sector 61, Noida from India Concrete Institute in the year 2017.
CIDC Vishwakarma Award for Best Construction Projects for Quay Construction at JNPJ, Mumbai from
Construction Industry Development Council in the year 2016;
Certificate of Appreciation for continuous improvement in quality systems and excellent performance
in maintaining quality standards from PMC Projects (India) Private Limited in the year 2016;
Certificate of Appreciation for continuous improvement in quality systems and excellent performance in
maintaining quality standards during the construction of Container Terminal with diaphragm wall from
Adani Ennore Container Terminal Private Limited in the year 2016;
Certificate of Merit for outstanding concrete structure of Jaipur Metro from Indian Concrete Institute in
the year 2016;
Certificate of Appreciation for continuous improvement in quality systems and excellent performance in
maintaining quality standards during the construction Container Terminal 4 from National Safety
Council of India in the year 2016;
CIDC Vishwakarma Award for Best Construction of Underground Tunneling of Metro, Kolkata in the
year 2015.
Awards
Award for professionalism and Commitment Oriented Approach from MECON Limited for the year
2016; and
Good Corporate Citizen Award from Bombay Chamber of Commerce and industry in the year 2017.
Information Technology
We are an information technology enabled organisation with systems and infrastructure set up at our offices and
project sites. Our offices and project sites are well connected for speedy communication. Currently, we have
implemented technology and solutions on firewall, anti-virus and anti-spam to protect data, email and hardware.
In addition, some of our critical business applications are developed in-house and other customized solutions are
used in functional area.
Intellectual Property Rights
Our trademark/logo ITD Cem is registered under class 16 (representing stationery, literature, drawings, manuals,
boards, signage) and under class 7 (representing plant and machinery) of the Trade Marks Act, 1999.
Employees
We believe that a trained and experienced employee base is essential for the success of a player in the construction
and infrastructure sector. As of September 30, 2017, our Company has a work force of 1,953dedicated employees,
comprising qualified engineers, skilled operators and workmen, a detailed break-up of which is given hereunder:
Category No. of employees
Managers 424
Executives 645
Supervisory Staff 803
Non- Supervisory Staff 81
Total 1,953
Human Resource Development and Training
We focus on building a performance-oriented culture through employee appraisals based entirely on their
performance. With a view to enhance the competence of our employees, we carry out behavioral / safety / ISO
and quality training programmes for our employees from time to time.
Insurance
We maintain to the extent available and feasible, a range of standard insurance policies to cover our assets, risks
and liabilities. Substantially all of our insurance policies relate to the coverage of our buildings, equipments, goods
- in- transit and liabilities towards our employees and are currently provided by leading insurance companies. The
121
policies provide appropriate coverage in relation to fire, floods, theft, burglary and personal injury claims by our
personnel. On our major projects, we maintain contractors all risk policies and third party liability insurance, with
appropriate endorsements.
Properties
The registered office and corporate office of the Company is situated at National Plastic Building, A-Subhash
Road, Paranjape B Scheme, Vile Parle (East), Mumbai – 400 057. The premises has been taken on leave and
license basis by the Company.
Apart from our registered office, we also have offices in Kolkata, New Delhi and Chennai.
122
REGULATIONS AND POLICIES
The following description is a summary of relevant regulations and policies applicable to our Company. This
description is based on the current provisions of Indian law, which are subject to change or modification or
interpretation by subsequent legislative, regulatory, administrative or judicial decisions. The laws set out herein
below and their description are not exhaustive, and are only intended to provide general information to Investors
and is neither designed nor intended to be a substitute for professional legal advice.
The following description is a summary of the relevant regulations and policies as prescribed by the GoI and other
regulatory bodies that are applicable to our business. The information detailed below has been obtained from
various legislations, including rules and regulations promulgated by regulatory bodies, and the bye laws of the
respective local authorities that are available in the public domain. The regulations set out below may not be
exhaustive and are merely intended to provide general information to the investors and are neither designed nor
intended to substitute for professional legal advice.
Indian Regulations
Our projects require the sanction of concerned authorities under the relevant Central/State legislations and local
by-laws at various stages. Set forth below are certain significant legislations and regulations that generally govern
the business in which we operate in India:
Roads and Highways
The primary central legislations governing the roads sector are the National Highways Act, 1956 and the National
Highways Authority of India Act, 1988.
National Highways Act, 1956 (“NH Act”)
The NH Act was enacted by the Indian Parliament to provide for the declaration of certain highways as national
highways and for matters connected therewith. Sections 3A to 3I of the NH Act contains a comprehensive scheme
for the acquisition of land for the building, maintenance, management or operation of a national highway or part
thereof and determination of amount payable as compensation and other related issues. Under the NH Act, the
government is vested with the power to declare and omit a highway as a national highway and also to acquire land
for this purpose. The government may by notification, declare its intention to acquire any land when it is satisfied
that for a public purpose such land is required for the building, maintenance, management or operation of a
national highway. The NH Act prescribes the procedures to be followed inter alia for declaration of an intention
to acquiring, entering and inspecting such land, hearing of objections, declaration required to be made for the
acquisition and the mode of taking possession. The NH Act also provides for payment of compensation to owners
who enjoy easement over such lands.
The central government is responsible for the development and maintenance of national highways. However, it
may direct that such functions may also be exercised by the state governments. The government also has the power
to enter into an agreement with any person for the development and maintenance of a part or whole of the highway.
Such person would have the right to collect and retain fees at such rates as may be notified by the government in
this regard.
National Highways Authority of India Act, 1988 (the “NHAI Act”)
The NHAI Act, an act of parliament, was promulgated in 1988 for the setting up of the NHAI as statutory agency
of the Government of India. It is a nodal agency of the Ministry of Road Transport and Highways and is
responsible for the development, maintenance and management of national highways entrusted to it and for
matters connected or incidental thereto. The NHAI was made an autonomous body in February 1995. It is
responsible for the development, maintenance, management and operation of National Highway totaling over
70,000 km. NHAI is mandated to implement National Highways Development Project (NHDP) in various phases.
Pursuant to the same the NHAI has the power to enter into and perform any contract necessary for the discharge
of its functions under the NHAI Act. The limit in relation to the value of the contracts that may be entered into by
NHAI is prescribed by GoI. However, such contracts can exceed the value so specified with the prior approval of
the GoI.
The National Highways Authority of India (Amendment) Bill, 2008, was approved by the Cabinet in December
2008. It aims at increasing institutional capacity of NHAI and execute the powers delegated to it. The government
123
plans to make NHAI a multi-disciplinary professional body with financial management and contract management
expertise. It aims at induction of professionals who in turn will enhance the capacity of NHAI to take strategic
decisions, widen the perspective, bring in best management practices and help in achieving goals of higher private
participation.
Irrigation Sector
Irrigation being an entry in the State List of the Seventh Schedule to the Constitution of India is governed by the
laws of state governments. Most states have separate irrigation departments whose functions, apart from
enforcement and implementation of relevant State Government legislation/ policy, also entail regulation of
engineering activities including research, design, execution, quality control of projects, canals and canal structures
in accordance with such legislation/ policy. Additionally, the Central Water Commission, Ministry of Water
Resources, GoI is entrusted with the general responsibilities of initiating, coordinating and furthering, schemes
for control, conservation and utilization of water resources throughout the country, including for irrigation, in
consultation with relevant State Governments.
In addition to the above, all management of water resources in India is guided by the National Water Policy, 2002
which broadly prioritizes water in the following manner: (i) drinking water; (ii) irrigation; (iii) hydropower; (iv)
ecology; (v) agro-industries and non-agricultural industries; and (vi) navigation and other uses. The National
Water Policy, 2002 further recommends the manner in which water resources are to be developed and managed
in the country and further encourages private sector participation in planning, development and management of
water resources projects for diverse uses, wherever feasible.
Foreign Ownership
Foreign investment in India is governed primarily by the provisions of FEMA, and the rules, regulations and
notifications thereunder, as issued by the Reserve Bank of India from time to time, and the policy prescribed by
the Department of Industrial Policy and Promotion, which provides for whether or not approval of the FIPB is
required for activities to be carried out by foreigners in India.
As laid down by the FEMA Regulations, no prior consents and approvals is required from the RBI, for FDI under
the "automatic route" within the specified sectoral caps. In respect of all industries not specified as FDI under the
automatic route, and in respect of investment in excess of the specified sectoral limits under the automatic route,
approval may be required from the FIPB and/or the RBI.
The Industrial Policy, 1991 prescribed the limits and the conditions subject to which foreign investment can be
made in different sectors of the Indian economy. Under the Industrial Policy and FEMA, FDI up to 100% is
permitted in construction and related engineering services. Further, the Industrial Policy now also permits foreign
direct investment under the automatic route in projects for construction and maintenance of roads, highways,
vehicular bridges, toll roads, vehicular bridges and ports and harbours.
No approvals of the FIPB or the RBI are required for such Allotment of Equity Shares under this Issue. Our
Company will be required to make certain filings with the RBI after the completion of the Issue.
Ownership restrictions of Foreign Portfolio Investors (FPI)
In terms of the FPI Regulation, the issue of Equity Shares to a single FPI or an investor group (which means the
same set of ultimate beneficial owner(s) investing through multiple entities) is not permitted to exceed 10% of
our post-Issue Equity Share capital. Further, in terms of the FEMA Regulations, the total holding by each FPI
shall be below 10% of the total paid-up Equity Share capital of our Company and the total holdings of all FPIs
put together shall not exceed 24% of the paid-up Equity Share capital of our Company. The aggregate limit of
24% may be increased up to the sectoral cap by way of a resolution passed by our Board followed by a special
resolution passed by the Shareholders of our Company and subject to prior intimation to RBI.
Fiscal Legislations
The Company is subject to certain fiscal legislations such as the Income Tax Act, 1961, the Goods and Services
Tax Act and the Customs Act, 1962. In addition, we are also required to obtain registration under various State
Acts on Excise and Sales for the purposes of carrying on our business in those States.
Labour Regulations
124
We are also required to comply with an extensive set of laws, rules and regulations in relation to hiring and
employment of labour.
A brief explanation in relation to the labour regulations as applicable to us is given herein below:
Payment of Gratuity Act, 1972
The Payment of Gratuity Act, 1972 provides for the payment of gratuity to employees in certain prescribed
establishments. Gratuity is payable to an employee on the termination of his employment after he has rendered
continuous service for not less than five years on his superannuation, on his retirement or resignation or on his
death or disablement due to accident.The Payment of Gratuity Act, 1972, as amended (“Gratuity Act”)
establishes a scheme for the payment of gratuity to employees engaged in every factory, mine, oil field, plantation,
port and railway company, every shop or establishment in which ten or more persons are employed or were
employed on any day of the preceding twelve months and in such other establishments in which ten or more
employees are employed or were employed on any day of the preceding twelve months, as notified by the Central
Government from time to time. Penalties are prescribed for non-compliance with statutory provisions.
Under the Gratuity Act, an employee who has been in continuous service for a period of five years will be eligible
for gratuity upon his retirement, resignation, superannuation, death or disablement due to accident or disease.
However, the entitlement to gratuity in the event of death or disablement will not be contingent upon an employee
having completed five years of continuous service. The maximum amount of gratuity payable may not exceed
INR 10,00,000.
Payment of Wages Act, 1936
This Act is applicable to factories and industrial or other establishments where the monthly wages payable are
less than INR 18,000. The Act inter alia seeks to regulate the payment of wages in terms of the duration of
employment (work hours, overtime wages, and holidays), quantum of wages including overtime wages,
deductions from wages, of certain classes of employed persons. There are certain compliances under the Act
including maintenance of registers. The Act also regulates minimum wages to be fixed by the appropriate
governments for the employees, bonus entitlements disbursements of wages by the employers within the stipulated
time frame without unauthorised deductions.
The Minimum Wages Act, 1948
The Minimum Wages Act, 1948, as amended, provides a framework for State governments to stipulate the
minimum wage applicable to a particular industry. The minimum wage may consist of a basic rate of wages and
a special allowance; or a basic rate of wages and the cash value of the concessions in respect of supplies of essential
commodities; or an all-inclusive rate allowing for the basic rate, the cost of living allowance and the cash value
of the concessions, if any. Workmen are to be paid for overtime at overtime rates stipulated by the appropriate
government. Contravention of the provisions of this legislation may result in imprisonment for a term up to six
months or a fine up to ₹500 or both.
The Employees’ State Insurance Act, 1948 ("ESI Act")
The Employees’ State Insurance Act, 1948 is to provide benefits for employees or their beneficiaries in case of
sickness, maternity, disablement and employment injury and to make provision for the same. Under this Act,
every employee (including casual and temporary employees), whether employed directly or through a contractor,
who is in receipt of wages up to ₹ 21,000 per month is entitled to be insured. In respect of such employees, both
the employer and the employee must make certain contributions to the Employee State Insurance Corporation.
Currently, the employee’s contribution rate is 1.75% of the wages and that of employer’s is 4.75% of the wages
paid/payable in respect of the employee in every wage period.
Industrial Disputes Act, 1947
The Industrial Disputes Act, 1947, as amended (“ID Act”) provides the procedure for investigation and settlement
of industrial disputes. When a dispute exists or is apprehended, the appropriate Government may refer the dispute
to a labour court, tribunal or arbitrator, to prevent the occurrence or continuance of the dispute, or a strike or lock-
out while a proceeding is pending. The labour courts and tribunals may grant appropriate relief including ordering
modification of contracts of employment or reinstatement of workmen.
125
The Contract Labour (Regulation and Abolition) Act, 1970
This act applies to our Company only when we employed twenty or more workmen on any day of the preceding
twelve months as Contract labour at any contract site. As the provision of this act Principal Employer should
register for employing Contract Labour in his Establishment. On receipt of registration Certificate from
appropriate authority under this act, they can engaged Contractor in their establishment. The contractor should
take license from licensing authority after obtaining form III from Principal Employer. In the absence of
registration, contract labour cannot be employed in the establishment. Likewise, every contractor to whom the
CLRA applies is required to obtain a license and not to undertake or execute any work through contract labour
except under and in accordance with the license issued. The CLRA imposes certain obligations on the contractor
in relation to establishment of canteens, rest rooms, drinking water, washing facilities, first aid, other facilities
and payment of wages. However, in the event the contractor fails to provide these amenities, the principal
employer is under an obligation to provide these facilities within a prescribed time period. Penalties, including
both fines and imprisonment, may be levied for contravention of the provisions of the CLRA.
The Buildings and Other Construction Workers (Regulation of Employment and Conditions of Service)
Act, 1996
The Buildings and Other Construction Workers (Regulation of Employment and Conditions of Service) Act, 1996,
as amended (the “Construction Workers Act”), provides for regulation of employment and conditions of service
of building and other construction workers including safety, health and welfare measures in every establishment
which employs or employed during the preceding year, 10 or more workers. However, it does not apply in respect
of residential houses constructed for one’s own purpose at a cost of less than INR 10,00,000 and in respect of
other activities to which the provisions of the Factories Act, 1948 and the Mines Act, 1952 apply. Each
establishment to which the Construction Workers Act applies must be registered within a period of 60 days from
the commencement of work. Further, every employer must give notice of commencement of building or other
construction work 30 days in advance. Comprehensive health and safety measures for construction workers have
been provided through the Building and Other Construction Workers (Regulation of Service and Conditions of
Service) Central Rules, 1998. The Construction Workers Act provides for constitution of safety committees in
every establishment employing 500 or more workers with equal representation from workers and employers in
addition to appointment of safety officers qualified in the field. Any violation of the provisions for safety measures
is punishable with imprisonment for three months or a fine of a maximum of ₹ 2,000 or both. Continuing
contraventions attract an additional fine of ₹ 100 per day. The Construction Workers Act also provides for
penalties for failure to give notice of commencement of building or other construction work and obstruction of
inspection, enquiry, etc.
Employee’s Compensation Act, 1923
If personal injury is caused to a workman by accident during employment, his employer would be liable to pay
him compensation. However, no compensation is required to be paid if the injury did not disable the workman for
three days or the workman was at the time of injury under the influence of drugs or alcohol, or the workman
wilfully disobeyed safety rules. Where death results from the injury the workman is liable to be paid the higher of
50% of the monthly wages multiplied by the prescribed relevant factor (which bears an inverse ratio to the age of
the affected workman, the maximum of which is 228.54 for a worker aged 16 years) or ₹ 80,000. Where permanent
total disablement results from injury the workman is to be paid the higher of 60% of the monthly wages multiplied
by the prescribed relevant factor or INR 90,000. The maximum wage which is considered for the purposes of
reckoning the compensation is INR 8,000.
Payment of Bonus Act, 1965
The Payment of Bonus Act, 1965 (the “Bonus Act”), provides that an employee in a factory or in any
establishment where 20 or more persons, who are employed on any day during an accounting year, who has
worked for at least 30 working days in a year is eligible to be paid a bonus. Under this Act, every employer is
bound to pay to every employee, in respect of the accounting year, a minimum bonus which is 8.33% of the salary
or wage earned by the employee during the accounting year or ₹100, whichever is higher. The provisions of the
Payment of Bonus Act, 1965 also provide that a minimum annual bonus which is payable to every employee, is
irrespective of whether or not the employee has made a profit or loss in the corresponding accounting year for
which the bonus is payable. Contravention of the provisions of the Bonus Act by a company is punishable with
imprisonment for a term of up to six months or a fine of up to 1,000 or both, against persons in charge of, and
responsible to the company for the conduct of the business of the company at the time of contravention.
126
Inter-State Migrant Workmen’s (Regulation of Employment and Conditions of Service) Act, 1979
The Inter-state Migrant Workers Act, 1979 applies to any establishment or contractor who employees five (5) or
more inter-state migrant workmen (whether or not in addition to other workmen) on any day of the preceding
twelve months. An ‘inter-state migrant workman’ is defined under Section 2 (e) to include any person who is
recruited by or through a contractor in one state under an agreement or other arrangement for employment in an
establishment in another state, whether with or without the knowledge of the principal employer in relation to
such establishment. All such establishments employing migrant workers must be registered otherwise such
workmen cannot be employed by them.
Sexual Harassment of women at workplace (Prevention, Prohibition and Redressal) Act, 2013
Sexual Harassment of women at workplace (Prevention, Prohibition and Redressal) Act, 2013 which was notified
on December 9, 2013 provides for protection against sexual harassment of women at workplace and for the
prevention and redressal of complaints of sexual harassment and for matters connected therewith or incidental
thereto. The Act defines sexual harassment at the work place and creates a mechanism for redressal of complaints.
It also provides safeguards against false or malicious charges.
The Industrial Employment (Standing Orders) Act, 1946
This Act is applicable to industrial establishments, wherein 100 or more workmen are employed, or were
employed on any day of the preceding 12 months. The Act seeks to define with sufficient precision the conditions
of employment of workmen employed and to make them known to such workmen. The employers in every such
establishment are required to frame draft standing orders and thereafter obtain necessary certification for such
orders. The certified standing orders are required to be posted by the employer in English and in the language
understood by the majority of his workmen on boards to be maintained for this purpose at or near the entrance
through which the majority of workmen enter the industrial establishment and in all departments thereof where
the workmen are employed. Failure to the employer to comply with the provisions of this Act will attract penalty
of ₹ 5000 and further fine which may extend to ₹ 200 for every day of such default.
The Employees’ Provident Funds and Miscellaneous Provisions Act, 1952
The Employees’ Provident Funds and Miscellaneous Provisions Act, 1952 was introduced with the institution of
provident funds and pension funds for employees in establishments, which employ more than 20 persons, and
factories specified in Schedule I of the Act. The funds constituted under these schemes framed under the Act
consist of contributions from both the employer and the employees, in the manner specified in this Act.
The Equal Remuneration Act, 1976
Under the provisions of this act a Company has to provide the payment of equal remuneration to men and women
workers and for the prevention of discrimination on the ground of sex against women in the matter of employment
and for matter connected therewith of incidental thereto.
No employer shall make any discrimination against women while making recruitment for the same work or work
of a similar nature.
If any complaint with regard to the contravention of any provision of the Act and claims arising out of non-
payment of wages at equal rates to men and women workers for the same work or work of a similar nature shall
be heard and decided by an authority appointed by an appropriate Government.
Provision of penalties on contravention of the provisions of the Act or (b) makes any payment of remuneration at
unequal rates to men and women workers for the same work or work of similar nature, or (c) makes any
discrimination between men and women workers in contravention of the provisions of the Act, he would be
punished with fine ₹10,000/-.
The Maternity Benefit Act, 1961
This act regulates the employment of women for certain periods before and after child –birth and provides for
maternity benefit and certain other benefits.
127
The Factories Act, 1948
The Factories Act, 1948 is applicable whereon ten or more workers are working or were working on any day of
the preceding twelve months, and in any part of which a manufacturing process is being carried on with the aid
of power, or is ordinarily so carried on but does not include a mine subject to the operation of the Mines Act
1952 (35 of 1952).
The objective of the act is to secure to the workers employed in the factories health, Safety, Welfare, proper
working hours, leave and other benefits.
Environmental Laws
Some of the important environmental and other legislations that are applicable to us are described as under.
Environment (Protection) Act, 1986
The Environment (Protection) Act was enacted as a general legislation to safeguard the environment from all
sources of pollution by enabling coordination of the activities of the various regulatory agencies concerned, to
enable creation of an authority with powers for environmental protection, regulation of discharge of environmental
pollutants etc. The purpose of the Act is to act as an "umbrella" legislation designed to provide a frame work for
Central government co-ordination of the activities of various central and state authorities established under
previous laws, such as Water Act & Air Act. It includes water, air and land and the interrelationships which exist
among water, air and land, and human beings and other living creatures, plants, micro-organisms and property.
Forest (Conservation) Act, 1980
The Forest (Conservation) Act, 1980 prevents State Governments from making any order directing that any forest
land be used for a non-forest purpose or that any forest land is assigned through lease or otherwise to any private
person or corporation not owned or controlled by the government without the approval of GoI. The Ministry of
Environment and Forests mandates that ‘environment impact assessment’ must be conducted for projects. In the
process, the said Ministry receives proposals for the setting up of projects and assesses their impact on the
environment before granting clearances to the projects.
Air (Prevention and Control of Pollution) Act, 1981
The Air (Prevention and Control of Pollution) Act 1981, was enacted to provide for the prevention, control and
abatement of air pollution. The statute was enacted with a view to protect the environment and surroundings from
any adverse effects of the pollutants that may emanate from any factory or manufacturing operation or activity. It
lays down the limits with regard to emissions and pollutants that are a direct result of any operation or activity.
Periodic checks on the factories are mandated in the form of yearly approvals and consents from the corresponding
Pollution Control Boards in the state.
Water (Prevention and Control of Pollution) Act, 1974
The Water Act was enacted in 1974 in order to provide for the prevention and control of water pollution by
factories and manufacturing industries and for maintaining or restoring the wholesomeness of water. In respect to
an Industrial Undertaking it applies to the (i) Occupier (the owner and management of the undertaking); (ii) Outlet;
(iii) Pollution; and (iv)Trade effluents. The Act requires that approvals be obtained from the corresponding
Pollution Control Boards in the state.
Water (Prevention and Control of Pollution) Cess Act, 1977
The Water Cess Act is a legislation providing for the levy and collection of a cess on local authorities and
industries based on the consumption of water by such local authorities and industries so as to enable
implementation of the Water Act by the regulatory agencies concerned.
The Hazardous Wastes (Management, Handling and Transboundary Movement) Rules, 2008, as amended
(“Hazardous Wastes Rules”)
The Hazardous Wastes Rules impose an obligation on every occupier of a facility generating hazardous waste for
safe and environmentally sound handling of hazardous waste generated at such facility. Every person engaged in
128
generation, processing, treatment, packaging, storage, transportation, use, collection, destruction, conversion,
offering for sale and transfer of hazardous waste must obtain an approval from the applicable State Pollution
Control Board. The occupier, the importer, the transporter and the operator are liable for damages to the
environment or third party resulting from the improper handling and disposal of hazardous waste. The operator
and the occupier of a facility are liable for any fine that may be levied by the respective State Pollution Control
Boards, penalty for the contravention of the provisions of the Hazardous Waste Rules includes imprisonment up
to five years and imposition of fines as may be specified in the EPA or both.
The Municipal Solid Wastes (Management & Handling) Rules, 2000 (“Municipal Solid Wastes Rules”)
The Municipal Solid Wastes Rules shall apply to every municipal authority responsible for collection, segregation,
storage, transportation, processing and disposal of municipal solid wastes. Municipal solid wastes include
commercial and residential wastes generated in municipal or notified areas in either solid or semi-solid form,
excluding industrial hazardous wastes but including treated bio-medical wastes. The operator of a facility involved
in collecting, segregating, storing, transporting, processing and disposal of municipal solid wastes and any other
agency appointed by the municipal authority for the management and handling of municipal solid wastes is
required to obtain an authorization from the State Pollution Control Board to set up a waste processing and
disposal facility including landfills. Any municipal solid waste generated is required to be managed and handled
in accordance with the procedures specified in the Municipal Solid Wastes Rules.
Manufacture, Storage and Import of Hazardous Chemicals Rules, 1989 ("Hazardous Chemicals Rules")
The Hazardous Chemicals Rules stipulate that an occupier in control of an industrial activity has to provide
evidence for having identified the major accidental hazards and taking adequate steps to prevent major accidents
and to limit their consequences to persons and the environment. The persons working on site have to be provided
with information, training and equipment including antidotes necessary to ensure their safety. Rules also create
an obligation on the occupier of such premises to notify the concerned authorities on occurrence of any major
accident on the site with 48 hours.
The Noise Pollution Regulation & Control Rules, 2000 (Amended 2010)
An Employer shall ensure at a construction site of a building or other construction work that adequate measures
are taken to protect building workers against the harmful effects of excessive noise or vibration at such
construction site and the noise level in no case exceeds the limits laid down in Schedule I annexed to these rules.
Noise emitting from the construction equipment /vehicles shall be reduced by maintaining it in good working
condition. Noise in excess shall be controlled using appropriate engineering methods like erecting sound barriers,
segregating the noise generating zones / area. Awareness shall be created amongst people working high noise
areas. Workers exposed to such noise shall be provided with appropriate Personal Protective equipment.
The Shops and Establishments Act
Under the provisions of local shops and establishments legislations applicable in the states in which establishments
are set up, establishments are required to be registered. Such legislations regulate the working and employment
conditions of the workers employed in shops and establishments including commercial establishments and provide
for fixation of working hours, rest intervals, overtime, holidays, leave, termination of service, maintenance of
shops and establishments and other rights and obligations of the employers and employees.
The Mines Act, 1952
A Company inter alia has to take permission for quarry under the Mines Act, 1952 and pay necessary royalties to
the Government. Under the provision of this act a company has to provide health and safety measure to the
workers. This act is mainly applicable where quarry operation is going on for project purpose.
The Explosives Act 1884
A company has to inter alia take licence under the Explosive Act 1884 in certain cases for possession, use and
transport of Explosive at Contract Site. A license granted under Section 6-B may contain in addition to prescribed
conditions such other conditions as may be considered necessary by the licensing authority in any particular case.
The Motor Vehicle Act, 1988 and he Central Motor Vehicle Rules, 1989
129
The Motor Vehicle Act was enacted in 1988 to take care of equipment and vehicles used on construction site. All
equipment and vehicles shall carry valid legal documents and maintained in good working condition. The
operators and Drivers to these equipment and vehicles must possess valid driving license issued by the authority.
In no case shall exceed prescribed speed limits on roads or at sites.
130
BOARD OF DIRECTORS AND SENIOR MANAGEMENT
Overview
Our Board currently consists of 8 (eight) Directors. Our Articles of Association provide that the number of
directors shall not be less than three (3) and not more than 15 (fifteen). Further, our Articles of Association
provides that one-third of the strength of the Board of Directors shall be liable to retire by rotation or if their
number is not three or a multiple of three, the number nearest to one-third shall retire from office at every AGM.
A retiring Director shall be eligible for re-appointment.
The Companies Act, 2013, provides that unless the Articles of the Company provide for retirement of all directors
at every general meeting, not less than two-thirds of the total number of directors, excluding the independent
directors, shall be liable to retire by rotation. One-third of the directors liable to retire by rotation shall
automatically retire every year at annual general meeting and shall be eligible for re-appointment. The directors
to retire by rotation shall be decided based on those who have been longest in office since their last election, and
as between persons appointed on the same day, the same shall be determined by lot. The independent directors
may be appointed for a maximum of two terms of up to five consecutive years; however, such directors are eligible
for re-appointment after the expiry of three years of ceasing to be an independent director (whether or not each
term is for a period of five years) provided that such directors are not, during the three year period, appointed in
or associated with our Company in any other capacity, either directly or indirectly. Any reappointment of
independent directors inter alia, shall be on the basis of performance evaluation report and requires the approval
of the shareholders by way of a special resolution. None of the Directors on the Board of Directors of our Company
are members of more than ten committees or chairman of more than five committees across all the public
companies in which they are directors.
Our senior management team is under the overall supervision and control of the Managing Director for our day-
to-day operations.
Our Board of Directors
The following table sets forth details regarding the Board as on the date of this Preliminary Placement Document:
Sr.
No.
Name, Designation, Address, Occupation, DIN,
Term and Nationality
Age (in years) Designation
1. Mr. Premchai Karnasuta
Address: 12/ 3 Soi Soonvijai, 3, New Petchburi Road,
Bangkapi, Huaykwang, Bangkok 10320, Thailand
Occupation: Business
DIN: 00233779
Term: Liable to retire by rotation
Nationality: Thai
64 Non – Executive
Director and
Chairman
2. Mr. Pathai Chakornbundit
Address: 342/48 Soi Ram Indra 14, Ram Indra Road,
Tharang, Bangkhan, Bangkok - 10230, Thailand
Occupation: Business
DIN: 00254312
Term: Liable to retire by rotation
Nationality: Thai
75 Non – Executive
Director and Vice-
Chairman
3. Mr. Adun Saraban
58 Managing Director
131
Sr.
No.
Name, Designation, Address, Occupation, DIN,
Term and Nationality
Age (in years) Designation
Address: Heritage, 703, 7thfloor Floor Hiranandani,
Powai, Mumbai - 400 076
Occupation: Business
DIN: 01312769
Term: 3 (three) years from January 1, 2016
Nationality: Thai
4. Mr. Darius Erachshaw Udwadia
Address: Empress Court, 142, M-Karve Road,
Churchgate, Mumbai 400 020
Occupation: Advocate and Solicitor
DIN: 00009755
Term: 5 (five) years from August 6, 2014
Nationality: Indian
78 Independent
Director
5. Mr. Per Ebbe Hofvander
Address: Fyrvagen 11 23940 Falsterbo, Sweden
Occupation: Professional
DIN: 00254616
Term: 5 (five) years from August 6, 2014
Nationality: Swedish
74 Independent
Director
6. Mr. Deba Prasad Roy
Address: Apt. 505, Nestle 1, B Wing, Pandurang
Budhkar Marg, Mumbai 400 013
Occupation: Professional
DIN: 00049269
Term: 5 (five) years from August 6, 2014
Nationality: Indian
76 Independent
Director
7. Mrs. Ramola Shripad Mahajani
Address: 112 Satnam Apartments,
Cuffe Parade, Mumbai - 400 005
Occupation: Professional
DIN: 00613428
Term: 5 (five) years from November 6, 2014
Nationality: Indian
70 Independent
Director
8. Mr. Piyachai Karnasuta
42 Non - Executive
Director
132
Sr.
No.
Name, Designation, Address, Occupation, DIN,
Term and Nationality
Age (in years) Designation
Address: 12 Soi Soonvijay 3, New Phetburi Road,
Bangkapi, Huaikwang, Bangkok – 10310, Thailand
Occupation: Business
DIN:07247974
Term: Liable to retire by rotation
Nationality: Thai
Brief Profile of the Director of the Company
Mr. Premchai Karnasuta is a Director and Chairman of our Company since 2004 and he is also the President
and Director of Italian-Thai Development Public Company Limited, the Promoter of our Company. He holds a
Bachelor’s degree in Mining Engineering from Colorado School of Mines, United States of America and a Masters
degree in Business Administration from University of Southern California, United States of America. He has more
than three decades of experience in the infrastructure construction industry and has been the guiding force of our
Company’s progress over the years.
Mr. Pathai Chakornbundit is a Non- Executive Director of our Company since 2004. He is also the Vice
Chairman of the Company. He holds a Bachelors’ Degree in Engineering from Chulalongkorn University. He
holds experience of more than four decades in the construction industry. He is also a Director and Senior Executive
Vice President of Italian-Thai Development Public Company Limited, the Promoter of our Company.
Mr. Adun Saraban is the Managing Director of our Company since 2009 and the Managing Director of the
Company from 2010. He has experience of more than three decades in Civil Engineering and Construction Project
Management and also brings in vast exposure to global best modern construction methodologies. He holds a
bachelor’s degree in Civil Engineering from the King Mongkut’s University of Technology, Thonburi, Thailand.
Mr. Darius Erach Udwadia has been and is an Independent Director of the Company since 1983. He has been
re-appointed as an Independent Director of the Company in August, 2014 for a period of five consecutive years
in terms of the applicable provisions of the Companies Act, 2013. He holds a Master of Arts degree and a Bachelor
of Laws degree from Mumbai University He is a Solicitor and Advocate at the High Court of Bombay and a
Solicitor at the Supreme Court of England.. He has spent nearly 54 years in active law practice and has significant
experience and expertise in corporate law, joint ventures, mergers, acquisitions and takeovers, corporate
restructuring, foreign collaboration, project and infrastructure finance, intellectual property, telecommunications,
international loans and finance – related transactions and instruments, mutual funds, real estate and conveyancing.
Mr. Per Ebbe Hofvander has been an Independent Director of the Company since 2005. He was re-appointed
as an Independent Director in August, 2014 for a period of five consecutive years in term of the provisions of the
Companies Act, 2013. He holds a Master’s degree in Civil Engineering from Chalmers University of Technology,
Gothenburg, Sweden. He has more than four decades of experience in civil engineering and has a huge exposure
in many overseas projects and international businesses.
Mr. Deba Prasad Roy has been an Independent Director of the Company since 2007. He was re-appointed as an
Independent Director in August, 2014 for a period of five consecutive years in term of the provisions of the
Companies Act, 2013. He holds a Masters of Chemistry degree from Jadavpur University, Calcutta. He has rich
and wide experience in corporate, international and investment banking sectors of over 40 years. He is a certified
associate of the Indian Institute of Banker and fellow of Indian Council of Arbitration.
Mrs. Ramola Mahajani has been appointed as an Independent Director of the Company in November, 2014 for
a period of five consecutive years in term of the provisions of the Companies Act, 2013. She has considerable
knowledge and experience in Human Resources Development and Management of over 40 years. Her areas of
expertise include application of the principles of occupation psychology in employee selection, training,
management development and human resource planning, project management and leadership skill, and extensive
experience interacting with internal as well as external customer. She holds a Master’s degree in Science, Arts,
Chartered Psychologist and an associate fellowship of the British Psychological Society.
133
Mr. Piyachai Karnasuta is a Non – Executive Director of our Company since 2015. He has experience and
knowledge in Civil Engineering and Construction of over 14 years. He holds a Bachelor’s degree in Civil
Engineering from Washington University and a Masters in Business Administration from Waseda University. He
is an Executive Vice President of Italian-Thai Development Public Company Limited, the Promoter of our
Company.
Relationship with other Directors
None of the Directors is related to each other as per the applicable provisions of the Companies Act, 2013.
Borrowing Powers of Board of Directors
In terms of the Articles of Association, the Board may, from time to time, at its discretion by a resolution passed
at a meeting of the Board, accept deposits from members either in advance of calls or otherwise and generally
raise or borrow or secure the payment of any sum or sums of money for the purposes of the Company. Provided,
however, where the moneys to be borrowed together with the moneys already borrowed (apart from temporary
loans obtained from the Company’s bankers in the ordinary course of business) exceed the aggregate of the paid-
up capital of the Company and its free reserves, as defined under the Act, the Board shall not borrow such moneys
without the consent of the Company in general meeting by a Special Resolution.
The Board of Directors are authorized to borrow money upon such terms and conditions as the Board may think
fit not exceeding an aggregate amount of ₹1,20,000 lakh over and above the aggregate of paid up share capital
and free reserves of the Company pursuant to the resolution passed by the shareholders vide postal ballot dated
August 11, 2014.
Interest of our Directors
Our Managing Director is interested to the extent of the remuneration, paid to him. Our Non-Executive Directors
would be interested to the extent of annual commission, if any paid to them and thereof..
Except as otherwise stated in this Preliminary Placement Document, our Company has not entered into any
contract, agreement or arrangement during the preceding two years from the date of this Preliminary Placement
Document in which any of the Directors are interested, directly or indirectly, and no payments have been made to
them in respect of any such contracts, agreements or arrangements which are proposed to be made with them.
Other than as disclosed in this Preliminary Placement Document, there are no outstanding transactions other than
in the ordinary course of business undertaken by our Company, in which the Directors are interested. Further, our
Company has not availed of any loans from the Directors which are currently outstanding.
Terms of appointment of our Managing Director
Mr. Adun Saraban – Managing Director
Mr. Adun Saraban has been reappointed as the Managing Director of the Company for a period of 3(three) years
from January 1, 2016 to December 31, 2018 pursuant to the shareholder’s resolution dated May 12, 2016 and the
Board has been authorized to make periodic increases in remuneration payable to Mr. Saraban from time to time
subject to limitations prescribed by the Act. Below are the terms of his appointment including details of the
remuneration being paid to him pursuant to resolution passed by the Board of Directors of the Company on
November 9, 2016:
Category Particulars
Remuneration The Company shall pay a monthly salary of ₹ 8,21,250/- (Rupees eight lakh twenty one
thousand two hundred and fifty only) for the period from January 1, 2017 to December
31, 2018 (both days inclusive) with a periodic increase as the Board may determine,
provided that his monthly salary shall not exceed ₹ 9,00,000/- (Rupees nine lakh only).
Perquisites Mr. Adun Saraban shall enjoy the following perquisites:
a. Use of furnished residential accommodation taken on lease or leave and license
basis by the Company;
b. Reimbursement by the Company of all charges in connection with supply of gas,
134
Category Particulars
electricity and water consumed and furnishings at the residence;
c. The use of telephone(s) at his residence, the rent, call charges for the business of
the Company and other outgoings;
d. Reimbursement of medical expenses actually incurred by him;
e. Leave travel concession once in a year for him;
f. The benefit of personal accident and mediclaim insurance policies effected by the
Company;
g. The use of a chauffeur driven motor car for business purposes;
h. The benefit of the Company’s provident fund scheme which shall not exceed 12%
of his salary;
i. Gratuity at the rate of one half month’s salary for each completed year of service;
j. the rate of one half month’s salary for each completed year of service;
k. Leave on full remuneration in accordance with the Companies Act, 2013;
l. Casual and sick leave on full remuneration including all benefits in accordance
with the Companies Act, 2013 for their time being;
m. Reimbursement of travelling and entertainment expenses reasonably incurred by
him exclusively for the business of the Company and as approved by the Board.
Non- Executive Directors’ Commission and Sitting Fees
Our Non-Executive Directors in India are paid remuneration by way of sitting fees of:
a. ₹ 20,000 for attending each meeting of our Board, Audit Committee, Nomination and Remuneration
Committee and Independent Directors’ Meet;
b. ₹ 5,000 for Share Transfer Committee; and
c. ₹ 10,000 for meeting of any other committee of the Board.
The following table sets forth details of remuneration by way of commission and sitting fees paid by our Company
to the current Non-Executive Directors residing in India for the Fiscal 2014, Fiscal 2015 and Fiscal 2016 and for
the period from January 1, 2017 to September 30, 2017:
(₹ in lakh)
Name of the Non –
Executive
Directors*
From January 1,
2017 to
September 30,
2017
Fiscal Year 2016 Fiscal Year 2015 Fiscal Year 2014
Mr. Darius Erach
Udwadia
3,80,000 9,50,000 3,35,000 1,70,000
Mr. Deba Prasad
Roy
2,60,000 7,80,000 1,60,000 90,000
Mrs. Ramola
Mahajani
1,60,000 6,60,000 1,10,000 15,000
*Our Company does not pay any sitting fees and/ commission to its Non – Executive Directors who are residing
outside India.
Corporate Governance
Our Company is required to comply with applicable corporate governance requirements, including the SEBI
Listing Regulations with the Stock Exchanges and the SEBI ICDR Regulations in respect of the constitution of
the Board and committees thereof. The corporate governance framework of our Company is based on an effective,
independent Board of Directors, separation of the supervisory role of the Board of Directors from the executive
management team and proper constitution of the committees of the Board of Directors, as required by law.
The Board of Directors function either as a full corporate Board or through various committees constituted to
oversee specific operational areas. The executive management of our Company provides the Board of Directors
with detailed reports on the performance of our Company periodically.
The Board of Directors presently consists of 8 (eight) Directors. Of the 8 (eight) Directors, our Company has 1
(one) Managing Director and 7 (seven) are Non- Executive Directors out of which 4 (four) are Independent
Directors.
135
Organisation Structure
Corporate Structure
Committee of the Board of Directors
Our Board of Directors presently has five committees which have been constituted in accordance with the relevant
provisions of the Companies Act and SEBI Listing Regulations:
i. Audit Committee;
ii. Nomination and Remuneration Committee;
iii. Stakeholders Relationship Committee;
iv. Corporate Social Responsibility Committee; and
v. Share Transfer Committee.
Board of Directors
Managing Director
Chief
Operating
Officer
Chief
Financial
Officer
Chief Technical
Officer
Chief
Commercial
Officer
Chief Business
Development
Officer
Company
Secretary
Internal
Audit
4 Divisional
Heads
ITD Cementation Projects India
Limited (Wholly owned
subsidiary)
ITD Cemindia
JV (ITD’ share -80%)
ITD- ITD Cem
JV (ITD’ share -49%)
ITD Cementation India Limited (Engaged in marine works, highways & bridges, metros, airports,
hydro-tunneling, dams & canals, water & waste water treatment and
specialist foundation engineering projects
)
ITD-ITD Cem JV (Consortium of ITD-ITD
Cementation) (ITD’ share -40%)
ITD Cem Maytas Consortium (ITD’ share -95%)
CEC-ITD Cem-
TPL JV (ITD’ share -40%)
136
Our Company has also constituted a Risk Management Committee comprising of Mr. Per Ebbe Hofvander
(Chairman), Mr. Adun Saraban and Mr. B. K. Saha.
The following table sets forth the details of the members of the aforesaid committees:
Sr. No. Committee Members
1. Audit Committee Mr. Per Ebbe Hofvander (Chairman)
Mr. Darius Erach Udwadia
Mr. Pathai Chakornbundit
Mr. Deba Prasad Roy
2. Nomination and Remuneration Committee Mr. Darius Erach Udwadia (Chairman)
Mr. Premchai Karnasuta
Mr. Pathai Chakornbundit
Mr. Per Ebbe Hofvander
3. Stakeholders Relationship Committee Mr. Pathai Chakornbundit
Mr. Adun Saraban
4. Corporate Social Responsibility Committee Mr. Per Ebbe Hofvander (Chairman)
Mr. Pathai Chakornbundit
Mr. Adun Saraban
5. Risk Management Committee Mr. Per Ebbe Hofvamder (Chairman)
Mr. Adun Saraban
Mr. B. K. Saha
6. Share Transfer Committee Mr. Darius Erach Udwadia (Chairman)
Mr. Adun Saraban
Mr. Rahul Neogi (Company Secretary)
7. QIP Committee of Directors Mr. Pathai Chakornbundit
Mr. Darius Erach Udwadia
Mr. Deba Prasad Roy
Mr. Adun Saraban
Key Managerial Personnel
Under the provisions of the Act, the management of the whole of the affairs of the Company is entrusted to the
managing director who has substantial powers of management of the affairs of the Company.
The table below sets out the names of our key managerial personnel and their current responsibilities:
Sr.
No.
Name Designation Date of appointment
1. Mr. Adun Saraban Managing Director January 1, 2010
2. Mr. Prasad Patwardhan Chief Financial Officer July 16, 2017
3. Mr. Rahul Neogi Company Secretary and Compliance
Officer
February 1, 2017
Brief Profiles of the Key Managerial Personnel
Mr. Prasad Patwardhan, 51 years of age, is the Chief Financial Officer of our Company with effect from July
16, 2017. He holds a Bachelor’s degree in Commerce from the University of Mumbai. He is a member of The
Institute of Chartered Accountants of India since January 1990. He has over 25 years of experience in resource
mobilization, accounting, taxation and investor relations. He joined our Company as the Chief Financial Officer
and is in charge of the financial reporting, financial strategy, compliance, taxation and co-ordination of statutory
and management reporting.
Mr. Rahul Neogi, 56 years of age, is the Company Secretary and Compliance Officer of our Company with effect
from February 1, 2017. He holds a Bachelor’s degree in Commerce from Patna University and a Bachelor’s degree
in Law from Bhagalpur University. He is a member of The Institute of Company Secretaries of India since 1995
and is also a certified Associate of the Indian Institute of Bankers. He has around 22 years of experience in
handling company law and related legislations.
137
For details of interest and other confirmations of Mr. Adun Saraban please see page 133.
Interest of Key Managerial Personnel
Our key managerial personnel do not have any interest in our Company other than to the extent of the remuneration
or benefits to which they are entitled to as per their terms of appointment and to the extent of the Equity Shares
held by them or their dependents in our Company, if any.
Other than as disclosed in this Preliminary Placement Document, there is no outstanding transaction other than in
the ordinary course of business undertaken by our Company, in which the key managerial personnel are interested.
The perquisites and allowances that may be payable to the key managerial personnel of our Company are in
accordance with our Company’s human resources policies. Except as disclosed above, our key managerial
personnel are not entitled to any other non-salary related amount or benefit.
Related Party Transactions
Except as disclosed in this Preliminary Placement Document, our Company has not entered into any related party
transaction during the last three financial years.
Loans to Directors and Key Managerial Personnel
As on the date of this Preliminary Placement Document, there are no amounts which are due to our Company,
from any of its Directors or key managerial personnel in the nature of loans and advances. Our Company has not
given any guarantees in favour of any Director or any key managerial personnel.
Other Confirmations
Except as stated above in “Interest of our Directors” and “Interests of Key Managerial Personnel”, none of our
Directors or any key managerial personnel of our Company has any financial or other material interest in this
Issue.
138
PRINCIPAL SHAREHOLDERS
The table below represents the shareholding pattern of our Company in accordance with Regulation 31 of the
Listing Regulations, as on December 31, 2017:
SUMMARY STATEMENT HOLDING OF SPECIFIED SECURITIES
Category of
Shareholders
No. of
Sharehol
ders
No. of fully
paid up equity
shares held
Total no of
shares held
Shareholding as
a % of total no.
of shares
(circulated as per
SCRR, 1957) As
a % of (A+B+C2)
Number of equity
shares held in
dematerialised form
A) Promoter &
Promoter
Group
1 8,01,13,180 8,01,13,180 51.63 8,01,13,180
B) Public 30,957 7,50,44,720 7,50,44,720 48.37 73,98,0615
C)Shares
underlying DRS
0.00 0.00 0.00 0.00 0.00
C2)Shares held
by Employees
Trust
0.00 0.00 0.00 0.00 0.00
C)Non
Promoter-Non
Public
0.00 0.00 0.00 0.00 0.00
Grand Total 30,958 15,51,57,900 15,51,57,900 100 15,37,80,345
STATEMENT SHOWING SHAREHOLDING PATTERN OF THE PROMOTER AND PROMOTER
GROUP
Category of
Shareholders
No. of
Shareholders
No. of fully
paid up
equity
shares held
Total no.
of shares
held
Shareholding as% of
total no. of shares
(calculated as per
SCRR,1975)As a %of
(A+B+C2)
Number of
equity shares
held in
dematerialized
form
A1)Indian
A2)Foreign
Any Other
(specify)
1 8,01,13,180 8,01,13,180 51.63 8,01,13,180
Italian Thai
Development
Public Company
Limited
1 8,01,13,180 8,01,13,180 51.63 8,01,13,180
Sub Total A2 1 8,01,13,180 8,01,13,180 51.63 8,01,13,180
A=A1+A2 1 8,01,13,180 8,01,13,180 51.63 8,01,13,180
STATEMENT SHOWING SHAREHOLDING PATTERN OF THE PUBLIC SHAREHOLDER
Category & Name of
Shareholder
No. of
Share
holder
No. of Fully
paid up
equity
shares held
Total no. of
shares held
Sharehol
ding %
calculate
d as per
SCRR
1957, As
a % of
(A+B=C2
)
No. of
Voting
Rights
Total
as a %
of
total
voting
rights
No. of equity
shares held
in
dematerializ
ed form (not
applicable)
B1)INSTITUTIONS 0 0 0.00 0.00
139
Category & Name of
Shareholder
No. of
Share
holder
No. of Fully
paid up
equity
shares held
Total no. of
shares held
Sharehol
ding %
calculate
d as per
SCRR
1957, As
a % of
(A+B=C2
)
No. of
Voting
Rights
Total
as a %
of
total
voting
rights
No. of equity
shares held
in
dematerializ
ed form (not
applicable)
Mutual Funds 49 3,41,82,886 3,41,82,886 22.03 3,41,82,886 22.03 3,41,82,886
Reliance Capital Trustee Co.
Ltd. - a/c Reliance Tax
Saver (ELSS) Fund
3 93,76,105 93,76,105 6.04 93,76,105 6.04 93,76,105
Sundaram Mutual Fund A/C
Sundaram Smile Fund
11 26,57,499 26,57,499 1.71 26,57,499 1.71 26,57,499
Franklin Templeton Mutual
Fund A/C Franklin India
High Growth Companies
Fund
2 40,00,000 40,00,000 2.58 40,00,000 2.58 40,00,000
UTI-MNC FUND 4 56,49,430 56,49,430 3.64 56,49,430 3.64 56,49,430
Sbi Magnum Monthly
Income Plan
8 54,01,284 54,01,284 3.48 54,01,284 3.48 54,01,284
IDFC Premier Equity Fund 2 35,63,055 35,63,055 2.30 35,63,055 2.30 35,63,055
Venture Capital Funds 0 0 0 0.00 0 0.00 0
Alternate Investment Funds 0 0 0 0.00 0 0.00 0
Foreign Venture Capital
Investors
0 0 0 0.00 0 0.00 0
Foreign Portfolio Investors 21 43,45,180 43,45,180 2.80 43,45,180 2.80 43,45,180
Eastspring Investments India
Infrastructure Equityopen
Limited
1 25,84,178 25,84,178 1.67 25,84,178 1.67 25,84,178
Financial Institutions/Banks 6 161,930 161,930 0.10 161,930 0.10 161,430
Insurance Companies 0 0 0 0.00 0 0.00 0
Provident Funds/Pension
Funds
0 0 0 0.00 0 0.00 0
Any Other
Sub Total (B)(1) 76 3,86,89,996 3,86,89,996 24.94 3,86,89,996 24.94 3,86,88,496
Central Government/State
Government(s)/President of
India
0 0 0 0.00 0 0.00 0
Sub Total (B)(2) 0 0 0 0.00 0 0.00 0
Non-Institutions
Individual shareholders
holding
Nominal share capital up to
Rs.2 lakhs
29,133 2,31,46,929 2,31,46,929 14.92 2,31,46,929 14.92 2,31,46,929
Individual shareholders
holding
Nominal share capital in
excess of Rs. 2 Lakhs
6 62,55,083 62,55,083 4.03 62,55,083 4.03 62,55,083
Hitesh Ramji Javeri 1 40,00,020 40,00,020 2.58 40,00,020 2.58 40,00,020
NBFCs Registered with RBI 4 3,150 3,150 0.00 3,150 0.00 3,150
Employee Trusts 0 0 0 0.00 0 0.00 0
Overseas Depositories
(Holding DRs)(Balancing
figure)
0 0 0 0.00 0 0.00 0
Any Other
TRUSTS 3 3,951 3,951 0.00 3,951 0.00 3,951
Alternative Investment Fund 1 2,50,000 2,50,000 0.16 2,50,000 0.16 2,50,000
140
Category & Name of
Shareholder
No. of
Share
holder
No. of Fully
paid up
equity
shares held
Total no. of
shares held
Sharehol
ding %
calculate
d as per
SCRR
1957, As
a % of
(A+B=C2
)
No. of
Voting
Rights
Total
as a %
of
total
voting
rights
No. of equity
shares held
in
dematerializ
ed form (not
applicable)
Non-Resident Indians 610 7,44,117 7,44,117 0.48 7,44,117 0.48 7,42,617
Clearing Members 155 1,02,268 1,02,268 0.07 1,02,268 0.07 1,02,268
Non-Resident Indian Non
Repatriable
207 2,18,704 2,18,704 0.14 2,18,704 0.14 2,18,704
Bodies Corporates 761 53,36,962 53,36,962 3.44 53,36,962 3.44 53,14,232
Param Capital Research
Private Limited
1 20,00,000 20,00,000 1.29 20,00,000 1.29 20,00,000
I E P F 1 2,93,560 2,93,560 0.19 2,93,560 0.19 2,93,560
Sub Total (B)(3) 30,881 3,63,54,724 3,63,54,724 23.43 3,63,54,724 23.43 3,52,92,119
Total Public Shareholding
(B) = (B)(1)+(B)(2)+(B)(3)
30,957 7,50,44,720 7,50,44,720 48.37 7,50,44,720 48.37 7,39,80,615
STATEMENT SHOWING SHAREHOLDING PATTERN OF THE NON PROMOTER – NON PUBLIC
SHAREHOLDER
Category & Name
of the
Shareholders (I)
No. of
shareholders
(III)
No. of
fully
paid up
equity
shares
held
Total no. of
shares held
(VII=IV+V+VI)
Shareholding %
calculated as per
SCRR,1975 As%
of (A+B+C2)
(VIII)
Number of equity
shares held in
dematerialized
form (XIV)(not
applicable)
C1)Custodian/DR
Holder
0 0 0.00
C2)Employee
Benefit Trust
0 0 0.00
Details of disclosure made by the Trading Members holding 1% or more of the Total No. of shares of the
company
Sr. No. Name of the
Trading Member
Name of the
Beneficial
Owner
No. of shares
held
% of total no. of
shares
Date of reporting
by the Trading
Member
- NIL NIL NIL NIL NIL
141
ISSUE PROCEDURE
The following is a summary intended to present a general outline of the procedure relating to the application,
bidding, payment, Allocation and Allotment of the Equity Shares to be issued pursuant to the Issue. The procedure
followed in the Issue may differ from the one mentioned below, and investors are presumed to have apprised
themselves of the same from our Company or the BRLM. Investors that apply in this Issue will be required to
confirm and will be deemed to have represented to our Company, the BRLM and their respective directors,
officers, agents, advisors, affiliates and representatives that they are eligible under all applicable laws, rules,
regulations, guidelines and approvals to acquire Equity Shares as a QIB and will not offer, sell, pledge or transfer
the Equity Shares to any person who is not eligible under applicable laws, rules, regulations, guidelines and
approvals to acquire Equity Shares. Our Company and the BRLM and their respective directors, officers, agents,
advisors, affiliates and representatives accept no responsibility or liability for advising any investor on whether
such investor is eligible to acquire Equity Shares. Investor is advised to inform themselves of any restrictions or
limitations that may be applicable to them. See the chapters titled “Distribution and Solicitation Restrictions”
and “Transfer Restrictions” beginning on pages 153and 159, respectively.
The Issue is being made to QIBs in reliance upon Chapter VIII of the SEBI Regulations and section 42 of the
Companies Act, 2013 and the rules thereunder. The Issue has been approved by our members vide postal ballot
dated December 12, 2017 and has been approved by our Board on September 21, 2017.
Our Company has received the in-principle approvals dated January 24, 2018 and January 24, 2018 from the NSE
and the BSE, respectively, under Regulation 28 (1) of the SEBI Listing Regulations. Our Company has also filed
a copy of this Preliminary Placement Document with the Stock Exchanges.
After the Allotment of Equity Shares, our Company shall make applications to the Stock Exchanges for the listing
approvals. Subsequently, after the credit of Equity Shares to the beneficiary accounts with the Depository
Participant, our Company shall make applications to the Stock Exchanges for the final listing and trading
approvals.
Our Company shall also make the requisite filings with the RoC and SEBI within the stipulated period as required
under the Companies Act, 2013 and the Companies (Prospectus and Allotment of Securities) Rules, 2014.
The Equity Shares have not been and will not be registered under the U.S. Securities Act or registered, listed or
otherwise qualified in any other jurisdiction outside India and may not be offered or sold within the United States
except pursuant to an exemption from, or in a transaction not subject to, the registration requirements of the U.S.
Securities Act and applicable state securities laws. Accordingly, the Equity Shares are being offered and sold (a)
in the United States only to persons who are qualified institutional buyers (as defined in Rule 144A under the U.S.
Securities Act) pursuant to Section 4(a)(2) or another available exemption from registration under the U.S.
Securities Act, and (b) outside the United States in offshore transactions in reliance on Regulation S or pursuant
to another exemption from, or in transactions not subject to, the registration requirements of the U.S. Securities
Act. The Equity Shares are transferable only in accordance with the restrictions described under the sections
“Distribution and Solicitation Restrictions” and “Transfer Restrictions” on pages 153 and 159, respectively.
Qualified Institutions Placement
The Issue is being made only to QIBs in reliance upon Chapter VIII of the SEBI ICDR Regulations and Section
42 of the Companies Act, 2013 read with Rule 14 of the Companies (Prospectus and Allotment of Securities)
Rules, 2014, and, through the mechanism of a QIP. Under Chapter VIII of the SEBI ICDR Regulations and Section
42 of the Companies Act, 2013 read with Rule 14 of the Companies (Prospectus and Allotment of Securities)
Rules, 2014, a company may issue equity shares to QIBs, subject to certain conditions including:
the shareholders of the issuer have passed a special resolution approving such QIP. Such special resolution
must specify that the allotment of securities is proposed to be made pursuant to the QIP at the Relevant Date
as maybe determined by the Board or any of its committee thereof;
equity shares of the same class of such issuer, which are proposed to be allotted through the QIP, are listed
on a recognised stock exchange in India having nation-wide trading terminals for a period of at least one year
prior to the date of issuance of notice to its shareholders for convening the meeting to pass the above-
mentioned special resolution;
142
the aggregate of the proposed issue and all previous QIPs made by the issuer in the same financial year does
not exceed five times the net worth (as defined in the SEBI ICDR Regulations) of the issuer as per the audited
balance sheet of the previous financial year;
the issuer shall be in compliance with the minimum public shareholding requirements set out in the SCRR;
the issuer shall have completed allotments with respect to any prior offer or invitation made by the issuer or
shall have withdrawn or abandoned any prior invitation or offer made by the issuer;
the issuer shall offer to each Allottee at least such number of the securities in the issue which would aggregate
to at least ₹ 20,000 calculated at the face value of the securities;
the offer must be made through a private placement offer letter and an application form serially numbered
and addressed specifically to the QIB to whom the offer is made and is sent within 30 days of recording the
names of such QIBs;
the offering of securities by issue of public advertisements or utilisation of any media, marketing or
distribution channels or agents to inform the public about the issue is prohibited
At least 10% of the equity shares issued to QIBs must be allotted to Mutual Funds, provided that, if this portion
or any part thereof to be allotted to mutual funds remains unsubscribed, it may be allotted to other QIBs.
Bidders are not allowed to withdraw their Bids after the Issue Closing Date.
Additionally, there is a minimum pricing requirement under the SEBI ICDR Regulations. The Floor Price shall
not be less than the average of the weekly high and low of the closing prices of the Equity Shares of the same
class of the Equity Shares of the Issuer quoted on the stock exchange during the two weeks preceding the Relevant
Date. However, a discount of up to 5% of the Floor Price is permitted in accordance with the provisions of the
SEBI ICDR Regulations.
The “Relevant Date” referred to above, for Floor Price, will be the date of the meeting in which the Board of
Directors or any committee duly authorised by the Board of Directors decides to open the Issue and “stock
exchange” means any of the recognised stock exchanges in India on which the equity shares of the issuer of the
same class are listed and on which the highest trading volume in such equity shares has been recorded during the
two weeks immediately preceding the Relevant Date. Further, in accordance with the resolution of our
Shareholders passed on December 12, 2017 our Company may offer a discount of not more than 5% on the Floor
Price
Our Company has applied for and received the in-principle approval of the Stock Exchanges under Regulation
28(1) of the Listing Regulations for the listing of the Equity Shares on the Stock Exchanges. Our Company has
also delivered a copy of this Preliminary Placement Document to the Stock Exchanges.
Our Company shall also make the requisite filings with the RoC and SEBI within the stipulated period as required
under the Companies Act, 2013 and the Companies (Prospectus and Allotment of Securities) Rules, 2014.
The Issue has been authorized by (i) the Board pursuant to a resolution passed on September 21, 2017, and (ii)
the shareholders, pursuant to a resolution passed by postal ballot on December 12, 2017.
The Equity Shares will be Allotted within 12 months from the date of the shareholders’ resolution approving the
QIP and within 60 days from the date of receipt of subscription money from the successful Bidders. For details of
refund of application money, please see the section “Issue Procedure – Pricing and Allocation – Designated Date
and Allotment of Equity Shares” beginning on page 60.
The Equity Shares issued pursuant to the Issue must be issued on the basis of this Preliminary Placement
Document and the Placement Document that shall contain all material information including the information
specified in Schedule XVIII of the SEBI ICDR Regulations and the requirements prescribed under Form PAS-4
of the Companies (Prospectus and Allotment of Securities) Rules, 2014. The Preliminary Placement Document
and the Placement Document are private documents provided to only the QIBs through serially numbered copies
and are required to be placed on the website of the concerned Stock Exchanges and of our Company with a
143
disclaimer to the effect that it is in connection with an issue to QIBs and no offer is being made to the public or
to any other category of investors.
The minimum number of Allottees for the Issue shall not be less than:
two, where the issue size is less than or equal to ₹ 25,000 lakh; and
five, where the issue size is greater than ₹ 25,000 lakh.
No single allottee shall be allotted more than 50 % of the issue size.
QIBs that belong to the same group or that are under common control shall be deemed to be a single allottee. For
details of what constitutes “same group” or “common control”, please see the section “Issue Procedure—
Application Process—Application Form” beginning on page 146.
Securities allotted to a QIB pursuant to the Issue shall not be sold for a period of one year from the date of
allotment except on the floor of a recognised stock exchange in India. Allotments made to FVCIs, VCFs and AIFs
in the Issue are subject to the rules and regulations that are applicable to them, including in relation to lock-in
requirements.
The Equity Shares in this Issue have not been and will not be registered under the U.S. Securities Act, or any state
securities laws of the United States and unless so registered, may not be offered, sold or delivered within the
United States except pursuant to an exemption from, or in a transaction not subject to, the registration requirements
of the U.S. Securities Act and applicable state securities laws in the United States. Accordingly, the Equity Shares
are being offered and sold outside the United States in offshore transactions in reliance on Regulation S and the
applicable laws of the jurisdictions where those offers and sales are made. For a description of certain restrictions
on transfer of the Equity Shares, please see “Transfer Restrictions” on page 159.
The Equity Shares have not been and will not be registered, listed or otherwise qualified in any other jurisdiction
outside India and may not be offered or sold, and Bids may not be made by persons in any such jurisdiction,
except in compliance with the applicable laws of such jurisdiction.
Issue Procedure
1. Our Company and BRLM shall circulate serially numbered copies of this Preliminary Placement Document
and the serially numbered Application Form, either in electronic or physical form, to only the QIBs who are
the QIBs and the Application Form will be specifically addressed to such QIBs who are the QIBs. In terms
of Section 42(3) of the Companies Act, 2013, our Company shall maintain complete records of the QIBs /
QIBs to whom the Preliminary Placement Document and the serially numbered Application Form have been
dispatched. Our Company will make the requisite filings with the RoC and SEBI within the stipulated time
period as required under the Companies Act, 2013 and the Companies (Prospectus and Allotment of
Securities) Rules, 2014.
2. The list of QIBs to whom the Preliminary Placement Document and Application Form is delivered will be
determined by the BRLM in consultation with our Company, at their sole discretion. UNLESS A SERIALLY
NUMBERED PRELIMINARY PLACEMENT DOCUMENT ALONG WITH THE SERIALLY
NUMBERED APPLICATION FORM IS ADDRESSED TO A PARTICULAR QIB, NO INVITATION TO
SUBSCRIBE SHALL BE DEEMED TO HAVE BEEN MADE TO SUCH QIB. Even if such documentation
were to come into the possession of any person other than the intended recipient, no offer or invitation to
offer shall be deemed to have been made to such person and any application that does not comply with this
requirement shall be treated as invalid. Our Company shall intimate the Bid/Issue Opening Date to the Stock
Exchanges.
3. QIBs may submit an Application Form, including any revisions thereof, during the Bidding Period to the
BRLM.
4. Bidders will be required to indicate the following in the Application Form:
name of the QIB to whom Equity Shares are to be Allotted;
number of Equity Shares Bid for;
price at which they are agreeable to subscribe for the Equity Shares, provided that QIBs may also indicate
144
that they are agreeable to submit a Bid at “Cut-off Price”; which shall be any price as may be determined by
our Company in consultation with the BRLM at or above the Floor Price net of such discount as approved in
accordance with SEBI ICDR Regulations;
details of the depository account to which the Equity Shares should be credited; and
a representation that it is outside the United States, and it has agreed to certain other representations set forth
in the Application Form;
SEBI registration number, if applicable;
For Systemically Important NBFCs following documents shall be enclosed with the application (i) the
certificate of registration issued by the RBI under Section 45 –IA of the RBI Act, 1934 and (ii) networth
certificate from its statutory auditors or any independent chartered accountant based on the last audited
financial statements.
Note: Each sub-account of an FII other than a sub-account which is a foreign corporate or a foreign individual
will be considered as an individual QIB and separate Application Forms would be required from each such sub-
account for submitting Bids. FIIs or sub-accounts of FIIs are required to indicate SEBI FII/ sub-account
registration number in the Application Form.
5. Once a duly completed Application Form (including the revision of bids) is submitted by a QIB, such
Application Form constitutes an irrevocable offer and cannot be withdrawn after the Issue Closing Date. The
Issue Closing Date shall be notified to the Stock Exchanges and the QIBs shall be deemed to have been given
notice of such date after receipt of the Application Form.
6. The Bids made by asset management companies or custodians of Mutual Funds shall specifically state the
names of the concerned schemes for which the Bids are made. In case of a Mutual Fund, a separate Bid can
be made in respect of each scheme of the Mutual Fund registered with SEBI. Upon receipt of the Application
Form, after the Issue Closing Date, our Company shall determine the final terms, including the Issue Price of
the Equity Shares to be issued pursuant to the Issue in consultation with the BRLM. Upon determination of
the final terms of the Equity Shares, the BRLM will send the serially numbered CAN to the QIBs who have
been Allocated the Equity Shares. The dispatch of a CAN shall be deemed a valid, binding and irrevocable
contract for the QIB to pay the entire Issue Price for all the Equity Shares Allocated to such QIB. The CAN
shall contain details such as the number of Equity Shares Allocated to the QIB and payment instructions
including the details of the amounts payable by the QIB for Allotment of the Equity Shares in its name and
the Pay-In Date as applicable to the respective QIB. PLEASE NOTE THAT THE ALLOCATION WILL BE
AT THE ABSOLUTE DISCRETION OF OUR COMPANY AND WILL BE BASED ON
RECOMMENDATION OF THE BRLM.
7. Pursuant to receiving a CAN, each successful Bidder shall be required to make the payment of the entire
application monies for the Equity Shares indicated in the CAN at the Issue Price, only through electronic
transfer to our Company’s designated bank account by the Pay-In Date as specified in the CAN sent to the
respective successful Bidder. No payment shall be made by successful Bidder in cash. Please note that any
payment of application money for the Equity Shares shall be made from the bank accounts of the relevant
QIBs applying for the Equity Shares. Monies payable on Equity Shares to be held by joint holders shall be
paid from the bank account of the person whose name appears first in the application. Pending Allotment, all
monies received for subscription of the Equity Shares shall be kept by our Company in a separate bank
account with a scheduled bank and shall be utilised only for the purposes permitted under the Act.
8. Upon receipt of the application monies from the QIBs, our Company shall Allot Equity Shares as per the
details in the CANs sent to the successful Bidder.
9. After passing the resolution for Allotment and prior to crediting the Equity Shares into the depository
participant accounts of the successful Bidders, our Company shall apply to the Stock Exchanges for listing
approvals. Our Company will intimate to the Stock Exchanges the details of the Allotment and apply for
approvals for final listing of the Equity Shares on the Stock Exchanges prior to crediting the Equity Shares
into the beneficiary account maintained with the Depository Participant by the successful Bidder.
10. After receipt of the listing approvals of the Stock Exchanges, our Company shall credit the Equity Shares
Allotted pursuant to this Issue into the Depository Participant accounts of the respective Allottees.
11. Our Company will then apply for the final trading approvals from the Stock Exchanges.
145
12. The Equity Shares that would have been credited to the beneficiary account with the Depository Participant
of the QIBs shall be eligible for trading on the Stock Exchanges only upon the receipt of final trading and
listing approvals from the Stock Exchanges.
13. Upon receipt of intimation of final trading and listing approval from the Stock Exchanges, our Company shall
inform the Allottees of the receipt of such approval. Our Company and the BRLM shall not be responsible
for any delay or non-receipt of the communication of the final trading and listing permissions from the Stock
Exchanges or any loss arising from such delay or non-receipt. Final listing and trading approvals granted by
the Stock Exchanges are also placed on their respective websites. QIBs are advised to apprise themselves of
the status of the receipt of the permissions from the Stock Exchanges or our Company.
Qualified Institutional Buyers
Only QIBs not otherwise excluded pursuant to Regulation 86(1) (b) of the SEBI ICDR Regulations are eligible to
invest. As on date, under Regulation 2(1) (zd) of the SEBI ICDR Regulations, a QIB means:
alternate investment funds registered with SEBI
Eligible FPIs;
foreign venture capital investors registered with SEBI;
insurance companies registered with Insurance Regulatory and Development Authority;
insurance funds set up and managed by army, navy or air force of the Union of India;
insurance funds set up and managed by the Department of Posts, India;
multilateral and bilateral development financial institutions;
Mutual Fund;
pension funds with minimum corpus of ₹ 250 million;
provident funds with minimum corpus of ₹ 250 million;
public financial institutions as defined in Section 4A of the Companies Act, 1956 (Section 2(72) of the
Companies Act, 2013);
scheduled commercial banks;
state industrial development corporation;
the National Investment Fund set up by resolution no. F. No. 2/3/2005-DDII dated November 23, 2005 of the
Government published in the Gazette of India; and
venture capital funds registered with SEBI;
systemically important non-banking financial companies.
FIIs (other than a sub-account which is a foreign corporate or a foreign individual) and Eligible FPIs are permitted
to participate through the portfolio investment scheme under Schedule 2 and Schedule 2A of FEMA 20
respectively, in this Issue. FIIs and Eligible FPIs are permitted to participate in the Issue subject to compliance
with all applicable laws and such that the shareholding of the FPIs do not exceed specified limits as prescribed
under applicable laws in this regard.
In terms of the SEBI FPI Regulations, the issue of Equity Shares to a single FPI or an investor group (which
means the same set of ultimate beneficial owner(s) investing through multiple entities) is not permitted to exceed
10% of our post-Issue Equity Share capital. Further, in terms of the FEMA 20, the total holding by each FPI shall
be below 10% of the total paid-up Equity Share capital of our Company and the total holdings of all FPIs put
together shall not exceed 24% of the paid-up Equity Share capital of our Company. The aggregate limit of 24%
may be increased up to the sectoral cap by way of a resolution passed by the Board of Directors followed by a
special resolution passed by the shareholders of our Company.
Eligible FPIs are permitted to participate in the Issue subject to compliance with conditions and restrictions which
may be specified by the Government from time to time.
An FII or sub-account (other than a sub-account which is a foreign corporate or a foreign individual) who holds a
valid certificate of registration from SEBI shall be deemed to be an FPI until the expiry of the block of three years
for which fees have been paid as per the SEBI FII Regulations. An FII or sub-account (other than a sub-account
which is a foreign corporate or a foreign individual) may participate in the Issue, until the expiry of its registration
as a FII or sub-account, or until it obtains a certificate of registration as FPI, whichever is earlier. If the registration
of an FII or sub-account has expired or is about to expire, such FII or sub-account may, subject to payment of
conversion fees under the SEBI FPI Regulations, participate in the Issue. An FII or sub-account shall not be
eligible to invest as an FII after registering as an FPI under the SEBI FPI Regulations.
146
In terms of the FEMA 20, for calculating the aggregate holding of FPIs in a company, holding of all registered
FPIs as well as holding of FIIs (being deemed FPIs) shall be included. FPI’s investing in this Issue should ensure
that they are eligible under the applicable law or regulation to apply in this Issue.
Allotments to FVCIs, VCFs and AIFs in the Issue are subject to the rules and regulations that are applicable to
them, including in relation to lock-in requirements.
Under Regulation 86(1) (b) of the SEBI ICDR Regulations, no Allotment shall be made pursuant to the Issue,
either directly or indirectly, to any QIB being, or any person related to, the Promoter. QIBs which have all or any
of the following rights shall be deemed to be persons related to the Promoter:
rights under a shareholders’ agreement or voting agreement entered into with the Promoter or persons related
to the Promoter;
veto rights; or
a right to appoint any nominee director on the Board.
Provided, however, that a QIB which does not hold any shares in our Company and which has acquired the
aforesaid rights in the capacity of a lender shall not be deemed to be related to the Promoter.
Our Company and the BRLM are not liable for any amendment or modification or change to applicable laws or
regulations, which may occur after the date of this Preliminary Placement Document. QIBs are advised to make
their independent investigations and satisfy themselves that they are eligible to apply. QIBs are advised to ensure
that any single application from them does not exceed the investment limits or maximum number of Equity Shares
that can be held by them under applicable law or regulation or as specified in this Preliminary Placement
Document. Further, QIBs are required to satisfy themselves that their Bids would not eventually result in
triggering a tender offer under the Takeover Code, and the QIB shall be solely responsible for compliance with
the provisions of the Takeover Code, SEBI (Prohibition of Insider Trading) Regulations, 2015 and other
applicable laws, rules, regulations, guidelines and circulars.
A minimum of 10% of the Equity Shares in the Issue shall be allotted to Mutual Funds. If no Mutual Fund is
agreeable to take up the minimum portion as specified above, such minimum portion (or part thereof not so taken
up) may be allotted to other QIBs.
Note: Affiliates or associates of the BRLM who are QIBs may participate in the Issue in compliance with
applicable laws.
Application Process
Application Form
QIBs shall only use the serially numbered Application Forms (which are addressed to them) supplied by our
Company and the BRLM in either electronic form or by physical delivery for the purpose of making a Bid
(including revision of a Bid) in terms of this Preliminary Placement Document.
By making a Bid (including the revision thereof) for Equity Shares through Application Forms and pursuant to
the terms of this Preliminary Placement Document, the QIB will be deemed to have made the following
representations and warranties and the representations, warranties and agreements made under the sections
“Notice to Investors”, “Representations by Investors”, “Distribution and Solicitation Restrictions” and
“Transfer Restrictions” beginning on pages 1, 3, 153, and 159, respectively:
1. The QIB confirms that it is a QIB in terms of Regulation 2(1) (zd) of the SEBI ICDR Regulations and is
not excluded under Regulation 86 of the SEBI ICDR Regulations, has a valid and existing registration
under the applicable laws in India (as applicable) and is eligible to participate in the Issue;
2. The QIB confirms that it is not a Promoter and is not a person related to the Promoter, either directly or
indirectly and its Application Form does not directly or indirectly represent the Promoter or Promoter
Group or persons related to the Promoter as defined in the SEBI ICDR Regulations;
147
3. The QIB confirms that it has no rights under a shareholders’ agreement or voting agreement with the
Promoter or persons related to the Promoter, no veto rights or right to appoint any nominee director on the
Board other than those acquired in the capacity of a lender which shall not be deemed to be a person related
to the Promoter as defined in the SEBI ICDR Regulations;
4. The QIB acknowledges that it has no right to withdraw its Application after the Issue Closing Date;
5. The QIB confirms that if Equity Shares are Allotted through this Issue, it shall not, for a period of one year
from Allotment, sell such Equity Shares otherwise than on the Stock Exchanges;
6. The QIB confirms that the QIB is eligible to Bid and hold Equity Shares so Allotted. The QIB further
confirms that the holding of the QIB, does not and shall not, exceed the level permissible as per any
applicable regulations applicable to the QIB;
7. The QIB confirms that its Bids would not eventually result in triggering a tender offer under the Takeover
Code;
8. The QIB confirms that to the best of its knowledge and belief, the number of Equity Shares Allotted to it
pursuant to the Issue, together with other Allottees that belong to the same group or are under common
control, shall not exceed 50 % of the Issue Size. For the purposes of this representation:
The expression ‘belong to the same group’ shall derive meaning from the concept of ‘companies under the
same group’ as provided in sub-section (11) of Section 372 of the Companies Act, 1956; and
‘Control’ shall have the same meaning as is assigned to it by Regulation 2(1)(e) of the Takeover Code;
9. The QIBs shall not undertake any trade in the Equity Shares credited to its beneficiary account maintained
with the Depository Participant until such time that the final listing and trading approvals for the Equity
Shares are issued by the Stock Exchanges.
10. The QIB represents that it is outside the United States and is acquiring the Equity Shares in an offshore
transaction in reliance on Regulation S, and is not our affiliate or a person acting on behalf of such an
affiliate and it has agreed to certain other representations set forth in the Application Form. It also confirms
all other applicable representations and warranties included under “Representations by Investors”, “Notice
to Investors”, “Distribution and Solicitation Restrictions” and “Transfer Restrictions” beginning on pages
3, 1, 153 and 159 respectively.
QIBS MUST PROVIDE THEIR DEPOSITORY ACCOUNT DETAILS, PERMANENT ACCOUNT NUMBER,
THEIR DEPOSITORY PARTICIPANT’S NAME, DEPOSITORY PARTICIPANT IDENTIFICATION
NUMBER AND BENEFICIARY ACCOUNT NUMBER IN THE APPLICATION FORM. QIBS MUST
ENSURE THAT THE NAME GIVEN IN THE APPLICATION FORM IS EXACTLY THE SAME AS THE
NAME IN WHICH THE DEPOSITORY ACCOUNT IS HELD. FOR THIS PURPOSE, ELIGIBLE SUB
ACCOUNTS OF AN FII WOULD BE CONSIDERED AS AN INDEPENDENT QIB.
IF SO REQUIRED BY THE BRLM, THE QIB SUBMITTING A BID, ALONG WITH THE APPLICATION
FORM, WILL ALSO HAVE TO SUBMIT REQUISITE DOCUMENT(S) TO THE BRLM TO EVIDENCE
THEIR STATUS AS A "QIB" AS DEFINED HEREINABOVE.
IF SO REQUIRED BY THE BRLM, COLLECTION BANK(S) OR ANY STATUTORY OR REGULATORY
AUTHORITY IN THIS REGARD, INCLUDING AFTER ISSUE CLOSURE, THE QIB SUBMITTING A BID
AND/OR BEING ALLOTTED EQUITY SHARES IN THE ISSUE, WILL ALSO HAVE TO SUBMIT
REQUISITE DOCUMENT(S) TO FULFIL THE KNOW YOUR CUSTOMER (KYC) NORMS.
Demographic details such as address and bank account will be obtained from the Depositories as per the
Depository Participant account details given above.
The submission of an Application Form by a QIB shall be deemed a valid, binding and irrevocable offer for the
QIB to pay the entire Issue Price for the Equity Shares (as indicated by the CAN) and becomes a binding contract
on the QIB upon issuance of the CAN by our Company in favour of the QIB.
148
Bids by Mutual Funds
The bids made by the asset management companies or custodian of Mutual Funds shall specifically state the
names of the concerned schemes for which the Bids are made. Each scheme/fund of a mutual fund registered with
SEBI, will have to submit separate Application Form.
Each mutual fund will have to submit separate Application Forms for each of its participating schemes. Such
applications will not be treated as multiple bids provided that the bids clearly indicate the scheme for which the
bid has been made. However, for the purpose of calculating the number of allotters/applicants, various schemes
of the same mutual fund will be considered as a single allottee/applicant.
As per the current regulations, the following restrictions are applicable for investments by Mutual Funds:
No Mutual Fund scheme shall invest more than 10% of its net asset value in Equity Shares or equity related
instruments of any company provided that the limit of 10% shall not be applicable for investments in case of index
funds or sector or industry specific funds. No Mutual Fund under all its schemes should own more than 10% of
any company's paid-up capital carrying voting rights.
Bids by Systemically Important NBFCs
In case of application made by Systemically Important NBFCs registered with the RBI (i) the certificate of
registration issued by the RBI under Section 45 –IA of the RBI Act, 1934 and (ii) networth certificate from its
statutory auditors or any independent chartered accountant based on the last audited financial statements is
required to be attached to the application.
Please note that pursuant to the applicability of the directions issued by SEBI vide its circular bearing number
CIR/ CFD/ DIL/ 1/ 2011 dated April 29, 2011, all applicants who are QIBs, Non-Institutional Investors or are
applying in the Issue for Equity Shares for an amount exceeding ₹2 Lakh shall mandatorily make use of ASBA
facility, subject to their fulfilling the eligibility conditions to be an ASBA Investor. Further, all QIB applicants
and Non-Institutional Investors are mandatorily required to use ASBA, even if application amount does not exceed
₹2 Lakh subject to their fulfilling the eligibility conditions to be an ASBA Investor.
The above information is given for the benefit of the Bidders. We and the BRLM are not liable for any
amendments or modification or changes in applicable laws or regulations, which may happen after the date of this
Preliminary Placement Document. Bidders are advised to make their independent investigations and ensure that
the number of Equity Shares Bid for do not exceed the applicable limits under the applicable laws and regulations.
Submission of Application Form
All Application Forms must be duly completed with information including but not limited to the number of Equity
Shares applied for. All Application Forms duly completed along with payment and a copy of the PAN card or
PAN allotment letter shall be submitted to the BRLM either through electronic form or through physical delivery
at the following address:
Name Address Contact Person Contact Details
ICICI Securities
Limited
ICICI Center, H.T.
Parekh Marg
Churchgate,
Mumbai – 400 020
Maharashtra, India
Mr. Rishi Tiwari
/ Mr. Vishal
Kanjani
Tel : +91 22 6637 7176
Fax: +91 22 2282 6580
Email:[email protected]
Website: www.icicisecurities.com
The BRLM shall not be required to provide any written acknowledgement of receipt of the Application Form.
Permanent Account Number or PAN
Each QIB should mention its PAN allotted under the IT Act in the Application Form. Applications without this
information will be considered incomplete and are liable to be rejected. QIBs should not submit the GIR number
instead of the PAN as the Application Form is liable to be rejected on this ground.
Pricing and Allocation
149
Build-up of the Book
The QIBs shall submit their Bids (including the revision of bids) within the Bidding Period to the BRLM. Such
Bids cannot be withdrawn after the Issue Closing Date. The book shall be maintained by the BRLM.
Price Discovery and Allocation
Our Company, in consultation with the BRLM, shall determine the Issue Price, which shall be at or above the
Floor Price. However, our Company may offer a discount of not more than five (5) % on the Floor Price in terms
of Regulation 85 of the SEBI ICDR Regulations.
After finalization of the Issue Price, our Company shall update this Preliminary Placement Document with the
Issue details and file the same with the Stock Exchanges as the Placement Document.
Method of Allocation
Our Company shall determine the Allocation in consultation with the BRLM on a discretionary basis and in
compliance with Chapter VIII of the SEBI ICDR Regulations. Bids received from the QIBs at or above the Issue
Price shall be grouped together to determine the total demand.
The Allocation to all such QIBs will be made at the Issue Price. Allocation shall be decided by us in consultation
with the BRLM on a discretionary basis. Allocation to Mutual Funds for up to a minimum of 10 % of the Issue
Size shall be undertaken subject to valid Bids being received at or above the Issue Price.
THE DECISION OF OUR COMPANY IN CONSULTATION WITH THE BRLM IN RESPECT OF
ALLOCATION SHALL BE FINAL AND BINDING ON ALL QIBS. QIBS MAY NOTE THAT ALLOCATION
OF EQUITY SHARES IS AT THE SOLE AND ABSOLUTE DISCRETION OF OUR COMPANY IN
CONSULTATION WITH THE BRLM AND QIBS MAY NOT RECEIVE ANY ALLOCATION EVEN IF
THEY HAVE SUBMITTED VALID APPLICATION FORMS AT OR ABOVE THE ISSUE PRICE. NEITHER
OUR COMPANY NOR THE BRLM ARE OBLIGED TO ASSIGN ANY REASON FOR ANY NON-
ALLOCATION.
CAN
Based on the Application Forms received, our Company, in consultation with the BRLM, in their sole and absolute
discretion, shall decide the successful Bidder to whom the serially numbered CAN shall be sent, pursuant to which
the details of the Equity Shares Allocated to them and the details of the amounts payable for Allotment of such
Equity Shares in their respective names shall be notified to such successful Bidder. Additionally, a CAN will
include details of the relevant Escrow Account into which such payments would need to be made, address where
the application money needs to be sent, Pay-In Date as well as the probable designated date, being the date of
credit of the Equity Shares to the respective successful Bidder’s account.
The successful Bidders would also be sent the serially numbered Placement Document. The dispatch of the serially
numbered Placement Document and the serially numbered CAN to the successful QIBs shall be deemed a valid,
binding and irrevocable contract for the QIB to furnish all details that may be required by Company and the BRLM
and to pay the entire Issue Price for all the Equity Shares Allocated to such QIB.
QIBs are advised to instruct their Depository Participant to accept the Equity Shares that may be Allotted to them
pursuant to the Issue.
Bank Account for Payment of Application Money
Our Company has opened an escrow bank account; the “ITD Cementation India Limited – QIP Escrow Account”
with Axis Bank in terms of the arrangement among our Company, the BRLM and Axis Bank as Escrow Bank.
The QIB will be required to deposit the entire amount payable for the Equity Shares Allocated to it by the Pay-In
Date as mentioned in, and in accordance with, the respective CAN.
Payments are to be made only through electronic fund transfer.
Note: Payments through cheques are liable to be rejected.
If the payment is not made favouring “ITD Cementation India Limited – QIP Escrow Account” within the time
150
stipulated in the CAN, the Application Form and the CAN of the QIB are liable to be cancelled.
Our Company undertakes to utilise the amount deposited in “ITD Cementation India Limited – QIP Escrow
Account” only for the purposes of (i) adjustment against Allotment of Equity Shares in the Issue; or (ii) repayment
of application money if our Company is not able to Allot Equity Shares in the Issue.
In case of cancellations or default by the QIBs, our Company, the BRLM has the right to reallocate the Equity
Shares at the Issue Price among existing or new QIBs at their sole and absolute discretion.
Designated Date and Allotment of Equity Shares
The Equity Shares will not be Allotted unless the successful QIBs pay the amount payable as mentioned in the
CAN issued to them to the “ITD Cementation India Limited – QIP Escrow Account” as stated above. The Equity
Shares in the Issue will be issued and Allotment shall be made only in dematerialized form to the Allottees.
Allottees will have the option to re-materialize the Equity Shares, if they so desire, as per the provisions of the
Companies Act and the Depositories Act. Post the Allotment, the successful Bidders/Allottee would also be sent
a serially numbered Placement Document either in electronic form or by physical delivery.
Our Company, at its sole discretion, reserves the right to cancel the Issue at any time up to Allotment without
assigning any reason whatsoever. Post the Allotment and credit of Equity Shares into the QIBs’ Depository
Participant accounts, our Company will apply for final trading and listing approvals from the Stock Exchanges.
In the case of QIBs who have been Allotted more than 5% of the Equity Shares in the Issue, our Company shall
disclose the name and the number of the Equity Shares Allotted to such QIB to the Stock Exchanges and the Stock
Exchanges will make the same available on their website.
The Escrow Bank shall release the monies lying to the credit of the Escrow Cash Account to our Company after
Allotment of Equity Shares to QIBs.
In accordance with the Companies Act, 2013, in the event that our Company is unable to issue and Allot the
Equity Shares offered in the Issue or there is a cancellation of the Issue within 60 days from the date of receipt of
application money from a successful Bidder, our Company shall repay the application money within 15 days from
expiry of 60 day period, failing which our Company shall repay that money to such successful Bidders with
interest at the rate of 12 % per annum from expiry of the 60th day. The application money to be refunded by our
Company shall be refunded to the same bank account from which application money was remitted by the QIBs.
Other Instructions
Right to Reject Applications
Our Company, in consultation with the BRLM, may reject Bids, in part or in full, without assigning any reason
whatsoever. The decision of our Company and the BRLM in relation to the rejection of Bids shall be final and
binding.
Equity Shares in dematerialized form with NSDL or CDSL
The Allotment of the Equity Shares in the Issue shall be only in dematerialized form (i.e., not in physical
certificates but be fungible and be represented by the statement issued through the electronic mode). A QIB
applying for Equity Shares to be issued pursuant to the Issue must have at least one beneficiary account with a
Depository Participant of either NSDL or CDSL prior to making the Bid. Allotment to a successful QIB will be
credited in electronic form directly to the beneficiary account (with the Depository Participant) of the QIB.
Equity Shares in electronic form can be traded only on the stock exchanges having electronic connectivity with
NSDL and CDSL. The Stock Exchanges have electronic connectivity with NSDL and CDSL. The trading of the
Equity Shares to be issued pursuant to the Issue would be in dematerialised form only for all QIBs in the demat
segment of the respective Stock Exchanges.
Our Company and the BRLM will not be responsible or liable for the delay in the credit of Equity Shares to be
issued pursuant to the Issue due to errors in the Application Form or otherwise on part of the QIBs.
Release of funds to our Company
151
The Escrow Bank shall not release the monies lying to the credit of the “ITD Cementation India Limited – QIP
Escrow Account” till such time, that it receives an instruction in pursuance to the Escrow Agreement, along with
the Listing approval of the Stock Exchanges for the Equity Shares offered in the Issue.
Equity Shares in dematerialized form with NSDL or CDSL
The Allotment of the Equity Shares in this Issue shall be only in dematerialized form (i.e., not in the form of
physical certificates but be fungible and be represented by the statement issued through the electronic mode).
1. A QIB applying for Equity Shares in the Issue must have at least one beneficiary account with a
Depository Participant of either NSDL or CDSL prior to making the Bid.
2. The Equity Shares Allotted to a successful QIB will be credited in electronic form directly to the
beneficiary account (with the Depository Participant) of the QIB.
3. Equity Shares in electronic form can be traded only on the stock exchanges having electronic connectivity
with NSDL and CDSL. The BSE and the NSE have electronic connectivity with CDSL and NSDL.
4. The trading of the Equity Shares issued pursuant to the Issue would be in dematerialized form only for
all QIBs in the demat segment of the respective Stock Exchanges.
5. Our Company and the BRLM will not be responsible or liable for the delay in the credit of Equity Shares
due to errors in the Application Form or otherwise on the part of the QIBs.
For details of our Company Secretary and Compliance Officer, see the section titled “General Information” on
page 193
152
PLACEMENT
Placement Agreement
The BRLM has entered into a placement agreement dated January 24, 2018 with our Company, pursuant to which
the BRLM has agreed to procure, on a reasonable efforts basis, QIBs to subscribe for Equity Shares to be issued
pursuant to the Issue, pursuant to Chapter VIII of the SEBI ICDR Regulations and applicable provisions of the
Companies Act and Rules made thereunder.
The Placement Agreement contains customary representations and warranties as well as indemnities from us and
is subject to certain conditions and termination provisions contained therein.
Applications will be made to list the Equity Shares and admit them to trading on the Stock Exchanges. No
assurance can be given as to the liquidity or sustainability of the trading market for the Equity Shares, the ability
of holders of the Equity Shares to sell their Equity Shares or the price at which holders of the Equity Shares will
be able to sell their Equity Shares.
The Equity Shares in this Issue have not been and will not be registered under the U.S. Securities Act, or any state
securities laws of the United States and unless so registered, may not be offered, sold or delivered within the
United States except pursuant to an exemption from, or in a transaction not subject to, the registration requirements
of the U.S. Securities Act and applicable state securities laws in the United States. Accordingly, the Equity Shares
are being offered and sold outside the United States in offshore transactions in reliance on Regulation S and the
applicable laws of the jurisdictions where those offers and sales are made. The Equity Shares are transferable only
in accordance with the restrictions described under the sections “Distribution and Solicitation Restrictions” and
“Transfer Restrictions” on pages 153 and 159 respectively.
This Preliminary Placement Document has not been, and will not be, registered as a prospectus with the Registrar
of Companies in India and no Equity Shares will be offered in India or overseas to the public or any members of
the public in India or to any class of investors other than QIBs.
In connection with the Issue, the BRLM (or their affiliates) may, for their own accounts, enter into asset swaps,
credit derivatives or other derivative transactions relating to the Equity Shares at the same time as the offer and
sale of the Equity Shares, or in secondary market transactions. As a result of such transactions, the BRLM may
hold long or short positions in such Equity Shares. These transactions may comprise a substantial portion of the
Issue and no specific disclosure will be made of such positions. Affiliates of the BRLM may purchase Equity
Shares and be allocated Equity Shares.
153
DISTRIBUTION AND SOLICITATION RESTRICTIONS
The distribution of this Preliminary Placement Document and the offer, sale or delivery of the Equity Shares is
restricted by law in certain jurisdictions. Persons who come into possession of this Preliminary Placement
Document or any other offering material relating to the Equity Shares are advised to take legal advice with regard
to any restrictions that may be applicable to them and to observe such restrictions. This Preliminary Placement
Document may not be used for the purpose of an offer or sale in any circumstances in which such offer or sale is
not authorized or permitted.
GENERAL
No action has been taken or will be taken that would permit a public offering of the Equity Shares to occur in any
jurisdiction, or the possession, circulation or distribution of this Preliminary Placement Document or any other
material relating to the Company or the Equity Shares in any jurisdiction where action for such purpose is required.
Accordingly, the Equity Shares may not be offered or sold, directly or indirectly, and neither this Preliminary
Placement Document nor any offering materials or advertisements in connection with the Equity Shares may be
distributed or published in or from any country or jurisdiction except under circumstances that will result in
compliance with any applicable rules and regulations of any such country or jurisdiction. The Issue will be made
in compliance with the applicable SEBI ICDR Regulations. Each purchaser of the Equity Shares in the Issue will
be required to make, or be deemed to have made, as applicable, the acknowledgments and agreements as described
under “Transfer Restrictions”.
India
This Preliminary Placement Document may not be distributed, directly or indirectly, in India or to residents of
India and any Equity Shares may not be offered or sold, directly or indirectly, in India to, or for the account or
benefit of, any resident of India except as permitted by applicable Indian laws and regulations, under which an
offer is strictly on a private and confidential basis and is limited to eligible QIBs. This Preliminary Placement
Document is neither a public issue nor a prospectus under the Companies Act or an advertisement and should not
be circulated to any person other than to whom the offer is made.
Australia
This Preliminary Placement Document and the offer of Equity Shares are only made available in Australia to
persons to whom a disclosure document is not required to be given under Chapter 6D of the Australian
Corporations Act 2001 (the “Australian Corporations Act”) and has not been and will not be lodged or registered
with the Australian Securities & Investments Commission or any other regulatory body or agency in Australia.
This Preliminary Placement Document is not a prospectus, product disclosure statement or any other form of
formal “disclosure document” for the purposes of the Australian Corporations Act and is not required to, and does
not, contain all the information which would be required in a disclosure document under the Australian
Corporations Act. (i) The offer of the Equity Shares under this Preliminary Placement Document is only made to
persons to whom it is lawful to offer the Equity Shares without a disclosure document such as a professional
investor or sophisticated investor for the purposes of Chapter 6D of the Australian Corporations Act; (ii) this
Preliminary Placement Document is made available in Australia to persons as set forth in clause (i) above; and
(iii) by accepting this offer, the offeree represents that the offeree is such a person as set forth in clause (ii) above
and agrees not to sell or offer for sale within Australia any Equity Shares sold to the offeree within 12 months
after their transfer to the offeree under this Preliminary Placement Document.
Cayman Islands
This Preliminary Placement Document does not constitute an invitation or offer to the public in the Cayman
Islands of the Equity Shares, whether by way of sale or subscription. The Equity Shares are not offered or sold,
and will not be offered or sold, directly or indirectly, to the public in the Cayman Islands.
Dubai International Financial Centre
This Preliminary Placement Document relates to an "exempt offer" in accordance with the Dubai Financial
Services Authority (“DFSA”) Rulebook Markets Module, and which is not subject to any form of regulation or
approval by the DFSA. The DFSA has no responsibility for reviewing or verifying this Preliminary Placement
Document or any other documents in connection with this offer. Accordingly, the DFSA has not approved this
Preliminary Placement Document or any other associated documents nor taken any steps to verify the information
154
set out in this Preliminary Placement Document, and has no responsibility for it. The shares to which this
Preliminary Placement Document relates may be illiquid and/or subject to restrictions on their resale. Prospective
purchasers should conduct their own due diligence on the shares. If you do not understand the contents of this
document you should consult an authorised financial adviser. This Preliminary Placement Document may only be
provided to Professional Clients as defined in the DFSA Rulebook Conduct of Business Module (“COB Module”).
This offer is not directed at Retail Clients as defined in the COB Module.
European Economic Area
In relation to each member state of the European Economic Area which has implemented the Prospectus Directive
(each, a “Relevant Member State”), the Book Running Lead Manager has represented and warranted that it has
not made and will not make an offer to the public of any Equity Shares which are the subject of the issue of Equity
Shares contemplated by this Preliminary Placement Document in that Relevant Member State, except that the
Equity Shares may be offered to the public in that Member State at any time under the following exemptions
under the Prospectus Directive, if they have been implemented in that Relevant Member State:
1. to any legal entity which is a qualified investor, as defined in the Prospectus Directive (as defined below);
2. to fewer than 150 natural or legal persons (other than qualified investors as defined in the Prospectus Directive
or supplement a prospectus pursuant to Article 16 at the Prospectus Directive), subject to obtaining the prior
consent of the Book Running Lead Manager nominated by the Company for any such offer; or
3. at any time in any other circumstances falling within Article 3(2) of the Prospectus Directive, provided that
no such offer of the Equity Shares shall result in a requirement for the publication by the Company or the
Book Running Lead Manager of a prospectus or the initial purchaser of a prospectus pursuant to Article 3 of
the Prospectus Directive and each person who initially acquires any Equity Shares or to whom any offer is
made will be deemed to have represented, acknowledged and agreed with the Book Running Lead Manager
and the Company that it is a qualified investor within the meaning of the law of the Relevant Member State
implementing Article 2(1)I of the Prospectus Directive or any measure implementing the Prospectus Directive
in any Relevant Member State.
For the purposes of this provision, the expression “an offer to the public” in relation to any securities in any
Relevant Member State means the communication in any form and by any means of sufficient information on the
terms of the offer and any securities to be offered so as to enable an investor to decide to purchase any securities,
as the same may be varied in that Member State by any measure implementing the Prospectus Directive in that
Member State and the expression “Prospectus Directive” means Directive 2003/71/EC (and amendments thereto,
including the 2010 PD Amending Directive, to the extent implemented in the Relevant Member State), and
includes any relevant implementing measure in each Relevant Member State and the expression “2010 PD
Amending Directive” means Directive 2010/73/EU.
Hong Kong
This Preliminary Placement Document has not been approved by the Securities and Futures Commission in Hong
Kong and, accordingly, (i) the Equity Shares have not been offered or sold and will not be offered or sold in Hong
Kong, by means of any document, other than (a) to “professional investors” as defined in the Securities and
Futures Ordinance (Cap. 571) of Hong Kong (the “SFO”) and any rules made under that SFO; or (b) in other
circumstances which do not result in the document being a “prospectus” as defined in the Companies (Winding
up and Miscellaneous Provisions) Ordinance (Cap. 32) (the “CWUMPO”) of Hong Kong or which do not
constitute an offer to the public within the meaning of the CWUMPO; and (ii) the Book Running Lead Manager
has not issued or had in its possession for the purposes of the issue of Equity Shares whether in Hong Kong or
elsewhere any advertisement, invitation or document relating to the Equity Shares, which is directed at, or the
contents of which are likely to be accessed or read by, the public of Hong Kong (except if permitted to do so under
the securities laws of Hong Kong), other than with respect to Equity Shares which are or are intended to be
disposed of only to persons outside Hong Kong or only to “professional investors” as defined in the SFO and any
rules made under the SFO.
Japan
The Equity Shares have not been and will not be registered under the Financial Instruments and Exchange Law
of Japan (Act No. 25 of 1948, as amended; the “FIEA”) The Book Running Lead Manager has represented and
agreed that it will not offer or sell any Equity Shares, directly or indirectly, in Japan or to, or for the benefit of,
155
any resident in Japan (as defined under Item 5, Paragraph 1, Article 6 of the Foreign Exchange and Foreign Trade
Act (Act No. 228 of 1949, as amended)), or to others for reoffering or resale, directly or indirectly, in Japan or to,
or for the benefit of, a resident of Japan except pursuant to an exemption from the registration requirements of,
and otherwise in compliance with, the FIEA and any other applicable laws, regulations and ministerial guidelines
of Japan.
Korea
The Equity Shares have not been and will not be registered under the Financial Investment Business and Capital
Markets Act of Korea and none of the Equity Shares may be offered or sold, directly or indirectly, in Korea or to
any resident of Korea or to any persons for reoffering or resale, directly or indirectly, in Korea or to any resident
of Korea (as defined under the Foreign Exchange Transaction Act of Korea and its Enforcement Decree) except
pursuant to an exemption from the registration requirements of the Financial Investment Business and Capital
Markets Act of Korea available thereunder and/or in compliance with applicable laws and regulations of Korea.
Kuwait
This Preliminary Placement Document is not for general circulation to the public in Kuwait. The Equity Shares
have not been licensed for offering in Kuwait by the Kuwait Capital Markets Authority or any other relevant
Kuwaiti government agency. The offering of the Equity Shares in Kuwait on the basis a private placement or
public offering is, therefore, restricted in accordance with Law No. 7 of 2010 and the bylaws thereto (as amended).
No private or public offering of the Equity Shares is being made in Kuwait, and no agreement relating to the sale
of the Equity Shares will be concluded in Kuwait. No marketing or solicitation or inducement activities are being
used to offer or market the Equity Shares in Kuwait.
Malaysia
No prospectus or other offering material or document in connection with the offer and sale of the Equity Shares
has been or will be registered with the Securities Commission of Malaysia pursuant to the Securities Commission
Act, 1993 as the offer for purchase of, or invitation to purchase the Equity Shares is meant to qualify as an
“excluded offer or excluded invitation” within the meaning of Section 38 of the Securities Commission Act, 1993.
Each Lead Manager has severally represented, warranted or agreed that the Equity Shares will not be offered,
sold, transferred or otherwise disposed, directly or indirectly, nor any document or other material in connection
therewith distributed, in Malaysia, other than to persons falling within any one of the categories or person specified
in Schedule 2 and/or Schedule 3 of the Securities Commission Act, 1993 who are also persons to whom any offer
or invitation to purchase or sell would be an excluded offer or invitation within the meaning of Section 38 of the
Securities Commission Act, 1993.
Mauritius
The Equity Shares are not being offered to the public in Mauritius and nothing in the Preliminary Placement
Document or any information contained herein may be treated as a prospectus for the purposes of the Securities
Act 2005 of Mauritius. The Mauritius Financial Services Commission (FSC) has neither reviewed nor approved
the Preliminary Placement Document and the Company does not hold any licence issued by the FSC. Accordingly,
the Preliminary Placement Document has not been registered with the FSC. Equity Shares are being offered by
way of private placement only to the person to whom such offer has been made.
Only persons licensed by the FSC as, investment dealers, investment advisers or investment bankers conducting
activities as an investment dealer or investment adviser may market and carry out any form of solicitation in
Mauritius in respect to the offer, distribution or sale of the Equity Shares. Where solicitation does not exist, a
licensee as distributors of financial products may distribute the Equity Shares. The Equity Shares may not be
offered, distributed or sold, directly or indirectly, in Mauritius, except as permitted by applicable Mauritius law,
including but not limited to Securities Act 2005 of Mauritius.
The Company has not been authorized (or recognized) and does not intend to seek authorization (or recognition)
with the FSC, and the FSC expresses no opinion as to the matters contained in the Preliminary Placement
Document and as to the merits of an investment in the Company. There is no statutory compensation scheme in
Mauritius in the event of the Company’s failure.
New Zealand
156
This Preliminary Placement Document is not a prospectus. It has not been prepared or registered in accordance
with the Securities Act 1978 of New Zealand (the “New Zealand Securities Act”). This Preliminary Placement
Document is being distributed in New Zealand only to persons whose principal business is the investment of
money or who, in the course of and for the purposes of their business, habitually invest money, within the meaning
of section 3(2)(a)(ii) of the New Zealand Securities Act (“Habitual Investors”). By accepting this Preliminary
Placement Document, each investor represents and warrants that if they receive this Preliminary Placement
Document in New Zealand they are a Habitual Investor and they will not disclose this Preliminary Placement
Document to any person who is not also a Habitual Investor.
Oman
By receiving this Preliminary Placement Document, the person or entity to whom it has been issued understands,
acknowledges and agrees that this Preliminary Placement Document has not been approved by the Capital Market
Authority of Oman (the “CMA”) or any other regulatory body or authority in the Sultanate of Oman (“Oman”),
nor has the Book Running Lead Manager or any placement agent acting on its behalf received authorisation,
licensing or approval from the CMA or any other regulatory authority in Oman, to market, offer, sell, or distribute
interests in the Equity Shares within Oman.
No marketing, offering, selling or distribution of any interests in the Equity Shares has been or will be made from
within Oman and no subscription for any interests in the Equity Shares may or will be consummated within Oman.
Neither the Book Running Lead Manager nor any placement agent acting on its behalf is a company licensed by
the CMA to provide investment advisory, brokerage, or portfolio management services in Oman, nor a bank
licensed by the Central Bank of Oman to provide investment banking services in Oman. Neither the Book Running
Lead Manager nor any placement agent acting on its behalf advise persons or entities resident or based in Oman
as to the appropriateness of investing in or purchasing or selling securities or other financial products.
Nothing contained in this Preliminary Placement Document is intended to constitute Omani investment, legal,
tax, accounting or other professional advice. This Preliminary Placement Document is for your information only,
and nothing herein is intended to endorse or recommend a particular course of action. You should consult with an
appropriate professional for specific advice on the basis of your situation.
Qatar
This document does not, and is not intended to, constitute an invitation or an offer of securities in the State of
Qatar (including the Qatar Financial Centre) and accordingly should not be construed as such. The Equity Shares
have not been, and shall not be, offered, sold or delivered at any time, directly or indirectly, in the State of Qatar.
Any offering of the Equity Shares shall not constitute a public offer of securities in the State of Qatar.
By receiving this document, the person or entity to whom it has been provided to understands, acknowledges and
agrees that: (i) neither this Preliminary Placement Document nor the Equity Shares have been registered,
considered, authorized or approved by the Qatar Central Bank, the Qatar Financial Markets Authority, the Qatar
Financial Centre Regulatory Authority or any other authority or agency in the State of Qatar; (ii) neither the
Company nor persons representing the Company are authorized or licensed by the Qatar Central Bank, the Qatar
Financial Markets Authority, the Qatar Financial Centre Regulatory Authority, or any other authority or agency
in the State of Qatar, to market or sell the Equity Shares within the State of Qatar; (iii) this Preliminary Placement
Document may not be provided to any person other than the original recipient and is not for general circulation in
the State of Qatar; and (iv) no agreement relating to the sale of the Equity Shares shall be consummated within
the State of Qatar.
No marketing of the Equity Shares has been or will be made from within the State of Qatar and no subscription
to the Equity Shares may or will be consummated within the State of Qatar. Any applications to invest in the
Equity Shares shall be received from outside of Qatar. This document shall not form the basis of, or be relied on
in connection with, any contract in Qatar. Neither the Company nor persons representing the Company are, by
distributing this document, advising individuals resident in the State of Qatar as to the appropriateness of investing
in or purchasing or selling securities or other financial products. Nothing contained in this document is intended
to constitute investment, legal, tax, accounting or other professional advice in, or in respect of, the State of Qatar.
Saudi Arabia
Any investor in the Kingdom of Saudi Arabia or who is a Saudi person (a “Saudi Investor”) who acquires Equity
Shares pursuant to the Issue should note that the offer of Equity Shares is an offer to “Sophisticated Investors” (as
157
defined in Article 11 of the “Offer of Securities Regulations” as issued by the Board of the Capital Market
Authority resolution number 2-11-2004 dated October 4, 2004 and amended by the Board of the Capital Market
Authority resolution number 1-28-2008 dated August 18, 2008 (the “KSA Regulations”)) for the purposes of
Article 9 of the KSA Regulations. The Book Running Lead Manager has represented, warranted and agreed that
the offer of the Equity Shares will only be directed at Sophisticated Investors.
The offer of Equity Shares shall not therefore constitute a “public offer” pursuant to the KSA Regulations, but is
subject to the restrictions on secondary market activity under Article 17 of the KSA Regulations. Any Saudi
Investor who has acquired Equity Shares as a Sophisticated Investor may not offer or sell those Equity Shares to
any person unless the offer or sale is made through an authorised person appropriately licensed by the Saudi
Arabian Capital Market Authority and (i) the Equity Shares are offered or sold to a Sophisticated Investor; (ii) the
price to be paid for the Equity Shares in any one transaction is equal to or exceeds Saudi Arabian Riyal 1 million
or an equivalent amount; or (iii) the offer or sale is otherwise in compliance with Article 17 of the KSA
Regulations.
Singapore
The Book Running Lead Manager has acknowledged that this Preliminary Placement Document has not been
registered as a prospectus with the Monetary Authority of Singapore. Accordingly, the Book Running Lead
Manager has represented and agreed that it has not offered or sold any Equity Shares issued pursuant to the Issue
or caused such Equity Shares to be made the subject of an invitation for subscription or purchase and will not
offer or sell such Equity Shares issued pursuant to the Issue or cause such Equity Shares to be made the subject
of an invitation for subscription or purchase, and have not circulated or distributed, nor will they circulate or
distribute, this Preliminary Placement Document or any other document or material in connection with the offer
or sale, or invitation for subscription or purchase, of such Equity Shares issued pursuant to the Issue, whether
directly or indirectly, to persons in Singapore other than (i) to an institutional investor under Section 274 of the
Securities and Futures Act, Chapter 289 of Singapore (“SFA”), (ii) to a relevant person pursuant to Section 275(1),
or any person pursuant to Section 275(1A), and in accordance with the conditions specified in Section 275 of the
SFA, or (iii) otherwise pursuant to, and in accordance with the conditions of, any other applicable provision of
the SFA.
Where the Equity Shares are subscribed or purchased under Section 275 by a relevant person which is:
a corporation (which is not an accredited investor) (as defined in Section 4A of the SFA) the sole business of
which is to hold investments and the entire share capital of which is owned by one or more individuals, each
of whom is an accredited investor; or
a trust (where the trustee is not an accredited investor) whose sole purpose is to hold investments and each
beneficiary of the trust is an individual who is an accredited investor, securities (as defined in Section 239(1)
of the SFA) of that corporation to the beneficiaries’ rights and interest (howsoever described) in that trust shall
not be transferred within 6 months after that corporation or that trust has acquired the Equity Shares pursuant
to an offer made under Section 275 except:
to an institutional investor under Section 274 of the SFA or to a relevant person defined in Section 275(2) of
the SFA, or to any person arising from an offer referred to in Section 275(1A) or Section 276(4)(i)(B) of the
SFA;
where no consideration is or will be given for the transfer;
where the transfer is by operation of law;
as specified in Section 276(7) of the SFA; or
as specified in Regulation 32 of the Securities and Futures (Offers of Investments) (Shares and Debentures)
Regulations 2005 of Singapore.
United Arab Emirates (excluding the Dubai International Financial Centre)
This Preliminary Placement Document is not intended to constitute an offer, sale or delivery of shares or other
securities under the laws of the United Arab Emirates (the “UAE”). The Equity Shares have not been and will not
be registered under Federal Law No. 4 of 2000 Concerning the Emirates Securities and Commodities Authority
and the Emirates Security and Commodity Exchange, or with the UAE Central Bank, the Dubai Financial Market,
158
the Abu Dhabi Securities market or with any other UAE exchange. the Issue, the Equity Shares and interests
therein do not constitute a public offer of securities in the UAE in accordance with the Commercial Companies
Law, Federal Law No. 8 of 1984 (as amended) or otherwise. This Preliminary Placement Document is strictly
private and confidential and is being distributed to a limited number of investors and must not be provided to any
person other than the original recipient, and may not be reproduced or used for any other purpose. The interests
in the Equity Shares may not be offered or sold directly or indirectly to the public in the UAE.
By receiving this Preliminary Placement Document, the person or entity to whom this Preliminary Placement
Document has been issued understands, acknowledges and agrees that the Equity Shares have not been and will
not be offered, sold or publicly promoted or advertised in the Dubai International Financial Centre other than in
compliance with laws applicable in the Dubai International Financial Centre, governing the issue, offering or sale
of securities. The Dubai Financial Services Authority has not approved this Preliminary Placement Document nor
taken steps to verify the information set out in it, and has no responsibility for it.
United Kingdom
The Book Running Lead Manager has represented, warranted and undertaken that:
1. it has only communicated or caused to be communicated and will only communicate or cause to be
communicated in the United Kingdom any invitation or inducement to engage in investment activity (within
the meaning of section 21 of the Financial Services and Markets Act 2000 (“FSMA”) received by it in
connection with the issue or sale of any Equity Shares in circumstances in which section 21(1) of FSMA does
not apply to the Company; and
2. it has complied and will comply with all applicable provisions of FSMA with respect to anything done by it
in relation to the Equity Shares in, from or otherwise involving the United Kingdom.
United States of America
The Equity Shares offered in the Issue have not been and will not be registered under the U.S. Securities Act or
any state securities laws in the United States and may not be offered, sold or delivered in the United States except
pursuant to an exemption from, or in a transaction not subject to, the registration requirements of the U.S.
Securities Act and in accordance with any applicable state securities laws. The Equity Shares are being offered
and sold in the Issue only outside the United States in accordance with Regulation S in accordance with Regulation
S and the applicable laws of the jurisdictions where those offers and sales are made. To help ensure that the offer
and sale of the Equity Shares in the Issue was made in compliance with Regulation S, each purchaser of Equity
Shares in the Issue will be deemed to have made the representations, warranties, acknowledgements and
undertakings set forth in “Transfer Restrictions” on page 159.
159
TRANSFER RESTRICTIONS
Due to the following restrictions, investors are advised to consult legal counsel prior to purchasing Equity Shares
or making any offer, resale, pledge or transfer of the Equity Shares.
Pursuant to Chapter VIII of the SEBI ICDR Regulations, successful Bidder are not permitted to sell the Equity
Shares Allotted pursuant to the Issue for a period of one year from the date of Allotment, except on the Stock
Exchanges. Additionally, purchasers are deemed to have represented, agreed and acknowledged as below with
respect to purchase and sale of Equity Shares.
The Equity Shares have not been and will not be registered under the U.S. Securities Act and may not be offered
or sold within the United States except pursuant to an exemption from, or in a transaction not subject to, the
registration requirements of the U.S. Securities Act and applicable United States state securities laws.
Accordingly, the Equity Shares are being offered and sold only outside the United States in offshore transactions
in reliance on Regulation S, under the U.S. Securities Act and applicable laws of the jurisdictions where those
offers and sales are made.
General
Subject to the foregoing, by accepting this Preliminary Placement Document and purchasing any Equity Shares
under the Issue, you are deemed to have represented, warranted, acknowledged and agreed with the Company and
the Book Running Lead Manager as follows:
you have received a copy of the Preliminary Placement Document and such other information as you
deem necessary to make an informed decision and that you are not relying on any other information or
the representation concerning the Company or the Equity Shares and neither the Company nor any other
person responsible for this document or any part of it or the Book Running Lead Manager will have any
liability for any such other information or representation;
you are authorised to consummate the purchase of the Equity Shares in compliance with all applicable
laws and regulations;
you will comply with all laws, regulations and restrictions (including the selling restrictions contained in
this Preliminary Placement Document) which may be applicable in your jurisdiction and you have
obtained or will obtain any consent, approval or authorization required for you to purchase and accept
delivery of the Equity Shares, and you acknowledge and agree that none of our Company, the Book
Running Lead Manager or any of their respective affiliates shall have any responsibility in this regard;
you acknowledge (or if you are a broker-dealer acting on behalf of a customer, your customer has
confirmed to you that such customer acknowledges) that such Equity Shares have not been and will not
be registered under the U.S. Securities Act, or with any securities regulatory authority of any state of the
United States, and are subject to restrictions on transfer;
you and the person, if any, for whose account or benefit you are acquiring the Equity Shares, were located
outside the United States at the time the buy order for the Equity Shares was originated and continue to
be located outside the United States and have not purchased the Equity Shares for the account or benefit
of any person in the United States or entered into any arrangement for the transfer of the Equity Shares
or any economic interest therein to any person in the United States;
you are not an affiliate (as defined in Rule 405 of the U.S. Securities Act) of our Company or a person
acting on behalf of such affiliate; and you are not in the business of buying and selling securities or, if
you are in such business, you did not acquire the Equity Shares from our Company or an affiliate (as
defined in Rule 405 of the U.S. Securities Act) thereof in the initial distribution of the Equity Shares;
you certify that either (A) you are, or at the time the Equity Shares are purchased will be, the beneficial
owner of the Equity Shares and are located outside the United States (within the meaning of Regulation
S) or (B) you are a broker-dealer acting on behalf of your customer and your customer has confirmed to
you that (i) such customer is, or at the time the Equity Shares are purchased will be, the beneficial owner
of the Equity Shares, and (ii) such customer is located outside the United States (within the meaning of
Regulation S);
160
you are aware of the restrictions on the offer and sale of the Equity Shares pursuant to Regulation S
described in this Preliminary Placement Document and that neither the BSE nor the NSE is a “designated
offshore securities market” within the meaning of Regulation S of the U.S. Securities Act;
the Equity Shares have not been offered to you by means of any “directed selling efforts” as defined in
Regulation S; and
you acknowledge that our Company, the Book Running Lead Manager and their respective affiliates (as
defined in Rule 405 of the U.S. Securities Act), and others will rely upon the truth and accuracy of the
foregoing acknowledgements, representations and agreements and agrees that, if any of such
acknowledgements, representations and agreements deemed to have been made by virtue of its purchase
of the Equity Shares are no longer accurate, you will promptly notify our Company and the Book
Running Lead Manager, and if you are acquiring any of the Equity Shares as a fiduciary or agent for one
or more accounts, you represent that you have sole investment discretion with respect to each such
account and that you have full power to make the foregoing acknowledgements, representations and
agreements on behalf of such accounts.
you acknowledge that the Equity Shares have not been and will not be registered under the U.S. Securities
Act or the securities law of any state of the United States and warrant to our Company, the Book Running
Lead Manager and their respective affiliates that it will not offer, sell, pledge or otherwise transfer the
Equity Shares except in an offshore transaction complying with Rule 903 or Rule 904 of Regulation S
or pursuant to any other available exemption from registration under the U.S. Securities Act and in
accordance with all applicable securities laws of the states of the United States and any other jurisdiction,
including India.
you represent and warrant to our Company, the Book Running Lead Manager and their respective
affiliates that if it acquired any of the Equity Shares as fiduciary or agent for one or more investor
accounts, it has sole investment discretion with respect to each such account and that it has full power to
make the foregoing acknowledgments, representations and agreements on behalf of each such account.
the Company, the Book Running Lead Manager, their respective affiliates and others will rely upon the
truth and accuracy of your representations, warranties, acknowledgements and undertakings set out in
this document, each of which is given to (a) the Book Running Lead Manager on its own behalf and on
behalf of the Company, and (b) to the Company, and each of which is irrevocable and, if any of such
representations, warranties, acknowledgements or undertakings deemed to have been made by virtue of
your purchase of the Equity Shares are no longer accurate, you will promptly notify the Company.
you and any accounts for which you are subscribing to the Equity Shares (i) are each able to bear the
economic risk of the investment in the Equity Shares, (ii) will not look to the Company or the Book
Running Lead Manager or their respective affiliates for all or part of any such loss or losses that may be
suffered, (iii) are able to sustain a complete loss on the investment in the Equity Shares, (iv) have no
need for liquidity with respect to the investment in the Equity Shares, and (v) have no reason to anticipate
any change in its or their circumstances, financial or otherwise, which may cause or require any sale or
distribution by it or them of all or any part of the Equity Shares. You acknowledge that an investment in
the Equity Shares involves a high degree of risk and that the Equity Shares are, therefore, a speculative
investment. You are seeking to subscribe to the Equity Shares in this Issue for your own investment and
not with a view to distribution;
you have been provided access to this Preliminary Placement Document which you have read in its
entirety;
you are aware of the restrictions of the offer, sale and resale of the Equity Shares pursuant to Regulation
S;
you agree to indemnify and hold the Company and the Book Running Lead Manager and their respective
affiliates harmless from any and all costs, claims, liabilities and expenses (including legal fees and
expenses) arising out of or in connection with any breach of these representations and warranties. You
will not hold any of the Company or the Book Running Lead Manager and their respective affiliates
liable with respect to its investment in the Equity Shares. You agree that the indemnity set forth in this
paragraph shall survive the resale of the Equity Shares; and
161
any resale or other transfer, or attempted resale or other transfer, of the Equity Shares made other than in
compliance with the above-stated restrictions will not be recognized by our Company
162
INDIAN SECURITIES MARKET
The information in this section has been extracted from documents available on the website of SEBI and the Stock
Exchanges and has not been prepared or independently verified by our Company or the BRLM or any of their
respective affiliates or advisors.
India has a long history of organized securities trading. In 1875, the first stock exchange was established in
Mumbai.
Indian Stock Exchanges
Indian stock exchanges are regulated primarily by SEBI, as well as by the Government acting through the Ministry
of Finance, Capital Markets Division, under the SEBI Act, the SCRA and the SCRR as amended. On June 20,
2012, SEBI, in exercise of its powers under the SCRA and the SEBI Act notified the SCR (SECC) Regulations,
which regulate inter alia the recognition, ownership and internal governance of stock exchanges and clearing
corporations in India together with providing for minimum capitalisation requirements for stock exchanges. The
SCRA, the SCRR and the SCR (SECC) Regulations along with various rules, bye-laws and regulations of the
respective stock exchanges, regulate the recognition of stock exchanges, the qualifications for membership thereof
and the manner, in which contracts are entered into, settled and enforced between members of the stock exchanges.
The SEBI Act empowers SEBI to regulate the Indian securities markets, including stock exchanges and
intermediaries in the securities markets, promote and monitor self-regulatory organisations and prohibit fraudulent
and unfair trade practices. Regulations and guidelines concerning minimum disclosure requirements by public
companies, investor protection, insider trading, substantial acquisitions of shares and takeover of companies, buy-
backs of securities, employee stock option schemes, stockbrokers, merchant bankers, underwriters, mutual funds,
foreign institutional investors, foreign portfolio investors, credit rating agencies and other securities market
participants have been notified by the SEBI.
Most of the stock exchanges have their own governing board for self-regulation. The Stock Exchanges together
hold a dominant position among the stock exchanges in terms of the number of listed companies, market
capitalization and trading activity.
With effect from April 1, 2003, the stock exchanges in India operate on a trading day plus two, or T+2, rolling
settlement system. At the end of the T+2 period, obligations are settled with buyers of securities paying for and
receiving securities, while sellers transfer and receive payment for securities. For example, trades executed on a
Monday would typically be settled on a Wednesday. In order to contain the risk arising out of the transactions
entered into by the members of various stock exchanges either on their own account or on behalf of their customers,
the stock exchanges have designed risk management procedures, which include compulsory prescribed margins
on the individual broker members, based on their outstanding exposure in the market, as well as stock-specific
margins from the members.
Listing of Securities
The listing of securities on a recognised Indian stock exchange is regulated by the applicable Indian laws including
the Companies Act, the SCRA, the SCRR, the SEBI Act and various guidelines and regulations issued by the
SEBI and the SEBI Listing Regulations of the respective stock exchanges. The SCRA empowers the governing
body of each recognised stock exchange to suspend trading of or withdraw admission to dealings in the securities
of a listed company for a breach of or non-compliance with, any of the conditions or breach of company’s
obligations under the SEBI Listing Regulations or for any reason subject to the issuer receiving prior written
notice of the intent of the exchange and upon granting a hearing in the matter. SEBI also has the power to amend
the SEBI Listing Regulations and bye-laws of the stock exchanges in India, to overrule a stock exchange’s
governing body and withdraw recognition of a recognized stock exchange.
SEBI has notified the Securities and Exchange Board of India (Delisting of Equity Shares) Regulations, 2009 in
relation to the voluntary and compulsory delisting of equity shares from the stock exchanges. In addition, certain
amendments to the SCRR have also been notified in relation to delisting.
Pursuant to an amendment dated June 4, 2010 to the SCRR, all listed companies (except public sector companies)
are required to maintain a minimum public shareholding of at least 25 %. Any listed company which had public
shareholding of less than 25% at the time of commencement of the amendment dated June 4, 2010 to the SCRR
was required to increase its public shareholding to at least 25 % within a period of three years from the date of
163
such commencement. The SCRR also provides that if the public shareholding in a listed company falls below 25
% at any time, such company is required to bring the public shareholding to 25% within a maximum period of 12
months from the date of such fall in the manner prescribed by the SEBI. Consequently, a listed company may be
delisted from the stock exchanges for not complying with the minimum public shareholding requirement. Our
Company is in compliance with this minimum public shareholding requirement.
Disclosures under the Companies Act, 2013 and SEBI Listing Regulations
Public limited companies are required under the Companies Act and the SEBI Listing Regulations to prepare, file
with the registrar of companies and circulate to their shareholders audited annual accounts which comply with the
disclosure requirements and regulations governing their manner of presentation and which include sections relating
to corporate governance under the Companies Act, related party transactions and management’s discussion and
analysis as required under the SEBI Listing Regulations. In addition, a listed company is subject to continuing
disclosure requirements pursuant to the terms of the SEBI Listing Regulations.
Index-Based Market-Wide Circuit Breaker System
In order to restrict abnormal price volatility in any particular stock, the SEBI has instructed stock exchanges to
apply daily circuit breakers which do not allow transactions beyond a certain level of price volatility. The index
based market-wide circuit breaker system (equity and equity derivatives) applies at three stages of the index
movement, at 10%, 15% and 20%. These circuit breakers, when triggered, bring about a co-ordinated trading halt
in all equity and equity derivative markets nationwide. The market-wide circuit breakers are triggered
bymovement of either the SENSEX of the BSE or the S&P CNX NIFTY of the NSE, whichever is breached
earlier. With effect from October 1, 2013, the Stock Exchanges, shall on a daily basis translate the 10 %, 15 %
and 20 % circuit breaker limits of market wide index variation based on the previous days’ closing level of the
index.
In addition to the market-wide index-based circuit breakers, there are currently in place individual scrip-wise price
bands of 20 % movements either up or down for all scrips in the compulsory rolling settlement. However, no price
bands are applicable on scrips on which derivative products are available or scrips included in indices on which
derivative products are available.
The Stock Exchanges in India have the power to suspend trading during periods of market volatility. Margin
requirements are imposed by stock exchanges that are required to be maintained by the stockbrokers.
BSE
BSE was established in 1875 and is the oldest stock exchange in India. In 1956, it became the first stock exchange
in India to obtain permanent recognition from the Government under the SCRA. It has evolved over the years into
its present status as one of the premier stock exchanges of India. Pursuant to the BSE (Corporatisation and
Demutualisation) Scheme 2005 of the SEBI, with effect from August 19, 2005, the BSE was incorporated and is
now a company under the Companies Act.
NSE
NSE was established by financial institutions and banks to serve as a national exchange and to provide nationwide
online satellite-linked screen-based trading facilities with market-makers and electronic clearing and settlement
for securities including government securities, debentures, public sector bonds and units. The NSE was recognised
as a stock exchange under the SCRA in April 1993 and commenced operations in the wholesale debt market
segment in June 1994.
Stock Market Indices
There are several indices of stock prices on NSE, which include the S&P CNX Nifty, CNX Nifty Junior, S&P
CNX Defty, S&P CNX 500, CNX Midcap and CNX100. S&P CNX Nifty is a diversified 50 stock index
accounting for various sectors of the economy. It is used for a variety of purposes such as benchmarking fund
portfolios, index based derivatives and index funds. S&P CNX Nifty is owned and managed by India Index
Services and Products Limited (IISL), which is a joint venture between the NSE and CRISIL.
The two indices which are generally used in tracking the aggregate price movements on BSE are the Sensex and
the BSE 100 Index. The BSE Sensitive Index, or the Sensex, consists of listed shares of 30 large market
164
capitalization companies. The companies are selected on the basis of market capitalization, liquidity and industry
representation. The Sensex was first compiled in 1986 with the fiscal year ended March 31, 1979. The BSE 100
Index (formerly the BSE National Index) contains listed shares of 100 companies, including the 30 in the Sensex,
with 1983-1984 as the base year.
Trading Hours
Trading on both the NSE and the BSE occurs from Monday to Friday, between 9:15 a.m. and 3:30 p.m. IST
(excluding the 15 minutes pre-open session from 9:00 a.m. to 9:15 a.m. that has been introduced recently). The
BSE and the NSE are closed on public holidays. The recognised stock exchanges have been permitted to set their
own trading hours (in the cash and derivatives segments) subject to the condition that (i) the trading hours are
between 9.00 a.m. and 5.00 p.m.; and (ii) the stock exchange has in place a risk management system and
infrastructure commensurate to the trading hours
Trading Procedure
In order to facilitate smooth transactions, the BSE replaced its open outcry system with the BSE Online Trading
(BOLT) facility in 1995. This totally automated screen based trading in securities was put into practice nation-
wide. This has enhanced transparency in dealings and has assisted considerably in smoothening settlement cycles
and improving efficiency in back-office work.
NSE has introduced a fully automated trading system called National Exchange for Automated Trading (NEAT),
which operates on strict time/price priority besides enabling efficient trade. NEAT has provided depth in the market
by enabling large number of members all over India to trade simultaneously, narrowing the spreads.
Internet-based Securities Trading and Services
Internet trading takes place through order routing systems, which route customer orders to exchange trading
systems for execution. Stockbrokers interested in providing this service are required to apply for permission to the
relevant stock exchange and also have to comply with certain minimum conditions stipulated by SEBI. The NSE
became the first exchange to grant approval to its members for providing internet-based trading services. Internet
trading is possible on both the “equities” as well as the “derivatives” segments of the NSE.
Takeover Code
Disclosure and mandatory bid obligations for listed Indian companies under Indian law are governed by
theTakeover Code, as amended, which provides specific regulations in relation to substantial acquisition of shares
and takeover. Once the equity shares of a company are listed on a stock exchange in India, the provisions of the
Takeover Code will apply to any acquisition of our Company’s shares/voting rights/control. The Takeover Code
prescribes certain thresholds or trigger points in the shareholding a person or entity has in the listed Indian
company, which give rise to certain obligations on part of the acquirer. Acquisitions up to a certain threshold
prescribed under the Takeover Code mandate specific disclosure requirements, while acquisitions crossing
particular thresholds may result in the acquirer having to make an open offer of the shares of the target company.
The Takeover Code also provides for the possibility of indirect acquisitions, imposing specific obligations on the
acquirer in case of such indirect acquisition.
Prohibition of Insider Trading Regulations
The SEBI Prohibition of Insider Trading Regulations have been notified by SEBI to prohibit and penalize insider
trading in India. An insider is, among other things, prohibited from dealing in the securities of a listed company
when in possession of unpublished price sensitive information. The definition of "insider" includes any person
who is a connected person or in possession of or having access to unpublished price sensitive information. As per
SEBI Prohibition of Insider Trading Regulations, a connected person is one who has a connection with the
company that is expected to put him in possession of unpublished price sensitive information. Immediate relatives
and other categories of persons specified above are also presumed to be connected persons but such a presumption
is a deeming legal fiction and is rebuttable. This definition is also intended to bring into its ambit persons who
may not seemingly occupy any position in a company but are in regular touch with the company and its officers
and are involved in the know of the company’s operations. Since “generally available information” is defined, it
is intended that anyone in possession of or having access to unpublished price sensitive information should be
considered an “insider” regardless of how one came in possession of or had access to such information. The onus
of showing that a certain person was in possession of or had access to unpublished price sensitive information at
165
the time of trading would, therefore, be on the person levelling the charge after which the person who has traded
when in possession of or having access to unpublished price sensitive information may demonstrate that he was
not in such possession or that he has not traded or he could not access or that his trading when in possession of
such information was squarely covered by the exonerating circumstances. The board of directors, however, would
cause public disclosures of such unpublished price sensitive information well before the proposed transaction to
rule out any information asymmetry in the market.
The SEBI Prohibition of Insider Trading Regulations are primarily aimed at preventing abuse by trading when in
possession of unpublished price sensitive information and therefore, what matters is whether the person who takes
trading decisions is in possession of such information rather than whether the person who has title to the trades is
in such possession. Every person on appointment as a key managerial personnel or a director of the company or
upon becoming a promoter shall disclose his holding of securities of the company as on the date of appointment
or becoming a promoter, to the company within seven days of such appointment or becoming a promoter. Every
promoter, employee and director of every company shall disclose to the company the number of such securities
acquired or disposed of within two trading days of such transaction if the value of the securities traded, whether
in one transaction or a series of transactions over any calendar quarter, aggregates to a traded value in excess of ₹
10 lakh or such other value as may be specified. Further, every company shall notify the particulars of such trading
to the stock exchange on which the securities are listed within two trading days of receipt of the disclosure or from
becoming aware of such information. The board of directors of every company, whose securities are listed on a
stock exchange, shall formulate and publish on its official website, a code of practices and procedures for fair
disclosure of unpublished price sensitive information. The board of directors of every listed company and market
intermediary shall formulate a code of conduct to regulate, monitor and report trading by its employees and other
connected persons towards achieving compliance with these regulations.
Depositories
In August 1996, the Indian Parliament enacted the Depositories Act 1996 which provides a legal framework for
the establishment of depositories to record ownership details and effect transfers in electronic book-entry form.
SEBI framed regulations in relation to the formation and registration of such depositories, the registration of
participants and the rights and obligations of the depositories, participants, companies and beneficial owners. The
depository system has significantly improved the operation of the Indian securities markets.
Derivatives (Futures and Options)
Trading in derivatives is governed by SCRA, SCRR and SEBI Act. SCRA was amended in February 2000 and
derivatives contracts were included within the term “securities”, as defined by SCRA. Trading in derivatives in
India takes place either on separate and independent derivatives exchanges or on a separate segment of an existing
stock exchange. The derivatives exchange or derivatives segment of a stock exchange functions as a self-
regulatory organisation under the supervision of the SEBI.
166
DESCRIPTION OF THE EQUITY SHARES
Set forth below is certain information relating to our share capital, including a brief summary of some of the
provisions of the Memorandum and Articles of Association, the Act and certain related laws of India.
General
Our authorized capital is ₹ 7,500 lakhs divided into 300,000,000 Equity Shares of ₹ 1 each and 450 lakh preference
shares of ₹10 each. As of the date of this Preliminary Placement Document, 15,51,83,160 Equity Shares of ₹ 1
each were issued; 1551,57,900 Equity Shares of ₹ 1 each were paid up and outstanding.
Dividend
Under the Companies Act, 2013, unless the board recommends the payment of a dividend, the shareholders at a
general meeting have no power to declare any dividend. Subject to certain conditions specified in the Companies
Act, 2013, no dividend can be declared or paid by our Company for any financial year except out of the profits of
our Company for that year determined in accordance with the provisions of the Companies Act, 2013 or out of
the undistributed profits of previous Fiscal Years or out of both, arrived at in accordance with the provisions of
the Companies Act, 2013, or out of money provided by the Central Government or a state Government for
payment of dividend by our Company in pursuance of a guarantee given by that government. Pursuant to
Regulation 43 of the SEBI Listing Regulations, listed companies are required to declare and disclose their
dividends on per share basis only. The dividend recommended by the Board and approved by the shareholders at
a general meeting is distributed and paid to shareholders in proportion to the paid-up value of their equity shares
as at the record date for which such dividend is payable. In addition, the Board may declare and pay interim
dividends. Under the Companies Act, 2013, dividends can only be paid in cash to shareholders listed on the
register of shareholders on the date which is specified as the “record date” or “book closure date”. No shareholder
is entitled to a dividend while unpaid calls on any of his equity shares are outstanding. Dividends must be paid
within 30 days from the date of the declaration and any dividend that remains unpaid or unclaimed after that
period must be transferred within seven days to a special unpaid dividend account held at a scheduled bank. Any
money that remains unpaid or unclaimed for seven years from the date of such transfer must be transferred by our
Company to the Investor Education and Protection Fund established by the Government.
Our Company may, before the declaration of any dividend in any financial year, transfer such percentage of its
profits for that financial year as it may consider appropriate to the reserves of our Company. The Companies Act,
2013 and the Companies (Declaration of Dividend) Rules, 2014, provide that if the profit for a year is insufficient,
the dividend for that year may be declared out of free reserves, subject to certain conditions prescribed under those
legislations.
Capitalization of Reserves and Issue of Bonus Shares
Under the Companies Act, 2013, the board of directors of a company may, if so approved by the shareholders in
a general meeting, capitalise and distribute the profits or reserves of such company among its shareholders. The
Companies Act, 2013 permits the issue of fully paid up bonus shares from its free reserves, shares premium
account or capital redemption reserve account, provided that bonus shares shall not be issued by capitalising
reserves created by revaluation of assets. These bonus equity shares must be distributed to shareholders in
proportion to the number of equity shares owned by them as recommended by the board of directors of such
company.
Any issue of bonus shares by a listed company would be subject to the SEBI Regulations. The relevant SEBI
Regulations prescribe that no company shall make a bonus issue of equity shares if it has outstanding fully or
partly convertible debt instruments at the time of making the bonus issue, unless it has made reservation of the
equity shares in the same class in favour of the holders of the outstanding convertible debt instruments in
proportion to the convertible part thereof and the equity shares reserved for the holders of fully or partly
convertible debt instruments shall be issued at the time of conversion of such convertible debt instruments on the
same terms or same proportion on which the bonds were issued. Further, for issuance of such bonus shares, a
company should not have defaulted in the payment of interest or principal in respect of fixed deposits and interest
on existing debentures or principal on redemption of such debentures. The declaration of bonus shares in lieu of
a dividend cannot be made. The bonus issue shall be made out of free reserves built out of genuine profits or share
premium collected in cash only. The reserves created by revaluation of fixed assets cannot be capitalised. Further,
a company should have sufficient reason to believe that it has not defaulted in respect of the payment of statutory
dues of the employees, such as contributions to provident funds, gratuities and/or bonuses.
167
Our Company in a General Meeting may resolve that any moneys, investments or other assets forming part of the
undivided profits of our Company standing to the credit of the Reserve Fund, or any Capital Redemption Reserve
Account, or in the hands of our Company and available for dividend (or representing premium received on the
issue of shares and standing to the credit of the Shares Premium Account) be capitalized and distributed among
such of the shareholders as would be entitled to receive the same if distributed by way of dividend and in the same
proportions on the footing that they become entitled thereto as capital and that all or any part of such capitalized
fund be applied on behalf of such shareholders in paying up in full either at par or at such premium as the resolution
may provide, any unissued shares or debentures or debenture-stock of our Company which shall be distributed
accordingly or in or towards payment of the uncalled liability on any issued shares or debentures or debenture-
stock and that such distribution or payment shall be accepted by such shareholders in full satisfaction of their
interest in the said capitalized sum, provided that a Share Premium Account and a Capital Redemption Reserve
Account may only be applied in the paying of any unissued shares to be issued to members of our Company as
fully paid bonus shares.
Pre-emptive Rights and Alteration of Share Capital
Subject to the provisions of the Companies Act, 2013, our Company can increase its share capital by issuing new
equity shares. Such new equity shares must be offered to existing shareholders registered on the record date in
proportion to the amount paid-up on those equity shares at that date. The offer shall be made by notice specifying
the number of equity shares offered and the date (being not less than fifteen days and not exceeding thirty days
from the date of the offer) within which the offer, if not accepted, will be deemed to have been declined. After
such date the Board may dispose of the equity shares offered in respect of which no acceptance has been received,
in such manner as they think is not disadvantageous to the shareholders and our Company. The offer is deemed
to include a right exercisable by the person concerned to renounce the shares in favor of any other person provided
that the person in whose favor such shares have been renounced is approved by the Board in their absolute
discretion.
However, under the provisions of the Companies Act, 2013 and the Companies (Share Capital and Debentures)
Rules, 2014, new shares may be offered to any persons, whether or not those persons include existing shareholders
or employees to whom shares are allotted under a scheme of employees stock options, either for cash or for
consideration other than cash, if a special resolution to that effect is passed by the shareholders of our Company
in a general meeting. The issue of the Equity Shares pursuant to the Issue has been approved by a special resolution
of our Company’s shareholders and such shareholders have waived their pre-emptive rights with respect to such
Equity Shares.
Our Company’s issued share capital may, among other things, be increased by the exercise of warrants attached
to any of our Company’s securities entitling the holder to subscribe for shares. The Articles of Association provide
that our Company may consolidate or sub-divide our Company’s share capital or cancel equity shares which have
not been taken up by any person and diminish the amount of its share capital by the amount of the Shares so
cancelled. Our Company can also alter its share capital by way of a reduction of capital, in accordance with the
Companies Act, 2013.
General Meetings of Shareholders
Our Company must hold its annual general meeting each year within 15 months of the previous annual general
meeting and within six months after the end of each accounting year. The RoC may extend this period in special
circumstances at our Company’s request. The Board may convene an extraordinary general meeting of
shareholders when necessary and shall convene such a meeting at the request of a shareholder or shareholders
holding in the aggregate not less than 10% of our Company’s issued paid-up capital.
Written notice convening a meeting setting out the date and place of the meeting and its agenda must be given to
members at least 21 days prior to the date of the proposed meeting and where any special business is to be
transacted at the meeting, an explanatory statement shall be annexed to the notice as required under the Companies
Act, 2013. A general meeting may be called after giving shorter notice if consent is received, in writing or by
electronic mode, from shareholders holding not less than 95% of our Company’s paid-up capital.
A listed company intending to pass a resolution relating to matters such as, but not limited to, an amendment in
the objects clause of the memorandum of association, a buy-back of shares under the Companies Act, 2013, the
giving of loans or extending a guarantee in excess of limits prescribed under the Companies Act, 2013 is required
to pass the resolution by means of a postal ballot instead of transacting the business in the general meeting of our
168
Company. A notice to all the shareholders must be sent along with a draft resolution explaining the reasons thereof
and requesting them to send their assent or dissent in writing on a postal ballot within a period of thirty days from
the date of such notice. Shareholders may exercise their right to vote at general meetings or through postal ballot
by voting through e-voting facilities in accordance with the circular dated April 17, 2014 issued by the SEBI and
the Companies Act, 2013. Under the Companies Act, 2013, unless, the Articles of Association provide for a larger
number: (i) five shareholders present in person, if the number of shareholders as on the date of meeting is not
more than 1,000; (ii) 15 shareholders present in person, if the number of shareholders as on the date of the meeting
is more than 1,000 but up to 5,000; and (iii) 30 shareholders present in person, if the number of shareholders as
on the date of meeting exceeds 5,000, shall constitute a quorum for a general meeting of our Company. The
quorum requirements applicable to shareholder meetings under the Companies Act, 2013 have to be physically
complied with.
Voting Rights
At a general meeting upon a show of hands, every member holding shares and entitled to vote and present in
person has one vote. Upon a poll, the voting rights of each member entitled to vote and present in person or by
proxy is in the same proportion to such member’s share of the paid-up equity capital of our Company.
Pursuant to Section 110 and other applicable provisions, if any, of the Act read with Rule 22 of the Companies
(Management and Administration) Rules, 2014 and the Companies (Management and Administration)
Amendment Rules, 2015 (including any statutory modifications, amendments or re-enactments thereof for the
time being in force), certain items of business to be transacted by certain specified companies require approval of
members sought only by means of a postal ballot.
Ordinary resolutions may be passed by simple majority of those present and voting. Special resolutions require
that the votes cast in favor of the resolution must be at least three times the votes cast against the resolution. The
Companies Act, 2013 provides that to amend the Articles of Association of a company, a special resolution is
required to be passed in a general meeting.
A member may exercise his vote at a meeting by electronic means in accordance with the Act read with and
Regulation 44 of the Securities and Exchange Board of India (Listing Obligations and Disclosure Requirements)
Regulations, 2015, and shall vote only once. A member may exercise his voting rights by proxy to be given in the
form required by the Articles of Association. The instrument appointing a proxy is required to be lodged with us
not later than 48 hours before the time of the meeting. A member may, by a single power of attorney, grant a
general power of representation regarding several general meetings of members. Any member may appoint a
proxy. A corporate member is also entitled to nominate a representative to attend and vote on its behalf at general
meetings. A proxy may not vote except on a poll and does not have a right to speak at meetings. A member which
is a legal entity may appoint an authorized representative who can vote in all respects as if a member both on a
show of hands and a poll.
The Companies Act, 2013 allows our Company to issue shares with differential rights as to dividend, voting or
otherwise, subject to certain conditions. In this regard, the law requires that for a company to issue shares with
differential voting rights, the company must have, inter alia, had distributable profits in terms of the Companies
Act, 2013 for the last three financial years and it must not have defaulted in filing annual accounts and annual
returns for the immediately preceding three financial years.
Register of Members and Record Dates
Our Company is obliged to maintain a register and index of members in terms of the Companies Act, 2013. Our
Companyis entitled to keep in any State or country outside India a branch register of members resident in that
State or country. Our Company recognizes as members only those persons whose names appear on the register of
members and cannot recognize any person holding any share or part of it upon any express, implied or constructive
trust, except as permitted by law. In the case of shares held in physical form, transfers of shares are registered in
the register of members upon lodgment of the share transfer form duly complete in all respects accompanied by a
share certificate or, if there is no certificate, the letter of allotment in respect of shares transferred together with
duly stamped transfer forms. In respect of electronic transfers, the depository transfers shares by entering the name
of the purchaser in its books as the beneficial owner of the shares. In turn, the name of the depository is entered
into our Company’s records as the registered owner of the shares. The beneficial owner is entitled to all the rights
and benefits as well as the liabilities with respect to the shares held by a depository.
The Register may be closed for any period not exceeding 45 days in each year but not exceeding 30 days at any
169
one time, as the Board may deem expedient in accordance with the provisions of the Companies Act, 2013. Under
Regulation 42 of the SEBI Listing Regulations, our Company may, upon at least seven working days’ advance
notice to such stock exchanges, set a record date and/or close the register of members in order to ascertain the
identity of shareholders. The trading of shares and the delivery of certificates in respect thereof may continue
while the register of shareholders is closed.
Under the Companies Act, 2013, our Company is also required to maintain a register of debenture holders and a
register of any other security holders.
Annual Report and Financial Results
The annual report must be presented at the annual general meeting. The report includes financial information, a
corporate governance section and management’s discussion and analysis and is sent to our Company’s
shareholders.
Under the Companies Act, 2013, our Company must file its balance sheet and profit and loss account with the
Registrar of Companies within thirty days from the date of the annual general meeting. The Companies Act, 2013
also requires listed companies to place their financial statements, including consolidated financial statements, if
any, and all other documents required to be attached thereto, on their website. As required under the SEBI Listing
Regulations, copies are required to be simultaneously sent to the Stock Exchanges on which the shares are listed.
Our Company must also publish its financial results in at least one English language daily newspaper circulating
in the whole or substantially the whole of India and also in a daily newspaper published in the language of the
region of the Registered Office (i.e. Marathi).
Transfer of Equity Shares
Shares held through depositories are transferred in the form of book entries or in electronic form in accordance
with applicable SEBI ICDR Regulations. These regulations provide the regime for the functioning of the
depositories and their participants and set out the manner in which the records are to be kept and maintained and
the safeguards to be followed in this system. Transfers of beneficial ownerships of shares held through a
depository are exempt from stamp duty.
The SEBI requires that for trading and settlement purposes shares should be in book-entry form for all investors,
except for transactions that are not made on a stock exchange and transactions that are not required to be reported
to the stock exchange.
The securities of our Company are freely transferable, subject to the provisions of the Companies Act, 2013. If a
public company without sufficient cause refuses to register a transfer of shares within thirty days from the date on
which the instrument of transfer or intimation of transmission, as the case may be, is delivered to our Company,
the transferee may appeal to the National Company Law Tribunal seeking to register the transfer.
Pursuant to Regulation 40 of the SEBI Listing Regulations, in the event that a transfer of shares is not effected
within 15 days or where our Company has failed to communicate to the transferee any valid objection to the
transfer within the stipulated time period of 15 days, our Company is required to compensate the aggrieved party
for the opportunity loss caused by the delay.
A transfer may also be by transmission. Subject to the provisions of the Articles of Association, any person
becoming entitled to shares in consequence of the death or insolvency of any member may, upon producing such
evidence as may from time to time properly be required by the Board, be registered as a member in respect of
such shares, or may, subject to the regulations as to transfer contained in the Articles of Association, transfer such
shares. The Articles of Association provide that our Company shall charge no fee for registration of transfer,
transmission, probate, succession certificate and letters of administration, certificate of death or marriage, power
of attorney or other similar document. No shares shall in any circumstances be transferred to any minor, insolvent
or person of unsound mind.
Acquisition by us of our own Equity Shares
A company is prohibited from acquiring its own shares unless the consequent reduction of capital is effected by
an approval of at least 75% of its shareholders, voting on it in accordance with the Companies Act, 2013 and
sanctioned by the High Court of competent jurisdiction (or the National Company Law Tribunal once it is
notified). Subject to certain conditions, a company is prohibited from giving, whether directly or indirectly and
whether by means of loan, guarantee, and provision of security or otherwise, any financial assistance for the
170
purpose of or in connection with a purchase or subscription made or to be made by any person for any shares in
our Company or its holding company. However, pursuant to the Companies Act, 2013, a company has been
empowered to purchase its own shares or other specified securities out of its free reserves, the securities premium
account or the proceeds of any fresh issue of shares or other specified securities (other than the kind of shares or
other specified securities proposed to be bought back) subject to certain conditions, including:
the buy-back should be authorized by the Articles of Association of our Company;
a special resolution has been passed at a general meeting authorizing the buy-back (in the case of listed
companies, by means of a postal ballot);
the buy-back is limited to 25% or less of the aggregate of the total paid-up capital and free reserves;
the debt owed by our Company is not more than twice the paid up capital and free reserves after such buy-
back; and
the buy-back is in accordance with the Securities and Exchange Board of India (Buy-Back of Securities)
Regulations 1998, as amended.
A board resolution will constitute sufficient corporate authorization for a buy-back that is for less than 10% of the
total paid-up equity capital and free reserves of our Company. A company buying back its securities is required
to extinguish and physically destroy the securities so bought back within seven days of the last date of completion
of the buy-back. Further, a company buying back its securities is not permitted to buy back any securities for a
period of one year from the buy-back or to issue the same kind of shares or specified securities for six months
subject to certain limited exceptions.
A company is also prohibited from purchasing its own shares or specified securities through any subsidiaries
company including its own subsidiary companies or through any investment company. Further, a company is
prohibited from purchasing its own shares or specified securities, if our Company is in default in the repayment
of deposit or interest, in the redemption of debentures or preference shares, in payment of dividend to a
shareholder, in repayment of any term loan or interest payable thereon to any financial institution or bank or in
the event of non-compliance with certain other provisions of the Companies Act, 2013.
Liquidation Rights
Subject to the rights of creditors, of employees and of the holders of any other shares entitled by their terms of
issue to preferential repayment over the shares, in the event of winding up of our Company, the holders of the
Equity Shares are entitled to be repaid the amounts of capital paid-up or credited as paid-up on such shares. All
surplus assets after payments due to employees, the holders of any preference shares and other creditors belong
to the holders of the Equity Shares in proportion to the amount paid-up or credited as paid-up on such shares,
respectively at the commencement of the winding-up.
171
TAXATION
The information provided below sets out the possible tax benefits available to the shareholders in a summary
manner only and is not a complete analysis or listing of all potential tax consequences of the purchase, ownership
and disposal of equity shares under the current tax laws presently in force in India. Several of these benefits are
dependent on us or our shareholders fulfilling conditions prescribed under relevant tax laws. We may not choose
to fulfill such conditions. This information is not exhaustive or comprehensive and is not intended to be a substitute
for professional advice. Investors are advised to consult their own tax consultant with respect to the tax
implications of an investment in the Equity Shares. Investors should note that a draft of the Direct Tax Code Bill
has been placed before the Indian Parliament. If that law comes into effect, there could be an impact on the tax
provisions mentioned below.
To,
The Board of Directors
ITD Cementation India Limited
National Plastic Building,
A-Subhash Road, Paranjape,
B-Scheme, Vile Parle (East),
Mumbai – 400 057
Sub: Proposed Qualified Institutions Placement of equity shares of face value of ₹ 1 each (the
“Offering”) of ITD Cementation India Limited (the “Issuer”) in accordance with the Securities
and Exchange Board of India (Issue of Capital and Disclosure Requirements) Regulations, 2009,
as amended (“SEBI ICDR Regulations”) the Companies Act, 2013 (“the Act”), as amended, to
investors in India and outside the United States of America in reliance on Regulation S of the
United States Securities Act of 1933, as amended (the “Securities Act”).
1. This report is issued in accordance with the terms of our engagement letter dated 12 January 2018.
2. The Statement of Tax Benefits available to the Issuer and its Shareholders (hereinafter referred to as “the
Statement”) under the Income Tax Act, 1961 (read with Income Tax Rules, circulars, notifications) as
amended by the Finance Act, 2017 (hereinafter collectively referred to as the “Income Tax Regulations”) has
been prepared by the management of the Issuer in connection with the Offering, which we have initialed for
identification purposes.
Management’s Responsibility
3. The preparation of this Statement as of the date of our report which is to be included in the Preliminary
Placement Document and Placement Document relating to the Offering is the responsibility of the management
of the Issuer and has been approved by the Executive Committee of the Board of Directors, namely the QIP
Committee of Directors, of the Issuer at its meeting held on 24 January 2018 for the purpose set out in
paragraph 9 below. The management’s responsibility includes designing, implementing and maintaining
internal control relevant to the preparation and presentation of the Statement, and applying an appropriate basis
of preparation; and making estimates that are reasonable in the circumstances. The Management is also
responsible for identifying and ensuring that the Issuer complies with the laws and regulations applicable to
its activities.
Auditor’s Responsibility
4. Our work has been carried out in accordance with Standards on Auditing, as per the ‘Guidance Note on Audit
Reports or Certificates for Special Purposes’ (Revised 2016) and other applicable authoritative
pronouncements issued by the Institute of Chartered Accountants of India. Our work has not been carried out
in accordance with the auditing standards generally accepted in the United States of America (“U.S.”),
standards of the US Public Company Accounting Oversight Board and accordingly should not be relied upon
by any one as if it had been carried out in accordance with those standards or any other standards besides the
standards referred to in this report
5. Pursuant to the SEBI ICDR Regulations and the Act, it is our responsibility to report whether the Statement
prepared by the Issuer, presents, in all material respects, the possible special tax benefits available as of 21
January 2018 to the Issuer and the shareholders of the Issuer, in accordance with the Income Tax Regulations
172
as at the date of our report.
6. Our work was performed solely to assist you in meeting your responsibilities in relation to your compliance
with the Act and the SEBI ICDR Regulations in connection with the Offering.
Inherent Limitations
7. We draw attention to the fact that the Statement includes certain inherent limitations that can influence the
reliability of the information.
Several of the benefits mentioned in the Statement are dependent on the Issuer or its shareholders fulfilling
the conditions prescribed under the relevant provisions of the tax laws. Hence, the ability of the Issuer or its
shareholders to derive the tax benefits is dependent upon fulfilling such conditions, which may or may not be
fulfilled. The benefits discussed in the Statement are not exhaustive.
The Statement is only intended to provide general information to the investors and is neither designed nor
intended to be a substitute for professional tax advice. In view of the individual nature of the tax consequences
and the changing tax laws, each investor is advised to consult his or her own tax consultant with respect to the
specific tax implications arising out of their participation in the Issue.
Further, we give no assurance that the Revenue authorities/ Courts will concur with our views expressed
herein. Our views are based on the existing provisions of law and its interpretation, which are subject to change
from time to time. We do not assume responsibility to update the views consequent to such changes.
Opinion
8. In our opinion, the Statement prepared by the Issuer presents, in all material respects, the possible special tax
benefits available as of 21 January 2018, to the Issuer and the shareholders of the Issuer, in accordance with
the Income Tax Regulations as at the date of our report.
Considering the matter referred to in paragraph 7 above, we are unable to express any opinion or provide any
assurance as to whether:
(i) the Issuer or its shareholders will continue to obtain the benefits per the Statement in future; or
(ii) the conditions prescribed for availing the benefits per the Statement have been/ would be met with.
Restriction on Use
9. This report is addressed to and is provided to enable the Board of Directors of the Issuer to include this report
in the Preliminary Placement Document and Placement Document, prepared in connection with the Offering
to be filed by the Issuer with the SEBI and the concerned stock exchanges and is not to be used, circulated,
quoted or otherwise referred to for any other purpose without our prior written consent.
For Walker Chandiok & Co LLP
Chartered Accountants
Firm Registration No: 001076N/N500013
Rakesh R. Agarwal
Partner
Membership No: 109632
Place: Mumbai
Date: 24 January 2018
173
ANNEXURE TO STATEMENT OF TAX BENEFITS AVAILABLE TO THE ISSUER AND ITS EQUITY
SHAREHOLDERS UNDER THE APPLICABLE TAX LAWS IN INDIA
The information provided below sets out the possible special tax benefits available to the Issuer and the Equity
Shareholders in a summary manner only and is not a complete analysis or listing of all potential tax consequences
of the purchase, ownership and disposal of equity shares, under the current tax laws presently in force in India.
It is not exhaustive or comprehensive and is not intended to be a substitute for professional advice. Investors are
advised to consult their own tax consultant with respect to the tax implications of an investment in the Equity
Shares particularly in view of the fact that certain recently enacted legislation may not have a direct legal
precedent or may have a different interpretation on the benefits, which an investor can avail.
You should consult your own tax advisors concerning the Indian tax implications and consequences of
purchasing, owning and disposing of equity shares in your particular situation.
As per the taxation laws in force, the possible special tax benefits / consequences, as applicable, to the Issuer and
its Equity Shareholders investing in the Equity Shares are summarized below:
1 SPECIAL TAX BENEFITS AVAILABLE TO THE ISSUER - UNDER THE INCOME-TAX
ACT, 1961 (the “IT Act”)
1.1 Income exempt under section 86 of the IT Act
As per section 86 of the IT Act, share in income received by a member of an Association of Persons
(“AOP”) shall be treated as “exempt income” if that AOP is chargeable to tax on its total income at the
maximum marginal rate or any higher rate under any of the provisions of this Act. Further, the
computation of income of the AOP has to be in accordance with the provision of section 67A of the IT
Act.
The Issuer has entered into various integrated joint ventures with numerous entities for undertaking
specific project(s). As informed to us, these integrated joint ventures are to be treated as AOP for income-
tax purposes. Further, we have been informed that the AOP are subject to tax and accordingly, the
Issuer’s share in profits from such AOP(s) is considered as exempt income.
1.2 MAT credit
As per section 115JB of the IT Act, a company would be liable to pay MAT at the rate of 18.5% on its
book profits, if such tax on book profits exceed the taxes computed under the normal tax provisions of
the IT Act. Further the Finance Act, 2017 has prescribed guidelines for adjustments to be made to book
profits in the context of accounting treatment (including transitional provisions) on account of adopting
Indian Accounting Standards (“Ind -AS”).
MAT credit eligible to be carried forward will be the difference between MAT paid and the tax computed
as per the normal provisions of the IT Act for that assessment year. Such MAT credit is allowed to be
carried forward for set off purposes for up to fifteen assessment years immediately succeeding the
assessment year in which the MAT credit becomes allowable under section 115JAA(1A) of the IT Act.
MAT credit can be set off in a year when tax is payable under the normal provisions of the IT Act. MAT
credit to be allowed shall be the difference between the tax computed as per the normal provisions of the
IT Act and MAT payable for that assessment year.
1.3 Under Section 80G of the IT Act, donation made by a company to certain relief funds and charitable
institutions can be claimed as deduction. Donations made to prescribed funds are only qualify as
deduction. The various donations specified in section 80G are eligible for deduction upto either 100% or
50% with or without restriction as provided in the section.
1.4 Under section 80GGA of the IT Act allows deduction for donation made towards scientific research or
rural development. 100% of the amount that is donated or contributed is considered eligible for donation.
1.5 Capital gains
174
As per Section 10(38) of the IT Act, capital gains arising from transfer of a long-term capital asset being
an equity share in the Company or unit of an equity oriented fund, where the transaction of sale is
chargeable to Securities Transaction Tax (“STT”) or in case the sale is transacted through a recognized
stock exchange located in any International Financial Services Center (“IFSC”) and where the
consideration for such transaction is paid or payable in foreign currency, shall be exempt from tax in the
hands of the Company
As per provisions of Section 112 of the IT Act, Long-term Capital Gain (“LTCG”), not exempt under
Section 10(38) of the IT Act, are subject to tax at the rate of 20% with indexation benefits. However, if
such tax payable on transfer of listed securities (other than unit or units of an equity oriented mutual fund
or zero coupon bonds) exceeds 10% of the LTCG (without indexation benefit), the excess tax shall be
ignored for the purpose of computing the tax payable by the Company.
As per provisions of Section 111A of the IT Act, Short-term Capital Gain (“STCG”) arising on sale of
equity shares or units of an equity oriented mutual fund, are subject to tax at the rate of 15%, provided
that the transaction is chargeable to STT.
Under Section 54EC of the IT Act, capital gains arising from transfer of long term capital assets, other
than those exempt under section 10(38) of the IT Act, shall be exempt from tax, subject to the conditions
and to the extent specified therein, if the capital gains are invested within a period of six months from
the date of transfer in the bonds redeemable after three years and issued by specified institutions/company
or notified by the Government. Where a part of the capital gains is reinvested, the exemption is available
on a proportionate basis. The maximum investment in the specified long term asset cannot exceed Rs. 50
lakhs per assessee during any financial year in which the original asset is transferred and in the subsequent
financial year. Where the new bonds are transferred or converted into money within three years from the
date of their acquisition, the amount so exempt shall be taxable as capital gains in the year of transfer/
conversion.
Under Section 54EE of the IT Act and subject to the conditions specified therein, LTCG arising to any
assessee would be exempt from tax if such capital gains are invested within six months after the date of
such transfer in long term specified asset, which means unit or units, issued before April 1, 2019 of such
fund as may be notified by the Central Government subject to investment ceiling of Rs. 50 lakhs.
1.6 Under Section 35(1)(ii)/(iii) of the IT Act, Where the assessee does not himself carry on scientific
research but makes contributions to other institutions for this purposes deduction is allowed if:
Payment is made to an approved scientific association which has, as its object, undertaking of scientific
research related or unrelated to the business of assessee, a deduction of 150% of expenditure incurred is
allowed.
Payment is made to an approved university, college or other institution for the use of scientific research
related or unrelated to the business of the company, deduction shall be allowed to the extent of 150% of
the actual expenditure.
Payment is made to an approved university, college or other institution for the use of research in social
sciences or statistical research related or unrelated to the business of the assesse, deduction shall be
allowed to the extent of 100% of the actual expenditure.
1.7 Dividend Income
As per provisions of Section 10(34) the IT Act, dividend (both interim and final) received by the
Company on its investments in shares of another domestic company is exempt from tax.
As per provisions of Section 10(35) of the IT Act, income received in respect of units of a mutual fund
specified under Section 10(23D) of the Act (other than income arising from transfer of such units) is
exempt from tax.
As per sub-section (1A) to section 115-O of the IT Act, the domestic Company will be allowed to set-
off, subject to the prescribed conditions, the dividend received from its subsidiary company during the
financial year against the dividend distributed by it, while computing the Dividend Distribution Tax
(“DDT”), as per provision of section 115-O(1) of the IT Act.
175
1.8 Weighted Deduction Under Section 80JJAA of the Act
As per provisions of Section 80JJAA of the IT Act, a Company engaged in any business is entitled to
claim a deduction of an amount equal to 30% of ‘additional employee cost’ paid to additional employees
employed during the year subject to prescribed conditions. Such deduction is available for three
assessment years, including the assessment year in which the employment is made subject to meeting
conditions prescribed in this regard.
2 SPECIAL TAX BENEFITS AVAILABLE TO THE SHAREHOLDERS OF THE ISSUER
2.1 Special tax benefits to Foreign Portfolio Investors (“FPIs”)
Section 2(14) of the IT Act provides that any security held by a FPI who has invested in such securities
in accordance with the regulations made under Securities and Exchange Board of India Act, 1992 would
be treated as a capital asset only so that any income arising from transfer of such security by a FPI would
be treated in the nature of capital gains.
Under section 115AD(1)(ii) of the IT Act, income by way of STCG arising to the FPI on transfer of
shares shall be chargeable at a rate of 30% where such transactions are not subjected to STT and at the
rate of 15% if such transaction of sale is entered on a recognised stock exchange in India and is chargeable
to STT.
Under section 115AD(1)(iii) of the IT Act, income by way of LTCG arising from the transfer of shares
(in cases not covered under section 10(38) of the IT Act) held in the Company will be taxable at the rate
of 10%. The benefits of cost indexation and of foreign currency fluctuations are not available to FPIs.
As per provisions of the section 10(34) of the IT Act, dividend (both interim and final), if any, received
by shareholders from a domestic company is exempt from tax.
The proviso to explanation 5 to section 9(1)(i) of the IT Act, clarifies that the indirect transfer provision
shall not be applicable to non-resident investors in FIIs/FPIs, where such FIIs/FPIs are registered with
Securities Exchange Board of India (“SEBI”) as Category I or Category II Foreign Portfolio Investor
under the SEBI (Foreign Portfolio Investors) Regulation, 2014. It is also amendment to be effect
retrospectively from AY 2012-13.
2.2 Special tax benefits to Venture Capital Companies/ Funds
Under section 10(23FB) of the IT Act, any income of Venture Capital Company registered with SEBI or
Venture Capital Fund registered under the provision of the Registration Act, 1908 (set up to raise funds
for investment in venture capital undertaking notified in this behalf), would be exempt from income tax,
subject to conditions specified therein. (Not applicable to income of venture capital fund/company being
an investment fund specified in clause of the Explanation 1 to section 115UB of the IT Act).
Venture Capital Companies / Funds are defined to include only those companies / funds which have been
granted a certificate of registration, before the 21st day of May, 2012 as a Venture Capital Fund or have
been granted a certificate of registration as Venture Capital Fund as a sub-category of Category I
Alternative Investment Fund.
‘Venture capital undertaking’ means a venture capital undertaking as defined in clause (n) of regulation
2 of the Venture Capital Funds Regulations or as defined in clause (aa) of sub-regulation (1) of regulation
2 of the SEBI (Alternative Investment Funds) Regulations, 2012.
As per section 115U(1) of the IT Act, any income accruing or arising to or received by a person out of
investments made in Venture Capital Company/ Fund would be taxable in the hands of the person making
an investment in the same manner as if it were the income accruing/arising/received by such person had
the investments been made directly in the venture capital undertaking.
As per section 115U(5) of the IT Act, the income accruing or arising to or received by the Venture Capital
Company/Funds from investments made in a venture capital undertaking if not paid or credited to a
person (who has investments in a Venture Capital Company /Fund) shall be deemed to have been credited
176
to the account of the said person on the last day of the previous year in the same proportion in which such
person would have been entitled to receive the income had it been paid in the previous year.
As per provisions of Section 10(34) of the IT Act, dividend (both interim and final), if any, received by
shareholders from a domestic company is exempt from tax.
2.3 Special tax benefits available to Alternative Investment Fund (Category I and II)
Under section 10(23FBA) of the IT Act, any income of an investment fund other than the income
chargeable under the head "Profits and gains of business or profession" is exempt from income tax.
As per section 115UB(1) of the IT Act, any income accruing or arising to or received by a person out of
his investments in investment Fund would be taxable in the hands of the person making an investment in
the same manner as if it were the income accruing/arising/received by such person had the investments
by the investment fund been made directly by him.
As per section 115UB(6) of the IT Act, the income accruing or arising to or received by the investment
fund if not paid or credited to the person (who has investments in the investment fund) shall be deemed
to have been credited to the account of the said person on the last day of the previous year in the same
proportion in which such person would have been entitled to receive the income had it been paid in the
previous year.
2.4 Special tax benefits available to Mutual Funds
As per section 10(23D) of the IT Act, any income of Mutual Funds registered under the Securities and
Exchange Board of India Act, 1992 or Regulations made thereunder and such other Mutual Funds set up
by public sector banks or public financial institutions or authorised by the Reserve Bank of India subject
to such conditions as the Central Government may, by notification in the Official Gazette, specify in this
behalf will be exempt from income tax.
Notes:
The above Statement of Tax Benefits sets out the provisions of law (i.e. the IT Act as amended by the
Finance Act, 2017) presently in force in India, in a summary manner only and is not a complete analysis
or listing of all potential tax consequences of the purchase, ownership and disposal of equity shares;
The above Statement of Tax Benefits sets out the only the special tax benefits available to the Issuer and
its shareholders under the current tax laws (i.e. the IT Act as amended by the Finance Act, 2017)
presently in force in India. These benefits are dependent on the Issuer or its shareholders fulfilling the
conditions prescribed under the relevant tax laws;
The above statement covers only certain relevant direct tax law benefits and does not cover any indirect
tax law benefits or benefits under any other law;
This statement is only intended to provide general information to the investors and is neither designed
nor intended to be a substitute for professional tax advice. In view of the individual nature of the tax
consequences, the changing tax laws, each investor is advised to consult his or her/ its own tax consultant
with respect to the specific tax implications arising out of their participation in the issue;
In respect of non-residents, the tax rates and the consequent taxation mentioned above shall be further
subject to any benefits available under the DTAA, if any, between India and the country in which the
non-resident has fiscal domicile;
The stated benefits will be available only to the sole/first named holder in case the shares are held by
joint shareholders;
The tax rates (including rates for tax deduction at source) mentioned in this Statement is applicable for
Assessment Year 2018-19.
The tax rates (including rates for tax deduction at source) mentioned in this statement exclude surcharge
and education cess. These rates are to be increased with surcharge and education cess as are applicable,
if any.
177
LEGAL PROCEEDINGS
Our Company, our Subsidiary and our Promoter are subject to various legal proceedings from time to time mostly
arising in the ordinary course of their business. Except as described below, we are not involved in any material
legal proceedings and our Company is not aware of any proceedings that are threatened, which if determined
adversely, may have, or have had, a material adverse effect on our business, properties, financial condition or
results or operations of our Company. We believe that none of the contingencies, either individually or in the
aggregate, would have a material adverse effect on our financial condition, results of operations or cash flows.
Other than as disclosed below, our Company has no outstanding default in relation to statutory dues payable,
dues payable to holders of any debentures and interest thereon, and in respect of deposits and interest thereon,
defaults in repayment of loans from any bank or financial institution. Other than as disclosed below, there has
been no other instances of compounding of offences, prosecutions filed (whether pending or not) fines imposed,
compounding of offences in the last three years immediately preceding the year of the Issue.
Further, except as disclosed below, we are not subject to any other outstanding litigations which may impact our
future revenues which have monetary value of more than 1 % of our net worth, for the last completed financial
year on a standalone basis.
I. LITIGATION INVOLVING OUR COMPANY
Civil Cases
A. Litigation filed by the Company
1. Arbitration of 2015 filed by our Company against V. O. Chidambaranar Post Trust (“Respondent”)
before the Hon’ble Arbitral Tribunal of sole arbitrator Hon’ble Justice Mr. K. Venkataraman
(Retired).
The Respondent and the Company had entered into a contract dated April 5, 2007 (“Contract”) for
construction of the Cargo Berth No. 9 at Tuticorin Port. The Contract was commenced on December 2,
2006 and was scheduled to be completed within a period of 15 months. The Company has claimed that
the Contract was delayed due to non - fulfilment of fundamental contractual obligations by the
Respondent. Due to repeated delay and failure in executing the scope of Contract, the Company has
claimed that there was enormous escalation of cost, expenses and loss of precious man-power time and
energy on the part of the Company. When the Company requested the Respondent for payment of
escalation in prices beyond the original Contract period, the same was rejected by the Respondent.
Therefore, the Company invoked the arbitration clause in the Contract and initiated arbitration
proceeding against the Respondent.
At present, the matter is pending before the Arbitral Tribunal.
2. Original Suit No. 31 of 2012 filed by our Company against the State of Andhra Pradesh (“Defendant
No. 1”) and the Chief Engineer, North Coast Vishakhapatnam, Andhra Pradesh (“Defendant No. 2”)
and the Project Administration and Superintending Engineer, Irrigation and C.A.D Department
(“Defendant No. 3”) and the Executive Engineer, T.B.P Division No. 1 Parvatipuram (“Defendant
No. 4”) (Defendant No. 1, 2, 3 and 4 shall collectively be referred to as the “Defendants”) before the
Court of the District Judge, at Vizianagaram. The matter was transferred from the Vizianagaram
Court to Parvathipuram Court and renumbered as Original Suit No. 36 of 2015.
The Defendant No. 1 and the Company had entered into an contract on October 25, 2004 (“Contract”)
for construction of inter alia left side earth dam, formation of new state highway, investigation, designs,
preparations of estimates and maintenance of Thotapalli Barrage Project by the Company (“Project”)
across Nagavali River, near Thotapalli, Garugubilli Mandal, Vizianagaram district, Andhra Pradesh. The
total value of work under the Contract was mutually agreed at ₹ 119,87,82,000/-. The work under the
Contract could not progress due to various reasons such as delay in payments, non-release of huge sums
of due money, denial of legitimate payments, public interest litigation cases filed against the Project,
inordinate delay in handing over the possession of site, delay in removal of obstacles, encroachments,
approval of designs and drawings. Due to the extensive delays/ disruptions and non-availability of work
fronts, severe damages/ losses were caused to the Company which severely disrupted its cash flow.
178
Therefore, the Company had on May 3, 2011 issued a legal notice under section 80 of the Code of Civil
Procedure, 1908 calling upon the Defendants to pay a sum of ₹ 80.03 crores approximately for expenses
incurred under the Contract. However, the claims of the Company were denied by the Defendants in their
replies. Thereafter, the Company revised its claim amount and initiated legal proceeding against the
Defendants for recovery of ₹ 66,12,94,013/- as expenses incurred on account of non-payment of certified
bills, reimbursement of non-contractual deduction, retention money, uncompensated price escalation,
additional cost towards changes in Defendant’s requirements, additional cost due to prolongation of the
Contract period, loss due to withdrawal of balance work and interest on delayed payment and unpaid
amounts.
During the pendency of Civil Suit no.31/2012 filed by the Company ( described above), before the court
of the District Judge, Vizianagaram, Andhra Pradesh, the CAD & ID had initiated action for recovery of
₹ 77,23,00,000 against the Company as alleged amount due towards the extra cost for the completion of
the balance works post rescission of Contract. Thereafter, the matter was transferred from Vizianagaram
Court to Parvathipuram court and was renumbered as Original Suit No. 36 of 2015. Meanwhile, the
Company challenged the impugned demand notice dated January 9, 2013 by filing Writ Petition No.4718
of 2013 before the Andhra Pradesh High Court and obtained interim injunction vide order June 26, 2013
which continues till date. The matter is currently pending.
3. Suit filed by our Company against the State of Andhra Pradesh (“Defendant No. 1”), Chief Engineer,
FFC, LMD Colony, Karimnagar, Karimnagar district (“Defendant No. 2”), Superintending Engineer,
Sripadsagar Projects (“Defendant No. 3”) and Executive Engineer, Division No. 1, Sripadsagar
Yellampally Project) (“Defendant No. 4”) (Defendants No. 1, 2, 3 and 4 shall hereinafter be referred
to as “Defendants”) before the City Civil Court, Hyderabad
The Company had entered into an agreement dated November 7, 2004 for construction of Sripada
Yellampally Project, across river Godavari, near Yellampally village, Ramagundam Mandal, Karimnagar
District, Andhra Pradesh (“Contract”)., the value of the works under the Contract was agreed up to ₹
40,885 lakh. The work under the Contract could not progress due to various reasons such as delay in
payments, non-release of huge sums of due money, denial of legitimate payments, public interest
litigation cases filed against the project, inordinate delay in handing over the possession of site, delay in
removal of obstacles, encroachments, approval of designs and drawings. Due to the extensive delays/
disruptions and non-availability of work fronts, sever damages and losses were caused to the Company
and its cash flow was severely disrupted. Therefore the Company had issued a legal notice under section
80 of the Code of Civil Procedure, 1908 on January 25, 2012 claiming for an amount of ₹ 157,65,65,000/-
for payment of additional costs and losses arising from the aforesaid breach and default by the Defendant
under the Contract. However, the claims of the Company were denied by the Defendants. Thereafter, the
Company initiated legal proceedings against the Defendants to recover the aforesaid amount as expenses
incurred on account of outstanding amount of final bill, non-payment of certified bills, reimbursement
of non-contractual deduction, retention money, uncompensated price escalation, additional cost towards
changes in Defendant’s requirements, additional cost due to prolongation of the Contract period, loss due
to withdrawal of balance work and interest on delayed payment and unpaid amounts before the District
Court of Karimnagar.
Thereafter the matter was transferred to the City Civil Court of Hyderabad and is presently pending for
issue of summons for appearance to the parties.
4. Company Petition No. 375 of 2016 filed by the Company against ABG Shipyard Limited
(“Respondent”) before the High Court of Gujarat at Ahmedabad
The Respondent had engaged the Company to carry out civil construction infrastructure work at the
shipyard of the Respondent near Dahej in Gujarat and had issued various purchase orders from time to
time. The Company has duly completed the work and raised bills in the name of the Respondent from
time to time. However, despite sending various reminders including five different legal notices issued by
the Company, the Respondent failed and neglected in paying the outstanding amounts aggregating to a
total of ₹ 19,66,62,412/- along with interest at the rate of 18% per annum. The Company has therefore
filed a winding up petition before the High Court of Gujarat to wind up the Respondent and appoint an
Official Liquidator to take control of the assets, business affairs, books of accounts, etc. of the
Respondent.
In the meanwhile, the National Company Law Tribunal (“NCLT”), Ahmedabad has passed an order
179
dated August 1, 2017 in the matter of the Respondent declaring moratorium and appointment of
Insolvency Resolution Professional (“IRP”) under the Insolvency and Bankruptcy Code, 2016. A notice
dated August 16, 2017 was issued in the newspapers inviting claims before the IRP. The Company has
submitted its claim to the IRP on September 22, 2017.
In view of the order passed by the NCLT, the matter before the High Court of Gujarat was adjourned and
is presently pending.
5. Special Civil Suit No. 379 of 2015 filed by the Company against Konkan Railway Corporation Limited
(“Defendant”) before the Court of the Civil Judge Senior Division, Thane at Thane
The Defendant had invited tenders for construction of tunnels T6, T10, T11, T12 and T9 between Kauri
and Dugga on the Katra- Dharam Section of Udahmapur – Srinagar – Baramulla New Broad Gauge
Railway Line Project in the state of Jammu and Kashmir, India and the offer of the Company was
accepted by the Defendant. The Defendant and the Company entered into a contract on October 18, 2010
(“Contract”) for a value of Rs. 1,89,41,30,803/- (“Contract Value”) detailing the manner in which the
works need to be executed by the Company. Under the Contract, the Company had inter alia claimed for
a sum of ₹ 35,01,00,000/- over and above the Contract Value for price variation as a result of fluctuation
in market prices of the input materials. However, the Defendant has refused to pay the price variation
amounts under the Contract. The dispute was referred to arbitration in accordance with the terms of the
Contract. However, the Arbitral Tribunal was unable to resolve the disputes between the Parties. The
Company has filed this suit to recover a sum of ₹ 35,01,00,000/- under the said Contract along with
interest at the rate of 15.75% per annum calculated from the due date till the date of realisation.
Thereafter, the Defendant filed an application under section 8 of Arbitration and Conciliation Act, 1996
before the Civil Judge Senior Division, Thane alleging that the dispute under the Contract has already
been referred to an arbitral tribunal constituted in accordance with the terms of the Contract and therefore,
the present suit is not maintainable. However, the same was dismissed by the Hon’ble Court vide order
dated April 7, 2017.
The matter is presently pending before the Court of the Civil Judge, Senior Division, Thane.
6. Civil Suit filed by the Company against Indian Oil Corporation Limited (“Defendant No. 1”) and
(“Defendant No. 2”) (Defendant No. 1 and 2 shall hereinafter be referred to as “Defendants before
the High Court of Delhi
Defendant No.1 had entered into a contract dated June 14, 2010 (“Contract”) with the Company for
carrying on piling work for the south side of the Paradip Refinery Project at Odisha. The value of the
Contract is ₹ 148,97,89,453/-. The Company has alleged that during the execution of the Contract, the
Company had faced several obstructions and hindrances for reasons beyond the control of the Company
and attributable solely to Defendant No. 1 and Defendant No. 2. However, the Defendants had wrongly
imposed damages upon the Company to the tune of 1% of the total Contract value for delay in
performance of the Contract. The Company has therefore filed the present suit claiming for a sum of ₹ 23,66,88,492/- from the Defendants for recovery of costs and losses incurred by the Company under the
Contract.
The matter is presently pending before the High Court of Delhi.
7. Writ Petition No. 10808 of 2010 filed by the Company against the Joint Commissioner of Warangal,
Marishetti Santosh and the Executive Engineer, Sripadsagar before the High Court of Andhra
Pradesh
Mr. Santosh Marishetti and 1704 other contract labourers represented through Mr. Devasani Bikshapathi,
general secretary Andhra Pradesh State Multiple Contractors Labor Union filed a claim application
(“Claim”), against our Company, under section 20 (2) of the Minimum Wages Act 1948 before the Joint
Commissioner of Labour at Warangal alleging non-payment of minimum wages, rest pay and overtime
pay, aggregating to ₹ 23,78,09,495.
Subsequently, our Company filed a writ petition bearing number 10808 of 2010 before the High Court
at Hyderabad, inter alia praying that the Claim is not maintainable under section 20 of the Minimum
Wages Act 1948. The High Court vide their order dated April 30, 2010 (“Order”) granted interim stay
180
to all proceeding of the claim application. Thereafter, complainant workmen filed a petition before the
High Court at Hyderabad praying inter alia to vacate the said Order. The Single Judge of the High Court
at Hyderabad, vide order dated September 29, 2010, (“Order 2”) set aside the Order and dismissed the
Writ petition. Aggrieved by the Order 2, our Company filed a writ Appeal bearing number 1169 of 2010
before the Division Bench of High Court at Hyderabad (“Division Bench”) inter alia praying for setting
aside the Order 2. The Division Bench vide its order dated February 24, 2011 directed that claim
application pending before the Joint Commissioner of Labour at Warangal be transferred for adjudication
to the Joint Commissioner of Labour, Twin City Hyderabad with a further direction for the disposal of
the claim application in accordance with law.
The matter is currently pending.
8. Labour Cases
Sr.
No.
Year Parties and Court of
Litigation
Particulars of the Case Status
1. 2017 Writ Petition No. 9654 of
2016 filed against Union of
India & Others. before the
High Court of Delhi at New
Delhi.
The Company has filed
the civil writ petition
under Article 226 of the
Constitution of India.
The matter is pending for
filing of rejoinder before the
High Court of Delhi.
2. 2014 Application No. 4 of 2014
filed against Rashtriya
General Kamgar Sena & its
Members before the
Industrial Court at Mumbai.
The Company has filed
the application in order to
get an immediate relief
from the Court and avoid
fatal consequences.
The application is pending
before the Industrial Court
at Mumbai.
B. Litigation filed against the Company
1. Appeal to Arbitration No. 4 of 2009 filed by the State of Goa represented by Executive Engineer, Public
Works Department, Goa (“Appellant”) against the Company before the High Court of Bombay at Goa
Our Company had entered in a contract with the Appellant on June 22, 2000 (“Contract”) for
construction of road bridge between Amona and Khandola, by the State of Goa. On April 19, 2002, the
scope of Contract was increased by the Appellant and the revised contract value stood at ₹
23,71,47,709.15/-. Subsequently, certain differences and disputes arose under the Contract and the
Company initiated arbitration proceedings against the Appellant. The Company had claimed inter alia,
that the Appellant has refused to pay the additional costs incurred by the Company due to expansion of
its scope of services and had delayed in complying with its obligations under the Contract. The Arbitral
Tribunal vide its order dated December 10, 2007 ordered the Appellant to pay the Company an amount
of ₹ 9,89,74,501 together with interest at the rate of 12% per annum (“Award”). The Appellant thereafter
filed a Civil Miscellaneous Petition No. 52 of 2008 before the Court of Principal District Judge at Panjim
on March 19, 2008 challenging the Award passed by the Arbitral Tribunal. By order dated February 13,
2009 (“Order”), the Hon’ble District Judge rejected the application filed by the Appellant. The Appellant
challenged the said Order of the Hon’ble District Judge by filing an appeal before the Goa Bench of the
Bombay High Court. The Hon’ble High Court passed an interim award directing the Appellant to deposit
a sum of ₹ 1,730 lakh along with accrued interest. Thereafter, the Company filed a Miscellaneous Civil
Application No. 411 of 2011 seeking withdrawal of the amount deposited by the Appellant. This was
allowed by the Hon’ble High Court subject to the Company procuring a bank guarantee for the same
amount along with an undertaking by a director of the Company confirming that in the event the appeal
is upheld, the Company will return the amount withdrawn along with interest.
The matter is now pending before the Goa Bench of the Bombay High Court for final hearing.
2. Arbitration filed by M/s SSJV Projects Pvt. Ltd. – Zarubezhvodstroy Joint Venture (“Claimant”)
against the Company before the Hon’ble Arbitral Tribunal of Justice G. Patri BasavannaGoud
The Claimant had entered into an agreement (“Agreement”) with National Thermal Power Corporation
(“NTPC”) for construction of barrage and de-silting chamber package for Tapovan - Vishnugad
Hydroelectric Project (4x 130W) on the river Dhauliganga in Chamoli District, Uttaranchal. The
181
Claimant subsequently entered into a sub- contract dated February 6, 2009 (“Sub - Contract”) with the
Company to construct a cut off wall for the chamber package of NTPC. The Claimant has alleged that
the Company had delayed in performance of its obligations under the Sub- Contract which in turn
resulted in termination of the Agreement by NTPC. The Claimant has further alleged that the termination
caused severe financial losses to the Claimant and with a view to recover the same from the Company,
the Claimant has initiated the present arbitration against the Company.
At present, the matter is pending before the Arbitral Tribunal for arguments of the Company.
3. Arbitration filed by M/s R. Venkatramaiah (“Claimant”) against the Company before the Hon’ble
Arbitral Tribunal of Shri. S. S. Singh
The Company had entered into an agreement with National Highway Authority of India (“NHAI”) for
widening and upgrading of the existing 1-lane roads in the state of Andhra Pradesh (“Project”). The
Company subsequently entered into a sub-contract (“Sub-Contract”) with the Claimant for executing
earthwork, sub-base in respect of the Project. The Claimant has initiated arbitration proceedings against
the Company on the grounds that the Company has delayed in performance of its obligations under the
Sub-Contract and the bills raised by the Claimant amounting to ₹ 2,21,33,990/- have remained unpaid
by the Company, thereby resulting in severe financial loss to the Claimant. The Company has in its
statement of defence responded to the claims of the Claimant alleging that the Claimant has not
performed its obligations under the Sub-Contract and has in turn, demanded for compensatory cost from
the Claimant.
At present, the matter is pending before the Arbitral Tribunal.
4. Civil Suit No. 55 of 2009 filed by Senbo Engineering Limited (“Plaintiff”) against the Company in the
High Court of Calcutta
The Plaintiff had entered into an agreement (“Agreement”) with Hooghly Bridge River Commissioners
for construction of a flyover. The Plaintiff subsequently entered into a sub-contract (“Sub-Contract”)
with the Company for providing services in connection with design, engineering and consultancy
services required for execution of the Agreement. The Plaintiff has alleged that the Company did not
provide the services under the Sub-Contract and therefore filed a suit for seeking damages before the
High Court of Calcutta. The Plaintiff also filed an interim application for preventing the Company from
depositing the post-dated cheque given to the Company. In response to the same, the Company has
claimed that it had provided pre-tender services to the Plaintiff prior to entering into the Agreement and
the post-dated cheque was issued by the Plaintiff in lieu of the same. The Hon’ble Court has granted this
interim application and prevented the Company from depositing the cheque until final disposal of the
suit.
At present, the matter is pending before the High Court of Calcutta.
5. Writ Petition No.8166 of 2017 filed by Shri. Somnath Brijlal Bhatia (“Petitioner”) against the
Company in the High Court of Bombay
The Company had entered into an agreement (“Agreement”) with National Highway Authority of India
(“NHAI”) for widening the existing 2 lane carriageways to 4 lane carriageway at Pune, Satara
(“Project”). For the Project, the Company had applied for seeking quarry operation permission for
effective blasting work in the property bearing Gat No.84 and the same was granted, subject to certain
terms and conditions. The Petitioner filed an application before the Tahsildar alleging that the Company
had carried out illegal and unauthorized blasting and quarrying operations on the property bearing Gat
No.84/8/A and also on 84/8/B which belonged to the applicant. The Tahsildar based on report submitted
by the Circle Inspector, passed an order penalizing the Company for an amount of ₹ 38,69,76,000/-. The
Company then filed a writ petition before the High Court of Bombay, however the same was rejected.
Thereafter, the Company filed an appeal before the Sub Divisional Officer but the same was also rejected.
The Company then preferred a 2nd appeal before the Additional Collector Satara which was allowed and
the Additional Collector passed an order (“Order”) remanding the matter back to the Sub-Divisional
Officer (“SDO”) for enquiry. The Petitioner aggrieved by the Order filed a revision application before
the Additional Commissioner, Pune and the same was accepted. The Company preferred a Revision
Application before the Minister of Forest & Revenue, Maharashtra (“Minister”). The Minister stayed
182
the order passed by the Additional Commissioner, Pune. The Petitioner then filed a writ petition before
the High Court of Mumbai against the order of Minister and the High Court disposed off all other
decisions and ordered that the Revision Application pending before the Minister be decided within 3
months. The Minister has finally decided the Revision Application vide his order dated April 6, 2017 in
the Company’s favour and directed the SDO to conduct further inquiry in terms of the observations made
by the Minister in his Order. While communication from the SDO is awaited, the Petitioner has filed a
writ petition against the impugned order of the Minister.
At present, the matter is pending before the High Court of Bombay.
6. Labour Cases
Sr. No Year Parties and Court of
Litigation
Particulars of the Case Status
1. 1996 Petition No. 5330 of 1996
filed by The Labour
Enforcement Officer,
Phulpur, Allahabad before the
Chief Judicial Magistrate,
Allahabad.
The Labour Enforcement
Officer filed a complaint
alleging non-maintenance of
records & registers and non-
display of notices at the work
site.
At present, the
matter is pending
before the Chief
Judicial Magistrate,
Allahabad.
2. 1996 Petition No. 5329 of 1996
filed by the Labour
Enforcement Officer,
Phulpur, Allahabad before the
Chief Judicial Magistrate,
Allahabad
The Labour Enforcement
Officer filed a complaint
alleging non-maintenance of
records and registers and non-
display of notices at the work
site.
At present, the
matter is pending
before the Chief
Judicial Magistrate,
Allahabad.
3. 1998 Petition No. 412 of 1998 filed
by the Labour Enforcement
Officer, Dhanbad before the
Chief Judicial Magistrate,
Dhanbad.
The Labour Enforcement
Officer, Dhanbad filed a
complaint alleging non-
maintenance of records and
registers and non-display of
notices at the work site. The
Company filed an application
Cr.MP No. 1087 of 2002 before
the Hon’ble High Court of
Jharkhand (“Court”) for
quashing the matter. The Court
passed an interim stay order on
the matter.
At present, the
matter is pending
before the Chief
Judicial Magistrate.
4. 1999 Case No. 14 of 1999 filed by
the Labour Enforcement
Officer, Paradip, Allahabad
before the Chief Judicial
Magistrate, Allahabad
The Labour Enforcement
Officer, Paradip filed a
complaint alleging non-
maintenance of records and
registers and non-display of
notices at the work site.
At present, the
matter is pending
before the 1st Class
Judicial Magistrate.
5. 1996 Petition No. 83 of 1996 filed
by the Labour Enforcement
Officer, Phulpur, Allahabad
before the Chief Judicial
Magistrate, Allahabad.
The Labour Enforcement
Officer, Phulpur, Allahabad
filed a complaint alleging that
the Company did not take the
license required under the Act
and also for non-maintenance of
records and registers at the work
site.
At present, the
matter is pending
before the Chief
Judicial Magistrate,
Allahabad.
Complaint under Section 22 and Section 24 of the Minimum Wages Act, 1948
6. 2003 Petition No.394/3 of 2003
filed by the Labour
Enforcement Officer,
Chennai before the Judicial
Magistrate, Tiruvottiyur.
The Labour Enforcement
Officer, Chennai filed a
complaint under Section 22 and
Section 24 of the Minimum
Wages Act alleging less
payment than the minimum rates
At present, the
matter is pending
before the Judicial
Magistrate,
Tiruvottiyur.
183
Sr. No Year Parties and Court of
Litigation
Particulars of the Case Status
of wages fixed for the employee
and also for the breach of Rule
22 of The Minimum Wages Rule
1950 (failure to display the name
and address of the inspector in
English and in a language
understood by the majority of
the workers in a clean and
legible condition).
Complaint under Section 78 and Section 76 of Contract Labour Act, 1971
7. 2003 Petition No. 395/3 of 2003
filed by the Labour
Enforcement Officer,
Chennai before the Judicial
Magistrate, Tiruvottiyur.
The Labour Enforcement
Officer, Chennai filed a
complaint under Section 78 and
Section 76 of Contract Labour
Act, 1971 alleging non-
maintenance of muster roll,
wage roll and non-issuance of
employment card.
At present, the
matter is pending
before the Judicial
Magistrate,
Tiruvottiyur.
Disputes under Section 33 C (2) of the Industrial Dispute Act, 1947
8. 2014 Application No. IDA 148 of
2014 filed by Abdul Rehman
Hussian before the 7thLabour
Court at Mumbai.
The workman filed a complaint
under Section 33 C (2) (dispute
relating to money/benefit
entitled to worker from the
employer) of the Industrial
Dispute Act, 1947.
At present, the
matter is pending
before the 7th
Labour Court at
Bandra.
9. 2014 Application No. 136 of 2014
filed by Habibu Rahman T
Hussain before the 7thLabour
Court at Mumbai.
The workman filed a complaint
under Section 33 C (2) (dispute
relating to money/benefit
entitled to worker from the
employer) of the Industrial
Dispute Act, 1947.
At present, the
matter is pending
before the
7thLabour Court at
Bandra.
10. 2014 Application No. 149 of 2014
filed by Rafat Ali Irshad Ali
before the 7thLabour Court at
Mumbai.
The workman filed a complaint
under Section 33 C (2) (dispute
relating to money/benefit
entitled to worker from the
employer) of the Industrial
Dispute Act, 1947.
At present, the
matter is pending
before the
7thLabour Court at
Bandra.
11. 2014 Application No. 150 of 2014
filed by Abid Ali Mohammad
Haneef before the 7thLabour
Court at Mumbai.
The workman filed a complaint
under Section 33 C (2) (dispute
relating to money/benefit
entitled to worker from the
employer) of the Industrial
Dispute Act, 1947.
At present, the
matter is pending
before the
7thLabour Court at
Bandra.
12. 2014 Application No. 151 of 2014
filed by Samaru Rajbur
before the 7th Labour Court at
Mumbai.
The workman filed a complaint
under Section 33 C (2) (dispute
relating to money/benefit
entitled to worker from the
employer) of the Industrial
Dispute Act, 1947.
At present, the
matter is pending
before the
7thLabour Court at
Bandra.
13. 2014 Application No. 147 of 2014
filed by Alijan Mohammad
Raja before the 7thLabour
Court at Mumbai.
The workman filed a complaint
under Section 33 C (2) (dispute
relating to money/benefit
entitled to worker from the
employer) of the Industrial
Dispute Act, 1947.
At present, the
matter is pending
before the 7th
Labour Court at
Bandra.
14. 2015 Application No. 37 of 2015
filed by Mumtaz Ali Sakir Ali
before the 7thLabour Court at
The workman filed a complaint
under Section 33 C (2) (dispute
relating to money/benefit
At present, the
matter is pending
before the
184
Sr. No Year Parties and Court of
Litigation
Particulars of the Case Status
Mumbai. entitled to worker from the
employer) of the Industrial
Dispute Act, 1947.
7thLabour Court at
Bandra.
15. 2015 Application No.52 of
2015filed by Saratullah
Shaikh before the 7thLabour
Court at Mumbai.
The workman filed a complaint
under Section 33 C (2) dispute
relating to money/benefit
entitled to worker from the
employer of the Industrial
Dispute Act, 1947.
At present, the
matter is pending
before the
7thLabour Court at
Bandra.
16. 2013 Application No. 26046 of
2013 filed by Arobindo
Chakravorty before the High
Court of Calcutta.
The workman filed a complaint
under Section 33 C (2) dispute
relating to money/benefit
entitled to worker from the
employer of the Industrial
Dispute Act, 1947.
At present, the
matter is pending
before the High
Court of Calcutta.
Complaints regarding Unfair labour practices
17. 2012 Application No. Unfair
Labour Practice 67 of 2012
filed by Jata Shankar Gautam
before the Industrial Court,
Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
18. 2012 Application No Unfair
Labour Practice 68 of 2012
filed by Gautam Chopade
before the Industrial Court,
Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
19. 2012 Application No. Unfair
Labour Practice 69 of 2012
filed by Kashiram
Prabhuddin before the
Industrial Court, Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
20. 2012 Application No. Unfair
Labour Practice 70 of 2012
filed Ram Sevak Fagu before
the Industrial Court, Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
21. 2012 Application No. Unfair
Labour Practice 71 of 2012
filed by Ram Subhagi
Mahabal before the Industrial
Court, Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
22. 2012 Application No. Unfair
Labour Practice 72 of 2012
filed by Ram Dhawal Rajmal
before the Industrial Court,
Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
23. 2012 Application No. Unfair
Labour Practice 73 of 2012
filed by Samappa Poojary
before the Industrial Court,
Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
24. 2012 Application No. Unfair
Labour Practice 74 of 2012
filed by Vijay Shankar Halde
before the Industrial Court,
Mumbai
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai
25. 2012 Application No. Unfair
Labour Practice 75 of 2012
The workman filed a complaint
of Unfair Labour Practices for
At present, the
matter is pending
185
Sr. No Year Parties and Court of
Litigation
Particulars of the Case Status
filed by Ramfer Rasiyan
before the Industrial Court,
Mumbai
hiring outsiders at the worksite
in preference to the local
workmen.
before the Industrial
Court, Mumbai
26. 2012 Application No. Unfair
Labour Practice 76 of 2012
filed by Raja Ram Shirapat
before the Industrial Court,
Mumbai
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai
27. 2012 Application No. Unfair
Labour Practice 78 of 2012
filed by Bholanath Bisai
before the Industrial Court,
Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
28. 2012 Application No.Unfair
Labour Practice 79 of 2012
filed by Amarjeet Chaudhary
before the Industrial Court,
Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
29. 2012 Application No. Unfair
Labour Practice 80 of 2012
filed by Jaiprakash Sukhu
before the Industrial Court,
Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
30. 2012 Application no. Unfair
Labour Practice 81 of 2012
filed by Sheshram Sukha
before the Industrial Court,
Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
31. 2012 Application No. Unfair
Labour Practice 82 of 2012
filed by M. Jama Hasmullah
before the Industrial Court,
Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
32. 2012 Application No. Unfair
Labour Practice 83 of 2012
filed by Rasiyavan Saheb
before the Industrial Court,
Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
33. 20212 Application No 84 of 2012
filed by Bholanath Tasu
before the Industrial
Court,Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
34. 2012 Unfair Labour Practice 85 of
2012 filed by Dost. M.
Hasamatali before the
Industrial Court, Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
35. 2012 Unfair Labour Practice 86 of
2012 filed by Ashok Kumar
Mishra filed before the
Industrial Court, Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
36. 2012 Application No. Unfair
Labour Practice 87 of 2012
filed by Loknath Kalpu
before the Industrial Court,
Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
186
Sr. No Year Parties and Court of
Litigation
Particulars of the Case Status
37. 2012 Application No. 88 of 2012
filed by Tulsi Jokhan before
the Industrial Court, Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
38. 2012 Application no. Unfair
Labour Practice 89 of 2012
filed by Ram Prasad Verma
before the Industrial Court,
Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
39. 2012 Application No. Unfair
Labour Practice 92 of 2012
filed by Nandu.K.Bhosale
before the Industrial Court,
Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
40. 2012 Application no. Unfair
Labour Practice 94 of 2012
filed by Ramesh Kamble
before the Industrial Court,
Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
41. 2012 Application No. Unfair
Labour Practice 95 of 2012
filed by Sajiullah Hisabi
before the Industrial Court,
Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
42. 2012 Application No. Unfair
Labour Practice 96 of 2012
filed by Vinay Kumar Gowd
before the Industrial Court,
Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
43. 2012 Application No. Unfair
Labour Practice 97 of 2012
filed by Sitaram Prahuddin
before the Industrial Court,
Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
44. 2012 Application No. Unfair
Labour Practice 98 of 2012
filed by Muhabbat Ali before
Industrial Court, Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
45. 2012 Application No. Unfair
Labour Practice 99 of 2012
filed by Ramhit Nayanraj
before the Industrial Court,
Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
46. 2012 Application No. Unfair
Labour Practice 100 of 2012
filed by Shriram Rambali
before the Industrial Court,
Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
47. 2012 Application No. Unfair
Labour Practice 101 of 2012
filed by Prakash Pawar before
the Industrial Court, Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
48. 2012 Application No. Unfair
Labour Practice 102 of 2012
filed by Chandrakant Jadhav
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
At present, the
matter is pending
before the Industrial
187
Sr. No Year Parties and Court of
Litigation
Particulars of the Case Status
before the Industrial Court,
Mumbai.
in preference to the local
workmen.
Court, Mumbai.
49. 2012 Application No. Unfair
Labour Practice 103 of 2012
filed by Babulal Ravindra
before the Industrial Court,
Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
50. 2012 Application No. Unfair
Labour Practice 104 of 2012
filed by Shiya Ram Verma
before the Industrial Court,
Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
51. 2012 Application No. Unfair
Labour Practice 105 of 2012
filed by Mustak Mohd Haddis
before the Industrial Court,
Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
52. 2012 Application No. Unfair
Labour Practice 106 of 2012
filed by Subramaniyam
Kanda Swami before the
Industrial Court, Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
53. 2012 Application No. Unfair
Labour Practice 107 of 2012
filed by Kamla Prasad Yadav
before the Industrial
Court,Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
54. 2012 Application No. Unfair
Labour Practice 108 of 2012
filed by Samiullah Idris
before the Industrial Court,
Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
55. 2012 Application No. Unfair
Labour Practice 109 of 2012
filed by Saeed Khan Abdul
Razak before the Industrial
Court, Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
56. 2012 Application No. Unfair
Labour Practice 110 of 2012
filed by Chandrabali
Paradeshi before the
Industrial Court, Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
57. 2012 Application No. Unfair
Labour Practice 66 of 2012
filed by Samiullah Khairullah
before the Industrial Court,
Mumbai.
The workman filed a complaint
of Unfair Labour Practices for
hiring outsiders at the worksite
in preference to the local
workmen.
At present, the
matter is pending
before the Industrial
Court, Mumbai.
58. 2014 Application No Unfair
Labour Practice 12 of 2014
filed by Engineering Mazdor
Sabha before the Industrial
Court, Mumbai.
The Applicant filed a complaint
alleging that the Company
refused to bargain Collectively,
with a recognized union (Item 5
of Schedule II), and failure to
implement the
award/settlement/agreement
(Item 9 of schedule IV) of the
Maharashtra Recognition of
Trade Unions and Prevention of
Unfair Labour Practices Act,
At present, the
matter is pending
before the Industrial
Court, Mumbai.
188
Sr. No Year Parties and Court of
Litigation
Particulars of the Case Status
1971.
59. 2017 Application No LCR 17/2017
filed by Mohd Arshad Khan
before the Labour Court,
Jaipur.
The Applicant filed a complaint
alleging that the Company
hadn’t furnished the balance
payment under Payment of
Wages Act.
At present the
matter is pending
before the Labour
Court, Jaipur.
60. 2017 Writ Petition No. 9654 of
2016 filed by Rashtriya
Janwadi Kamgar Sabghatana
before the High Court at
Bombay.
The Applicant has filed an
application to challenge the
virus of section 21 of the
Maharashtra Recognition of
Trade Unions (MRTU) and
Prevention of Unfair Labour
Practices Act (PULP).
At present the
matter is pending
before the High
Court at Bombay.
61. 2014 Application No. 7 of 2009
filed by Lais Mohammed
Samiullah before the
Controlling Authority
industrial court Mumbai.
The Applicant has filed an
application for payment of
Gratuity under the Provisions of
The Payment of Gratuity Act,
1972.
At present the
matter is pending
before the
Controlling
Authority industrial
court Mumbai.
62. 2014 Application No. 24 of 2014
filed against Rashtriya
General Kamgar Sena before
the Industrial Tribunal at
Mumbai.
The Application was filed by the
Respondent against the
Company for re-instatement and
back wages.
At present the
matter is still
pending before the
Industrial Court at
Mumbai.
63. 2011 Application No. 61/8022 of
2010 filed by the General
Secretary, State Multiple
Contractor’s Labour Union
and Naraya Naguda before
the Additional
Commissioner, Hyderabad.
The Application was filed by the
Complainant towards unpaid
wages and retrenchment
compensation under section 33-
C of Industrial Disputes Act,
1947.
At present, the
matter is pending
before the
Additional
Commissioner, t
Hyderabad.
64. 2003 Writ petition No.10320 of
2003 filed by the Registrar
before the High Court of
Kolkata.
The Respondent has filled the
petition challenging the order
dated April 4, 2003.
At present the
matter is pending
before the High
Court of Kolkata.
Criminal Cases
A. Litigation filed by the Company
Our Company has instituted 1 (one) Criminal Case No. 8602 of 2017 under Section 138 of the Negotiable
Instruments Act, 1881 before the Chief Judicial Magistrate Court at Ahmedabad against Lalan
Developers Private Limited for dishonour of a cheque of ₹ 5,55,443/- (Rupees five lakhs fifty five four
hundred and forty three) issued in the name of our Company. This matter is presently pending before the
Chief Judicial Magistrate Court at Ahmedabad.
B. Litigation filed against the Company
1. Labour cases
Sr.
No
Year Parties and Court of
Litigation
Particulars of the Case Status
1. 2015 State of Madhya Pradesh v.
Dattaray Babu Ram Akhade
before the Chief Magistrate
Officer
The case was filed against the
Company regarding the theft of
materials from the premises of
one of our client’s power
projects.
Order dated July 16,
2015 has been
passed in the matter
granting bail to the
accused person.
2. 2016 Sanjay Bajoria v. ITD The case was filed against the The matter is
189
Sr.
No
Year Parties and Court of
Litigation
Particulars of the Case Status
Cementation India Limited
before the Metropolitan
Magistrate
Company under section 287,
288, 377 and 338 of Indian
Penal Code, 1860.
presently pending
before the
Metropolitan
Magistrate.
3. 2017 NCT of Delhi v. Munesh
Kumar and Ors. before the
Metropolitan Magistrate
The case was filed against the
Company due to the occurrence
of a fatal accident at the work
site.
The matter is
presently pending
before the
Metropolitan
Magistrate.
4. 1998 Gurunam Singh Hothi v. B.
Raghavan, General Manager
and P. K. Kapoor, Director
before the Metropolitan
Magistrate.
The complaint was filed against
the Company due to non-
payment of security bills.
The matter is
presently pending
before the
Metropolitan
Magistrate.
5. 1999 Criminal Compliant No.14 of
1999 filed by the Labour
Enforcement Officer, Paradip
before the 1st Class Judicial
Magistrate, Kujang.
The Labour Enforcement
Officer, Paradip filed a
complaint alleging non-
maintenance of records and
registers and non-display of
notices at the work site.
At present, the
matter is pending
before the First
Class Judicial
Magistrate, Kujang.
2. Case No. DC/MG/3/KV/915/16 filed by Ashok Brijlal Bhatia (“Applicant”) against the Company in
the Court of District Collector Satara, Satara
The Company had entered into an (“Agreement”) with National Highway Authority of India (“NHAI”)
for widening the exiting 2 lane carriageways to 4 lane of Pune, Satara (“Project”). For the Project, the
Company had applied for seeking quarry operation permission for effective blasting work in the property
bearing Gat No.84 and the same was granted, subject to certain terms and conditions. The Applicant filed
a complaint requesting the Collector to conduct inquiry alleging that the Company had carried out illegal
and authorized blasting and quarrying operations on the property bearing Gat No.84/8/A and also on
84/8/B which belonged to the applicant’s family. In response, the Company claimed that all necessary
permissions and provisions were complied with and further the suit could not be taken into cognizance
since the same is barred by limitation under Section 468 of the Code of Criminal Procedure, 1973. Both
parties completed their respective oral arguments. Our Company has also filed written submissions.
At present, the complaint is pending before the Court of District Collector Satara for order.
II. LITIGATION INVOLVING OUR SUBSIDIARY
Nil
III. LITIGATIONS INVOLVING OUR PROMOTER
As on September 30, 2017, there is no litigation or legal action pending or taken by any ministry or
department of the Government or statutory authority against our Promoter during the last three years
immediately preceding the year of the circulation of this Preliminary Placement Document and any
direction issued by such ministry or department of the Government or statutory authority upon conclusion
of such litigation or legal action, save and except as under:
1. The Promoter had received a notice dated October 14, 2015 (“Notice”) from the Recovery Officer,
Employees Provident Fund Organisation, Jalpaiguri (“EPF Officer”) demanding for payment of ₹
6,78,12,961/- on account of provident fund dues under section 14 B along with interest under section
7Q (“EPF Dues”) of the Employees’ Provident Fund and Miscellaneous Provisions Act, 1952 (“EPF
Act”). The EPF Dues demanded by the EPF Officer is for recovery of provident fund dues in reference
to the international workers stationed at the project office of the Promoter for providing specialised
services towards constructing roads at West Bengal. Further, the EPF Officer has also issued a notice to
Standard Chartered Bank for freezing the bank account of the Promoter and instructed the said Bank to
pay the amount held in the account of the Promoter directly to the EPF Officer.
190
Prior to receipt of this said Notice, the project office had filed Writ Petition No. 510 (W) of 2011 before
the High Court of Calcutta against a similar demand action of the EPF Officer in relation to the payment
of EPF dues of international workers. The Hon’ble High Court had passed an interim order dated April
23, 2013 in the said matter restricting the EPF Officer from taking any further action in the said matter
till final disposal of the Writ Petition. However, the EPF Officer has issued the said Notice under the
EPF Act demanding for payment of EPF Dues.
At present, the Promoter has paid an amount of ₹ 6,29,60, 801/- to the EPF Officer under protest. Further,
the Writ Petition is presently pending before the High Court of Calcutta for final disposal.
2. Arbitration filed by our Promoter against National Highway Authority of India (“Respondent”) before
the Hon’ble Arbitral Tribunal of three arbitrators comprising of Justice P Ramakrisnam Raju as the
Presiding Arbitrator, Shri D Sreerama Murthy and Shri. A. B. Desai.
The Respondent and the Promoter had entered into a contract dated April 20, 2006 (“Contract”) of
widening and strengthening of existing National Highway from 2 lane to 4 lane from Km. 255 to 228 of
Assam Border to Gairkatta section of NH-31C in West Bengal or East West corridor under phase II
programme of NHDP. The Contract was scheduled to be completed within a period of 30 months,
however the same got delayed. The Promoter has filed arbitration proceedings under two separate
references. The first arbitration reference was claiming for additional costs and losses amounting to ₹
2,189,887,204/- incurred due to the said delay in the performance of the Contract and wrong levy of
liquidated damages through encashment of bank guarantee issued by the Promoter.
The matter is presently pending before the arbitral tribunal.
3. Arbitration filed by our Promoter against National Highway Authority of India (“Respondent”) before
the Hon’ble Arbitral Tribunal of Three arbitrators comprising of Shri S. C. Gupta as Presiding
Arbitrator, Shri Jagmohan Lal and Shri A. B. Desai
We refer to the facts elucidated under para III (2) of this chapter. In furtherance to the same, our Promoter
has filed a second reference of arbitration claiming for balance retention money, payments towards
statement at completion, payment towards final statement and interest together amounting to ₹
7,70,23,799/- .
The matter is presently pending before the arbitral tribunal.
IV. PROCEEDINGS UNDER THE COMPANIES ACT
There has been no inquiry, inspection or investigations initiated or conducted against the Company under
the Companies Act, 2013 or any previous company law in the last three years immediately preceding the
year of circulation of this Preliminary Placement Document against either our Company or our
Subsidiary. Further, there have not been any prosecutions filed (whether pending or not), fines imposed,
compounding of offences under the Companies Act, 2013 or any previous company law, in the last three
years immediately preceding the year of circulation of this Preliminary Placement Document with respect
to the Company or its Subsidiary.
V. MATERIAL FRAUDS COMMITTED AGAINST OUR COMPANY IN THE LAST THREE YEARS
There have been no material frauds committed against our Company in the last three years.
VI. POTENTIAL LITIGATION AGAINST OUR COMPANY
Crime No. 01/RCO-CIU-ACB/ 2018 by the Anti Corruption Bureau, Andhra Pradesh against our
employee and representative.
For details on the matter, please refer the Risk Factor no.1 on page 29.
VII. TAX RELATED PROCEEDINGS
A. Tax related litigation involving our Company
191
1. Income Tax
There are 4 (four) income tax matters amounting to ₹ 315.48 lakh approximately, involving our
Company, pending at various levels of adjudication.
2. Central Excise
There is 1 (one) central excise matter amounting to ₹ 52 lakh approximately, involving our Company,
pending at various levels of adjudication.
3. Sales Tax and Value Added Tax
There are 25 (twenty five) sales tax and value added tax matters amounting to ₹3,336.17 lakhs
approximately, involving our Company, pending at various levels of adjudication.
B. Tax related proceedings involving the Subsidiary
There are no tax related proceedings against the Subsidiary of our Company.
192
INDEPENDENT ACCOUNTANTS
Our Company’s current statutory auditors, M/s. Walker Chandiok & Co., LLP, Chartered Accountants,
bearing registration number 001076N/N500013 are independent auditors with respect to our Company as
required by the Companies Act and in accordance with the guidelines issued by the Institute of Chartered
Accountants of India. Our Statutory Auditors have audited financial statements as of and for the Fiscal Year
ended December 31, 2016, December 31, 2015 and December 31, 2014 and for the three month period ended
March 31, 2017, 6 months ended June 30, 2017 and nine months ended September 30, 2017, whose reports
are included in this Preliminary Placement Document. Please see the chapter titled “Financial Statements”
beginning on page 194.
193
GENERAL INFORMATION
1. Our Company was originally incorporated on June 24, 1978 as a limited company under the Companies
Act, 1956 in the name of Cemindia Company Limited. On September 7, 1994, our Company changed its
name to Trafalgar House Construction India Limited. Our Company changed its name to Kvaerner
Cementation India Limited on September 1, 1998. On July 11, 2001, the name of our Company was
further changes to Skanska Cementation India Limited. Our Company changed its name to ITD
Cementation India Limited on May 26, 2005.
2. As of the date of this Preliminary Placement Document, our authorized capital is ₹750,000,000 (Rupees
seven thousand five hundred lakh only) divided into 300,000,000 (three thousand lakh) Equity Shares of
Re. 1 (Rupee one) each aggregating to ₹ 300,000,000 (Rupees three thousand lakh) and 45,000,000 (four
hundred fifty lakh only) preference shares of ₹ 10 (Rupees ten each) aggregating to a total of ₹ 450,000,000 (Rupees four thousand and five hundred lakh only). As of the date of this Preliminary
Placement Document, 15,51,83,160 Equity Shares of ₹ 1 each have been issued and 15,51,57,900 Equity
Shares of ₹1 each have been subscribed and paid up.
3. Our Registered Office is located at National Plastic Building, A-Subhash Road, Paranjape B Scheme,
Vile Parle (East), Mumbai, Maharashtra, 400 057.
4. Under our Memorandum of Association, our principal objects are to carry on the business described in
the chapter titled “Our Business” beginning on page 102. The objects are set out in Clause III of our
Memorandum of Association.
5. This Issue was authorized and approved by our Board by its resolutions dated September 21, 2017 and
approved by our shareholders vide a special resolution passed through postal ballot on December 12,
2017.
6. Our Company has applied for and received in-principle approvals from the BSE and the NSE under
Regulation 28 of the SEBI Listing Regulations for the issue of the Equity Shares. We will apply for final
approvals to list our Equity Shares to be issued in the Issue on the BSE and the NSE.
7. Copies of our Memorandum and Articles of Association will be available for inspection during usual
business hours on any weekday (except Saturday, Sunday and public holidays) during the offering period
of this Issue at our Registered Office.
8. Other than as set forth in this Preliminary Placement Document, there has been no significant change in
our financial results since December 31, 2016, the date of our last audited financial statements.
9. Except as disclosed in this Preliminary Placement Document, we are not involved in any material legal
proceedings and we are not aware of any threatened legal proceedings, which, if determined adversely,
could result in a material adverse effect on our business, financial condition or results of operations.
10. Our Company has obtained necessary consents, approvals and authorisations required in connection with
this Issue.
11. M/s. Walker Chandiok & Co. LLP, Chartered Accountants have audited our financial statements as of
and for the twelve months period ended on December 31, 2016, December 31, 2015 and December 31,
2014 and have also prepared unaudited statements for the three month period ended March 31, 2017, 6
months ended June 30, 2017 and nine months ended September 30, 2017. They have provided their
consent for inclusion of their reports in relation thereto in this Preliminary Placement Document.
12. We confirm that we are in compliance with the minimum public shareholding requirements as provided
in the SEBI Listing Regulations.
13. Our Company and the BRLM accept no responsibility for statements made otherwise than in this
Preliminary Placement Document and anyone placing reliance on any other source of information,
including our website www.itdcem.co.in, would be doing so at his or her own risk.
14. The Floor Price for this Issue is ₹ 213.20 per Equity Share calculated in accordance with Regulation 85
of the SEBI ICDR Regulations. Our Company may offer a discount of not more than 5% on the Floor
Price in terms of Regulation 85 of the SEBI ICDR Regulations.
194
FINANCIAL STATEMENTS
INDEX
Sr.
No.
Contents Page No.
1. Auditor’s Report and Financial Statements for the twelve months period ended
December 31, 2016
195 – 225
2. Auditor’s Report and Financial Statements for the twelve months year ended
December 31, 2015
226 – 259
3. Auditor’s Report and Financial Statements for the twelve months year ended
December 31, 2014
260 – 285
4. Limited Review Report and consolidated Financial Results of our Company as of
and for the three months period ended March 31, 2017.
286 – 289
5. Limited Review Report and consolidated Financial Results of our Company as of
and for the six months period ended June 30, 2017.
290 – 295
6. Limited Review Report and consolidated Financial Results of our Company as of
and for the nine months period ended September 30, 2017.
296 – 300
Independent Auditor’s Report
To
The Members of
ITD Cementation India Limited
Report on the Consolidated Financial Statements1. We have audited the accompanying consolidated financial
statements of ITD Cementation India Limited, (“the Holding
Company”) and its subsidiary (the Holding Company and
its subsidiary together referred to as “the Group”), and
unincorporated jointly controlled entities which comprise
the Consolidated Balance Sheet as at 31 December 2016, the
Consolidated Statement of Profit and Loss and the Consolidated
Cash Flow Statement for the year then ended and a summary
of the significant accounting policies and other explanatory
information.
Management’s Responsibility for the Consolidated Financial Statements2. The Holding Company’s Board of Directors is responsible for
the preparation of these consolidated financial statements in
terms of the requirements of the Companies Act, 2013 ( “the
Act”) that give a true and fair view of the consolidated financial
position, consolidated financial performance and consolidated
cash flows of the Group and unincorporated jointly controlled
entities, in accordance with the accounting principles generally
accepted in India, including the Accounting Standards
specified under Section 133 of the Act, read with Rule 7 of
the Companies (Accounts) Rules, 2014 (as amended). The
Holding Company’s Board of Directors, and the respective
Board of Directors/management of the subsidiary included in
the Group, and unincorporated jointly controlled entities are
responsible for the design, implementation and maintenance
of internal control relevant to the preparation and presentation
of the financial statements that give a true and fair view and are
free from material misstatement, whether due to fraud or error.
Further, in terms with the provisions of the Act, the respective
Board of Directors of the Holding Company and its subsidiary
which is incorporated in India, are responsible for maintenance
of adequate accounting records; safeguarding the assets;
preventing and detecting frauds and other irregularities;
selection and application of appropriate accounting policies;
making judgments and estimates that are reasonable and
prudent; and design, implementation and maintenance of
adequate internal financial controls, that were operating
effectively for ensuring the accuracy and completeness of
the accounting records, relevant to the preparation and
presentation of the financial statements, which have been
used for the purpose of preparation of the consolidated
financial statements by the directors of the Holding Company,
as aforesaid.
Auditor’s Responsibility3. Our responsibility is to express an opinion on these consolidated
financial statements based on our audit.
4. While conducting the audit, we have taken into account the
provisions of the Act, the accounting and auditing standards
and matters which are required to be included in the auditor’s
report under the provisions of the Act and the Rules made
thereunder.
5. We conducted our audit in accordance with the Standards
on Auditing specified under Section 143(10) of the Act. Those
Standards require that we comply with ethical requirements
and plan and perform the audit to obtain reasonable assurance
about whether the consolidated financial statements are free
from material misstatement.
6. An audit involves performing procedures to obtain audit
evidence about the amounts and the disclosures in the
consolidated financial statements. The procedures selected
depend on the auditor’s judgment, including the assessment
of the risks of material misstatement of the consolidated
financial statements, whether due to fraud or error. In making
those risk assessments, the auditor considers internal financial
controls relevant to the Holding Company’s preparation of
the consolidated financial statements that give a true and fair
view in order to design audit procedures that are appropriate
in the circumstances. An audit also includes evaluating the
appropriateness of the accounting policies used and the
reasonableness of the accounting estimates made by the
Holding Company’s Board of Directors, as well as evaluating the
overall presentation of the consolidated financial statements.
7. We believe that the audit evidence obtained by us is sufficient
and appropriate to provide a basis for our audit opinion on the
consolidated financial statements.
Opinion8. In our opinion and to the best of our information and according
to the explanations given to us, the aforesaid consolidated
financial statements give the information required by the Act
in the manner so required and give a true and fair view in
conformity with the accounting principles generally accepted
in India, of the consolidated state of affairs of the Group and
unincorporated jointly controlled entities as at 31 December
2016, their consolidated profit and their consolidated cash
flows for the year ended on that date.
195
Emphasis of Matter9. We draw attention to Note 37 to the consolidated financial
statements which describes the uncertainty related to
recoverability of long-term trade receivables and unbilled
work in progress aggregating to H2,863.37 lakhs (31 December
2015: H2,863.37 lakhs) and H8,677.57 lakhs (31 December 2015:
H8,677.57 lakhs) respectively, outstanding as at 31 December
2016, representing various claims recognised during the
earlier period based on the terms and conditions implicit
in the contracts. These claims being technical in nature and
being subject matter of litigation, the Company has assessed
the recoverability of these claims based on legal opinion from
an independent counsel. On the basis of such assessment,
management is of the opinion that the claims are tenable
and would be realized in full and accordingly no adjustments
have been made in the consolidated financial statements.
Our opinion on the consolidated financial statements is not
modified in respect of these matters.
Report on Other Legal and Regulatory Requirements10. As required by Section 143(3) of the Act, and based on the
auditor’s reports of the subsidiary and unincorporated jointly
controlled entities, we report, to the extent applicable, that:
a) We have sought and obtained all the information and
explanations which to the best of our knowledge and
belief were necessary for the purpose of our audit of the
aforesaid consolidated financial statements;
b) in our opinion, proper books of account as required by
law relating to preparation of the aforesaid consolidated
financial statements have been kept so far as it appears
from our examination of those books and the reports of
the other auditors;
c) The consolidated financial statements dealt with by
this Report are in agreement with the relevant books of
account maintained for the purpose of preparation of the
consolidated financial statements;
d) in our opinion, the aforesaid consolidated financial
statements comply with the Accounting Standards
specified under Section 133 of the Act, read with Rule 7 of
the Companies (Accounts) Rules, 2014(as amended);
e) The matter described in paragraph 9 under the Emphasis
of Matter, in our opinion, may have an adverse effect on
the functioning of the Group;
f ) On the basis of the written representations received from
the directors of the Holding Company as on 31 December
2016 taken on record by the Board of Directors of the
Holding Company and the report of the other statutory
auditors of its subsidiary company incorporated in India,
none of the directors of the Group company, is disqualified
as on 31 December 2016 from being appointed as a
director in terms of Section 164 (2) of the Act.
g) we have also audited the internal financial controls over
financial reporting (IFCoFR) of the Holding Company and
its subsidiary company which is incorporated in India, as
at 31 December 2016, in conjunction with our audit of the
consolidated financial statements of the group for the year
ended on that date and our report dated 21 February 2017
as per Annexure I expressed an unmodified opinion.
h) With respect to the other matters to be included in
the Auditor’s Report in accordance with Rule 11 of the
Companies (Audit and Auditor’s) Rules, 2014, in our
opinion and to the best of our information and according
to the explanations given to us:
(i) except for the possible effect of the matters
described above in paragraph 9 under the Emphasis
of Matters paragraph and as detailed in Note 30 (d)
to (e), the consolidated financial statements disclose
the impact of pending litigations on the consolidated
financial position of the Group and unincorporated
jointly controlled entities;
(ii) the Group and unincorporated jointly controlled
entities has made provisions as required under
applicable law or accounting standards, for
foreseeable losses, if any, on long-term contracts. The
Company did not have any derivative contracts.
(iii) There were no amounts which were required to be
transferred to the Investor Education and Protection
Fund by the Holding Company, and its subsidiary
company, incorporated in India.
For Walker Chandiok & Co LLPChartered Accountants
Firm’s Registration No.: 001076N/N500013
per Sudhir N. PillaiPlace : Mumbai Partner
Date : 21 February 2017 Membership No.: 105782
196
Annexure I
Independent Auditor’s report on the Internal Financial Controls under Clause (i) of Sub-section 3 of Section 143 of the Companies Act, 2013 (“the Act”)1. In conjunction with our audit of the consolidated financial
statements of the ITD Cementation India Limited (“the Holding
Company”) and its subsidiary incorporated in India, (the
Holding Company and its subsidiaries together referred to as
“the Group”) and unincorporated jointly controlled entities,
as at and for the year ended 31 December 2016, we have
audited the internal financial controls over financial reporting
(IFCoFR) of the Holding Company and its subsidiary company
incorporated in India, as at that date.
Management’s Responsibility for Internal Financial Controls2. The respective Board of Directors of the Holding Company and
its subsidiary company incorporated in India, are responsible
for establishing and maintaining internal financial controls
based on the internal control over financial reporting criteria
established by the Company considering the essential
components of internal control stated in the Guidance Note
on Audit of Internal Financial Controls over Financial Reporting
(the “Guidance Note”) issued by the Institute of Chartered
Accountants of India (“ICAI”). These responsibilities include
the design, implementation and maintenance of adequate
internal financial controls that were operating effectively for
ensuring the orderly and efficient conduct of the company’s
business, including adherence to the company’s policies, the
safeguarding of the company’s assets, the prevention and
detection of frauds and errors, the accuracy and completeness
of the accounting records, and the timely preparation of
reliable financial information, as required under the Act.
Auditors’ Responsibility3. Our responsibility is to express an opinion on the IFCoFR of the
Holding Company and its subsidiary company, as aforesaid,
based on our audit. We conducted our audit in accordance with
the Standards on Auditing, issued by the Institute of Chartered
Accountants of India (ICAI) and deemed to be prescribed under
section 143(10) of the Act, to the extent applicable to an audit
of IFCoFR and the Guidance Note issued by the ICAI. Those
Standards and the Guidance Note require that we comply
with ethical requirements and plan and perform the audit to
obtain reasonable assurance about whether adequate IFCoFR
were established and maintained and if such controls operated
effectively in all material respects.
4. Our audit involves performing procedures to obtain audit
evidence about the adequacy of the IFCoFR and their
operating effectiveness. Our audit of IFCoFR included
obtaining an understanding of IFCoFR, assessing the risk that a
material weakness exists, and testing and evaluating the design
and operating effectiveness of internal control based on the
assessed risk. The procedures selected depend on the auditor’s
judgement, including the assessment of the risks of material
misstatement of the financial statements, whether due to fraud
or error.
5. We believe that the audit evidence we have obtained is
sufficient and appropriate to provide a basis for our audit
opinion on the IFCoFR of the Holding Company and its
subsidiary company as aforesaid.
Meaning of Internal Financial Controls over Financial Reporting6. A company’s IFCoFR is a process designed to provide
reasonable assurance regarding the reliability of financial
reporting and the preparation of financial statements for
external purposes in accordance with generally accepted
accounting principles. A company’s IFCoFR includes those
policies and procedures that (1) pertain to the maintenance of
records that, in reasonable detail, accurately and fairly reflect
the transactions and dispositions of the assets of the company;
(2) provide reasonable assurance that transactions are recorded
as necessary to permit preparation of financial statements in
197
accordance with generally accepted accounting principles, and
that receipts and expenditures of the company are being made
only in accordance with authorisations of management and
directors of the company; and (3) provide reasonable assurance
regarding prevention or timely detection of unauthorised
acquisition, use, or disposition of the company’s assets that
could have a material effect on the financial statements.
Inherent Limitations of Internal Financial Controls over Financial Reporting7. Because of the inherent limitations of IFCoFR, including the
possibility of collusion or improper management override of
controls, material misstatements due to error or fraud may
occur and not be detected. Also, projections of any evaluation
of the IFCoFR to future periods are subject to the risk that
the IFCoFR may become inadequate because of changes in
conditions, or that the degree of compliance with the policies
or procedures may deteriorate.
Opinion8. In our opinion, the Holding Company and its subsidiary
company incorporated in India, have, in all material respects,
adequate internal financial controls over financial reporting
and such internal financial controls over financial reporting
were operating effectively as at 31 December 2016, based on
the internal control over financial reporting criteria established
by the Company considering the essential components of
internal control stated in the Guidance Note issued by ICAI.
For Walker Chandiok & Co LLPChartered Accountants
Firm’s Registration No.: 001076N/N500013
per Sudhir N. PillaiPlace : Mumbai Partner
Date : 21 February 2017 Membership No.: 105782
198
Consolidated Balance Sheet as at 31 December 2016
(Currency : Indian Rupee in lakhs)
Notes As at 31 December 2016
As at 31 December 2015
EQUITY AND LIABILITIESShareholders’ FundsShare capital 2 1,551.58 1,551.58 Reserves and surplus 3 53,520.39 49,269.85
55,071.97 50,821.43 Non-Current LiabilitiesLong-term borrowings 4 4,062.13 1,178.81 Long-term provisions 5 902.36 694.56
4,964.49 1,873.37 Current LiabilitiesShort-term borrowings 6 37,105.85 56,211.69 Trade payables 7
- Total outstanding dues of Micro Enterprises and Small Enterprises 758.85 - - Total outstanding dues of creditors other than Micro Enterprises
and Small Enterprises 63,208.08 75,429.28
Current maturity of long-term-borrowings 4 5,131.01 2,684.22 Other current liabilities 8 46,996.70 55,837.61 Short-term provisions 9 2,544.04 1,621.57
1,55,744.53 1,91,784.37 Total 2,15,780.99 2,44,479.17 ASSETSNon-Current AssetsFixed Assets
- Tangible assets 10 38,184.36 34,898.52 - Capital work-in-progress 560.20 267.22
Deferred tax assets (net) 11 2,756.42 4,423.39 Long-term loans and advances 12 27,518.73 22,167.51 Long-term trade receivables 16 2,863.37 2,863.37 Other non-current assets 13 - 23.79
71,883.08 64,643.80 Current AssetsCurrent investment 14 0.26 0.26 Inventories 15 84,567.21 1,17,538.07 Trade receivables 16 26,482.29 30,917.17 Cash and bank balances 17 18,509.82 14,760.26 Short-term loans and advances 12 14,298.79 16,500.51 Other current assets 18 39.54 119.10
1,43,897.91 1,79,835.37 Total 2,15,780.99 2,44,479.17 Significant accounting policies 1
Notes 1 to 42 form an integral part of these consolidated financial statements
This is the consolidated balance sheet referred to in our report of even date
For and on behalf of the Board of Directors
Adun Saraban P. ChakornbunditManaging Director DirectorDIN No.01312769 DIN No.00254312
S. Ramnath Rahul NeogiChief Financial Officer Company SecretaryFCA No. 030663 ACS No.10653
Place : Mumbai
For Walker Chandiok & Co LLP Chartered AccountantsFirm Registration No. 001076N/N500013
Sudhir N. Pillai Partner Membership No: 105782
Place : Mumbai Date: 21 February 2017 Date: 21 February 2017
199
Consolidated Statement of Pro�t and Loss for the year ended 31 December 2016
(Currency : Indian Rupee in lakhs)
Notes Year ended 31 December 2016
Year ended 31 December 2015
REVENUE
Contract revenue 3,08,856.02 3,06,870.03
Other operating income 19 103.98 224.87
Other income 20 2,522.16 2,217.41
Total revenue 3,11,482.16 3,09,312.31
EXPENSES
Cost of materials consumed 73,225.93 80,945.83
Sub-contract expense 1,32,999.85 1,29,588.37
Employees benefits expense 21 25,380.31 22,240.69
Finance costs 22 11,652.27 13,771.36
Depreciation expense 10 4,494.45 3,665.05
Other expenses 23 56,368.55 55,162.40
Total Expenses 3,04,121.36 3,05,373.70
Pro�t before exceptional item and tax 7,360.80 3,938.61
Exceptional items 24 - (12,397.19)
Pro�t/(loss) before tax 7,360.80 (8,458.58)
Tax expense
Current tax (3,455.44) (265.37)
Less: Minimum alternative tax credit entitlement 2,550.83 -
Earlier year tax adjustments 21.55 (131.83)
Deferred tax (charge)/credit (1,666.97) 2,925.02
Net pro�t /(loss) for the year 4,810.77 (5,930.76)
Earnings/(loss) per equity share of H1each 25
Basic and diluted 3.10 (3.82)
Notes 1 to 42 form an integral part of these consolidated financial statements
This is the consolidated statement of profit and loss referred to in our report of even date
For Walker Chandiok & Co LLP For and on behalf of the Board of DirectorsChartered AccountantsFirm Registration No. 001076N/N500013
Sudhir N. Pillai Adun Saraban P. ChakornbunditPartner Managing Director DirectorMembership No: 105782 DIN No.01312769 DIN No.00254312
S. Ramnath Rahul NeogiChief Financial Officer Company SecretaryFCA No. 030663 ACS No.10653
Place : Mumbai Place : MumbaiDate: 21 February 2017 Date: 21 February 2017
200
Consolidated Cash Flow Statement for the year ended 31 December 2016
(Currency : Indian Rupee in lakhs)
Year ended 31 December 2016
Year ended 31 December 2015
CASH FLOW FROM OPERATING ACTIVITIES
Net profit/(loss) before tax 7,360.80 (8,458.58)
Adjustments for:
Depreciation expense 4,494.45 3,665.05
Finance Costs 11,652.27 13,771.36
Interest income (1,189.16) (449.58)
Provision for doubtful debts 2,050.07 1,367.65
Provision for doubtful deposits 2.74 50.22
Bad debts written off on one time settlement with NHAI - 12,397.19
Loss/(profit) on sale of fixed assets (net) 74.58 (815.02)
Sundry balances written back (310.09) (235.81)
Prior years provision written back (209.34) -
Operating pro�t before working capital changes 23,926.32 21,292.48
Adjustment for change in working capital
Decrease/(Increase) in Inventories 32,970.86 (4,412.85)
Decrease/(Increase) in trade receivables 2,384.81 (3,396.19)
Increase in loans and advances (438.35) (12,266.25)
(Decrease)/Increase in trade payables and other current liabilites (19,258.94) 47,792.02
Cash generated from operations 39,584.70 49,009.21
Direct taxes paid (3,666.15) (2,503.69)
Net cash generated from operating activities 35,918.55 46,505.52
CASH FLOW FROM INVESTING ACTIVITIES
Purchase of fixed assets (including capital work in progress) (8,008.44) (5,862.62)
Proceeds from sale of fixed assets 122.60 1,258.21
Fixed Deposit with bank (maturity beyond three months) (391.00) (6,372.42)
Proceeds from fixed deposit with bank (maturity beyond three months) 6,364.14 222.87
Interest received 1,275.61 344.88
Net cash used in investing activities (637.09) (10,409.08)
CASH FLOW FROM FINANCING ACTIVITIES
Proceeds from long term borrowings 8,733.03 997.38
Repayment of long term borrowings (3,402.92) (5,547.48)
Proceeds from short term borrowings (net) (19,105.84) (11,907.84)
Interest paid (11,799.21) (13,749.82)
Dividend paid (0.71) (1.27)
Net cash used in �nancing activities (25,575.65) (30,209.03)
Net increase in cash and cash equivalents 9,705.81 5,887.41
Cash and cash equivalents at the beginning of year 8,382.74 2,495.33
Cash and cash equivalents at the end of year 18,088.55 8,382.74
201
Consolidated Cash Flow Statement for the year ended 31 December 2016
(Currency : Indian Rupee in lakhs)
Year ended 31 December 2016
Year ended 31 December 2015
Componenets of cash and cash equivalents (Refer note 17)
Cash in hand 64.93 157.51
Balance with scheduled banks
- current accounts 3,641.81 3,600.56
- unpaid dividend bank accounts 5.46 6.17
- deposit with original maturity upto 3 months 14,376.35 4,618.50
18,088.55 8,382.74
Notes :1. Figures given in brackets indicate cash outflow
2. The consolidated cash flow statement has been prepared under Indirect Method as per the Accounting Standard 3 Cash Flow Statement
issued by the Institute of Chartered Accountants of India.
3. The figures of the previous year have been regrouped/reclassified, where necessary, to conform with the classification of the current
year.
This is the consolidated cash flow statement referred to in our report of even date
For Walker Chandiok & Co LLP For and on behalf of the Board of DirectorsChartered AccountantsFirm Registration No. 001076N/N500013
Sudhir N. Pillai Adun Saraban P. ChakornbunditPartner Managing Director DirectorMembership No: 105782 DIN No.01312769 DIN No.00254312
S. Ramnath Rahul NeogiChief Financial Officer Company SecretaryFCA No. 030663 ACS No.10653
Place : Mumbai Place : MumbaiDate: 21 February 2017 Date: 21 February 2017
202
Summary of signi�cant accounting policies and other explanatory information to the consolidated �nancial statements as at and for the year ended 31 December 2016 (Currency : Indian Rupee in lakhs)
CORPORATE INFORMATIONITD Cementation India Limited (‘ITD Cem’ or ‘the Company’) was incorporated in 1978 and is engaged in construction of a wide variety of
structures like maritime structures, mass rapid transport systems (MRTS), dams & tunnels, airports, highways, bridges & flyovers and other
foundations and specialist engineering work. The activities of the Company comprise only one business segment viz Construction.
1. SIGNIFICANT ACCOUNTING POLICIES
A. Basis of preparation and Principles of Consolidation
(i) Basis of Preparation of Consolidated Financial StatementsThe consolidated financial statements have been prepared to comply in all material respects with the accounting standards notified
by the Companies (Accounting Standards) Rules, 2006 read with Rule 7 to the Companies (Accounts) Rules 2014 in respect of
Section 133 of the Companies Act, 2013. The consolidated financial statements are prepared under the historical cost convention,
on an accrual basis of accounting.
The accounting policies applied are consistent with those used in the previous year.
The consolidated financial statement comprises the financial statements of ITD Cementation India Limited (“the Holding Company”)
and its subsidiary (the Holding Company and its subsidiary together referred to as “the Group”) and unincorporated jointly controlled
entities.
(ii) Principles of ConsolidationThe consolidated financial statements have been prepared on the following basis:
a. The financial statements of the Holding Company and its subsidiary company have been consolidated on a line by line basis by
adding together the book values of like items of assets, liabilities, income and expenses, after eliminating intra-group balances/
transactions and elimination of resulting unrealized profits in accordance with Accounting Standard (‘AS’) - 21 ‘Consolidated
Financial Statements’ notified by the Companies (Accounting Standards) Rules, 2006 read with Rule 7 to the Companies
(Accounts) Rules 2014 in respect of Section 133 of the Companies Act, 2013.
b. The Interests in Joint Ventures which are in the nature of unincorporated jointly controlled entities have been consolidated by
using the proportionate consolidation method on a line by line basis by adding together the book values of like items of assets,
liabilities, income and expenses, after eliminating intra-group balances/ transaction and elimination of resulting unrealized
profits in accordance with AS 27 - ‘Financial Reporting of Interests in Joint Ventures’ notified by the Companies (Accounting
Standards) Rules, 2006 read with Rule 7 to the Companies (Accounts) Rules 2014 in respect of Section 133 of the Companies
Act, 2013.
c. Consolidated financial statements are prepared using uniform policies for like transaction and other events in similar
circumstances and are presented, to the extent possible, in the same manner as the Company’s separate financial statements.
d. Notes to the consolidated financial statements, represents notes involving items which are considered material and are
accordingly duly disclosed. Materiality for the purpose is assessed in relation to the information contained in the consolidated
financial statement. Further, additional statutory information disclosed in separate financial statements of the subsidiary and/
or a parent having no bearing on the true and fair view of the consolidated financial statement has not been disclosed in the
consolidated financial statements.
e. The difference between the cost to the Group of investment in subsidiary and joint ventures and the proportionate share in the
equity of the investee company as at the date of the acquisition of stake is recognized in the consolidated financial statements
as goodwill or capital reserve, as the case may be. Goodwill arising on consolidation is tested for impairment annually.
B. Accounting estimatesThe preparation of the consolidated financial statements in conformity with generally accepted accounting principles requires
management to make estimates and assumptions that affect the reported amounts of assets and liabilities and disclosure of contingent
liabilities as at the date of consolidated financial statements and the results of operation during the reported year. Although these
estimates are based upon management’s best knowledge of current events and actions, actual results could differ from these estimates
which are recognised in the year in which they are determined.
203
Summary of signi�cant accounting policies and other explanatory information to the consolidated �nancial statements as at and for the year ended 31 December 2016 (Currency : Indian Rupee in lakhs)
C. Fixed assetsTangible assets are stated at cost, less accumulated depreciation and impairment losses, if any. Cost comprises the purchase price and
any attributable cost of bringing the asset to its working condition for its intended use. Borrowing costs relating to acquisition of fixed
assets which takes substantial period of time to get ready for its intended use are also included to the extent they relate to the period till
such assets are ready to be put to use.
Subsequent expenditures related to an item of tangible asset are added to its book value only if they increase the future benefits from
the existing asset beyond its previously assessed standard of performance.
Capital work in progress represents expenditure incurred in respect of capital projects under development and are carried at cost. Cost
includes related acquisition expenses, construction cost and other direct expenditure.
D. Depreciation on tangible �xed assets(i) Depreciation on tangible assets is provided on straight line basis at useful life prescribed in Schedule II to the Companies Act, 2013
on a pro-rata basis. However, certain class of plant and machinery are depreciated on the useful life different from the useful life
prescribed in Schedule II to the Companies Act, 2013 having regard to useful life of those assets in construction projects based on
the management’s experience of use of those assets which is in line with industry practices.
(ii) Leasehold improvements are amortized over the lease period or useful life whichever is lower.
(iii) Depreciation for additions to/deductions from, owned assets is calculated pro rata from/to the day of additions/deductions.
(iv) In case of Joint Ventures, depreciation on fixed assets is provided on straight-line method at the rates determined as per the useful
lives of the respective assets and the life of the project.
E. Impairment of assetsThe carrying amounts of the Company’s assets are reviewed at each balance sheet date if there is any indication of impairment based on
internal/external factors. An impairment loss is recognized whenever the carrying amount of an asset exceeds its recoverable amount.
The recoverable amount is the greater of the assets net selling price and its value in use. Impairment loss is recognized in the Statement
of Profit and Loss or against revaluation surplus where applicable beyond the carrying value that would have prevailed by charging usual
depreciation if there was no impairment.
A previously recognized impairment loss is increased or reversed depending on changes in circumstances. However the carrying value
after reversal is not increased beyond the carrying value that would have prevailed by charging usual depreciation if there was no
impairment.
F. InvestmentsInvestments, which are readily realisable and intended to be held for not more than one year from the date on which such investments
are made, are classified as current investments. All other investments are classified as non-current investments.
Current investments are carried in the consolidated financial statements at lower of cost or fair value determined on an individual
investment basis. Non-current investments are carried at cost and provision for diminution in value is made to recognise a decline other
than temporary in the value of the investments.
On disposal of an investment, the difference between its carrying amount and net disposal proceeds is charged or credited to the
Statement of Profit and Loss.
G. Inventoriesi. Construction materials are valued at cost. Cost is determined on a first-in, first-out method and comprises the purchase price
including duties and taxes (other than those subsequently recoverable by the Company from the taxing authorities).
ii. Tools and equipment are stated at cost less the amount amortised. Tools and equipment are amortised over their estimated useful
lives ranging from 3 to 10 years. Cost is determined by the weighted average method.
iii. Machinery spares that are of regular use are charged to the statement of profit and loss as and when consumed.
iv. Unbilled work in progress: Work done remaining to be certified/billed is recognized as unbilled work in progress provided it is
probable that they will be recovered in the accounts. The same is valued at the realizable value.
204
Summary of signi�cant accounting policies and other explanatory information to the consolidated �nancial statements as at and for the year ended 31 December 2016 (Currency : Indian Rupee in lakhs)
H. Revenue recognition
i) On contractsRevenue from construction contracts is recognised on the basis of percentage completion method. The stage of completion of
a contract is determined by the proportion that contract costs incurred for work performed upto the reporting date bear to the
estimated total contract costs. Contract revenue earned in excess of certification has been classified as “Unbilled work-in-progress”
and certification in excess of contract revenue has been classified as “Amount due to customer“ under “Other current liabilities” in
the consolidated financial statements.
Amounts recoverable in respect of the price and other escalation, bonus claims adjudication and variation in contract work required
for performance of the contract to the extent that it is probable that they will result in revenue.
In addition, if it is expected that the contract will make a loss, the estimated loss is immediately provided for in the books of account.
Contractual liquidated damages, payable for delays in completion of contract work or for other causes, are accounted for as costs
when such delays and causes are attributable to the Company or when deducted by the client.
ii) Accounting for Joint Venture ContractsRevenue from long term construction contracts executed in unincorporated joint ventures under work sharing arrangements is
recognized on the same basis as similar contracts independently executed by the Company.
(iii) Service IncomeService income is accounted on accrual basis in accordance with the terms of agreement with the parties.
(iv) Insurance claimsInsurance claims are recognized as income based on certainty of receipt.
(v) Interest Income and other incomeInterest and other income are accounted for on accrual basis except where the receipt of income is uncertain in which case it is
accounted for on receipt basis.
I. Advances from customers, progress payments and retentionAdvances received from customers in respect of contracts are treated as liabilities and adjusted against progress billing as per terms of
the contract.
Progress payments received are adjusted against amount receivable from customers in respect of the contract work performed.
Amounts retained by the customers until the satisfactory completion of the contracts are recognised as receivables. Where such
retention has been released by customers against submission of bank guarantees, the amount so released is adjusted against receivable
from customers and the value of bank guarantees is disclosed as a contingent liability.
J. Foreign currency transactions
i. Initial RecognitionForeign currency transactions are recorded in the reporting currency, by applying to the foreign currency amount the exchange
rate between the reporting currency and the foreign currency at the date of the transaction.
ii. ConversionForeign currency monetary items are reported using the closing rate. Non-monetary items which are carried in terms of historical
cost denominated in a foreign currency are reported using the exchange rate at the date of the transaction.
iii. Exchange Di�erencesExchange differences arising on the settlement of monetary items or on reporting company’s monetary items at rates different
from those at which they were initially recorded during the year, or reported in previous consolidated financial statements, are
recognized as income or as expenses in the year in which they arise.
205
Summary of signi�cant accounting policies and other explanatory information to the consolidated �nancial statements as at and for the year ended 31 December 2016 (Currency : Indian Rupee in lakhs)
iv. Forward exchange contracts not intended for trading or speculation purposesThe premium or discount arising at the inception of forward exchange contracts is amortized as expense or income over the life
of the contract. Exchange differences on such contracts are recognized in the statement of profit and loss in the year in which the
exchange rates change. Any profit or loss arising on cancellation or renewal of forward exchange contract is recognized as income
or as expense for the year.
K. Employee bene�ts
i. De�ned bene�t planIn terms of the Guidance on implementing Accounting Standard (AS) 15 - Employee Benefits, issued by the Accounting Standards
Board of the Institute of Chartered Accountants of India, the Provident Fund set up by the Company is treated as a defined benefit
plan. This is administered through trusts of the Company. The Company has to meet the interest shortfall, if any. Accordingly,
the contribution paid or payable and the interest shortfall, if any, is recognised as an expense in the period in which services are
rendered by the employee. Further, the pattern of investments for investible funds is as prescribed by the Government. Accordingly,
other related disclosures in respect of provident fund have not been made.
Further Company has defined benefit plans for post-employment benefits in the form of Gratuity. The Company has taken an
insurance policy under the Group Gratuity Scheme with the insurance company to cover the Gratuity Liability. The liability for
Defined Benefit Plans is provided on the basis of valuations, as at the Balance Sheet date, carried out by an independent actuary.
The obligations are measured as the present value of estimated future cash flows discounted at rates reflecting the prevailing
market yields of Indian Government securities as at the Balance Sheet date for the estimated term of the obligations. The estimate
of future salary increases considered takes into account the inflation, seniority, promotion and other relevant factors.
The expected rate of return of plan assets is the Company’s expectation of the average long-term rate of return expected on
investments of the fund during the estimated term of the obligations. Plan assets are measured at fair value as at the Balance Sheet
date. The actuarial valuation method used by independent actuary for measuring the liability is the Projected Unit Credit method.
ii. De�ned contribution plan:The certain employees of the Company are also participant in the superannuation plan, employee state insurance scheme
and Labour Welfare Fund scheme which is a defined contribution plan. The Company has no obligations to the Plan beyond
its contributions. The company’s contributions to Defined Contribution Plans are charged to the Statement of Profit and Loss as
incurred.
iii. Other employee bene�tsThe Company treats accumulated leave expected to be carried forward beyond twelve months, as long-term employee benefit
for the measurement purposes. Such long-term compensated absences are provided for based on the actuarial valuations using
the projected unit credit method at the period end. Accumulated leave which is expected to be utilised within next 12 months,
is treated as short-term employee benefit. Actuarial gains and losses in respect of the defined benefit plans are recognised in the
Statement of Profit and Loss in the period in which they arise.
L. Earnings Per ShareBasic earnings per share is calculated by dividing the net profit or loss after tax for the year attributable to equity shareholders by the
weighted average number of equity shares outstanding during the year. The number of shares used in computing diluted earnings per
share comprises the weighted average number of shares considered for deriving basic earnings per share and also the weighted average
number of shares which could have been issued on conversion of all dilutive potential equity shares.
M. Taxation
Current taxProvision for current tax is recognized based on the estimated tax liability computed after taking credit for allowances and exemptions
in accordance with the Income Tax Act, 1961.
206
Summary of signi�cant accounting policies and other explanatory information to the consolidated �nancial statements as at and for the year ended 31 December 2016 (Currency : Indian Rupee in lakhs)
Minimum Alternative Tax (MAT) credit is recognised as an asset only when and to the extent there is convincing evidence that the
company will pay normal income tax during the specified period. In the year in which the MAT credit becomes eligible to be recognized
as an asset in accordance with the recommendations contained in Guidance Note issued by the Institute of Chartered Accountants of
India, the said asset is created by way of a credit to the Statement of Profit and Loss and shown as MAT Credit Entitlement. The Company
reviews the same at each balance sheet date and writes down the carrying amount of MAT Credit Entitlement to the extent there is no
longer convincing evidence to the effect that Company will pay normal Income Tax during the specified period.
Deferred taxDeferred tax assets and liabilities are recognized for the future tax consequences attributable to timing differences between the financial
statements’ carrying amounts of existing assets and liabilities and their respective tax basis. Deferred tax assets and liabilities are measured
using the enacted tax rates or tax rates that are substantively enacted at the balance sheet dates. The effect on deferred tax assets and
liabilities of a change in tax rates is recognised in the period that includes the enactment date. Where there is unabsorbed depreciation
or carry forward losses, deferred tax assets are recognized only if there is virtual certainty supported by convincing evidence that they
can be realised against future taxable profits. Other deferred tax assets are recognized only to the extent there is reasonable certainty of
realization in the future. Such assets are reviewed at each balance sheet date to reassess realization. Timing differences originating and
reversing during the tax holiday period are not considered for the purpose of computing deferred tax assets and liabilities.
N. LeasesLeases, where the lessor effectively retains substantially all the risks and benefits of ownership of the leased term, are classified as
operating leases. Operating lease payments are recognized as an expense in the Statement of Profit and Loss account on a straight-line
basis over the lease term.
O. Provisions and Contingent LiabilitiesA provision is recognized when the Company has a present obligation as a result of past events and it is probable that an outflow of
resources will be required to settle the obligation, in respect of which a reliable estimate can be made. Provisions are not discounted to
their present value and are determined based on management’s best estimates required to settle the obligation at the Balance Sheet
date. These are reviewed at each Balance Sheet date and adjusted to reflect the current best estimates.
Contingent Liabilities are disclosed in respect of possible obligations that arise from past events, whose existence would be confirmed
by the occurrence or non-occurrence of one or more uncertain future events not wholly within the control of the Company.
Contingent assets are neither recognised nor disclosed in the consolidated financial statements.
P. Cash and cash equivalentsCash and cash equivalents comprise of cash at bank and cash in hand. The Company considers all highly liquid investments with an
original maturity of three month or less from date of purchase, to be cash equivalents.
207
Summary of signi�cant accounting policies and other explanatory information to the consolidated �nancial statements as at and for the year ended 31 December 2016 (Currency : Indian Rupee in lakhs)
2. Share capitalAs at 31 December 2016 As at 31 December 2015
Number Amount Number Amount
Authorised Share Capital
Equity shares of H1 each 30,00,00,000 3,000.00 30,00,00,000 3,000.00
Redeemable preference shares of H10 each 4,50,00,000 4,500.00 4,50,00,000 4,500.00
34,50,00,000 7,500.00 34,50,00,000 7,500.00
Issued
Equity shares of H1 each 15,51,83,160 1,551.83 15,51,83,160 1,551.83
15,51,83,160 1,551.83 15,51,83,160 1,551.83
Subscribed and fully paid-up
Equity shares of H1 each 15,51,57,900 1,551.58 15,51,57,900 1,551.58
15,51,57,900 1,551.58 15,51,57,900 1,551.58
a) Reconciliation of equity shares outstanding at the beginning and at the end of the reporting period
As at 31 December 2016 As at 31 December 2015
Number Amount Number Amount
At the beginning of the year 15,51,57,900 1,551.58 1,55,15,790 1,551.58
Add: Conversion on account of share split (Refer note below) - - 13,96,42,110 -
Balance at the end of the year 15,51,57,900 1,551.58 15,51,57,900 1,551.58
Pursuant to the approval of the members at the 37th Annual General Meeting of the Company held on 13 May 2015 to the sub-division
of the Equity Shares of the Company, each Equity Share of nominal face value of H10 each was sub-divided to 10 (ten) Equity Share of
H1 each. The effective date for the said sub-division was 24 August 2015.
d) Shareholders holding more than 5% of the equity shares in the Company as at 31 December 2016
As at 31 December 2016 As at 31 December 2015
Number % Holding Number % Holding
Equity shares of H1 each
Italian-Thai Development Public Company Limited, Thailand 8,01,13,180 51.63% 8,01,13,180 51.63%
HDFC Trustee Company Limited 1,05,76,780 6.82% 1,10,33,180 7.11%
As per records of the Company, including its register of shareholders/members and other declarations received from shareholders
regarding beneficial interest, the above shareholding represents both legal and beneficial ownership of shares.
c) Shares held by holding Company
As at 31 December 2016 As at 31 December 2015
Number Amount Number Amount
Equity shares of H1 each
Italian-Thai Development Public Company Limited,
Thailand
8,01,13,180 801.13 8,01,13,180 801.13
b) Terms/rights attached to equity sharesThe Company has only one class of equity shares having a par value of H1 per share. Each holder of equity shares is entitled to one vote
per share. The Company declares and pays dividends in Indian Rupees. The dividend proposed if any by the Board of Directors is subject
to the approval of the shareholders in the ensuing Annual General Meeting, except interim dividend.
In the event of liquidation of the Company, the holders of equity shares will be entitled to receive remaining assets of the Company,
after distribution of all preferential amounts, if any. The distribution will be in proportion to the number of equity shares held by the
shareholders.
208
Summary of signi�cant accounting policies and other explanatory information to the consolidated �nancial statements as at and for the year ended 31 December 2016 (Currency : Indian Rupee in lakhs)
4. Long-term borrowingsAs at 31 December 2016 As at 31 December 2015
Non-current Current Non-current Current
Secured
Rupee term loans
- From bank 2,650.00 4,270.40 196.00 1,989.04
- From other parties - - 315.04 273.94
Plant loans
- From bank 484.56 361.94 212.91 100.76
- From other party 843.61 435.32 364.77 281.04
Vehicle loans from bank 83.96 63.35 90.09 39.44
4,062.13 5,131.01 1,178.81 2,684.22
2. Share capital (contd.)
e) Aggregate number of bonus shares issued, shares issued for consideration other than cash and shares bought back during theperiod of �ve years immediately preceeding the reporting date.The Company has not issued any bonus shares, shares for consideration other than cash and bought back any shares during five years
immediately preceeding the reporting date.
f ) Out of the total issued capital, 25,260 (31 December 2015 : 25,260) equity shares of H1 each have been kept in abeyance pending final
settlement of rights issues.
3. Reserves and surplusAs at
31 December 2016As at
31 December 2015
Securities premium account 45,556.44 45,556.44
General reserve 676.48 676.48
Surplus in the statement of pro�t and loss
Balance at the beginning of the year 3,036.93 8,997.30
Add : Transferred from statement of profit and loss 4,810.77 (5,930.76)
Less : Proposed dividend on equity shares (Refer note 3.1 below) (465.47) -
Less : Tax on proposed equity dividend (94.76) -
Less : Adjustment on account of additional depreciation (Refer note 3.2 below) - (29.61)
7,287.47 3,036.93
53,520.39 49,269.85
3.1 The Board of Directors of the Company, in its meeting held on 21 February 2017, have proposed a final dividend of H0.30 per equity share
for the financial year ended 31 December 2016. The proposal is subject to the approval of shareholders in the ensuing Annual General
Meeting.
3.2 In the previous year, the Company had provided depreciation on the basis of useful life of fixed assets as mandated by Schedule II of the
Companies Act, 2013. Further, in line with Schedule II, the Company undertook technical evaluation of certain fixed assets to determine
the true useful life and recomputed the depreciation on that basis. Consequently, the depreciation and loss for the year ended 31
December 2015 was lower by H217 lakhs. Further, H29.61 lakhs (net of tax adjustment of H13.24 lakhs) had been adjusted to the opening
balance of the retained earnings where the remaining useful life of the assets was NIL as at 1 January 2015.
209
Summary of signi�cant accounting policies and other explanatory information to the consolidated �nancial statements as at and for the year ended 31 December 2016 (Currency : Indian Rupee in lakhs)
5. Long-term provisionAs at
31 December 2016As at
31 December 2015
Provision for employee benefits
- Leave entitlement (Refer note 32) 902.36 694.56
902.36 694.56
6. Short-term borrowingsAs at
31 December 2016As at
31 December 2015
Secured
Cash credit facilities 11,118.65 35,217.80
Working capital demand loan 8,487.20 3,493.89
Unsecured
Commercial paper 17,500.00 17,500.00
37,105.85 56,211.69
Rupee term loan - from bank (secured)Term loan obtained from Doha Bank carries an interest rate of 10.15 percent per annum and repayable in 3 installments starting from November 2017. This loan is secured by hypothecation of Kolkata area depot land.
Term loan obtained from Exim Bank carries interest rate of 11.0 percent per annum. This loan is repayable on 31 July 2017 or on receipt of retention money which ever is earlier. This loan is secured by entire moveable assets of the project.
Term loan obtained from Exim Bank carries interest rate of 11.25 percent per annum. This loan is repayable in 5 quarterly installments starting from September 2016 or out of projects receipts which ever is earlier. This loan is secured by entire moveable assets of the project.
Term loan obtained from Vijaya Bank carried an interest rate of 12.25 percent per annum and has been fully repaid during the year. This loan was secured by hypothecation of Kolkata area depot land.
Rupee term loans from other parties (secured)Term loan obtained from Indiabulls Housing Finance Limited carried an interest rate of 13.50 percent per annum and has been fully repaid during the year. This loan was secured by hypothecation of Kolkata office premises
Term loan obtained from Tata Capital Financial Services Limited carried an interest rate of 13 percent per annum and has been fully repaid during the year. This loan was secured by hypothecation of the office purchased out of this loan.
Plant loans from bank (secured)Loan obtained from Axis bank for purchase of commercial vehicle /construction equipment carries interest rate ranging between 10.75 to 11.03 percent per annum and are repayble in 36 monthly installments. These loans are secured by first and exclusive charge on specific vehicle/equipment financed by the bank.
Loan obtained from Kotak Mahindra Bank Ltd. for purchase of commercial vehicle /construction equipment carries an interest rate of 9.65 percent per annum and are repayble in 46 to 58 monthly installments.These loans are secured by first and exclusive charge on specific vehicle/equipment financed by the bank.
Plant loans from other party (secured)Loans obtained from Tata Capital Limited for purchase of construction equipment carry interest rate ranging between 11.00 to 12.50 percent per annum and are repayable in 29 to 60 monthly installments. These loans are secured by first and exclusive charge on specific equipment financed by the institution.
Vehicle loans from bank (secured)Loan obtained from Axis Bank for purchase of vehicles carry interest rate ranging between 9.50 to 10.50 percent per annum and are repayble in 60 monthly installments. These loans are secured by hypothecation of the vehicles purchased out of these loans.
4. Long-term borrowings (contd.)
210
Summary of signi�cant accounting policies and other explanatory information to the consolidated �nancial statements as at and for the year ended 31 December 2016 (Currency : Indian Rupee in lakhs)
7. Trade payables As at
31 December 2016As at
31 December 2015Total outstanding dues of Micro Enterprises and Small Enterprises 758.85 - Total outstanding dues of creditors other than Micro Enterprises and Small Enterprises 63,208.08 75,429.28
63,966.93 75,429.28 The Company has amounts due to micro and small suppliers registered under the Micro, Small and Medium Enterprises Development Act 2006 (MSMED Act), as at 31 December 2016.The disclosure pursuant to the said Act is as under:- Principal amount due to suppliers under MSMED Act 758.85 - - Interest accrued and due to suppliers under MSMED Act on the above amount 6.87 - - Payment made to suppliers (other than interest) beyond appointed day during the year 632.89 - - Interest paid to suppliers under MSMED Act - - - Interest due and payable to suppliers under MSMED Act towards payments already made 5.10 - - Interest accrued and remaining unpaid at the end of the accounting year 6.87 - - The amount of further interest remaining due and payable even in the succeeding years, until such date when the interest dues as above are actually paid to the small enterprise for the purpose of disallowance as a deductible expenditure under section 23 of the MSMED Act.
6.87 -
Note: This information, as required to be disclosed under the MSMED Act, has been determined to the extent such parties have been identified on the basis of information available with the Company
8. Other current liabilities As at
31 December 2016As at
31 December 2015Creditors for capital expenses 358.99 145.08 Interest accrued and due - 138.87 Interest accrued but not due 81.23 89.30 Unpaid dividend * 5.46 6.17 Advances from customers 26,508.04 46,411.63 Material received from customers 167.39 58.76 Amount due to customers 13,401.49 2,292.94 Payable to Co-venturer 16.69 16.98 Employee related dues 3,537.45 3,030.12 Statutory dues payable 401.79 653.51 Others 2,518.17 2,994.25
46,996.70 55,837.61
* Not due for credit to Investor Education & Protection Fund
Cash credit facilities (secured)Cash credit facilities are availed from consortium bankers carries various interest rates ranging from 10.90 to 15.15 percent per annum and are secured by first pari passu charge on the current assets and movable plant and machinery other than those hypothecated against plant loans. These facilities are payable on demand.
Working capital demand loan (secured)Working capital demand loan carry interest rate ranging from 9.70 to 12.00 percent per annum and are secured by first pari passu charge on the current assets and movable plant and machinery other than those hypothecated against plant loans. These facilities are payable on demand.
Commercial Paper (unsecured)Commercial Paper is issued to HDFC Trustee Company Limited and Escorts Mutual Fund carries interest rate ranging between 10.00 to 10.50 percent.
6. Short-term borrowings (contd.)
211
Summary of signi�cant accounting policies and other explanatory information to the consolidated �nancial statements as at and for the year ended 31 December 2016 (Currency : Indian Rupee in lakhs)
9. Short term provisions As at
31 December 2016As at
31 December 2015
Provision for employee benefits
- Gratuity (Refer note 32) 1,654.96 1,317.93
- Leave entitlement (Refer note 32) 132.19 100.42
- Provident fund 196.66 182.11
Provision for taxation (net of advance tax) - 21.11
Proposed dividend 465.47 -
Provision for tax on proposed dividend 94.76 -
2,544.04 1,621.57
10. Tangible assetsGross Block Freehold
landLeasehold
improvmentsBuildings Plant and
machineryEarth-
moving machinery
O�ce equipment
and furniture
Vehicles Total
Gross block
Balance as on 1 January 2015 15.32 453.82 1,099.17 46,181.56 6,776.66 1,902.49 582.40 57,011.42
Additions 533.39 - - 4,022.09 793.64 145.57 29.08 5,523.77
Disposals - - (34.51) (1,472.10) (157.37) (121.91) (26.85) (1,812.74)
Balance as on 31 December 2015
548.71 453.82 1,064.66 48,731.55 7,412.93 1,926.15 584.63 60,722.45
Additions during the year 1.21 568.04 170.39 6,178.28 816.46 192.27 50.82 7,977.47
Disposals during the year - - - (404.91) (22.85) (163.34) (17.47) (608.57)
As at 31December 2016 549.92 1,021.86 1,235.05 54,504.92 8,206.54 1,955.08 617.98 68,091.35
Accumulated depreciation
Balance as on 1 January 2015
- 195.23 98.95 16,858.26 4,694.20 1,403.32 235.63 23,485.59
Depreciation charge - 102.87 16.80 2,773.62 521.86 192.85 57.05 3,665.05
Reversal on disposal of
assets
- - (13.73) (1,082.95) (132.89) (123.46) (16.53) (1,369.56)
Transition Adjustments
(Refer note 3.2)
- - - 0.11 - 40.61 2.13 42.85
As at 31 December 2015 - 298.10 102.02 18,549.04 5,083.17 1,513.32 278.28 25,823.93
Charge for the year - 32.70 18.86 3,597.08 617.70 164.99 63.12 4,494.45
Disposals during the year - - - (211.25) (20.34) (162.57) (17.23) (411.39)
As at 31 December 2016 - 330.80 120.88 21,934.87 5,680.53 1,515.74 324.17 29,906.99
Net block
As at 31 December 2016 549.92 691.06 1,114.17 32,570.05 2,526.01 439.34 293.81 38,184.36
As at 31 December 2015 548.71 155.72 962.64 30,182.51 2,329.76 412.83 306.35 34,898.52
Note: Buildings include H0.09 lakhs (31 December 2015: H0.09 lakhs) being the cost of shares in co-operative housing societies.
212
Summary of signi�cant accounting policies and other explanatory information to the consolidated �nancial statements as at and for the year ended 31 December 2016 (Currency : Indian Rupee in lakhs)
11. Deferred tax assets (net) As at
31 December 2016As at
31 December 2015
Deferred tax asset arising on account of (A)
Provision for doubtful debts 2,057.42 1,309.46
Provision for employee benefits 1,093.34 651.20
Disallowance u/s 43B as per Income Tax Act, 1961 443.53 419.86
Provision for doubtful deposits 19.32 30.14
Disallowance for forseeable loss as per Income Computation and Disclosure Standards
(ICDS )
163.59 356.54
Unabsorbed business loss 1,954.12 4,211.56
Others 0.04 11.01
Total (A) 5,731.36 6,989.77
Deferred tax liability arising on account of (B)
Timing difference between book depreciation and depreciation as per Income Tax Act,
1961
2,974.94 2,566.38
Total (B) 2,974.94 2,566.38
Deferred tax assets (A-B) 2,756.42 4,423.39
12. Loans and advancesAs at 31 December 2016 As at 31 December 2015
Long-term Short-term Long-term Short-term
(Unsecured, considered good unless otherwise stated)
Capital advances 1,206.01 - 1,254.11 -
Security and other deposits
- considered good 263.72 2,404.95 293.41 1,526.07
- considered doubtful - 55.84 - 97.55
Receivable from Holding Company (Refer note 36) - 6,755.21 - 2,081.27
Other loans and advances:
Advance recoverable in cash or kind
- considered good - 2,775.98 - 10,504.79
Prepaid expenses - 2,348.22 - 2,368.23
Loans and advances to employees - 14.43 - 20.15
Balances with statutory / government authorities 18,429.77 - 15,762.74 -
Advance income tax (net of provisions for tax) 7,619.23 - 4,857.25 -
27,518.73 14,354.63 22,167.51 16,598.06
Less : Provision for doubtful deposits - (55.84) - (97.55)
27,518.73 14,298.79 22,167.51 16,500.51
213
Summary of signi�cant accounting policies and other explanatory information to the consolidated �nancial statements as at and for the year ended 31 December 2016 (Currency : Indian Rupee in lakhs)
14. Current investmentsAs at 31 December 2016 As at 31 December 2015
No. of Shares Book Value No. of Shares Book Value
(Non-trade, unquoted at lower of cost and fair value)
Investments in equity shares
AVR Infra Private Limited (Face value of H10 each) 2,600 0.26 2,600 0.26
0.26 0.26
15. InventoriesAs at
31 December 2016As at
31 December 2015
Construction materials 11,762.94 15,242.35
Tools and equipment 6,061.42 5,653.67
Machinery spares 1,880.19 1,826.66
Unbilled work in progress (Refer note 37) 64,862.66 94,815.39
84,567.21 1,17,538.07
16. Trade receivables (Refer notes 37)As at 31 December 2016 As at 31 December 2015
Long-term Short-term Long-term Short-term
(unsecured, considered good unless otherwise stated)
Trade receivables outstanding for more than six months
- Considered good * 2,863.37 13,738.03 2,863.37 19,330.29
- Considered doubtful - 5,944.91 - 4,237.73
2,863.37 19,682.94 2,863.37 23,568.02
Less: Provision for doubtful debts - (5,944.91) - (4,237.73)
2,863.37 13,738.03 2,863.37 19,330.29
Other debts ** - 12,744.26 - 11,586.88
2,863.37 26,482.29 2,863.37 30,917.17
Notes :
* Includes retention money 571.41 11,121.36 571.41 11,040.01
** Includes retention money - 3,294.68 - 4,033.27
13. Other non-current assetsAs at
31 December 2016As at
31 December 2015
Non-current bank balances (Refer note 17) - 16.90
Interest accrued but not due - 6.89
- 23.79
214
Summary of signi�cant accounting policies and other explanatory information to the consolidated �nancial statements as at and for the year ended 31 December 2016 (Currency : Indian Rupee in lakhs)
18. Other current assetsAs at
31 December 2016As at
31 December 2015
Interest accrued but not due 39.54 119.10
39.54 119.10
19. Other operating income Year ended
31 December 2016Year ended
31 December 2015
Service income from unincorporated joint ventures 103.98 224.87
103.98 224.87
17. Cash and bank balancesAs at 31 December 2016 As at 31 December 2015
Non-current Current Non-current Current
Cash and cash equivalents
Cash in hand - 64.93 - 157.51
Balance with banks
- current accounts - 3,641.81 - 3,600.56
- unpaid dividend bank accounts - 5.46 - 6.17
Bank deposits with original maturity not more than 3 months - 14,376.35 - 4,618.50
- 18,088.55 - 8,382.74
Other bank balances
Deposits with maturity of more than 3 months but less than
12 months *
- 421.27 - 6,377.52
Bank deposits with maturity of more than 12 months ** - - 16.90 -
- 18,509.82 16.90 14,760.26
Less: Amounts disclosed as Other non-current assets
(Refer note 13)
- - (16.90) -
- 18,509.82 - 14,760.26
* Includes H241.65 lakhs (previous year H241.65 lakhs) earmarked against bank guarantees taken by the Company and H22 lakhs (previous
year H10 lakhs) placed as earnest money deposit.
** Placed as earnest money deposit
215
Summary of signi�cant accounting policies and other explanatory information to the consolidated �nancial statements as at and for the year ended 31 December 2016 (Currency : Indian Rupee in lakhs)
20. Other IncomeYear ended
31 December 2016Year ended
31 December 2015Interest income :
- on bank deposits 1,179.20 408.15 - on income tax refund 184.44 52.55 - on sales tax refund 204.12 - - from customer on settlement - 81.01 - others 9.96 41.43
Other non operating income :- Profit on sale of fixed assets (net) - 815.02 - Exchange gain (net) 43.82 20.62 - Sundry balances written back 310.09 235.81 - Provisions no longer required, written back 209.34 - - Insurance claim 34.87 175.49 - Miscellaneous income 346.32 387.33
2,522.16 2,217.41
21. Employee bene�ts expenseYear ended
31 December 2016Year ended
31 December 2015
Salaries and wages 22,948.89 19,993.94
Contribution to gratuity (Refer note 32) 589.18 725.28
Contribution to provident and other funds (Refer note 32) 1,715.76 1,386.83
Staff welfare expenses 126.48 134.64
25,380.31 22,240.69
22. Finance costs Year ended
31 December 2016Year ended
31 December 2015Interest expenses
- Cash credit facilities and working capital demand loan 4,243.23 6,411.07 - Long term loan 716.67 1,000.77 - Commercial papers 1,668.62 1,386.18 - Advances from customers 1,721.52 1,814.37 - Letter of credit 368.82 378.44 - Buyer's credit - 5.15 - Others 56.49 123.09
Other borrowing costs- Applicable net loss on foreign currency transactions and transition - 55.71 - Bank charges and guarantee commission 2,876.92 2,596.58
11,652.27 13,771.36
216
Summary of signi�cant accounting policies and other explanatory information to the consolidated �nancial statements as at and for the year ended 31 December 2016 (Currency : Indian Rupee in lakhs)
24. Exceptional itemsYear ended
31 December 2016Year ended
31 December 2015
Loss on account of one time settlement with National Highway Authority of India [Refer
note 38]
- (12,397.19)
- (12,397.19)
23. Other expenseYear ended
31 December 2016Year ended
31 December 2015
Plant hire expenses 6,082.02 5,995.35
Power and fuel 8,164.42 7,097.04
Sales tax on works contracts 7,857.93 8,146.71
Travelling expenses 1,014.96 926.17
Tools and equipment 2,038.01 1,740.02
Foreseeable loss 970.08 231.96
Site transport and conveyance 2,691.16 2,559.47
Repairs and maintenance:
- Plant & machinery 1,256.70 646.13
- Others 188.35 323.81
Insurance 1,351.17 1,323.74
Professional fees 1,487.44 2,501.78
Rent (Refer note 39) 2,808.51 2,759.49
Consumption of spares 2,144.76 1,821.82
Security charges 1,226.05 1,308.67
Temporary site installations 592.81 834.75
Postage and telephone 230.77 214.01
Auditor remuneration (Refer note 26) 105.20 84.40
Provision for doubtful debts (Refer note 27) 2,050.07 1,367.65
Provision for doubtful deposits (Refer note 28) 2.74 50.22
Rates & taxes 295.98 86.14
Water charges 798.35 704.61
Printing and stationery 168.46 161.50
Infotech expenses 265.58 294.52
Service tax 7,707.82 9,794.14
Labour cess 2,797.65 1,851.04
Directors’ sitting fees 8.90 6.05
CSR expenses # - 19.74
Loss on sale of fixed assets (net) 74.58 -
Miscellaneous expenses 1,988.08 2,311.47
56,368.55 55,162.40
# The Company is not liable to incur any expenses on CSR as per Section 135 of the Companies Act, 2013
217
Summary of signi�cant accounting policies and other explanatory information to the consolidated �nancial statements as at and for the year ended 31 December 2016 (Currency : Indian Rupee in lakhs)
25. Earnings per shareYear ended
31 December 2016Year ended
31 December 2015
Weighted average number of equity shares outstanding during the year 15,51,57,900 15,51,57,900
Add:- Dilutive effect - -
Weighted average number of equity shares used to compute diluted earning/(loss) per
share
15,51,57,900 15,51,57,900
Net profit/(loss) after tax attributable to equity shareholders 4,810.77 (5,930.76)
Earning per share :
Basic and diluted 3.10 (3.82)
(With effect from record date 24 August 2015, the face value of the Company’s shares have been sub-divided from H10 per share to H1
per share. For the previous year, the equity shares and basic and diluted Earnings per share has been presented to reflect for the split in
accordance with Accounting Standard 20 - Earning Per Share).
26. Auditor remuneration (including service tax)Year ended
31 December 2016Year ended
31 December 2015
Audit fee* 48.48 32.64
Tax audit fee 22.28 20.32
Limited review 29.31 27.48
Certification 3.10 2.97
Out-of-pocket expenses 2.03 0.99
105.20 84.40* Includes fees for audit of Internal Financial Controls over financial reporting H13.80 lakhs (Previous year: NIL)
27. Provision for doubtful debtsYear ended
31 December 2016Year ended
31 December 2015
Bad debts written off during the year 342.89 -
Add: Provision for doubtful debts at the end of year 5,944.91 4,237.73
Less: Provision for doubtful debts at the beginning of year 4,237.73 2,870.08
2,050.07 1,367.65
28. Provision for doubtful depositsYear ended
31 December 2016Year ended
31 December 2015
Deposits written off during the year 44.45 -
Provision for doubtful deposits at the end of year 55.84 97.55
Less: Provision for doubtful deposits at the beginning of year 97.55 47.33
2.74 50.22
218
Summary of signi�cant accounting policies and other explanatory information to the consolidated �nancial statements as at and for the year ended 31 December 2016 (Currency : Indian Rupee in lakhs)
30. Contingent Liabilities*Year ended
31 December 2016Year ended
31 December 2015
a) Guarantees/Letter of credits given by banks in respect of contracting commitments in
the normal course of business
43,094.03 35,140.25
b) The Company has a number of claims on customers for price escalation and / or
variation in contract work. In certain cases which are currently under arbitration, the
customers have raised counter-claims. The Company has received legal advice that
none of the counter-claims are legally tenable. Accordingly no provision is considered
necessary in respect of these counter claims.
21743.22 12,016.77
c) Corporate Guarantee given to bank on behalf of Joint Ventures 48,651.00 48,651.00
d) Sales Tax matters pending in appeals 6,311.74 3,901.35
e) Income Tax matters pending in appeals 1,933.07 1,607.91
f ) Excise matter pending in appeal 51.70 51.70
* It is not practicable for the company to estimate the timings of cash outflows, if any, in respect of the above pending resolution of the
respective proceedings. The Company does not expect any reimbursements in respect of the above contingent liabilities other than stated
therein above. Future cash outflows in respect of the above are determinable only on receipt of judgments/ decisions pending with various
forums/ authorities. The Company does not expect any outflow of economic resources in respect of the above and therefore no provision is
made in respect thereof.
29. CommitmentYear ended
31 December 2016Year ended
31 December 2015
Estimated amount of contracts remaining to be executed on capital accounts and not
provided for (net of advances)
5390.36 417.32
31. Particulars of unhedged foreign currency exposures at the reporting date:
a) There is no derivative outstanding at the reporting date
b) Unhedged foreign currency exposures at the reporting date:
Buyers credit, Trade payables and Acceptances
As at 31 December 2016 As at 31 December 2015
Foreign Currency
Exchange Rate
INR in lakhs Foreign Currency
Exchange Rate
INR in lakhs
US Dollar Exposure 64,755 68.69 44.48 14,526 66.60 9.67
EURO Exposure 2,31,409 72.64 168.10 13,811 99.41 13.73
Total 212.58 23.40
219
Summary of signi�cant accounting policies and other explanatory information to the consolidated �nancial statements as at and for the year ended 31 December 2016 (Currency : Indian Rupee in lakhs)
32. Employee bene�ts
i) GratuityThe following tables summarise the components of net benefit expense recognised in the Statement of Profit and Loss and the funded
status and amounts recognised in the balance sheet for the respective plans.
31 December 2016 31 December 2015
The amount recognised in the Statement of Pro�t and Loss :
Current Service Cost 274.52 253.12
Interest Cost 207.70 161.75
Expected return on plan assets (126.48) (119.56)
Net actuarial loss for the year 233.44 429.97
Net bene�t expense 589.18 725.28
The amount recognised in the balance sheet :
Defined benefit obligation 3,273.44 2,684.44
Fair value of plan assets 1,618.48 1,366.51
Plan liability 1,654.96 1,317.93
Changes in the present value of the de�ned bene�t obligations :
Defined benefit obligation at beginning of the year 2,684.44 2,160.83
Current service cost 274.52 253.12
Interest cost 207.70 161.75
Actuarial loss 281.50 387.26
Benefit paid (174.72) (278.52)
Present value of de�ned bene�t obligation at end of year 3,273.44 2,684.44
Changes in the fair value of the plan assets of the gratuity plan :
Plan assets at beginning of the period 1,366.51 1,367.21
Expected return on Plan Assets 126.63 119.55
Contributions by employer 250.00 200.00
Benefit Paid (172.73) (277.54)
Actuarial gain/(loss) on plan assets 48.07 (42.71)
Fair value of plan assets at end of the year 1,618.48 1,366.51
The amount of defined benefit obligation, plan assets, the defecit thereof and the experience adjustments on plan assets and plan
liabilities for the current and previous four years are as follows:
2016 2015 2014 2013 2012
Defined Benefit Obligation 3,273.44 2,684.44 2,160.83 1,759.84 1,714.10
Plan Assets 1,618.48 1,366.51 1,367.21 1,225.67 1,216.84
Deficit (1,654.96) (1,317.93) (793.62) (534.17) (497.26)
Experience adjustments on plan assets 48.07 (42.71) 48.05 (82.26) 71.78
Experience adjustment on plan liabilities (281.50) (387.26) (145.25) 189.33 (118.31)
The gratuity fund is invested in a Group Gratuity policy invested with the Life Insurance Corporation of India and Birla Sunlife Insurance.
The fair value of plan assets with Life Insurance Corporation of India and Birla Sunlife Insurance as at 31 December 2016 are H0.18 lakhs
(31 December 2015 - H0.16 lakhs) and H1,618.29 lakhs (31 December 2015 - H1,366.35 lakhs) respectively. The management understands
that the assets in these portfolios are well diversified and as such the long term return thereon is expected to be higher than the rate of
return on Government Bonds.
The overall expected rate of return on assets is determined based on the market prices prevailing on that date, applicable to the period
over which the obligation is to be settled.
220
Summary of signi�cant accounting policies and other explanatory information to the consolidated �nancial statements as at and for the year ended 31 December 2016 (Currency : Indian Rupee in lakhs)
32. Employee bene�ts (contd.)
The principal assumptions used in determining the gratuity obligations :
31 December 2016 31 December 2015
Discount rate 7.30% 8.00%
Expected rate of return on plan assets 9.00% 9.00%
Salary esclation rate 5.00% 5.00%
Withdrawal rates Upto age 44 - 5%
45 years & above - 2.5%
Upto age 44 - 5%
45 years & above - 2.5%
The estimates of future salary increases, considered in actuarial valuation take account of inflation, seniority, promotion and other
relevant factors such as supply and demand in the employment market.
ii) The Company’s expense for the superannuation and provident fund aggregates H1,715.76 lakhs during the year ended 31 December
2016 (31 December 2015 - H1,386.83 lakhs)
Provident fund of employees is managed by the Company through trust “ITD Cementation India Limited Workmen Provident Fund”, In
line with the Provident Fund and Miscellaneous Provision Act, 1952. The plan guarantees interest at the rate notified by the Provident
Fund Authorities. The contribution by the employer and employee together with the interest accumulated thereon are payable to
employees at the time of separation from the Company or retirement, whichever is earlier. The benefits vests immediately on rendering
of the services by the employee.
In terms of the guidance note issued by the Accounting Standards Board (ASB) of the Institute of Chartered Accountants of India for
measurement of provident fund liabilities, the valuer has certified that there is no shortfall as at 31 December 2016 and 31 December
2015.
iii) The liability for leave entitlement and compensated absences as at 31 December 2016 is H1034.55 lakhs (31 December 2015 : H794.98
lakhs).
34. SubsidiaryThe following Subsidiary Company (incorporated in India) has been consolidated in the consolidated financial statement applying
Accounting Standard (AS) - 21:
Name of the Subsidiary
31 December 2016 31 December 2015
Proportion of Ownership
Interest
Voting Power Proportion of Ownership
Interest
Voting Power
ITD Cementation Projects India Limited 100% 100% 100% 100%
35. Unincorporated Jointly Controlled EntitiesThe following unincorporated Jointly Controlled Entities have been consolidated applying Accounting Standard (AS) - 27 (“Financial
Reporting of Interests in Joint Ventures”).
% of Participation as at 31 December 2016
% of Participation as at31 December 2015
ITD Cemindia JV 80% 80%
ITD - ITD Cem JV 49% 49%
ITD - ITDCem JV (Consortium of ITD - ITD Cementation) 40% 40%
ITD-Cem Maytas Consortium 95% 95%
CEC-ITD Cem-TPL JV 40% -
All the above are unincorporated jointly controlled entities in India
33. Segment reportingThe activities of the Company comprises of only one business segment viz Construction. The Company operates in only one geographical
segment viz India. Hence the Company’s financial statements also represents the segmental information.
221
Summary of signi�cant accounting policies and other explanatory information to the consolidated �nancial statements as at and for the year ended 31 December 2016 (Currency : Indian Rupee in lakhs)
35. Unincorporated Jointly Controlled Entities (contd.)
The proportionate share of assets, liabilities, income and expenditure of the unincorporated Jointly Controlled Entities, consolidated in
the accounts is tabulated hereunder:
As at 31 December 2016 As at 31 December 2015
Non-current assets
Net Block 4,623.49 5,585.58
Capital work-in-progress - 70.37
Deferred tax assets 2,753.35 801.19
Current Assets :
Inventories 17,866.36 17,807.59
Trade receivables 3,737.53 4,800.88
Cash and bank balances 2,036.80 668.34
Loans and advances 7,473.17 6,655.19
Total Current Assets (A) 31,113.86 29,932.00
Current Liabilities (B) 19,756.82 16,054.38
Net Current Assets (A-B) 11,357.04 13,877.62
Total Assets 18,733.88 20,334.76
Liabilities
Loan Funds :
Secured loans 10,677.83 11,238.80
Reserves and surplus
Opening balance of retained earnings 6,602.42 5,909.11
Add : Loss for the year (5,576.17) (603.83)
Add : Share of brought forward loss and exceptional
loss on one time settlement with NHAI adjusted
against advances to joint venture
- 1,297.14
1,026.25 6,602.42
Total Liabilities 11,704.08 17,841.22
Revenue
Contract revenue 16,329.24 33,261.33
Other income 546.08 533.19
Total revenue 16,875.32 33,794.52
Expenses:
Site and administration expenses 20,493.34 29,629.98
Finance costs 2,777.90 2,264.59
Depreciation 1,263.67 1,179.75
Total expenses 24,534.91 33,074.32
(Loss)/pro�t before exceptional item and tax (7,659.59) 720.20
Exceptional item - 907.09
(Loss)/pro�t after exceptional item and tax (7,659.59) (186.89)
Provision for tax 131.26 (397.20)
Deferred tax credit 1,952.16 (19.74)
Loss after tax (5,576.17) (603.83)
Capital commitment 4,028.20 107.04
Contingent liabilities 11,384.61 2,341.86
222
Summary of signi�cant accounting policies and other explanatory information to the consolidated �nancial statements as at and for the year ended 31 December 2016 (Currency : Indian Rupee in lakhs)
36. Related Party Disclosures :
a) Names of related parties and description of relationship
A Enterprise where control exists - Holding CompanyItalian-Thai Development Public Company Limited
B Other related parties with whom the Company had transactionsi) Key management personnel (KMP)
Mr. Adun Saraban – Managing Director
Mr. S. Ramnath – Chief Financial Officer
Mr. Rahul Neogi - Company Secretary (appointed w.e.f. 1st February 2017)
Mr. R C. Daga - Company Secretary (retired on 31st January 2017)
ii) Fellow subsidiaryFirst Dhaka Elevated Expressway (FDEE) Company Limited
(b) Transactions with related parties for the year are as follows:
Transaction during the yearHolding
CompanyKMP Fellow
subsidiary
Contract Revenue
Italian-Thai Development Public Company Limited 131.61 - -
(-) (-) (-)
Sale of �xed assets
First Dhaka Elevated Expressway (FDEE) Company Limited - - -
(-) (-) (78.87)
Remuneration
Mr. Adun Saraban - 104.40 -
(-) (94.56) (-)
Mr. S. Ramnath - 62.16 -
(-) (52.27) (-)
Mr. R. C. Daga - 54.02 -
(-) (44.69) (-)
(Previous year figures are given in brackets)
(c) Balances at the year end:
Particulars Holding Company Fellow subsidiary
Trade receivables
Italian-Thai Development Public Company Limited 2.26 -
(25.89) (-)
Advance receivable in cash or kind
First Dhaka Elevated Expressway (FDEE) Company Limited - 78.87
(-) (78.87)
Loan and Advances
Italian-Thai Development Public Company Limited 6,755.21 -
(2,081.27) (-)
(Previous year figures are given in brackets)
223
Summary of signi�cant accounting policies and other explanatory information to the consolidated �nancial statements as at and for the year ended 31 December 2016 (Currency : Indian Rupee in lakhs)
37. (a) Long-term trade receivables at 31 December 2016 include variation claims of H309 lakhs (31 December 2015 - H309 lakhs) for
which the Company had received an arbitration award in its favour which has subsequently been upheld by the District Court.
The customer has challenged this Court Order. However, based on the above arbitration award, Court Order and legal opinion,
management is reasonably confident of recovery of these amounts.
(b) Long-term trade receivables and unbilled work-in-progress at 31 December 2016 include H1,139.96 lakhs (31 December 2015 -
H1,139.96 lakhs ) and H2,755.80 lakhs (31 December 2015 - H2,755.80 lakhs), in respect of a contract which has been rescinded
by the Company and long-term trade receivables and unbilled work-in-progress as at 31 December 2016 includes H1,414.41 lakhs
(31 December 2015 - H1,414.41 lakhs) and H5,921.77 lakhs (31 December 2015 - H5,921.77 lakhs) respectively, in respect of another
contract where the Company has received a notice from the customer withdrawing from the Company the balance works to
be executed under the contract for which the Company has also issued guarantees aggregating H1,497.13 lakhs (31 December
2015 - H1,497.13 lakhs). The Company has made claims against the customer to recover these amounts and has initiated legal
action. Based upon legal opinion received, management is reasonably confident of recovery of these amounts of long term trade
receivable and unbilled work-in-progress and consequently no changes have been made to the values and classification of these
amounts in the consolidated financial statements.
39. The disclosures as per provisions of Clauses 38, 39 and 41 of Accounting Standard 7 ‘Construction Contracts’ issued by Institute of
Chartered Accountants of India are as under:
Year ended31 December 2016
Year ended31 December 2015
a) Contract revenue recognised as revenue in the period Clause 38 (a) 3,08,856.02 3,06,870.03
b) Aggregate amount of costs incurred and recognised profits up to the reporting
date on Contract under progress Clause 39 (a)
7,35,627.74 9,74,089.03
c) Advance received on Contract under progress Clause 39 (b) 26,508.04 46,411.63
d) Retention amounts on Contract under progress Clause 39 ( c) 14,987.45 15,644.69
e) Gross amount due from customers for contract work as an asset Clause 41 (a) 64,862.66 94,815.39
f ) Gross amount due to customers for contract work as an liability Clause 41 (b) 13,401.49 2,292.94
40. Operating leasea) The Company has taken various residential/commercial premises and construction equipment on cancellable operating lease.
These lease agreements are normally renewed on expiry. Rental expenses in the statement of profit and loss for the year includes
lease payments towards premises H2,256.51 lakhs (31 December 2015 - H2,237.49 lakhs).
b) The Company, in addition to above, has taken commercial premises on leases (non-cancellable operating leases). The future
minimum lease payments in respect of which as at 31 December 2016 are as follows:
As at31 December 2016
As at31 December 2015
Minimum Lease Payments
Payable not later than 1 year 230.00 552.00
Payable later than 1 year and not later than 5 years - 230.00
Payable later than 5 years - -
Total 230.00 782.00
38. During the previous year ended 31 December 2015, the Company had signed a definitive agreement with the National Highways
Authority of India (NHAI) under which both parties have agreed to settle all awards received, claims under consideration at various
forums, pending disputes and amounts outstanding in the Company’s and joint venture’s books of account under trade receivables and
unbilled work-in-progress in respect of all the contracts executed by the company and Joint Venture. Pursuant to this settlement the
Company including its share in Joint Venture had accounted for the resultant loss on the settlement of H12,397.19 lakhs which had been
disclosed as an exceptional item.
224
Summary of signi�cant accounting policies and other explanatory information to the consolidated �nancial statements as at and for the year ended 31 December 2016 (Currency : Indian Rupee in lakhs)
41. The tax year for the Company being the year ending 31 March, the provision for taxation for the year is the aggregate of the provision
made for the three months ended 31 March 2016 and the provision based on the figures for the remaining nine months up to 31
December 2016, the ultimate tax liability of which will be determined on the basis of the figures for the period 1 April 2016 to 31 March
2017.
42. Previous year figures have been regrouped or reclassified, to conform to the current year’s presentation whereever considered
necessary.
For Walker Chandiok & Co LLP For and on behalf of the Board of DirectorsChartered Accountants
Firm Registration No. 001076N/N500013
Sudhir N. Pillai Adun Saraban P. ChakornbunditPartner Managing Director Director
Membership No: 105782 DIN No.01312769 DIN No.00254312
S. Ramnath Rahul NeogiChief Financial Officer Company Secretary
FCA No. 030663 ACS No.10653
Place : Mumbai Place : Mumbai
Date: 21 February 2017 Date: 21 February 2017
These leases have no escalation clauses.
Rental expenses in the statement of profit and loss for the year includes H552.00 lakhs (31 December 2015 - H522.00 lakhs) towards
such non-cancellable leases.
c) General descriptions of non-cancellable lease terms :
- Lease rentals are charged on the basis of agreed terms.
- Assets are taken on lease over a period of 3-5 years.
- The Company did not sublease any of its assets and hence did not receive any sub lease payments during the current or
previous year.
40. Operating lease (contd.)
225
Independent Auditor’s ReportTo The Members of ITD Cementation India Limited
Report on the Consolidated Financial Statements1. We have audited the accompanying consolidated
financial statements of ITD Cementation India Limited,(“the Holding Company”) and its subsidiary (the HoldingCompany and its subsidiary together referred to as “theGroup”) and unincorporated jointly controlled entities,which comprise the Consolidated Balance Sheet as at 31 December 2015, the Consolidated Statement of Profitand Loss and the Consolidated Cash Flow Statement forthe year then ended, and a summary of the significantaccounting policies and other explanatory information.
Management’s Responsibility for the Consolidated Financial Statements2. The Holding Company’s Board of Directors is
responsible for the preparation of these consolidated financial statements in terms of the requirements of the Companies Act, 2013 ( “the Act”) that give a true and fair view of the consolidated financial position, consolidated financial performance and consolidated cash flows of the Group and unincorporated jointly controlled entities, in accordance with the accounting principles generally accepted in India, including the Accounting Standards specified under Section 133 of the Act, read with Rule 7 of the Companies (Accounts) Rules, 2014 (as amended). The Holding Company’s Board of Directors, and the respective Board of Directors/management of the subsidiary included in the Group and unincorporated jointly controlled entities are responsible for the design, implementation and maintenance of internal control relevant to the preparation and presentation of the financial statements that give a true and fair view and are free from material misstatement, whether due to fraud or error. Further, in terms with the provisions of the Act, the respective Board of Directors of the Holding Company, its subsidiary which is incorporated in India and unincorporated jointly controlled entities are responsible for maintenance of adequate accounting records; safeguarding the assets; preventing and detecting frauds and other irregularities; selection and application of appropriate accounting policies; making judgments and estimates that are reasonable and prudent; and design, implementation and maintenance
of adequate internal financial controls, that were
operating effectively for ensuring the accuracy and completeness of the accounting records, relevant to the preparation and presentation of the financial statements, which have been used for the purpose of preparation of the consolidated financial statements by the directors of the Holding Company, as aforesaid.
Auditor’s Responsibility3. Our responsibility is to express an opinion on these
consolidated financial statements based on our audit.
4. While conducting the audit, we have taken into accountthe provisions of the Act, the accounting and auditingstandards and matters which are required to be included in the auditor’s report under the provisions of the Actand the Rules made thereunder.
5. We conducted our audit in accordance with theStandards on Auditing specified under Section 143(10)of the Act. Those Standards require that we comply withethical requirements and plan and perform the auditto obtain reasonable assurance about whether theconsolidated financial statements are free from materialmisstatement.
6. An audit involves performing procedures to obtain auditevidence about the amounts and the disclosures inthe consolidated financial statements. The proceduresselected depend on the auditor’s judgment, includingthe assessment of the risks of material misstatementof the consolidated financial statements, whether dueto fraud or error. In making those risk assessments, theauditor considers internal financial controls relevant tothe Holding Company’s preparation of the consolidatedfinancial statements that give a true and fair view inorder to design audit procedures that are appropriate inthe circumstances, but not for the purpose of expressing an opinion on whether the Holding Company has inplace an adequate internal financial controls systemover financial reporting and the operating effectivenessof such controls. An audit also includes evaluating theappropriateness of the accounting policies used andthe reasonableness of the accounting estimates madeby the Holding Company’s Board of Directors, as well asevaluating the overall presentation of the consolidatedfinancial statements.
226
Annual Report, 2015 / 105
7. We believe that the audit evidence obtained by us issufficient and appropriate to provide a basis for ourqualified audit opinion on the consolidated financialstatements.
Basis for Qualified Opinion8. As stated in Note 36 to the consolidated financial
statements, the Company’s trade receivables andunbilled work in progress as at 31 December 2015include amounts aggregating H3,033 lakhs (31 December 2014: H2,655 lakhs) and H479 lakhs (31 December 2014: H1,584 lakhs) respectively, being considered as goodand recoverable by the management. These amountsare presently under negotiation with the customers orsubject matter of litigation. In the absence of externalbalance confirmations from the customers or otheralternative audit evidence to corroborate management’s assessment of recoverability of these balances andhaving regard to the age of these receivables, we areunable to comment on the extent to which thesebalances are recoverable and consequential impact,if any, on the accompanying consolidated financialstatements. Our audit opinion on the consolidatedfinancial statements for the year ended 31 December2014 was also qualified in respect of this matter.
Qualified Opinion9. In our opinion and to the best of our information and
according to the explanations given to us, except forthe possible effects of the matter described in the Basisfor Qualified Opinion paragraph above the aforesaidconsolidated financial statements give the informationrequired by the Act in the manner so required and givea true and fair view in conformity with the accountingprinciples generally accepted in India, of the consolidated state of affairs of the Group and unincorporated jointlycontrolled entities as at 31 December 2015, and theirconsolidated loss and their consolidated cash flows forthe year ended on that date.
Emphasis of Matter10. We draw attention to Note 37 to the consolidated
financial statements which describes the uncertaintyrelated to recoverability of long-term trade receivablesand unbilled work in progress aggregating to H2,863lakhs (31 December 2014: H2,863 lakhs) and H8,678
lakhs (31 December 2014: H8,678 lakhs) respectively, outstanding as at 31 December 2015, representing various claims recognised during the earlier period based on the terms and conditions implicit in the contracts. These claims being technical in nature and being subject matter of litigation, the Company has assessed the recoverability of these claims based on legal opinion from an independent counsel. On the basis of such assessment, management is of the opinion that the claims are tenable and would be realized in full and accordingly no adjustments have been made in the consolidated financial statements. Our opinion is not modified in respect of these matters.
Report on Other Legal and Regulatory Requirements11. As required by the Companies (Auditor’s Report) Order,
2015 (“the Order”), issued by the Central Governmentof India in terms of Section 143(11) of the Act, andbased on the comments in the auditor’s report of theSubsidiary Company incorporated in India, we give inthe Annexure a statement on the matters specified inparagraphs 3 and 4 of the Order, as applicable to suchcompanies
12. As required by Section 143(3) of the Act, and based onthe auditor’s reports of the subsidiary, we report, to theextent applicable, that:a) we have sought and except for the possible effect
of the matter described in the Basis for QualifiedOpinion paragraph, obtained all the information and explanations which to the best of our knowledge and belief were necessary for the purpose of our auditof the aforesaid consolidated financial statements;
b) except for the possible effects of the matterdescribed in the Basis for Qualified Opinionparagraph, in our opinion, proper books of accountas required by law relating to preparation of theaforesaid consolidated financial statements havebeen kept so far as it appears from our examinationof those books and the report of the other auditor;
c) the consolidated financial statements dealt withby this Report are in agreement with the relevantbooks of account maintained for the purposeof preparation of the consolidated financialstatements;
227
d) in our opinion, the aforesaid consolidated financialstatements comply with the Accounting Standardsspecified under Section 133 of the Act, read withRule 7 of the Companies (Accounts) Rules, 2014(asamended);
e) the matters described in paragraph 8 and paragraph10 under the Basis for Qualified Opinion and theEmphasis of Matters paragraph respectively, inour opinion, may have an adverse effect on thefunctioning of the Group and unincorporated jointly controlled entities;
f) on the basis of the written representations receivedfrom the directors of the Holding Company as on31 December 2015 taken on record by the Boardof Directors of the Holding Company and the reportof the statutory auditors of its subsidiary companyincorporated in India, none of the directors of thegroup is disqualified as on 31 December 2015 frombeing appointed as a director in terms of Section164 (2) of the Act.
g) with respect to the other matters to be included inthe Auditor’s Report in accordance with Rule 11 ofthe Companies (Audit and Auditor’s) Rules, 2014, inour opinion and to the best of our information andaccording to the explanations given to us:
(i) except for the possible effect of the mattersdescribed above in paragraph 8 and paragraph10 under the Basis for Qualified Opinion andthe Emphasis of Matters paragraph respectivelyand Note 29 (c) to (g), the consolidated financial
statements disclose the impact of pending litigations on the consolidated financial position of the Group and unincorporated jointly controlled entities;
(ii) except for the possible effects of the matterdescribed in the Basis for Qualified Opinionparagraph, as detailed in note 36 to theconsolidated financial statements, provisionhas been made in the consolidated financialstatements, as required under the applicablelaw or accounting standards, for materialforeseeable losses on long-term contractsincluding derivative contracts; and
(iii) There were no amounts which were requiredto be transferred to the Investor Education andProtection Fund by the Holding Company andits subsidiary company incorporated in India.
For Walker Chandiok & Co LLP (Formerly Walker, Chandiok & Co)Chartered AccountantsFirm’s Registration No.: 001076N/N500013
per Sudhir N. PillaiPlace: Mumbai Partner Date: 24 February 2016 Membership No.: 105782
228
Annexure to the Independent Auditor’s Report of even date to the members of ITD Cementation India Limited on the consolidated financial statements for the year ended 31 December 2015
Based on the audit procedures performed for the purpose of reporting a true and fair view on the consolidated financial statements of the Holding Company and taking into consideration the information and explanations given to us and the books of account and other records examined by us in the normal course of audit, we report that:
(i) (a) The Holding Company has maintained properrecords showing full particulars, including quantitative details and situation of fixed assets.
(b) The fixed assets have been physically verified bythe management of the Holding Company duringthe year and no material discrepancies were noticed on such verification. In our opinion, the frequency of verification of the fixed assets is reasonable havingregard to the size of the Holding Company and thenature of its assets.
(ii) (a) The management of the Holding Company hasconducted physical verification of inventory at reasonable intervals during the year.
(b) The procedures of physical verification of inventoryfollowed by the management of the HoldingCompany are reasonable and adequate in relationto the size of the Holding Company and the natureof its business.
(c) The Holding Company is maintaining proper records of inventory and no material discrepancies between physical inventory and book records were noticedon physical verification.
(iii) The Holding Company has not granted any loan, secured or unsecured to companies, firms or other partiescovered in the register maintained under Section 189of the Act. Accordingly, the provisions of clauses 3(iii)(a)and 3(iii)(b) of the Order are not applicable.
(iv) Owing to the nature of its business, the Holding Company does not sell any goods. Accordingly, clause 3(iv) of theOrder with respect to sale of goods is not applicable.In our opinion, there is an adequate internal controlsystem commensurate with the size of the HoldingCompany and the nature of its business for the purchase of inventory and fixed assets and for the sale of services. During the course of our audit, no major weakness hasbeen noticed in the internal control system in respect ofthese areas.
(v) The Holding Company has not accepted any depositswithin the meaning of Sections 73 to 76 of the Act andthe Companies (Acceptance of Deposits) Rules, 2014 (as amended). Accordingly, the provisions of clause 3(v) ofthe Order are not applicable.
(vi) We have broadly reviewed the books of accountmaintained by the Holding Company pursuant tothe Rules made by the Central Government for themaintenance of cost records under sub-section (1) ofSection 148 of the Act in respect of Holding Company’sservices and are of the opinion that, prima facie, theprescribed accounts and records have been made andmaintained. However, we have not made a detailedexamination of the cost records with a view to determine whether they are accurate or complete.
(vii) (a) Undisputed statutory dues including providentfund, employees’ state insurance, income-tax, sales-tax, wealth tax, service tax, duty of customs, duty of excise, value added tax, cess and other material statutory dues, as applicable, have generally been regularly deposited with the appropriate authorities by the Holding Company, though there has been a slight delay in a few cases. Further, no undisputed amounts payable in respect thereof were outstanding at the year-end for a period of more than six months from the date they became payable.
(b) There are no dues in respect of wealth tax, servicetax, duty of customs and cess that have not beendeposited with the appropriate authorities onaccount of any dispute by the Holding Company.
The dues outstanding in respect of income-tax, sales-tax, duty of excise and value added tax on account of any dispute by the Holding Company, are as follows:
229
Name of the statute Nature of dues Amount (H in lakhs)
Amount Paid Under Protest
(H in lakhs)
Period to which the amount relates
Forum where dispute is pending
Sales Tax Act/Works Contract Tax Act
Sales Tax 31.97 - 2004-05 Deputy Commissioner of Commercial Taxes, Bihar
Sales Tax Act/Works Contract Tax Act
Sales Tax 29.39 14.69 2003-04 Joint Commissioner of Commercial Taxes, Bihar
Sales Tax Act/Works Contract Tax Act
Sales Tax 45.29 9.06 2005-06 Taxation Appellate Tribunal, Patna
Sales Tax Act/Works Contract Tax Act
Sales Tax 3.95 - 2011-12 Assistant Commercial Tax Officer
Sales Tax Act/Works Contract Tax Act
Value Added Tax 129.60 19.91 2009-10 Joint Commissioner of Commercial Taxes, Rajkot
Sales Tax Act/Works Contract Tax Act
Sales Tax 149.45 15.00 2010-11 Deputy Commissioner (Commercial Taxes) Gandhidham
Sales Tax Act/Works Contract Tax Act
Value Added Tax 79.83 23.95 2006-07 & 2007-08 Assistant Commissioner (Appeals), Commercial Taxes, Ernakulam
Sales Tax Act/Works Contract Tax Act
Value Added Tax 10.38 2.70 2005-06 Maharashtra Sales Tax Tribunal, Mumbai
Sales Tax Act/Works Contract Tax Act
Sales Tax 0.68 0.34 2003-04 Assisstant Commissioner of Sales Tax, Orissa
Sales Tax Act/Works Contract Tax Act
Sales Tax 0.19 - 2005-06 Assisstant Commissioner, Rajasthan
Sales Tax Act/Works Contract Tax Act
Sales Tax 99.56 26.12 2006-07, 2007-08, 2008-09 & 2009-10
Appellate Deputy Commissioner of Commercial Taxes, Tamil Nadu
Sales Tax Act/Works Contract Tax Act
Sales Tax 4.29 - 1997-98 & 2007-08 Deputy Commissioner of Commercial Taxes, Uttar Pradesh
Sales Tax Act/Works Contract Tax Act
Sales Tax/ Entry Tax
168.71 - 2010-11 & 2011-12 Deputy Commissioner of Commercial Taxes, Allahabad
Sales Tax Act/Works Contract Tax Act
Sales Tax/ Value Added Tax
387.06 - 2004-05, 2006-07, 2007-08 & 2008-09
Appellate and Revisional board, West Bengal
Sales Tax Act/Works Contract Tax Act
Sales Tax 105.80 - 2010-11 Commissioner, Commercial Taxes, Kolkata
Sales Tax Act/Works Contract Tax Act
Sales Tax 16.60 - 1994-95 Revision Board (Tribunal), Kolkata
Sales Tax Act/Works Contract Tax Act
Value Added Tax 265.81 - 2011-12 Joint Commissioner Sales Tax, West Bengal
Sales Tax Act/Works Contract Tax Act
Sales Tax 478.17 70.00 2012-2013 The West Bengal Taxation Tribunal, Salt Lake, Kolkata
230
(c) There were no amounts which were required to betransferred to the Investor Education and Protection Fund by the Holding Company in accordance withthe relevant provisions of the Companies Act, 1956(1 of 1956) and rules made thereunder. Accordingly, the provisions of clause 3(vii)(c) of the Order are not applicable.
(viii) In our opinion, the Holding Company has no accumulated losses at the end of the financial year it has not incurredcash losses in the current and the immediately preceding financial year.
(ix) The Holding Company has not defaulted in repayment of dues to any bank or financial institution during the year.The Holding Company did not have any outstandingdebentures during the year.
(x) In our opinion, the terms and conditions on which theHolding Company has given guarantee for loans takenby others from banks or financial institutions are not,prima facie, prejudicial to the interest of the HoldingCompany.
(xi) In our opinion, the Holding Company has applied theterm loans for the purpose for which these loans wereobtained.
(xii) No fraud on or by the Holding Company has beennoticed or reported during the period covered by ouraudit.
For Walker Chandiok & Co LLP (Formerly Walker, Chandiok & Co)Chartered AccountantsFirm’s Registration No.: 001076N/N500013
per Sudhir N. PillaiPlace: Mumbai Partner Date: 24 February 2016 Membership No.: 105782
Name of the statute Nature of dues Amount (H in lakhs)
Amount Paid Under Protest
(H in lakhs)
Period to which the amount relates
Forum where dispute is pending
Sales Tax Act/Works Contract Tax Act
Sales Tax 0.15 - 1999-00 Joint Commissioner of Commercial Taxes, Bihar
Central Excise Act,1944 Excise Duty 51.70 - May 1998 to January 1999
Commissioner of Central Excise
Income Tax Act, 1961 Income Tax 123.13 - A.Y. 2010-11 Income Tax Appellate Tribunal, Mumbai
Income Tax Act, 1961 Income Tax 0.63 - A.Y.2010-11 Assessing Officer, Mumbai
Income Tax Act, 1961 Income Tax 137.85 - A.Y.2011-12 Income Tax Appellate Tribunal, Kolkata
Income Tax Act, 1961 Income Tax 386.20 - A.Y. 2011-12, 2012-13 & 2013-14
Commissioner of Income Tax (Appeals)
231
Consolidated Balance Sheet as at 31 December 2015(Currency : Indian Rupee in lakhs)
NotesAs at
31 December 2015As at
31 December 2014EQUITY AND LIABILITIESShareholders’ FundsShare capital 2 1,551.58 1,551.58 Reserves and surplus 3 49,269.85 55,230.22
50,821.43 56,781.80 Non-Current LiabilitiesLong-term borrowings 4 1,178.81 4,038.61 Long-term provisions 5 694.56 563.24
1,873.37 4,601.85 Current LiabilitiesShort-term borrowings 6 56,211.69 68,119.53 Trade payables 7 75,429.28 41,719.51 Other current liabilities 8 58,521.83 47,150.32 Short-term provisions 9 1,621.57 1,110.97
1,91,784.37 1,58,100.33 Total 2,44,479.17 2,19,483.98 ASSETSNon-Current AssetsFixed Assets
Tangible assets 10 34,898.52 33,525.83 Capital work-in-progress 267.22 328.36
Deferred tax assets, (net) 11 4,423.39 1,485.13 Long-term loans and advances 12 22,167.51 16,595.77 Long-term trade receivables 16 2,863.37 2,863.37 Other non-current assets 13 23.79 27.54
64,643.80 54,826.00 Current AssetsCurrent investment 14 0.26 0.26 Inventories 15 1,17,538.07 1,13,125.22 Trade receivables 16 30,917.17 41,285.81 Cash and bank balances 17 14,760.26 2,718.20 Short-term loans and advances 12 16,500.51 7,512.74 Other current assets 18 119.10 15.75
1,79,835.37 1,64,657.98 Total 2,44,479.17 2,19,483.98 Significant accounting policies 1
Notes 1 to 43 form an integral part of these consolidated financial statementsThis is the consolidated balance sheet referred to in our report of even date
For and on behalf of the Board of Directors
Adun Saraban P. ChakornbunditManaging Director Director DIN No.01312769 DIN No.00254312
S. Ramnath R. C. Daga Chief Financial Officer Company Secretary FCA No. 030663 ACS No.576
Place : Mumbai
For Walker Chandiok & Co LLP (formerly Walker, Chandiok & Co)Chartered AccountantsFirm Registration No. 001076N/N500013
Sudhir N. Pillai Partner Membership No: 105782
Place : Mumbai Date: 24 February 2016 Date: 24 February 2016
232
Consolidated Statement of Profit and Loss for the year ended 31 December 2015(Currency : Indian Rupee in lakhs)
NotesYear ended
31 December 2015Year ended
31 December 2014
REVENUE
Contract revenue 3,06,870.03 1,71,242.31
Other operating income 19 224.87 652.29
Other income 20 2,217.41 1,849.47
Total revenue 3,09,312.31 1,73,744.07
EXPENSES
Cost of materials consumed 80,945.83 64,392.02
Sub-contract expense 1,29,588.37 40,260.28
Employees benefits expense 21 22,240.69 19,363.89
Finance costs 22 13,771.36 13,550.37
Depreciation expense 10 3,665.05 4,270.88
Other expenses 23 55,162.40 38,770.92
Total Expenses 3,05,373.70 1,80,608.36
Profit / (loss) before exceptional item and tax 3,938.61 (6,864.29)
Exceptional items 24 (12,397.19) 9,553.25
(Loss) / profit before tax (8,458.58) 2,688.96
Tax expense
Current tax (265.37) (964.52)
Less: Minimum alternative tax credit entitlement - 720.23
Short provision for tax for earlier years (131.83) 132.69
Deferred tax credit / (charge) 2,925.02 (635.93)
Net (loss) / profit for the year (5,930.76) 1,941.43
Earnings/(loss) per equity share of H1 (previous year H10) each 25
Basic and diluted (3.82) 1.51
Notes 1 to 43 form an integral part of these consolidated financial statementsThis is the consolidated statement of profit and loss referred to in our report of even date
For Walker Chandiok & Co LLP For and on behalf of the Board of Directors(formerly Walker, Chandiok & Co)Chartered AccountantsFirm Registration No. 001076N/N500013
Sudhir N. Pillai Adun Saraban P. ChakornbunditPartner Managing Director Director Membership No: 105782 DIN No.01312769 DIN No.00254312
S. Ramnath R. C. Daga Chief Financial Officer Company Secretary FCA No. 030663 ACS No.576
Place : Mumbai Place : MumbaiDate: 24 February 2016 Date: 24 February 2016
233
Consolidated Cash Flow Statement for the year ended 31 December 2015(Currency : Indian Rupee in lakhs)
Year ended 31 December 2015
Year ended31 December 2014
CASH FLOW FROM OPERATING ACTIVITIES
Net (loss) / profit before tax (8,458.58) 2,688.96
Adjustments for:
Depreciation 3,665.05 4,270.88
Finance Cost 13,771.36 13,550.37
Interest income (449.58) (149.70)
Provision for doubtful debts 1,367.65 673.69
Provision for doubtful deposits 50.22 47.33
Depreciation written back - (9,553.25)
Bad debts written off on one settlement with NHAI 12,397.19 -
(Profit) / loss on sale of fixed assets (net) (815.02) 20.03
Sundry balances written back (235.81) (132.13)
Prior years provision written back - (176.95)
Provision for gratuity 725.28 359.44 Operating profit before working capital changes 22,017.76 11,598.67 Adjustment for change in working capital
Increase in Inventories (4,412.85) (17,442.63)
Increase in trade receivables (3,396.19) (4,664.43)
Increase in loans and advances (12,266.25) (4,051.90)
Increase in trade payables and other current liabilites 47,066.74 18,302.73
Cash generated from operations 49,009.21 3,742.44
Direct taxes (paid) / refund (2,503.69) 621.16 Net cash generated from operating activities 46,505.52 4,363.60 CASH FLOW FROM INVESTING ACTIVITIES
Purchase of fixed assets (including capital work in progress) (5,862.62) (4,912.77)
Proceeds from sale of fixed assets 1,258.21 342.37
Fixed Deposit with bank (maturity beyond three months) (6,372.42) (222.87)
Proceeds from fixed deposit with bank (maturity beyond three months) 222.87 795.89
Interest received 344.88 161.69 Net cash used in investing activities (10,409.08) (3,835.69)
234
(Currency : Indian Rupee in lakhs)
Year ended 31 December 2015
Year ended31 December 2014
CASH FLOW FROM FINANCING ACTIVITIES
Proceeds from issue of share capital - QIP (net of share issue expenses) - 13,999.05
Proceeds from long-term borrowings 997.38 6,841.34
Repayment of long-term borrowings (5,547.48) (6,857.11)
Repayment of short-term borrowings (net) (11,907.84) (402.81)
Interest paid (13,749.82) (13,874.75)
Dividend paid (1.27) (114.66)
Tax on distributed profits - (19.57)Net cash used in financing activities (30,209.03) (428.51)Net increase in cash and cash equivalents 5,887.41 99.40 Cash and cash equivalents at the beginning of year 2,495.33 2,395.93 Cash and cash equivalents at the end of year 8,382.74 2,495.33 Components of cash and cash equivalents (Refer note 17)
Cash in hand 157.51 194.75
Balance with scheduled banks
- current accounts 3,600.56 1,924.98
- unpaid dividend bank accounts 6.17 7.44
- deposits with original maturity not more than 3 months 4,618.50 368.16 8,382.74 2,495.33
Consolidated Cash Flow Statement for the year ended 31 December 2015
Notes : 1. Figures given in brackets indicate cash outflow
2. The consolidated cash flow statement has been prepared under Indirect Method as per the Accounting Standard 3 CashFlow Statement issued by the Institute of Chartered Accountants of India.
3. The figures of the previous year have been regrouped/reclassified, where necessary, to conform with the classification ofthe current year.
This is the consolidated cash flow statement referred to in our report of even date
For Walker Chandiok & Co LLP For and on behalf of the Board of Directors(formerly Walker, Chandiok & Co)Chartered AccountantsFirm Registration No. 001076N/N500013
Sudhir N. Pillai Adun Saraban P. ChakornbunditPartner Managing Director Director Membership No: 105782 DIN No.01312769 DIN No.00254312
S. Ramnath R. C. Daga Chief Financial Officer Company Secretary FCA No. 030663 ACS No.576
Place : Mumbai Place : MumbaiDate: 24 February 2016 Date: 24 February 2016
235
Summary of significant accounting policies and other explanatory information to the consolidated financial
statements as at and for the year ended 31 December 2015
CORPORATE INFORMATIONITD Cementation India Limited (‘ITD Cem’ or ‘the Company’) was incorporated in 1978 and is engaged in construction of a wide variety of structures like maritime structures, mass rapid transport systems (MRTS), dams & tunnels, airports, highways, bridges & flyovers and other foundations and specialist engineering work. The activities of the Company comprise only one business segment viz Construction.
1. SIGNIFICANT ACCOUNTING POLICIESA. Basis of preparation and Principles of Consolidation(i) Basis of Preparation of Consolidated Financial Statements
The consolidated financial statements have been prepared to comply in all material respects with the accountingstandards notified by the Companies (Accounting Standards) Rules, 2006 read with Rule 7 to the Companies (Accounts)Rules 2014 in respect of Section 133 of the Companies Act, 2013. The consolidated financial statements are preparedunder the historical cost convention, on an accrual basis of accounting.
The accounting policies applied are consistent with those used in the previous year.
The consolidated financial statement comprises the financial statements of ITD Cementation India Limited (“theHolding Company”) and its subsidiary (the Holding Company and its subsidiary together referred to as “the Group”) andunincorporated jointly controlled entities.
(ii) Principles of ConsolidationThe consolidated financial statements have been prepared on the following basis:
a. The financial statements of the Holding Company and its subsidiary company have been consolidated on a line byline basis by adding together the book values of like items of assets, liabilities, income and expenses, after eliminating intra-group balances/ transactions and elimination of resulting unrealized profits in accordance with AccountingStandard (‘AS’) - 21 ‘Consolidated Financial Statements’ notified by the Companies (Accounting Standards) Rules,2006 read with Rule 7 to the Companies (Accounts) Rules 2014 in respect of Section 133 of the Companies Act, 2013.
b. The Interests in Joint Ventures which are in the nature of unincorporated jointly controlled entities have beenconsolidated by using the proportionate consolidation method on a line by line basis by adding together the bookvalues of like items of assets, liabilities, income and expenses, after eliminating intra-group balances/ transaction and elimination of resulting unrealized profits in accordance with AS 27 - ‘Financial Reporting of Interests in Joint Ventures’ notified by the Companies (Accounting Standards) Rules, 2006 read with Rule 7 to the Companies (Accounts) Rules2014 in respect of Section 133 of the Companies Act, 2013.
c. Consolidated financial statements are prepared using uniform policies for like transaction and other events in similar circumstances and are presented, to the extent possible, in the same manner as the Company’s separate financialstatements.
d. Notes to the consolidated financial statements, represents notes involving items which are considered material andare accordingly duly disclosed. Materiality for the purpose is assessed in relation to the information contained in theconsolidated financial statement. Further, additional statutory information disclosed in separate financial statementsof the subsidiary and/or a parent having no bearing on the true and fair view of the consolidated financial statementhas not been disclosed in the consolidated financial statements.
e. The difference between the cost to the Group of investment in subsidiary and joint ventures and the proportionateshare in the equity of the investee company as at the date of the acquisition of stake is recognized in the consolidated financial statements as goodwill or capital reserve, as the case may be. Goodwill arising on consolidation is tested for impairment annually.
B. Accounting estimatesThe preparation of the consolidated financial statements in conformity with generally accepted accounting principlesrequires management to make estimates and assumptions that affect the reported amounts of assets and liabilities anddisclosure of contingent liabilities as at the date of consolidated financial statements and the results of operation during
236
Summary of significant accounting policies and other explanatory information to the consolidated financial
statements as at and for the year ended 31 December 2015
the reported year. Although these estimates are based upon management’s best knowledge of current events and actions, actual results could differ from these estimates which are recognised in the year in which they are determined.
C. Fixed assetsTangible assets are stated at cost, less accumulated depreciation and impairment losses, if any. Cost comprises thepurchase price and any attributable cost of bringing the asset to its working condition for its intended use. Borrowingcosts relating to acquisition of fixed assets which takes substantial period of time to get ready for its intended use are also included to the extent they relate to the period till such assets are ready to be put to use.
Subsequent expenditures related to an item of tangible asset are added to its book value only if they increase the futurebenefits from the existing asset beyond its previously assessed standard of performance.
Capital work in progress represents expenditure incurred in respect of capital projects under development and are carried at cost. Cost includes related acquisition expenses, construction cost and other direct expenditure.
D. Depreciation on tangible fixed assets(i) Depreciation on tangible assets is provided on straight line basis at useful life prescribed in Schedule II to the
Companies Act, 2013 on a pro-rata basis. However, certain class of plant and machinery are depreciated on the useful life different from the useful life prescribed in Schedule II to the Companies Act, 2013 having regard to useful life ofthose assets in construction projects based on the management’s experience of use of those assets which is in linewith industry practices.
(ii) Leasehold improvements are amortized over the lease period or useful life whichever is lower.
(iii) Depreciation for additions to/deductions from, owned assets is calculated pro rata from/to the month of additions/deductions.
(iv) In case of Joint Ventures, depreciation on fixed assets is provided on straight-line method at the rates determined asper the useful lives of the respective assets and the life of the project.
E. Impairment of assetsThe carrying amounts of the Company’s assets are reviewed at each balance sheet date if there is any indication ofimpairment based on internal/external factors. An impairment loss is recognized whenever the carrying amount of anasset exceeds its recoverable amount. The recoverable amount is the greater of the assets net selling price and its valuein use. Impairment loss is recognized in the Statement of Profit and Loss or against revaluation surplus where applicablebeyond the carrying value that would have prevailed by charging usual depreciation if there was no impairment.
A previously recognized impairment loss is increased or reversed depending on changes in circumstances. However thecarrying value after reversal is not increased beyond the carrying value that would have prevailed by charging usualdepreciation if there was no impairment.
F. InvestmentsInvestments, which are readily realisable and intended to be held for not more than one year from the date on whichsuch investments are made, are classified as current investments. All other investments are classified as non-currentinvestments.
Current investments are carried in the consolidated financial statements at lower of cost or fair value determined on anindividual investment basis. Non-current investments are carried at cost and provision for diminution in value is made torecognise a decline other than temporary in the value of the investments.
On disposal of an investment, the difference between its carrying amount and net disposal proceeds is charged or creditedto the Statement of Profit and Loss.
G. Inventoriesi. Construction materials are valued at cost. Cost is determined on a first-in, first-out method and comprises the
purchase price including duties and taxes (other than those subsequently recoverable by the Company from thetaxing authorities).
237
ii. Tools and equipment are stated at cost less the amount amortised. Tools and equipment are amortised over theirestimated useful lives ranging from 3 to 10 years. Cost is determined by the weighted average method.
iii. Machinery spares that are of regular use are charged to the statement of profit and loss as and when consumed.
iv. Unbilled work in progress: Work done remaining to be certified/billed is recognized as unbilled work in progressprovided it is probable that they will be recovered in the accounts. The same is valued at the realizable value.
H. Revenue recognitioni) On contracts
Revenue from construction contracts is recognised on the basis of percentage completion method. The stage ofcompletion of a contract is determined by the proportion that contract costs incurred for work performed upto thereporting date bear to the estimated total contract costs. Contract revenue earned in excess of certification has beenclassified as “Unbilled work-in-progress” and certification in excess of contract revenue has been classified as “Other current liabilities” in the consolidated financial statements.
Amounts recoverable in respect of the price and other escalation, bonus claims adjudication and variation in contract work required for performance of the contract to the extent that it is probable that they will result in revenue.
In addition, if it is expected that the contract will make a loss, the estimated loss is immediately provided for in thebooks of account.
Contractual liquidated damages, payable for delays in completion of contract work or for other causes, are accounted for as costs when such delays and causes are attributable to the Company or when deducted by the client.
ii) Accounting for Joint Venture ContractsRevenue from long term construction contracts executed in unincorporated joint ventures under work sharingarrangements is recognized on the same basis as similar contracts independently executed by the Company.
(iii) Service IncomeService income is accounted on accrual basis in accordance with the terms of agreement with the parties.
(iv) Insurance claimsInsurance claims are recognized as income based on certainty of receipt.
(v) Interest Income and other incomeInterest and other income are accounted for on accrual basis except where the receipt of income is uncertain in which case it is accounted for on receipt basis.
I. Advances from customers, progress payments and retentionAdvances received from customers in respect of contracts are treated as liabilities and adjusted against progress billingas per terms of the contract.
Progress payments received are adjusted against amount receivable from customers in respect of the contract workperformed.
Amounts retained by the customers until the satisfactory completion of the contracts are recognised as receivables.Where such retention has been released by customers against submission of bank guarantees, the amount so released isadjusted against receivable from customers and the value of bank guarantees is disclosed as a contingent liability.
J. Foreign currency transactionsi. Initial Recognition
Foreign currency transactions are recorded in the reporting currency, by applying to the foreign currency amount theexchange rate between the reporting currency and the foreign currency at the date of the transaction.
ii. ConversionForeign currency monetary items are reported using the closing rate. Non-monetary items which are carried in terms of historical cost denominated in a foreign currency are reported using the exchange rate at the date of the transaction.
Summary of significant accounting policies and other explanatory information to the consolidated financial
statements as at and for the year ended 31 December 2015
238
iii. ExchangeDifferencesExchange differences arising on the settlement of monetary items or on reporting company’s monetary items atrates different from those at which they were initially recorded during the year, or reported in previous consolidatedfinancial statements, are recognized as income or as expenses in the year in which they arise.
iv. Forward exchange contracts not intended for trading or speculation purposesThe premium or discount arising at the inception of forward exchange contracts is amortized as expense or incomeover the life of the contract. Exchange differences on such contracts are recognized in the statement of profit andloss in the year in which the exchange rates change. Any profit or loss arising on cancellation or renewal of forwardexchange contract is recognized as income or as expense for the year.
K. Employee benefitsi. Defined benefit plan
In terms of the Guidance on implementing Accounting Standard (AS) 15 - Employee Benefits, issued by the Accounting Standards Board of the Institute of Chartered Accountants of India, the Provident Fund set up by the Company istreated as a defined benefit plan. This is administered through trusts of the Company. The Company has to meet theinterest shortfall, if any. Accordingly, the contribution paid or payable and the interest shortfall, if any, is recognisedas an expense in the period in which services are rendered by the employee. Further, the pattern of investments forinvestible funds is as prescribed by the Government. Accordingly, other related disclosures in respect of providentfund have not been made.
Further company has defined benefit plans for post-employment benefits in the form of Gratuity. The Companyhas taken an insurance policy under the Group Gratuity Scheme with the insurance company to cover the GratuityLiability. The liability for Defined Benefit Plans is provided on the basis of valuations, as at the Balance Sheet date,carried out by an independent actuary.
The obligations are measured as the present value of estimated future cash flows discounted at rates reflecting theprevailing market yields of Indian Government securities as at the Balance Sheet date for the estimated term of theobligations. The estimate of future salary increases considered takes into account the inflation, seniority, promotionand other relevant factors.
The expected rate of return of plan assets is the Company’s expectation of the average long-term rate of returnexpected on investments of the fund during the estimated term of the obligations. Plan assets are measured at fairvalue as at the Balance Sheet date. The actuarial valuation method used by independent actuary for measuring theliability is the Projected Unit Credit method.
ii. Defined contribution plan:The certain employees of the Company are also participant in the superannuation plan, employee state insurancescheme and Labour Welfare Fund scheme which is a defined contribution plan. The Company has no obligations tothe Plan beyond its contributions. The company’s contributions to Defined Contribution Plans are charged to theStatement of Profit and Loss as incurred.
iii. Other employee benefitsThe Company treats accumulated leave expected to be carried forward beyond twelve months, as long-termemployee benefit for the measurement purposes. Such long-term compensated absences are provided for basedon the actuarial valuations using the projected unit credit method at the period end. Accumulated leave which isexpected to be utilised within next 12 months, is treated as short-term employee benefit. Actuarial gains and lossesin respect of the defined benefit plans are recognised in the Statement of Profit and Loss in the period in which theyarise.
L. Earnings Per ShareBasic earnings per share is calculated by dividing the net profit or loss after tax for the year attributable to equityshareholders by the weighted average number of equity shares outstanding during the year. The number of shares used
Summary of significant accounting policies and other explanatory information to the consolidated financial
statements as at and for the year ended 31 December 2015
239
in computing diluted earnings per share comprises the weighted average number of shares considered for deriving basic earnings per share and also the weighted average number of shares which could have been issued on conversion of all dilutive potential equity shares.
M. TaxationCurrent taxProvision for current tax is recognized based on the estimated tax liability computed after taking credit for allowances and exemptions in accordance with the Income Tax Act, 1961.
Minimum Alternative Tax (MAT) credit is recognised as an asset only when and to the extent there is convincing evidencethat the company will pay normal income tax during the specified period. In the year in which the MAT credit becomeseligible to be recognized as an asset in accordance with the recommendations contained in Guidance Note issued bythe Institute of Chartered Accountants of India, the said asset is created by way of a credit to the Statement of Profit andLoss and shown as MAT Credit Entitlement. The Company reviews the same at each balance sheet date and writes downthe carrying amount of MAT Credit Entitlement to the extent there is no longer convincing evidence to the effect thatCompany will pay normal Income Tax during the specified period.
Deferred taxDeferred tax assets and liabilities are recognized for the future tax consequences attributable to timing differencesbetween the consolidated financial statements’ carrying amounts of existing assets and liabilities and their respectivetax basis. Deferred tax assets and liabilities are measured using the enacted tax rates or tax rates that are substantivelyenacted at the balance sheet dates. The effect on deferred tax assets and liabilities of a change in tax rates is recognisedin the period that includes the enactment date. Where there is unabsorbed depreciation or carry forward losses, deferredtax assets are recognized only if there is virtual certainty supported by convincing evidence that they can be realisedagainst future taxable profits. Other deferred tax assets are recognized only to the extent there is reasonable certainty ofrealization in the future. Such assets are reviewed at each balance sheet date to reassess realization. Timing differencesoriginating and reversing during the tax holiday period are not considered for the purpose of computing deferred taxassets and liabilities.
N. LeasesLeases, where the lessor effectively retains substantially all the risks and benefits of ownership of the leased term, areclassified as operating leases. Operating lease payments are recognized as an expense in the Statement of Profit and Loss account on a straight-line basis over the lease term.
O. Provisions and Contingent LiabilitiesA provision is recognized when the Company has a present obligation as a result of past events and it is probable thatan outflow of resources will be required to settle the obligation, in respect of which a reliable estimate can be made.Provisions are not discounted to their present value and are determined based on management’s best estimates required to settle the obligation at the Balance Sheet date. These are reviewed at each Balance Sheet date and adjusted to reflectthe current best estimates.
Contingent Liabilities are disclosed in respect of possible obligations that arise from past events, whose existence wouldbe confirmed by the occurrence or non-occurrence of one or more uncertain future events not wholly within the controlof the Company.
Contingent assets are neither recognised nor disclosed in the consolidated financial statements.
P. Cash and cash equivalentsCash and cash equivalents comprise of cash at bank and cash in hand. The Company considers all highly liquid investments with an original maturity of three month or less from date of purchase, to be cash equivalents.
Summary of significant accounting policies and other explanatory information to the consolidated financial
statements as at and for the year ended 31 December 2015
240
2. Share capital
As at 31 December 2015 As at 31 December 2014
Number Amount Number Amount
Authorised Share Capital
Equity shares of H1 (previous year: H10) each 30,00,00,000 3,000.00 3,00,00,000 3,000.00
Redeemable preference shares of H10 each 4,50,00,000 4,500.00 4,50,00,000 4,500.00
34,50,00,000 7,500.00 7,50,00,000 7,500.00
Issued
Equity shares of H1 (previous year: H10) each 15,51,83,160 1,551.83 1,55,18,316 1,551.83
15,51,83,160 1,551.83 1,55,18,316 1,551.83
Subscribed and fully paid-up
Equity shares of H1 (previous year: H10) each 15,51,57,900 1,551.58 1,55,15,790 1,551.58
15,51,57,900 1,551.58 1,55,15,790 1,551.58
a) Reconciliation of equity shares outstanding at the beginning and at the end of the reporting period
As at 31 December 2015 As at 31 December 2014
Number Amount Number Amount
At the beginning of the year 1,55,15,790 1,551.58 1,15,15,790 1,151.58
Add: Conversion on account of share split (Refer note below)
13,96,42,110 - - -
Add : Issued during the year - - 40,00,000 400.00
Balance at the end of the year 15,51,57,900 1,551.58 1,55,15,790 1,551.58
c) Shares held by holding Company
As at 31 December 2015 As at 31 December 2014
Number Amount Number Amount
Equity shares of H1 (previous year: H10) each
Italian-Thai Development Public Company Limited, Thailand
8,01,13,180 801.13 80,11,318 801.13
Pursuant to the approval of the members at the 37th Annual General Meeting of the Company held on 13 May 2015 to the sub-division of the Equity Shares of the Company, each Equity Share of nominal face value of H10 each was sub-divided to 10 (ten) Equity Share of H1 each. The effective date for the said sub-division was 24 August 2015.
b) Terms/rights attached to equity sharesThe Company has only one class of equity shares having a par value of H1 (previous year H10) per share. Each holder ofequity shares is entitled to one vote per share. The Company declares and pays dividends in Indian Rupees. The dividendproposed if any by the Board of Directors is subject to the approval of the shareholders in the ensuing Annual GeneralMeeting, except interim dividend.
In the event of liquidation of the Company, the holders of equity shares will be entitled to receive remaining assets ofthe Company, after distribution of all preferential amounts, if any. The distribution will be in proportion to the number ofequity shares held by the shareholders.
Summary of significant accounting policies and other explanatory information to the consolidated financial
statements as at and for the year ended 31 December 2015 (Currency : Indian Rupee in lakhs)
241
3. Reserves and surplus
As at 31 December 2015
As at 31 December 2014
Securities premium account
Balance at the beginning of the year 45,556.44 31,957.38
Add: Additions during the year - 14,000.00
Less: Share issue expenses - (400.94)
Balance at the end of the year 45,556.44 45,556.44
General reserve 676.48 676.48
Surplus in the statement of profit and loss
Balance at the beginning of the year 8,997.30 7,055.87
Add : Transferred from statement of profit and loss (5,930.76) 1,941.43
Less : Adjustment on account of additional depreciation (Refer note 3.1 below) (29.61) -
3,036.93 8,997.30
49,269.85 55,230.22
2. Share capital (Contd..)
d) Shareholders holding more than 5% of the equity shares in the Company as at 31 December 2015
As at 31 December 2015 As at 31 December 2014
Number % Holding Number % Holding
Equity shares of H1 (previous year: H10) each
Italian-Thai Development Public Company Limited, Thailand
8,01,13,180 51.63% 80,11,318 51.63%
HDFC Trustee Company Limited 1,10,33,180 7.11% 10,28,361 6.63%
As per records of the Company, including its register of shareholders/members and other declarations received from shareholders regarding beneficial interest, the above shareholding represents both legal and beneficial ownership of shares.
e) Aggregate number of bonus shares issued, shares issued for consideration other than cash and shares bought backduring the period of five years immediately preceeding the reporting date.The Company has not issued any bonus shares, shares for consideration other than cash and bought back any sharesduring five years immediately preceeding the reporting date.
f) Out of the total issued capital, 25,260 (31 December 2014 : 2,526) equity shares of H1 (previous year H10) each have been kept in abeyance pending final settlement of rights issues.
3.1 The Company has provided depreciation on the basis of useful life of fixed assets as mandated by Schedule II of the Companies Act, 2013. Further, in line with Schedule II, the Company undertook technical evaluation of certain fixed assets to determine the true useful life and recomputed the depreciation on that basis. Consequently, the depreciation and loss for the year ended 31 December 2015 is lower by H217 lakhs. Further, H29.61 lakhs (net of tax adjustment of H13.24 lakhs) has been adjusted to the opening balance of the retained earnings where the remaining useful life of the assets was nil as at 1 January 2015.
Summary of significant accounting policies and other explanatory information to the consolidated financial
statements as at and for the year ended 31 December 2015 (Currency : Indian Rupee in lakhs)
242
4. Long-term borrowings
As at 31 December 2015 As at 31 December 2014
Non-current Current Non-current Current Secured
Rupee term loans- From bank 196.00 1,989.04 3,073.74 3,000.00 - From other parties 315.04 273.94 587.97 865.84
Plant loans- From bank 212.91 100.76 - - - From other party 364.77 281.04 242.89 297.00
Vehicle loans from bank 90.09 39.44 134.01 37.18 Unsecured
Rupee term loan from other party - - - 174.50 1,178.81 2,684.22 4,038.61 4,374.52
Amount disclosed under "Other current liabilities" (Refer note 8)
- (2,684.22) - (4,374.52)
1,178.81 - 4,038.61 -
Rupee term loan - from bank (secured)Term loan obtained from Exim Bank carries interest rate of 11.0 percent per annum. This loan is repayable on 31 July 2017 or on receipt of retention money which ever is earlier. This loan is secured by entire moveable assets of the project.
Term loan obtained from Vijaya Bank carries interest rate of 12.25 percent per annum and repayable in 3 monthly installments starting from November 2015. This loan is secured by hypothecation of Kolkata area depot land.
Rupee term loans from others (secured)Loan obtained from Indiabulls Housing Finance Limited for purchase of office (Kolkata) which carries an interest rate of 13.50 percent per annum and is repayable in 84 monthly installments commencing from April 2013. This loan is secured by hypothecation of the office purchased out of this loan.
Loan obtained from Tata Capital Financial Services Limited carries an interest rate of 13 percent per annum and is repayable in 24 monthly installments commencing from April 2014. This loan is secured by first and exclusive charge on specific equipments financed by the institution.
Plant loans from bank (secured)Loan obtained from Axis bank for purchase of commercial vehicle /construction equipment carry interest rate 10.75 percent per annum and are repayble in 36 monthly installments. These loans are secured by first and exclusive charge on specific vehicle/equipment financed by the bank.
Plant loans from other party (secured)Loans obtained from Tata Capital Limited for purchase of construction equipment carry interest rate ranging between 12.01 to 13.01 percent per annum and are repayable in 57 to 84 monthly installments. These loans are secured by first and exclusive charge on specific equipment financed by the institution.
Vehicle loans from bank (secured)Loan obtained from Axis Bank for purchase of vehicles carry interest rate ranging between 10 to 10.5 percent per annum and are repayble in 60 monthly installments. These loans are secured by hypothecation of the vehicles purchased out of these loans.
5. Long-term provision
As at 31 December 2015
As at 31 December 2014
Provision for employee benefits
- Leave entitlement (Refer note 31) 694.56 563.24 694.56 563.24
Summary of significant accounting policies and other explanatory information to the consolidated financial
statements as at and for the year ended 31 December 2015 (Currency : Indian Rupee in lakhs)
243
6. Short-term borrowings
As at 31 December 2015
As at 31 December 2014
Secured
Cash credit facilities 38,711.69 67,405.75
Buyer's credit - 713.78Unsecured
Commercial paper 17,500.00 - 56,211.69 68,119.53
7. Trade payables (Refer note 39)As at
31 December 2015As at
31 December 2014
Acceptances 7,265.52 8,048.48
Other trade payables 68,163.76 33,671.03 75,429.28 41,719.51
8. Other current liabilitiesAs at
31 December 2015As at
31 December 2014
Current maturity of long term debt (Refer note 4) 2,684.22 4,374.52
Creditors for capital expenses 145.08 303.35
Interest accrued and due 138.87 83.65
Interest accrued but not due 89.30 122.98
Unpaid dividend * 6.17 7.44
Advances from customers (Refer note 40) 46,411.63 35,514.07
Material received from customers 58.76 102.46
Amount due to customers (Refer note 40) 2,292.94 951.30
Payable to Co-venturer 16.98 15.20
Employee related dues 3,030.12 2,384.98
Statutory dues payable 653.51 924.09
Liability for foreign exchange contracts - 5.64
Others 2,994.25 2,360.64
58,521.83 47,150.32
* Not due for credit to Investor Education and Protection Fund
Cash credit facilities (secured)Cash credit facilities are availed from consortium bankers carries various interest rates ranging from 11.70 to 15.15 percent per annum and are secured by first pari passu charge on the current assets and movable plant and machinery other than those charged in favour of Tata Capital Limited. These facilities are payable on demand.
Commercial Paper (unsecured)Commercial Paper is issued to HDFC Trustee Company Limited and Deutsche Asset Management (India) Private Limited carries an interest rate of 11.50 percent.
Summary of significant accounting policies and other explanatory information to the consolidated financial
statements as at and for the year ended 31 December 2015 (Currency : Indian Rupee in lakhs)
244
9. Short term provisions
As at 31 December 2015
As at 31 December 2014
Provision for employee benefits
- Gratuity (Refer note 31) 1,317.93 793.62
- Leave entitlement (Refer note 31) 100.42 113.19
- Provident fund 182.11 178.33
Provision for taxation (net of advance tax) 21.11 25.83
1,621.57 1,110.97
10. Tangible assetsFreehold
landLeasehold
improve-ments
Buildings Plant and machinery
Earth-moving
machinery
Officeequipment
and furniture
Vehicles Total
Gross block
Balance as at 1 January 2014 15.32 453.82 1,099.17 42,323.26 6,788.52 2,167.12 458.96 53,306.17
Additions - - - 5,899.83 147.46 65.90 136.18 6,249.37
Deletions - - - (2,041.53) (159.32) (330.53) (12.74) (2,544.12)
Balance as at 31 December 2014 15.32 453.82 1,099.17 46,181.56 6,776.66 1,902.49 582.40 57,011.42
Additions 533.39 - - 4,022.09 793.64 145.57 29.08 5,523.77
Disposals - - (34.51) (1,472.10) (157.37) (121.91) (26.85) (1,812.74)
Balance as at 31 December 2015 548.71 453.82 1,064.66 48,731.55 7,412.93 1,926.15 584.63 60,722.45
Accumulated depreciation
Balance as at 1 January 2014 - 125.43 155.84 23,311.73 5,507.06 1,598.94 250.69 30,949.69
Depreciation charge - 69.80 39.45 3,497.64 461.69 143.28 59.02 4,270.88
Reversal on disposal of assets - - - (1,688.02) (124.83) (357.21) (11.67) (2,181.73)
Effect of change in accounting policy [Refer note 24 & 38(b)]
- - (96.34) (8,263.09) (1,149.72) 18.31 (62.41) (9,553.25)
As at 31 December 2014 - 195.23 98.95 16,858.26 4,694.20 1,403.32 235.63 23,485.59
Depreciation charge - 102.87 16.80 2,773.62 521.86 192.85 57.05 3,665.05
Reversal on disposal of assets - - (13.73) (1,082.95) (132.89) (123.46) (16.53) (1,369.56)
Transition Adjustments (Refer note 3.1)
- - - 0.11 - 40.61 2.13 42.85
As at 31 December 2015 - 298.10 102.02 18,549.04 5,083.17 1,513.32 278.28 25,823.93
Net block
As at 31 December 2015 548.71 155.72 962.64 30,182.51 2,329.76 412.83 306.35 34,898.52
As at 31 December 2014 15.32 258.59 1,000.22 29,323.30 2,082.46 499.17 346.77 33,525.83
Note: Buildings include H0.09 lakhs (31 December 2014 : H0.09 lakhs) being the cost of shares in co-operative housing societies.
Summary of significant accounting policies and other explanatory information to the consolidated financial
statements as at and for the year ended 31 December 2015 (Currency : Indian Rupee in lakhs)
245
11. Deferred tax assets (net)
As at 31 December 2015
As at 31 December 2014
Deferred tax asset arising on account of (A)
Provision for doubtful debts 1,309.46 975.54
Provision for employee benefits 651.20 496.43
Disallowance u/s 43B as per Income Tax Act, 1961 419.86 318.33
Provision for doubtful deposits 30.14 16.09
Disallowance for forseeable loss as per Income Computation and Disclosure Standards (ICDS )
356.54 -
Unabsorbed depreciation - 1,065.19
Unabsorbed business loss 4,211.56 984.04
Others 11.01 368.78
Total (A) 6,989.77 4,224.40
Deferred tax liability arising on account of (B)
Timing difference between book depreciation and depreciation as per Income Tax Act, 1961
2,566.38 2,739.27
Total (B) 2,566.38 2,739.27
Deferred tax assets (A-B) 4,423.39 1,485.13
Summary of significant accounting policies and other explanatory information to the consolidated financial
statements as at and for the year ended 31 December 2015 (Currency : Indian Rupee in lakhs)
12. Loans and advances
As at 31 December 2015 As at 31 December 2014
Long-term Short-term Long-term Short-term
(Unsecured, considered good unless otherwise stated)
Capital advances 1,254.11 - 1,012.39 -
Security and other deposits - -
- considered good 293.41 1,526.07 253.46 1,975.47
- considered doubtful - 97.55 - 47.33
Receivable from Holding Company (Refer note 35) - 2,081.27 - 1,172.88 Other loans and advances
Advance recoverable in cash or kind
- considered good - 10,504.79 - 2,820.91
Prepaid expenses - 2,368.23 - 1,526.53
Loans and advances to employees - 20.15 - 16.95
Balances with statutory / government authorities 15,762.74 - 12,574.43 -
Advance income tax (net of provisions for tax) 4,857.25 - 2,755.49 - 22,167.51 16,598.06 16,595.77 7,560.07
Less : Provision for doubtful deposits - (97.55) - (47.33) 22,167.51 16,500.51 16,595.77 7,512.74
246
13. Other non-current assets
As at 31 December 2015
As at 31 December 2014
Non-current bank balances (refer note 17) 16.90 22.00
Interest accrued but not due 6.89 5.54
23.79 27.54
15. Inventories
As at 31 December 2015
As at 31 December 2014
Construction materials 15,242.35 15,920.72
Tools and equipment 5,653.67 5,152.54
Machinery spares 1,826.66 1,817.74
Unbilled work in progress (Refer note 36 and 37) 94,815.39 90,234.22
1,17,538.07 1,13,125.22
14. Current investments
As at 31 December 2015 As at 31 December 2014
No. of Shares Book Value No. of Shares Book Value
(Non-trade, unquoted at lower of cost and fair value)
Investments in equity shares
AVR Infra Private Limited (Face value of H10 each) 2,600 0.26 2,600 0.26
0.26 0.26
Summary of significant accounting policies and other explanatory information to the consolidated financial
statements as at and for the year ended 31 December 2015 (Currency : Indian Rupee in lakhs)
16. Trade receivables (Refer notes 36 and 37)
As at 31 December 2015 As at 31 December 2014
Long-term Short-term Long-term Short-term
(unsecured, considered good unless otherwise stated)
Trade receivables outstanding for more than six months
- Considered good * 2,863.37 19,330.29 2,863.37 24,565.38
- Considered doubtful - 4,237.73 - 2,870.08
2,863.37 23,568.02 2,863.37 27,435.46
Less: Provision for doubtful debts - (4,237.73) - (2,870.08)
2,863.37 19,330.29 2,863.37 24,565.38
Other debts ** - 11,586.88 - 16,720.43 2,863.37 30,917.17 2,863.37 41,285.81
Notes :
* Includes retention money 571.41 11,040.01 571.41 8,095.83
** Includes retention money - 4,033.27 - 3,410.04
247
17. Cash and bank balances
As at 31 December 2015 As at 31 December 2014
Non-current Current Non-current Current
Cash and cash equivalents
Cash in hand - 157.51 - 194.75
Balance with banks -
- current accounts - 3,600.56 - 1,924.98
- unpaid dividend bank accounts - 6.17 - 7.44
Bank deposits with original maturity not more than 3 months 4,618.50 368.16 - 8,382.74 - 2,495.33
Other bank balances
Deposits with maturity of more than 3 months but less than 12 months *
- 6,377.52 - 222.87
Bank deposits with maturity of more than 12 months ** 16.90 - 22.00 - 16.90 14,760.26 22.00 2,718.20
Less : Amounts disclosed as Other non-current assets (Refer note 13)
(16.90) - (22.00) -
- 14,760.26 - 2,718.20
* Includes H241.65 lakhs (previous year H222.87 lakhs) earmarked against bank guarantees taken by the Company and H10lakhs (previous year H Nil) placed as earnest money deposit
** Placed as earnest money deposit
18. Other current assets
As at 31 December 2015
As at 31 December 2014
Interest accrued but not due 119.10 15.75
119.10 15.75
Summary of significant accounting policies and other explanatory information to the consolidated financial
statements as at and for the year ended 31 December 2015 (Currency : Indian Rupee in lakhs)
19. Other operating income
Year ended31 December 2015
Year ended 31 December 2014
Service income from unincorporated joint ventures 224.87 652.29
224.87 652.29
248
20. Other Income
Year ended31 December 2015
Year ended 31 December 2014
Interest- on bank deposits 408.15 131.40 - on income tax refund 52.55 320.88 - from customer on settlement 81.01 222.89 - others 41.43 18.30
Other non operating income:- Profit on sale of fixed assets (net) 815.02 - - Exchange gain (net) 20.62 - - Sundry balances written back 235.81 132.13 - Excess provisions of prior year written back - 176.95- Insurance claim 175.49 - - Miscellaneous income 387.33 846.92
2,217.41 1,849.47
21. Employee benefits expense
Year ended31 December 2015
Year ended 31 December 2014
Salaries and wages 19,993.94 17,648.07 Contribution to gratuity (Refer note 31) 725.28 359.44 Contribution to provident and other funds (Refer note 31) 1,386.83 1,278.92 Staff welfare expenses 134.64 77.46
22,240.69 19,363.89
22. Finance costsYear ended
31 December 2015Year ended
31 December 2014Interest expenses
- Cash credit facilities 6,411.07 9,069.73- Long term loan 1,000.77 1,149.08 - Commercial papers 1,386.18 - - Advances from customers 1,814.37 940.89 - Letter of credit 378.44 155.07 - Buyer's credit 5.15 17.84 - Others 123.09 118.13
Other borrowing costs- Applicable net loss on foreign currency transactions and transition 55.71 204.93 - Bank charges and guarantee commission 2,596.58 1,894.70
13,771.36 13,550.37
Summary of significant accounting policies and other explanatory information to the consolidated financial
statements as at and for the year ended 31 December 2015 (Currency : Indian Rupee in lakhs)
249
23. Other expense
Year ended31 December 2015
Year ended 31 December 2014
Plant hire expenses 5,995.35 4,848.76
Power and fuel 7,097.04 7,057.98
Sales tax on works contracts 8,146.71 5,396.99
Travelling expenses 926.17 890.64
Tools and equipment 1,740.02 1,025.41
Foreseeable loss 231.96 1,329.73
Site transport and conveyance 2,559.47 2,856.71
Repairs and maintenance:
- Plant and machinery 646.13 528.07
- Others 323.81 196.91
Insurance 1,323.74 849.59
Professional fees 2,501.78 2,356.09
Rent (Refer note 41) 2,759.49 2,709.79
Consumption of spares 1,821.82 1,287.58
Security charges 1,308.67 990.34
Temporary site installations 834.75 449.19
Postage, telephone and telegram 214.01 200.27
Auditor remuneration (Refer note 26) 84.40 75.46
Provision for doubtful debts (Refer note 27) 1,367.65 673.69
Provision for doubtful deposits 50.22 47.33
Rates and taxes 86.14 135.76
Water charges 704.61 370.22
Printing and stationery 161.50 137.01
Infotech expenses 294.52 200.66
Service tax 9,794.14 1,300.51
Labour cess 1,851.04 876.66
Exchange loss (net) - 114.74
Directors’ sitting fees 6.05 2.75
CSR expenses 19.74 12.87
Loss on sale of fixed assets (net) - 20.03
Miscellaneous expenses 2,311.47 1,829.18 55,162.40 38,770.92
24. Exceptional items
Year ended31 December 2015
Year ended 31 December 2014
a) Loss on account of one time settlement with National Highway Authorityof India [Refer note 38(a)]
(12,397.19) -
b) Profit for effect of change in depreciation policy from WDV to SLM[Refer note 38(b)]
- 9,553.25
(12,397.19) 9,553.25
Summary of significant accounting policies and other explanatory information to the consolidated financial
statements as at and for the year ended 31 December 2015 (Currency : Indian Rupee in lakhs)
250
25. Earnings per share
Year ended31 December 2015
Year ended 31 December 2014
Weighted average number of equity shares outstanding during the year 15,51,57,900 12,81,99,000
Add:- Dilutive effect - -
Weighted average number of equity shares used to compute diluted earning/(loss) per share
15,51,57,900 12,81,99,000
Net (loss) / profit after tax attributable to equity shareholders (5,930.76) 1,941.43
Earning per share :
Basic and diluted (3.82) 1.51
26. Auditor remuneration (including service tax)
Year ended31 December 2015
Year ended 31 December 2014
Audit fee 32.64 28.93
Tax audit fee 20.32 14.71
Limited review 27.48 24.73
Certification 2.97 5.96
Out-of-pocket expenses 0.99 1.13
84.40 75.46
27. Provision for doubtful debts
Year ended31 December 2015
Year ended 31 December 2014
Bad debts written off during the year - 17.36
Add: Provision for doubtful debts at the end of year 4,237.73 2,870.08
Less: Provision for doubtful debts at the beginning of year 2,870.08 2,213.75
1,367.65 673.69
28. Commitment*
Year ended31 December 2015
Year ended 31 December 2014
Estimated amount of contracts remaining to be executed on capital accounts and not provided for (net of advances)
417.32 1,977.92
(With effect from record date 24 August 2015, the face value of the Company’s shares have been sub-divided from H10 per share to H1 per share. For the previous year, the equity shares and basic and diluted Earnings per share has been presented to reflect for the split in accordance with Accounting Standard 20 - Earning Per Share)
Summary of significant accounting policies and other explanatory information to the consolidated financial
statements as at and for the year ended 31 December 2015 (Currency : Indian Rupee in lakhs)
251
29. Contingent Liabilities*
Year ended31 December 2015
Year ended 31 December 2014
a) Guarantees/Letter of credits given by banks in respect of contractingcommitments in the normal course of business
35,140.25 24,943.33
b) Corporate Guarantee given to bank on behalf of Joint Ventures 48,651.00 51,000.00
c) The Company has a number of claims on customers for price escalationand / or variation in contract work. In certain cases which are currentlyunder arbitration, the customers have raised counter-claims.The Company has received legal advice that none of the counter-claimsare legally tenable. Accordingly no provision is considered necessary inrespect of these counter claims.
12,016.77 12,016.77
d) Sales Tax matters pending in appeals 3,901.35 3,738.36
e) Income Tax matters pending in appeal 1,607.91 1,454.27
f) Excise matter pending in appeal 52.00 52.00
g) Entry tax matter pending in appeal - 335.15
* It is not practicable for the company to estimate the timings of cash outflows, if any, in respect of the above pendingresolution of the respective proceedings. The Company does not expect any reimbursements in respect of the abovecontingent liabilities other than stated therein above. Future cash outflows in respect of the above are determinable onlyon receipt of judgments/ decisions pending with various forums/ authorities. The Company does not expect any outflowof economic resources in respect of the above and therefore no provision is made in respect thereof.
30. Particulars of derivative instruments and unhedged foreign currency exposures at the reporting date:
a) Derivative outstanding at the reporting date:
Buyers credit, Trade payables and Acceptances
As at 31 December 2015 As at 31 December 2014
Foreign Currency
Exchange Rate
INR in lakhs
Foreign Currency
Exchange Rate
INR in lakhs
US Dollar Exposure - - - 9,45,307 63.80 603.11
EURO Exposure - - - 2,83,381 77.84 220.58
Total - 823.69
b) Unhedged foreign currency exposures at the reporting date:
Buyers credit, Trade payables and Acceptances
As at 31 December 2015 As at 31 December 2014
Foreign Currency
Exchange Rate
INR in lakhs
Foreign Currency
Exchange Rate
INR in lakhs
US Dollar Exposure 14,526 66.60 9.67 - - -
EURO Exposure 13,811 99.41 13.73 - - -
Total 23.40 -
Summary of significant accounting policies and other explanatory information to the consolidated financial
statements as at and for the year ended 31 December 2015 (Currency : Indian Rupee in lakhs)
252
31. Employee benefits
i) GratuityThe following tables summarise the components of net benefit expense recognised in the statement of profit and lossand the funded status and amounts recognised in the balance sheet for the respective plans.
31 December 2015 31 December 2014
The amount recognised in the statement of profit and loss :
Current Service Cost 253.12 214.41
Interest Cost 161.75 157.43
Expected return on plan assets (119.56) (109.59)
Net actuarial loss for the year 429.97 97.19 Net benefit expense 725.28 359.44
The amount recognised in the balance sheet :
Defined benefit obligation 2,684.44 2,160.83
Fair value of plan assets 1,366.51 1,367.21 Plan liability 1,317.93 793.62
Changes in the present value of the defined benefit obligations :
Defined benefit obligation at beginning of the year 2,160.83 1,759.84
Current service cost 253.12 214.41
Interest cost 161.75 157.43
Actuarial loss 387.26 145.25
Benefit paid (278.52) (116.10)Present value of defined benefit obligation at end of year 2,684.44 2,160.83
Changes in the fair value of the plan assets of the gratuity plan :
Plan assets at beginning of the period 1,367.21 1,225.67
Expected return on Plan Assets 119.55 109.59
Contributions by employer 200.00 100.00
Benefit Paid (277.54) (116.10)
Actuarial (loss)/gain on plan assets (42.71) 48.05 Fair value of plan assets at end of the year 1,366.51 1,367.21
The amount of defined benefit obligation, plan assets, the defecit thereof and the experience adjustments on plan assets and plan liabilities for the current and previous four years are as follows:
2015 2014 2013 2012 2011
Defined Benefit Obligation 2,684.44 2,160.83 1,759.84 1,714.10 1,473.32
Plan Assets 1,366.51 1,367.21 1,225.67 1,216.84 1,081.14
Deficit (1,317.93) (793.62) (534.17) (497.26) (392.18)
Experience adjustments on plan assets (42.71) 48.05 (82.26) 71.78 (108.93)
Experience adjustment on plan liabilities (387.26) (145.25) 189.33 (118.31) (27.20)
The gratuity fund is invested in a Group Gratuity policy invested with the Life Insurance Corporation of India and Birla Sunlife Insurance. The fair value of plan assets with Life Insurance Corporation of India and Birla Sunlife Insurance as at 31 December 2015 are H0.16 lakhs (31 December 2014 - H0.15 lakhs) and H1,366.35 lakhs (31 December 2014 - H1,367.06 lakhs) respectively. The management understands that the assets in these portfolios are well diversified and as such the long term return thereon is expected to be higher than the rate of return on Government Bonds.
Summary of significant accounting policies and other explanatory information to the consolidated financial
statements as at and for the year ended 31 December 2015 (Currency : Indian Rupee in lakhs)
253
31. Employee benefits (Contd..)
The overall expected rate of return on assets is determined based on the market prices prevailing on that date, applicable to the period over which the obligation is to be settled.
31 December 2015 31 December 2014
The principal assumptions used in determining the gratuity obligations :
Discount rate 8.00% 8.00%
Expected rate of return on plan assets 9.00% 9.00%
Salary esclation rate 5.00% 4.50%
Withdrawal rates Upto age 44 - 5% 45 years & above -2.5%
Upto age 44 - 2% 45 years & above - 1%
The estimates of future salary increases, considered in actuarial valuation take account of inflation, seniority, promotion and other relevant factors such as supply and demand in the employment market.
ii) The Company’s expense for the superannuation and provident fund aggregates H1,386.83 lakhs during the year (31December 2014 - H1,278.92 lakhs)
‘Provident fund for certain eligible employees is managed by the Company through trust “ The Provident Fund of ITDCementation India Limited”, In line with the Provident Fund and Miscellaneous Provision Act, 1952. The plan guaranteesinterest at the rate notified by the Provident Fund Authorities. The contribution by the employer and employee togetherwith the interest accumulated thereon are payable to employees at the time of separation from the Company or retirement, whichever is earlier. The benefits vests immediately on rendering of the services by the employee.In terms of the guidance note issued by the Accounting Standards Board (ASB) of the Institute of Chartered Accountantsof India for measurement of provident fund liabilities, the valuer has certified that there is no shortfall as at 31 December 2015 and 31 December 2014.
iii) The liability for leave entitlement and compensated absences as at year end is H794.98 lakhs (31 December 2014 :H676.43 lakhs).
Summary of significant accounting policies and other explanatory information to the consolidated financial
statements as at and for the year ended 31 December 2015 (Currency : Indian Rupee in lakhs)
33. SubsidiaryThe following Subsidiary Company (incorporated in India) has been consolidated in the consolidated financial statementapplying Accounting Standard (AS) - 21:
Name of the Subsidiary
As at 31 December 2015 As at 31 December 2014Proportion of
Ownership Interest
Voting Power Proportion of Ownership
Interest
Voting Power
ITD Cementation Projects India Limited 100% 100% 100% 100%
32. Segment reportingThe activities of the Company comprises of only one business segment viz Construction. The Company operates inonly one geographical segment viz India. Hence the Company’s financial statements also represents the segmentalinformation.
254
34. Unincorporated Jointly Controlled EntitiesThe following unincorporated Jointly Controlled Entities have been consolidated applying Accounting Standard (AS) - 27(“Financial Reporting of Interests in Joint Ventures”).
Name of the Joint Venture% of Participation as at 31 December
2015
% of Participation as at 31 December
2014
ITD Cemindia JV 80% 80%
ITD - ITD Cem JV 49% 49%
ITD - ITDCem JV (Consortium of ITD - ITD Cementation) 40% 40%
ITD-Cem Maytas Consortium 95% 95%All the above are unincorporated jointly controlled entities in India
Summary of significant accounting policies and other explanatory information to the consolidated financial
statements as at and for the year ended 31 December 2015 (Currency : Indian Rupee in lakhs)
The proportionate share of assets, liabilities, income and expenditure of the unincorporated Jointly Controlled Entities, consolidated in the accounts is tabulated hereunder:
Particulars As at 31 December 2015 As at 31 December 2014
Non-current assets
Net Block 5,585.58 5,395.62Capital work-in-progress 70.37 -Deferred tax assets 801.19 820.93
Current Assets :
Inventories 17,807.59 17,181.30Trade receivables 4,800.88 7,828.00Cash and bank balances 668.34 1,037.61Loans and advances 6,655.19 3,460.84
Total Current Assets (A) 29,932.00 29,507.75Current Liabilities (B) 16,054.38 15,028.02Net Current Assets (A-B) 13,877.62 14,479.73Total Assets 20,334.76 20,696.28Liabilities
Loan Funds :Secured loans 11,238.80 9,455.07
Reserves and surplus
Opening balance of retained earnings 5,909.11 5,398.58Add : (Loss) / profit for the year (603.83) 510.53Add : Share of brought forward loss and exceptional loss on one time settlement with NHAI adjusted against advances to joint venture
1,297.14 -
6,602.42 5,909.11Total Liabilities 17,841.22 15,364.18Revenue
Contract revenue 33,261.33 36,001.47Other income 533.19 1,160.01
Total revenue 33,794.52 37,161.48
255
Summary of significant accounting policies and other explanatory information to the consolidated financial
statements as at and for the year ended 31 December 2015 (Currency : Indian Rupee in lakhs)
Particulars As at 31 December 2015 As at 31 December 2014
Expenses:
Site and administration expenses 29,629.98 33,874.09Finance costs 2,264.59 1,554.81
Depreciation 1,179.75 1,328.18Total expenses 33,074.32 36,757.08Profit before exceptional item and tax 720.20 404.40
Exceptional item 907.09 -Profit after exceptional item and tax (186.89) 404.40
Provision for tax (397.20) 15.94Deferred tax credit (19.74) (122.07)
(Loss) / profit after tax (603.83) 510.53Capital commitment 107.04 -Contingent liabilities 2,341.86 2,519.28
34. Unincorporated Jointly Controlled Entities (Contd..)
35. Related Party DisclosuresA Names of related parties and description of relationship
Enterprise where control exists - Holding CompanyItalian-Thai Development Public Company Limited
B Other related parties with whom the Company had transactionsi) Key management personnel (KMP)
Mr. Adun Saraban – Managing DirectorMr. S. Ramnath – Chief Financial OfficerMr. R. C. Daga - Company Secretary
ii) Fellow subsidiaryFirst Dhaka Elevated Expressway (FDEE) Company Limited
b) Transactions with related parties for the year are as follows:
Transaction during the yearHolding
CompanyKMP Fellow
subsidiaryContract Revenue
Italian-Thai Development Public Company Limited - - -
(13.95) (-) (-) Dividend paid
Italian-Thai Development Public Company Limited - - -
(80.11) (-) (-) Sale of fixed assets
First Dhaka Elevated Expressway (FDEE) Company Limited - - 78.87
(-) (-) (-) Remuneration
Mr. Adun Saraban - 94.56 -
(-) (81.80) (-)
Mr. S. Ramnath - 52.27 -
(-) (48.36) (-)
Mr. R. C. Daga - 44.69 -
(-) (42.07) (-) (Figures in bracket represents previous year numbers)
256
35 Related Party Disclosures (Contd..)c) Balances at the year end :
Holding Company Fellow subsidiaryTrade receivables
Italian-Thai Development Public Company Limited 25.89 -
(28.91) (-) Advance receivable in cash or kind
First Dhaka Elevated Expressway (FDEE) Company Limited - 78.87
(-) (-) Loan and Advances
Italian-Thai Development Public Company Limited 2,081.27 -
(1,172.88) (-) (Figures in bracket represents previous year numbers)
Summary of significant accounting policies and other explanatory information to the consolidated financial
statements as at and for the year ended 31 December 2015 (Currency : Indian Rupee in lakhs)
36 Trade receivables and Unbilled Work-in-progress as at 31 December 2015 include amounts aggregating H3,033 lakhs (31 December 2014 - H2,655 lakhs) and H479 lakhs (31 December 2014 - H1,584 lakhs) respectively, which have been outstanding for a substantial period of time . The Company has been actively negotiating for recovery and also pursuing legal action of the balance receivables. In view thereof, management is reasonably confident of their recovery.
37 (a) Long-term trade receivables at 31 December 2015 include variation claims of H309 lakhs (31 December 2014 - H309 lakhs) for which the Company had received an arbitration award in its favour which has subsequently been upheld by the District Court. The customer has challenged this Court Order. However, based on the above arbitration award, Court Order and legal opinion, management is reasonably confident of recovery of these amounts.
(b) Long-term trade receivables and unbilled work-in-progress at 31 December 2015 include H1,140 lakhs (31 December 2014 - H1,140 lakhs ) and H2,756 lakhs (31 December 2014 - H2,756 lakhs) respectively, in respect of a contractwhich has been rescinded by the Company and long-term trade receivables and unbilled work-in-progress as at 31December 2015 includes H1,414 lakhs (31 December 2014 - H1,414 lakhs) and H5,922 lakhs (31 December 2014 -H5,922 lakhs) respectively, in respect of another contract where the Company has received a notice from the customer withdrawing from the Company the balance works to be executed under the contract for which the Company has also issued guarantees aggregating H1,497 lakhs (31 December 2014 - H1,497 lakhs). The Company has made claimsagainst the customer to recover these amounts and has initiated legal action. Based upon legal opinion received,management is reasonably confident of recovery of these amounts of long term trade receivable and unbilled work-in-progress and consequently no changes have been made to the values and classification of these amounts in theconsolidated financial statements.
38 (a) During the year ended 31 December 2015, the Company has signed a definitive agreement with the National Highways Authority of India (NHAI) under which both parties have agreed to settle all awards received, claims under consideration at various forums, pending disputes and amounts outstanding in the Company’s and joint venture’s books of account under trade receivables and unbilled work-in-progress in respect of all the contracts executed by the company and Joint Venture. Pursuant to this settlement the Company including its share in Joint Venture has accounted for the resultant loss on the settlement of H12,397 lakhs which has been disclosed as an exceptional item.
(b) During the year ended 31 December 2014, the Company had, with retrospective effect, changed its method ofproviding depreciation on fixed assets from the ‘Written Down Value’ method to the ‘Straight Line’ method effective1 October 2014. The change in the above accounting policy has resulted in a surplus of H9,553 lakhs relating to thedepreciation already charged upto the period ended 30 September 2014 which has been disclosed as an exceptional item in previous year.
257
Summary of significant accounting policies and other explanatory information to the consolidated financial
statements as at and for the year ended 31 December 2015 (Currency : Indian Rupee in lakhs)
39 Micro and Small EnterprisesThere are no Micro and Small Enterprises, to whom the Company owes dues, which are outstanding for more than 45 days as at 31 December 2015. This information as required to be disclosed under the Micro, Small and Medium Enterprises Development Act, 2006, has been determined to the extent such parties have been identified on the basis of information available with the Company. There is no interest paid or pavable during the year.
40. The disclosures as per provisions of Clauses 38, 39 and 41 of Accounting Standard 7 ‘Construction Contracts’ are asunder:
Year ended31 December 2015
Year ended 31 December 2014
a) Contract revenue recognised as revenue in the period Clause 38 (a) 3,06,870.03 1,71,242.31
b) Aggregate amount of costs incurred and recognised profits up to thereporting date on Contract under progress Clause 39 (a)
9,74,089.03 6,00,087.93
c) Advance received on Contract under progress Clause 39 (b) 46,411.63 35,514.07
d) Retention amounts on Contract under progress Clause 39 ( c) 15,644.69 12,077.28
e) Gross amount due from customers for contract work asan asset Clause 41 (a)
94,815.39 90,234.22
f) Gross amount due to customers for contract work asan liability Clause 41 (b)
2,292.94 951.30
41 Operating leasea) The Company has taken various residential/commercial premises and construction equipment on cancellable operating
lease. These lease agreements are normally renewed on expiry. Rental expenses in the statement of profit and loss forthe year includes lease payments towards premises H2,237.49 lakhs (31 December 2014 - H2,068.90 lakhs).
b) The Company, in addition to above, has taken commercial premises on leases (non-cancellable operating leases). Thefuture minimum lease payments in respect of which as at 31 December 2015 are as follows:
As at 31 December 2015
As at 31 December 2014
Minimum Lease Payments
Payable not later than 1 year 552.00 522.00
Payable later than 1 year and not later than 5 years 230.00 782.00
Payable later than 5 years - -
Total 782.00 1,304.00
These leases have no escalation clauses.
Rental expenses in the statement of profit and loss for the year includes H522.00 lakhs (31 December 2014 - H640.89 lakhs) towards such non-cancellable leases.
c) General descriptions of non-cancellable lease terms :- Lease rentals are charged on the basis of agreed terms.- Assets are taken on lease over a period of 3-5 years.- The Company did not sublease any of its assets and hence did not receive any sub lease payments during the current
or previous year.
258
Summary of significant accounting policies and other explanatory information to the consolidated financial
statements as at and for the year ended 31 December 2015 (Currency : Indian Rupee in lakhs)
42 The tax year for the Company being the year ending 31 March, the provision for taxation for the year is the aggregate of the provision made for the three months ended 31 March 2015 and the provision based on the figures for the remaining nine months up to 31 December 2015, the ultimate tax liability of which will be determined on the basis of the figures for the period 1 April 2015 to 31 March 2016.
43 Previous year figures have been regrouped or reclassified, to conform to the current year’s presentation whereever considered necessary.
For Walker Chandiok & Co LLP For and on behalf of the Board of Directors(formerly Walker, Chandiok & Co)Chartered AccountantsFirm Registration No. 001076N/N500013
Sudhir N. Pillai Adun Saraban P. ChakornbunditPartner Managing Director DirectorMembership No: 105782 DIN No.01312769 DIN No.00254312
S. Ramnath R. C. DagaChief Financial Officer Company SecretaryFCA No. 030663 ACS No.576
Place : Mumbai Place : MumbaiDate: 24 February 2016 Date: 24 February 2016
259
ITD Cementation India Limited
Independent Auditors’ Report
To
The Board of Directors of
ITD Cementation India Limited
1. We have audited the accompanying consolidated financial
statements of ITD Cementation India Limited (“the Company”),
its subsidiary and joint ventures (hereinafter collectively referred
to as the “Group”), which comprise the Consolidated Balance
Sheet as at 31 December 2014, the Consolidated Statement
of Profit and Loss and Consolidated Cash Flow Statement for
the year then ended, and a summary of significant accounting
policies and other explanatory information.
Management’s Responsibility for the Financial Statements
2. Management is responsible for the preparation of these
consolidated financial statements that give a true and fair view
of the consolidated financial position, consolidated financial
performance and consolidated cash flows of the Group in
accordance with accounting principles generally accepted in
India. This responsibility includes the design, implementation and
maintenance of internal control relevant to the preparation and
presentation of the consolidated financial statements that give
a true and fair view and are free from material misstatement,
whether due to fraud or error.
Auditors’ Responsibility
3. Our responsibility is to express an opinion on these consolidated
financial statements based on our audit. We conducted our
audit in accordance with the Standards on Auditing issued by
the Institute of Chartered Accountants of India. Those Standards
require that we comply with ethical requirements and plan
and perform the audit to obtain reasonable assurance about
whether the consolidated financial statements are free from
material misstatement.
4. An audit involves performing procedures to obtain audit
evidence about the amounts and disclosures in the consolidated
financial statements. The procedures selected depend on the
auditors’ judgment, including the assessment of the risks of
material misstatement of the consolidated financial statements,
whether due to fraud or error. In making those risk assessments,
the auditor considers internal control relevant to the Company’s
preparation and presentation of the consolidated financial
statements that give a true and fair view in order to design audit
procedures that are appropriate in the circumstances, but not
for the purpose of expressing an opinion on the effectiveness
of the Company’s internal control. An audit also includes
evaluating the appropriateness of accounting policies used
and the reasonableness of the accounting estimates made by
management, as well as evaluating the overall presentation of
the consolidated financial statements.
5. We believe that the audit evidence we have obtained is
sufficient and appropriate to provide a basis for our qualified
audit opinion.
Basis for Qualified Opinion6. As stated in Note 35 to the Financials Statements, the company’s
trade receivables and unbilled work in progress as at 31 December,
2014 include amounts aggregating H2,655 lakhs and H1,584 lakhs
respectively, being considered as good and fully recoverable by the
management. These amounts are presently under negotiation with
the customers. In the absence of external balance confirmations
from the customers or other alternative audit evidence to corroborate
management’s assessment of recoverability of these balances and
having regard to the age of these receivables, we are unable to
comment on the extent to which these balances are recoverable
and the consequential impact, if any, on the accompanying financial
statements.
Qualified Opinion7. In our opinion and to the best of our information and according
to the explanations given to us except for the possible effects of
the matter described in the Basis for Qualified Opinion paragraph
the consolidated financial statements give a true and fair view in
conformity with the accounting principles generally accepted in
India:
i) in the case of the Consolidated Balance Sheet, of the state
of affairs of the Group as at 31 December 2014;
ii) in the case of the Consolidated Statement of Profit and
Loss, of the profit for the year ended on that date; and
iii) in the case of the Consolidated Cash Flow Statement, of
the cash flows for the year ended on that date.
Emphasis of Matter
8. We draw attention to Note 36 to the consolidated financial
statements regarding long-term trade receivables, trade
receivables and unbilled work in progress aggregating to H2,863
lakhs (31 December 2013: H Nil), H8,521 lakhs (31 December
2013: H11,099 lakhs) and H25,467 lakhs (31 December 2013:
H25,507 lakhs) respectively, outstanding as at 31 December 2014,
representing various claims recognised during the earlier period
based on the terms and conditions implicit in the contracts.
These claims being technical in nature and being subject
matter of arbitration/ litigation, the Company has assessed the
recoverability of these claims based on recommendation of
Dispute Resolution Board, awards received from Arbitration
Tribunal, High Court orders received and legal opinion from
260
Annual Report 2014
an independent counsel. On the basis of such assessment,
management is of the opinion that the claims are tenable and
would be realized in full and accordingly no adjustments have
been made in the Financial Statement. Our opinion is not
qualified in respect of these matters.
9. We draw attention to Note 37 to the consolidated financial
statements which describes the uncertainty related to the
recoverability of group’s share of trade receivables and unbilled
work in progress aggregating to H2,076 lakhs and H2,394 lakhs,
respectively, in ITD Cemindia JV, company’s joint venture,
outstanding as at 31 December 2014, representing various claims
recognized during the earlier periods based on the terms and
conditions implicit in the contracts. These claims being technical
in nature and being subject matter of arbitration/ litigation, the
management of the group has assessed the recoverability of
these dues based on recommendation of Dispute Resolution
Board, awards received from Arbitration Tribunal and legal
opinion from an independent counsel. Pending the ultimate
outcome of these matters which is presently unascertainable, no
adjustments have been made in the accompanying consolidated
financial statements. Our opinion is not qualified in respect of
this matter.
Other Matters
10. We did not audit the financial statements of a subsidiary
included in the consolidated financial statements, whose financial
statements reflect total assets (after eliminating intra-group
transactions) of H4.90 lakhs as at 31 December 2014; total
revenues (after eliminating intra-group transactions) of H0.30
lakhs and net cash flows aggregating to H0.67 lakhs for the year
then ended. These financial statements have been audited by
other auditor whose audit report has been furnished to us by
the management, and our audit opinion on the consolidated
financial statements of the Group for the year then ended to the
extent they relate to the financial statements not audited by us
as stated in this paragraph is based solely on the audit report of
the other auditor. Our opinion is not qualified in respect of this
matter.
For Walker, Chandiok & Co LLP
(Formerly Walker, Chandiok & Co.)
Chartered Accountants
Firm Registration No.: 001076N/N500013
per Amyn Jassani
Partner
Membership No.: 46447
Mumbai
24 February 2015
261
ITD Cementation India Limited
Consolidated Balance Sheet as at 31 December 2014(Currency : Indian Rupee in lakhs)
NotesAs at
31st December 2014
As at
31st December 2013
EQUITY AND LIABILITIES
Shareholders’ Funds
Share capital 2 1,551.58 1,151.58
Reserves and surplus 3 55,230.22 39,689.74
56,781.80 40,841.32
Non-Current Liabilities
Long-term borrowings 4 4,038.61 1,140.91
Long-term provisions 5 563.24 417.37
4,601.85 1,558.28
Current Liabilities
Short-term borrowings 6 68,119.53 68,522.34
Trade payables 7 41,719.51 29,646.80
Other current liabilities 8 47,135.12 44,305.07
Short-term provisions 9 1,110.97 1,166.89
158,085.13 143,641.10
Total 219,468.78 186,040.70
ASSETS
Non-Current Assets
Fixed Assets
Tangible assets 10 33,525.83 22,356.48
Capital work-in-progress 328.36 672.87
Deferred tax assets 11 1,485.13 2,121.88
Long-term loans and advances 12 16,595.77 15,620.11
Long-term trade receivables 16 2,863.37 -
Other non-current assets 13 27.54 22.00
54,826.00 40,793.34
Current Assets
Current investment 14 0.26 0.26
Inventories 15 113,125.22 95,682.59
Trade receivables 16 41,285.81 40,158.45
Cash and bank balances 17 2,718.20 3,191.82
Short-term loans and advances 12 7,497.54 6,180.96
Other current assets 18 15.75 33.28
164,642.78 145,247.36
Total 219,468.78 186,040.70
Notes 1 to 43 form an integral part of these consolidated financial statements
This is the consolidated balance sheet referred to in our report of even date
For Walker Chandiok & Co LLP For and on behalf of the Board of Directors
(formerly Walker, Chandiok & Co.)
Chartered Accountants
Firm Registration No. 001076N/N500013
Amyn Jassani Adun Saraban P. Chakornbundit
Partner Managing Director Director
Membership No: 46447
S. Ramnath R. C. Daga
Chief Financial Officer Company Secretary
Mumbai Mumbai
24 February 2015 24 February 2015
262
Annual Report 2014
Consolidated Statement of Profit and Loss for the year ended 31 December 2014
(Currency : Indian Rupee in lakhs)
Notes Year ended
31st December 2014
Year ended
31st December 2013
REVENUE
Contract revenue 171,242.31 157,836.53
Other operating income 19 652.29 570.69
Other income 20 1,849.47 3,396.12
Total 173,744.07 161,803.34
EXPENSES
Cost of materials consumed 64,392.02 51,332.05
Sub-contract expense 40,260.28 32,123.64
Employees benefits expense 21 19,363.89 19,229.40
Finance costs 22 13,550.37 12,831.96
Depreciation expense 10 4,270.88 4,422.83
Other expenses 23 38,770.92 39,472.88
Total Expenses 180,608.36 159,412.76
(Loss)/profit before exceptional item & tax (6,864.29) 2,390.58
Exceptional item (Refer note 1 A.1) 9,553.25 -
Profit before tax 2,688.96 2,390.58
Tax expense
Current tax (964.52) (1,833.53)
Less: Minimum alternative tax credit entitlement 720.23 -
Short provision for tax for earlier years 132.69 25.41
Deferred tax (charge)/credit (635.93) 348.45
Net profit for the year 1,941.43 930.91
Earnings per equity share (face value of H10 each) 24
Before exceptional item
Basic and diluted (59.38) 8.08
After exceptional item
Basic and diluted 15.14 8.08
Notes 1 to 43 form an integral part of these consolidated financial statements
This is the consolidated statement of profit and loss referred to in our report of even date
For Walker Chandiok & Co LLP For and on behalf of the Board of Directors
(formerly Walker, Chandiok & Co.)
Chartered Accountants
Firm Registration No. 001076N/N500013
Amyn Jassani Adun Saraban P. Chakornbundit
Partner Managing Director Director
Membership No: 46447
S. Ramnath R. C. Daga
Chief Financial Officer Company Secretary
Mumbai Mumbai
24 February 2015 24 February 2015
263
ITD Cementation India Limited
Consolidated Cash Flow Statement for the year ended 31 December 2014(Currency : Indian Rupee in lakhs)
Year ended
31st December 2014
Year ended
31st December 2013
CASH FLOW FROM OPERATING ACTIVITIES
Net profit before tax 2,688.96 2,390.58
Adjustments for :
Depreciation 4,270.88 4,422.83
Depreciation written back (9,553.25) -
Finance cost 13,550.37 12,831.96
Interest income (149.70) (1,148.76)
Provision for doubtful debts 673.69 678.17
Provision for doubtful advances 47.33 49.56
Loss/(profit) on sale of fixed assets (net) 20.03 (52.77)
Sundry balances written back (132.13) (819.47)
Prior years provision written back (176.95) (883.55)
Operating profit before working capital changes 11,239.23 17,468.55
Adjustment for change in working capital
Increase in Inventories (17,442.63) (348.45)
(Increase)/decrease in Trade receivables (4,664.43) (4,451.68)
(Increase)/decrease) in Loans and advances (4,051.90) (3,053.19)
Increase/(decrease) in Trade payables and other current liabilities 18,662.17 10,233.27
Cash generated from operations 3,742.44 19,848.50
Direct taxes refunds/(paid 621.16 (1,160.94)
Net cash generated from operating activities 4,363.60 18,687.56
CASH FLOW FROM INVESTING ACTIVITIES
Purchase of fixed assets (including capital work in progress) (4,912.77) (5,829.42)
Proceeds from sale of fixed assets 342.37 198.47
Fixed deposit with bank (maturity beyond three months) (222.87) (795.89)
Proceeds from fixed deposit with bank (maturity beyond three months) 795.89 406.71
Interest received 161.69 1,139.80
Net cash used in investing activities (3,835.69) (4,880.33)
264
Annual Report 2014
Consolidated Cash Flow Statement (contd.) for the year ended 31 December 2014(Currency : Indian Rupee in lakhs)
Year ended
31st December 2014
Year ended
31st December 2013
CASH FLOW FROM FINANCING ACTIVITIES
Proceeds from issue of share capital - QIP (net of share issue expenses) 13,999.05 -
Repayment/(proceeds) from short term borrowings (net) (402.81) 5,581.13
Proceeds from long term borrowings 6,841.34 1,020.56
Repayment of long term borrowings (6,857.11) (7,993.94)
Interest paid (13,874.75) (13,023.57)
Dividend paid (114.66) (228.98)
Tax on distributed profits (19.57) (39.14)
Net cash (used in)/generated from financing activities (428.51) (14,683.94)
Net increase/(decrease) in cash and cash equivalents 99.40 (876.71)
Cash and cash equivalents at the beginning of year 2,395.93 3,272.64
Cash and cash equivalents at the end of year 2,495.33 2,395.93
Components of cash and cash equivalents (Refer note 17)
Cash in hand 194.75 164.56
Balance with scheduled banks
- current accounts 1,924.98 1,930.43
- dividend bank accounts 7.44 6.94
- deposits with maturity not more than 3 months 368.16 294.00
2,495.33 2,395.93
Notes :
1. Figures given in brackets indicate cash outflow
2. The consolidated cash flow statement has been prepared under Indirect Method as per the Accounting Standard 3 Cash Flow Statement
issued by the Institute of Chartered Accountants of India.
3. The figures of the previous year have been regrouped/reclassified, where necessary, to conform with the classification of the current
year.
This is the consolidated cash flow statement referred to in our report of even date
For Walker Chandiok & Co LLP For and on behalf of the Board of Directors
(formerly Walker, Chandiok & Co.)
Chartered Accountants
Firm Registration No. 001076N/N500013
Amyn Jassani Adun Saraban P. Chakornbundit
Partner Managing Director Director
Membership No: 46447
S. Ramnath R. C. Daga
Chief Financial Officer Company Secretary
Mumbai Mumbai
24 February 2015 24 February 2015
265
ITD Cementation India Limited
Summary of significant accounting policies and other explanatory information to the consolidated
financial statements for the year ended 31 December 2014
CORPORATE INFORMATION
ITD Cementation India Limited (‘ITD Cem’ or ‘the Company’) was
incorporated in 1978 and is engaged in construction of a wide variety
of structures like maritime structures, mass rapid transport systems
(MRTS), dams & tunnels, airports, highways, bridges & flyovers,
buildings and other foundations and specialist engineering work. The
activities of the Company comprise only one business segment viz
Construction.
I. SUMMARY OF SIGNIFICANT ACCOUNTING POLICIES
A. Basis of Preparation
The consolidated financial statements have been are prepared
to comply in all material respects with the notified accounting
standards by the Companies (Accounting Standards) Rules,
2006, the provisions of the Companies Act, 2013 (to the extent
notified) and the Companies Act, 1956 (to the extent applicable)
and guidelines issued by the Securities and Exchange Board of
India (SEBI). The financial statements are prepared under the
historical cost convention, on an accrual basis of accounting. The
accounting policies applied are consistent with those used in the
previous year.
The accounting policies adopted in the preparation of financial
statement are consistent with those of previous year except for
the change in accounting policy of the Company as explained
below.
A.1 Summary of change in accounting policy
Upto the period ended 30 September 2014, the Company had
been accounting for depreciation on fixed assets based on written
down value method. Effective 1 October 2014, the Company
has with retrospective effect changed its method of providing
depreciation on fixed assets from the ‘Written Down Value’
method to the ‘Straight Line’ method. Management believes that
this change will result in more appropriate presentation and will
give a systematic basis of depreciation charge, representative of
the time pattern in which the economic benefits will be derived
from the use of these assets. The Company has also carried out
a technical evaluation to assess the revised useful life of fixed
assets. The change in the above accounting policy has resulted
in a surplus of H9,553.25 lakhs relating to the depreciation
already charged upto the period ended 30 September 2014
which has been disclosed as an exceptional item. Had the
Company continued to use the earlier method of depreciation,
the depreciation expense for the current year would have been
higher by H192.49 lakhs.
B. Principles of Consolidation
The consolidated financial statements relate to the Company,
its subsidiary company, and its unincorporated Joint Ventures in
the form of Jointly Controlled Entities (collectively referred to
as the ‘Group’). The consolidated financial statements have been
prepared on the following basis:
i. The financial statements of the company, its subsidiary
company have been consolidated on a line by line basis
by adding together the book values of like items of assets,
liabilities, income and expenses, after fully eliminating intra-
group balances and intra-group transactions resulting in
unrealized profit or unrealized cash losses in accordance
with Accounting Standard (AS) - 21 “Consolidated Financial
Statements” notified by the Companies (Accounting
Standards) Rules, 2006, (as amended).
ii. The Interests in Joint Ventures which are in the nature of
jointly controlled entities have been consolidated by using
the proportionate consolidation method on a line by line
basis by adding together the book values of like items of
assets, liabilities, income and expenses, after eliminating
intra-group balances and intra-group transactions resulting
in group unrealized profit or unrealized cash losses as per
the Accounting Standard (AS) 27 “Financial Reporting
of Interests in Joint Ventures” notified by the Companies
(Accounting Standards) Rules, 2006, (as amended).
iii. Consolidated financial statements are prepared using
uniform policies for like transaction and other events in
similar circumstances and are presented, to the extent
possible, in the same manner as the Company’s separate
financial statements.
iv. Notes to the consolidated financial statements, represents
notes involving items which are considered material and
are accordingly duly disclosed. Materiality for the purpose
is assessed in relation to the information contained in the
consolidated financial statement. Further, additional statutory
information disclosed in separate financial statements of the
subsidiary and/or a parent having no bearing on the true
and fair view of the consolidated financial statement has
not been disclosed in the consolidated financial statements.
v. The difference between the cost to the Group of investment
in subsidiary and joint ventures and the proportionate
share in the equity of the investee company as at the date
of the acquisition of stake is recognized in the consolidated
financial statements as goodwill or capital reserve, as the
case may be. Goodwill arising on consolidation is tested for
impairment annually.
C. Accounting estimates
The preparation of the financial statements in conformity with
generally accepted accounting principles requires management
to make estimates and assumptions that affect the reported
amounts of assets and liabilities and disclosure of contingent
liabilities as at the date of financial statements and the results of
266
Annual Report 2014
Summary of significant accounting policies and other explanatory information to the consolidated
financial statements for the year ended 31 December 2014
operation during the reported period. Although these estimates
are based upon management’s best knowledge of current events
and actions, actual results could differ from these estimates.
D. Fixed assets
Fixed assets are stated at cost, less accumulated depreciation and
impairment losses, if any. Cost comprises the purchase price and
any attributable cost of bringing the asset to its working condition
for its intended use. Borrowing costs relating to acquisition of
fixed assets which takes substantial period of time to get ready
for its intended use are also included to the extent they relate to
the period till such assets are ready to be put to use.
E. Depreciation on tangible fixed assets
(i) Depreciation was provided as per the straight-line method
for assets acquired up to 31 March 1993 and as per the
written-down value method for assets acquired on or after
1 April 1993 using the rates prescribed under Schedule XIV
of Companies Act 1956.
Effective 1 October 2014, method of depreciation on
fixed assets is changed from written down value to straight
line method (as explained in A.1above) using the rates
prescribed under the Schedule XIV to the Companies Act,
1956. However in respect of the following asset categories,
depreciation is provided at higher rates in line with their
estimated useful life.
Tangible Assets Rate of Depreciation (% p.a.)
i) Plant and Machinery
a) Drilling machines,
demolition & cutting tools
8.33
b) Pumps, Ventilation Fans 8.33
c) Mining Cars, Mucking units 8.33
d) Other minor plant &
equipment of construction
activity
8.33
ii) Office Equipment 20.00
iii) Furniture and Fixtures 10.00
(ii) In case of Joint Ventures, depreciation on fixed assets is
provided on straight-line method at the rates determined
as per the useful lives of the respective assets and the life of
the project.
(iii) Leasehold improvements are amortised over the lease
period or useful life whichever is lower.
(iv) Depreciation for additions to/deductions from, owned
assets is calculated pro rata from/to the month of additions/
deductions.
(v) Individual assets costing less than H5,000 are depreciated in
full in the year they are put to use.
F. Impairment
The carrying amounts of the Company’s assets are reviewed at
each balance sheet date if there is any indication of impairment
based on internal/external factors. An impairment loss is
recognized whenever the carrying amount of an asset exceeds
its recoverable amount. The recoverable amount is the greater
of the assets net selling price and its value in use. Impairment
loss is recognized in the Statement of Profit and Loss or against
revaluation surplus where applicable beyond the carrying value
that would have prevailed by charging usual depreciation if there
was no impairment.
A previously recognized impairment loss is increased or reversed
depending on changes in circumstances. However the carrying
value after reversal is not increased beyond the carrying value
that would have prevailed by charging usual depreciation if there
was no impairment.
G. Investments
Long term investments are stated at cost and diminution
in carrying amount, other than temporary, is written down/
provided for. Investments in integrated Joint Ventures are carried
at cost of net of adjustments for Company’s share in profits or
losses as recognised. Investments that are readily realisable and
intended to be held for not more than a year are classified as
current investments. Current investments are carried at lower of
cost and fair value determined on an individual investment basis.
H. Inventories
Construction materials are valued at cost. Identified direct
materials remaining on completion of contract are valued at
their estimated scrap value. Cost is determined on a first-in,
first-out method and comprises the purchase price including
duties and taxes (other than those subsequently recoverable by
the enterprise from the taxing authorities).
Tools and equipment are stated at cost less the amount amortised.
Tools and equipment are amortised over their estimated useful
lives ranging from 3 to 10 years. Cost is determined by the
weighted average method.
Machinery spares that are of regular use are charged to the
statement of profit and loss as and when consumed.
Unbilled work in progress: Work done remaining to be certified/
billed as unbilled work in progress provided it is probable that
they will be recovered in the accounts. The same is valued at the
realizable value.
I. Revenue recognition
i. On contracts
Revenue from construction contracts is recognised on
the basis of percentage completion method. The stage of
completion of a contract is determined by the proportion
267
ITD Cementation India Limited
that contract costs incurred for work performed upto the
reporting date bear to the estimated total contract costs.
Amounts recoverable in respect of the price and other
escalation, bonus claims adjudication and variation in
contract work required for performance of the contract to
the extent that it is probable that they will result in revenue.
In addition, if it is expected that the contract will make
a loss, the estimated loss is provided for in the books of
account.
Contractual liquidated damages, payable for delays in
completion of contract work or for other causes, are
accounted for as costs when such delays and causes are
attributable to the Company or when deducted by the
client.
ii. On insurance claims
Insurance claims are recognized as income based on
certainty of receipt.
iii. Management Fee
Management Fee income is recognized based on the
contractual terms with the parties.
J. Advances from customers, progress payments and retention
Advances received from customers in respect of contracts are
treated as liabilities and adjusted against progress billing as per
terms of the contract.
Progress payments received are adjusted against amount
receivable from customers in respect of the contract work
performed.
Amounts retained by the customers until the satisfactory
completion of the contracts are recognised as receivables.
Where such retention has been released by customers against
submission of bank guarantees, the amount so released is
adjusted against receivable from customers and the value of
bank guarantees is disclosed as a contingent liability.
K. Foreign currency transactions
i. Initial Recognition
Foreign currency transactions are recorded in the reporting
currency, by applying to the foreign currency amount the
exchange rate between the reporting currency and the
foreign currency at the date of the transaction.
ii. Conversion
Foreign currency monetary items are reported using the
closing rate. Non monetary items which are carried in
terms of historical cost denominated in a foreign currency
are reported using the exchange rate at the date of the
transaction.
iii. Exchange Differences
Exchange differences arising on the settlement of monetary
items or on reporting company’s monetary items at rates
different from those at which they were initially recorded
during the year, or reported in previous financial statements,
are recognized as income or as expenses in the year in
which they arise.
iv. Forward exchange contracts not intended for trading or
speculation purposes
The premium or discount arising at the inception of
forward exchange contracts is amortized as expense or
income over the life of the contract. Exchange differences
on such contracts are recognized in the statement of profit
and loss in the year in which the exchange rates change.
Any profit or loss arising on cancellation or renewal of
forward exchange contract is recognized as income or as
expense for the year.
L. Retirement and other employee benefits
i. Defined benefit plan
In terms of the Guidance on implementing Accounting
Standard (AS) 15 - Employee Benefits, issued by the
Accounting Standards Board of the Institute of Chartered
Accountants of India, the Provident Fund set up by the
company is treated as a defined benefit plan. This is
administered through trusts of the company and the
company has no further obligation beyond making the
contributions. The Company has to meet the interest
shortfall, if any. However, as at the year end, no shortfall
remains provided for. Further, the pattern of investments
for investible funds is as prescribed by the Government.
Accordingly, other related disclosures in respect of
provident fund have not been made.
Further company has defined benefit plans for post-
employment benefits in the form of Gratuity. The Company
has taken an Insurance Policy under the Group Gratuity
Scheme with the insurance company to cover the Gratuity
Liability. The liability for Defined Benefit Plans is provided on
the basis of valuations, as at the Balance Sheet date, carried
out by an independent actuary.
The obligations are measured as the present value of
estimated future cash flows discounted at rates reflecting
the prevailing market yields of Indian Government securities
as at the Balance Sheet date for the estimated term of
the obligations. The estimate of future salary increases
considered takes into account the inflation, seniority,
promotion and other relevant factors.
The expected rate of return of plan assets is the company’s
expectation of the average long-term rate of return
expected on investments of the fund during the estimated
term of the obligations. Plan assets are measured at fair
value as at the Balance Sheet date. The actuarial valuation
method used by independent actuary for measuring the
liability is the Projected Unit Credit method.
Summary of significant accounting policies and other explanatory information to the consolidated
financial statements for the year ended 31 December 2014
268
Annual Report 2014
ii. Defined contribution plan
The certain employees of the Company are also participant
in the superannuation plan which is a defined contribution
plan. The Company has no obligations to the Plan beyond
its contributions.
The company’s contributions to Defined Contribution
Plans are charged to the Statement of Profit and Loss as
incurred.
iii. Other employee benefits
The employees of the company are also entitled for Leave
availment and/or Encashment as per the company’s policy.
The liability for Leave Entitlement is provided on the basis
of valuation, as at Balance Sheet date, carried out by an
independent actuary. The actuarial valuation method used
for measuring the liability is the Projected Unit Credit
method.
Termination benefits are recognised as an expense as and
when incurred.
Actuarial gains and losses comprise experience adjustments
and the effects of changes in actuarial assumptions and are
recognised immediately in the Statement of Profit and Loss
as income or expense.
M. Earnings per share
Basic earnings per share is calculated by dividing the net profit
or loss after tax for the year attributable to equity shareholders
by the weighted average number of equity shares outstanding
during the year. The number of shares used in computing diluted
earnings per share comprises the weighted average number of
shares considered for deriving basic earnings per share and also
the weighted average number of shares which could have been
issued on conversion of all dilutive potential equity shares.
N. Taxation
Current tax
Provision for current tax is recognized based on the estimated
tax liability computed after taking credit for allowances and
exemptions in accordance with the Income Tax Act, 1961.
Minimum Alternative Tax (MAT) credit is recognised as an asset
only when and to the extent there is convincing evidence that the
company will pay normal income tax during the specified period.
In the year in which the MAT credit becomes eligible to be
recognized as an asset in accordance with the recommendations
contained in Guidance Note issued by the Institute of Chartered
Accountants of India, the said asset is created by way of a credit
to the Statement of Profit and Loss and shown as MAT Credit
Entitlement. The Company reviews the same at each balance
sheet date and writes down the carrying amount of MAT Credit
Entitlement to the extent there is no longer convincing evidence
to the effect that Company will pay normal Income Tax during
the specified period.
Deferred tax
Deferred tax assets and liabilities are recognized for the future
tax consequences attributable to timing differences between
the financial statements’ carrying amounts of existing assets and
liabilities and their respective tax basis. Deferred tax assets and
liabilities are measured using the enacted tax rates or tax rates
that are substantively enacted at the Balance Sheet dates. The
effect on deferred tax assets and liabilities of a change in tax
rates is recognised in the period that includes the enactment
date. Where there is unabsorbed depreciation or carry forward
losses, deferred tax assets are recognized only if there is virtual
certainty supported by convincing evidence that they can be
realised against future taxable profits. Other deferred tax assets
are recognized only to the extent there is reasonable certainty
of realization in the future. Such assets are reviewed at each
Balance Sheet date to reassess realization. Timing differences
originating and reversing during the tax holiday period are not
considered for the purpose of computing deferred tax assets
and liabilities.
O. Leases
Leases, where the lessor effectively retains substantially all the
risks and benefits of ownership of the leased term, are classified
as operating leases. Operating lease payments are recognized
as an expense in the statement of profit and loss account on a
straight-line basis over the lease term.
P. Provisions and Contingent Liabilities
A provision is recognized when the Company has a present
obligation as a result of past events and it is probable that an
outflow of resources will be required to settle the obligation,
in respect of which a reliable estimate can be made. Provisions
are not discounted to their present value and are determined
based on management’s best estimates required to settle the
obligation at the Balance Sheet date. These are reviewed at each
Balance Sheet date and adjusted to reflect the current best
estimates.
Contingent Liabilities are disclosed in respect of possible
obligations that arise from past events, whose existence would
be confirmed by the occurrence or non-occurrence of one or
more uncertain future events not wholly within the control of
the Company.
Q. Cash and cash equivalents
Cash and cash equivalents in the cash flow statement comprise
cash at bank and in hand and short-term investments with an
original maturity of three months or less.
Summary of significant accounting policies and other explanatory information to the consolidated
financial statements for the year ended 31 December 2014
269
ITD Cementation India Limited
2. Share capital
As at 31st December 2014 As at 31st December 2013
Number Amount Number Amount
Authorised Share Capital
Equity shares of H10 each 30,000,000 3,000.00 15,000,000 1,500.00
Redeemable preference shares of H10 each 45,000,000 4,500.00 60,000,000 6,000.00
75,000,000 7,500.00 75,000,000 7,500.00
The Authorised share capital of the Company as at 31 December 2013 was H750,000,000 consisting of 15,000,000 Equity shares of H10 each
and 60,000,000 Redeemable preference shares of H10 each respectively. During the year, the shareholders of the Company have approved the
reclassification of Authorised share capital into 30,000,000 Equity shares of H10 each and 45,000,000 Redeemable preference shares of H10
each respectively aggregating H750,000,000 through postal ballot.
Issued
Equity shares of H10 each 15,518,316 1,551.83 11,518,316 1,151.83
15,518,316 1,551.83 11,518,316 1,151.83
Subscribed and fully paid-up
Equity shares of H10 each 15,515,790 1,551.58 11,515,790 1,151.58
15,515,790 1,551.58 11,515,790 1,151.58
a) Reconciliation of equity shares outstanding at the beginning and at the end of the reporting period
As at 31st December 2014 As at 31st December 2013
Number Amount Number Amount
Balance at the beginning of the year 11,515,790 1,151.58 11,515,790 1,151.58
Add : Issued during the year 4,000,000 400.00 - -
Balance at the end of the year 15,515,790 1,551.58 11,515,790 1,151.58
d) Shareholders holding more than 5% of the equity shares in the Company as at 31 December 2014
As at 31st December 2014 As at 31st December 2013
Number % Holding Number % Holding
Equity shares of H10 each
Italian-Thai Development Public Company Limited, Thailand 8,011,318 51.63 8,011,318 69.57
HDFC Trustee Company Limited 1,028,361 6.63 - -
c) Shares held by holding Company
As at 31st December 2014 As at 31st December 2013
Number Amount Number Amount
Equity shares of H10 each
Italian-Thai Development Public Company Limited, Thailand 8,011,318 801.13 8,011,318 801.13
Summary of significant accounting policies and other explanatory information to the consolidated
financial statements for the year ended 31 December 2014 (Currency : Indian Rupee in lakhs)
b) Terms/rights attached to equity shares
The Company has only one class of equity shares having a par value of H10 per share. Each holder of equity shares is entitled to one vote
per share. The Company declares and pays dividends in Indian Rupees. The dividend proposed, if any, by the Board of Directors is subject
to the approval of the shareholders in the ensuing Annual General Meeting, except interim dividend.
During the year, H Nil (31 December 2013 : H1.00) per share dividend recognised as distributions to equity share holders.
In the event of liquidation of the Company, the holders of equity shares will be entitled to receive remaining assets of the Company,
after distribution of all preferential amounts, if any. The distribution will be in proportion to the number of equity shares held by the
shareholders.
As per records of the Company, including its register of shareholders/members and other declarations received from shareholders
regarding beneficial interest, the above shareholding represents both legal and beneficial ownership of shares.
270
Annual Report 2014
4. Long-term borrowings
As at 31st December 2014 As at 31st December 2013
Non-current Current Non-current Current
Secured
Rupee term loans
- from bank 3,073.74 3,000.00 - 4,900.00
- from others 587.97 865.84 463.34 57.57
Plant loans from financial institution 242.89 297.00 433.61 324.92
Vehicle loans from bank 134.01 37.18 72.23 19.23
Unsecured
Rupee term loan
- from others - 174.50 171.73 1,986.27
4,038.61 4,374.52 1,140.91 7,287.99
Amount disclosed under "Other current liabilities" (Refer note 8) - (4,374.52) - (7,287.99)
4,038.61 - 1,140.91 -
3. Reserves and surplus
As at
31st December 2014
As at
31st December 2013
Securities premium account
Balance at the beginning of the year 31,957.38 31,957.38
Add: Additions during the year 14,000.00 -
Less: QIP expenses adjusted (400.94) -
Balance at the end of the year 45,556.44 31,957.38
General reserve
Balance at the beginning of the year 676.48 653.21
Add: Transferred from statement of profit and loss - 23.27
Balance at the end of the year 676.48 676.48
Surplus in the statement of profit and loss
Balance at the beginning of the year 7,055.87 6,284.75
Add : Transferred from statement of profit and loss 1,941.43 930.91
Less : Transferred to general reserve - (23.27)
Less : Proposed dividend on equity shares - (115.16)
Less : Tax on proposed equity dividend - (19.57)
Less : Tax on equity dividend for earlier year - (1.78)
8,997.30 7,055.88
55,230.22 39,689.74
Summary of significant accounting policies and other explanatory information to the consolidated
financial statements for the year ended 31 December 2014 (Currency : Indian Rupee in lakhs)
e) Aggregate number of bonus shares issued, shares issued for consideration other than cash and shares bought back during the period
of five years immediately preceding 31 December 2014
The Company has not issued any bonus shares nor has there been any buy back of shares during five years immediately preceding
31 December 2014.
f) Out of the total issued capital, 2,526 (31 December 2013 : 2,526) equity shares of H10 each have been kept in abeyance pending final
settlement of rights issues.
g) The Company has issued and allotted 4,000,000 equity shares of H10 each fully paid for cash at a premium of H350 per equity share to
Qualified Institutions Buyers (“QIB”) aggregating to H14,400 lakhs.
Expenses in relation to shares issued to QIB aggregating to H400.94 lakhs debited to Securities premium account.
2. Share capital (contd.)
271
ITD Cementation India Limited
Rupee term loan - from bank (secured)
Term loan obtained from Exim Bank carries interest rate of 12.25 percent per annum. This loan is repayable in six quarterly installments
commenced from December 2013.
Term loan obtained from Vijaya Bank carries interest rate of 12.25 percent per annum and repayable in three monthly installments starting from
November 2015. This loan is secured by hypothecation of Kolkata area depot land.
Rupee term loans from others (secured)
Loan obtained from Indiabulls Housing Finance Limited for purchase of office premises (Kolkata) which carries an interest rate of 13.50 percent
per annum and is repayable in 84 monthly installments commenced from April 2013. This loan is secured by hypothecation of the office
purchased out of this loan.
Loan obtained from Tata Capital Financial Services Limited carries an interest rate of 13 percent per annum and is repayable in 24 monthly
Plant loan from financial institution (secured)
Loan obtained from Tata Capital Limited for purchase of construction equipment carries interest rate ranging between 13.01 to 13.25 percent
per annum and are repayable in 57 to 84 monthly installments. These loans are secured by first and exclusive charge on specific equipment
financed by the institution.
Vehicle loan from bank (secured)
Loan obtained from AXIS Bank for purchase of vehicles carries interest rate ranging between 10 to 10.5 percent per annum and are repayable
in 60 monthly installments. These loans are secured by hypothecation of the vehicles purchased out of these loans.
Term loan - from financial institution (unsecured)
Term loan obtained from SREI Equipment Finance Private Limited carries interest rate of 11.56 percent per annum. These loans are repayable
in 29 monthly installments commenced from September 2012.
4. Long-term borrowings (contd.)
5. Long-term provision
As at
31st December 2014
As at
31st December 2013
Provision for employee benefits
- Leave entitlement (Refer note 30) 563.24 417.37
563.24 417.37
6. Short-term borrowings
As at
31st December 2014
As at
31st December 2013
Secured
Working capital loans from banks 67,405.75 63,411.58
Buyer's credit 713.78 5,110.76
68,119.53 68,522.34
Working capital loan from banks
Working capital loans availed from consortium bankers carries interest rates ranging between 11.7 to 15.7 percent per annum and are secured
by first pari passu charge on the current assets and movable plant and machinery other than those charged in favour of Tata Capital Limited.
These facilities are repayable on demand.
Buyer’s credit
Buyer credit loans obtained from bankers carries interest of LIBOR plus 1.5 to 3.5 percent per annum (quarterly rests). These loans are secured
by first pari passu charge on the current assets and movable plant and machinery other than those charged in favour of Tata Capital Limited.
Summary of significant accounting policies and other explanatory information to the consolidated
financial statements for the year ended 31 December 2014 (Currency : Indian Rupee in lakhs)
installments commenced from April 2014. This loan is secured by first and exclusive charge on specific equipments financed by the institution.
272
Annual Report 2014
7. Trade payables (Refer note 38)
As at
31st December 2014
As at
31st December 2013
Acceptances 8,048.48 1,517.69
Other than acceptances 33,671.03 28,129.11
41,719.51 29,646.80
8. Other current liabilities
As at
31st December 2014
As at
31st December 2013
Current maturity of long term debt (Refer note 4) 4,374.52 7,287.99
Creditors for capital expenses 303.35 62.77
Interest accrued and due 83.65 143.86
Interest accrued but not due 122.98 387.15
Unclaimed dividend * 7.44 6.94
Advances from customers (Refer note 39) 35,514.07 29,283.28
Material received from customers 102.46 213.06
Amount due to customers (Refer note 39) 951.30 2,177.52
Employee related dues 2,384.98 2,299.32
Statutory dues payable 924.09 907.24
Liability for foreign exchange contracts 5.64 242.73
Others 2,360.64 1,293.21
47,135.12 44,305.07
* Not due for credit to Investor Education & Protection Fund
9. Short term provisions
As at
31st December 2014
As at
31st December 2013
Provision for employee benefits
- Gratuity (Refer note 30) 793.62 534.17
- Leave entitlement (Refer note 30) 113.19 98.12
- Provident fund 178.33 145.96
Provision for taxation (net of advance tax) 25.83 253.91
Proposed dividend - 115.16
Provision for tax on proposed dividend - 19.57
1,110.97 1,166.89
Summary of significant accounting policies and other explanatory information to the consolidated
financial statements for the year ended 31 December 2014 (Currency : Indian Rupee in lakhs)
273
ITD Cementation India Limited
10. Tangible assets
Freehold
land
Leasehold
improvements
Buildings Plant and
machinery
Earth-moving
machinery
Office
equipment
and furniture
Vehicles Total
Gross block
Balance as on 1 January 2013 15.32 331.42 221.94 40,574.29 6,730.57 1,807.11 311.15 49,991.80
Additions - 122.40 877.23 2,289.13 88.11 408.24 170.15 3,955.26
Deletions - - - (540.16) (30.16) (48.23) (22.34) (640.89)
Balance as on 31 December 2013 15.32 453.82 1,099.17 42,323.26 6,788.52 2,167.12 458.96 53,306.17
Additions - - - 5,899.83 147.46 65.90 136.18 6,249.37
Disposals - - - (2,041.53) (159.32) (330.53) (12.74) (2,544.12)
Balance as on 31 December 2014 15.32 453.82 1,099.17 46,181.56 6,776.66 1,902.49 582.40 57,011.42
Accumulated depreciation
Balance as on 1 January 2013 - 39.74 110.95 20,152.79 5,005.58 1,495.91 217.07 27,022.04
Depreciation charge - 85.69 44.89 3,570.68 525.45 146.66 49.46 4,422.83
Reversal on disposal of assets - - - (411.74) (23.97) (43.63) (15.84) (495.18)
As at 31 December 2013 - 125.43 155.84 23,311.73 5,507.06 1,598.94 250.69 30,949.69
Depreciation charge - 69.80 39.45 3,497.64 461.69 143.28 59.02 4,270.88
Reversal on disposal of assets - - - (1,688.02) (124.83) (357.21) (11.67) (2,181.73)
Effect of change in depreciation policy - - (96.34) (8,263.09) (1,149.72) 18.31 (62.41) (9,553.25)
As at 31 December 2014 - 195.23 98.95 16,858.26 4,694.20 1,403.32 235.63 23,485.59
Net block
As at 31 December 2014 15.32 258.59 1,000.22 29,323.30 2,082.46 499.17 346.77 33,525.83
As at 31 December 2013 15.32 328.39 943.33 19,011.53 1,281.46 568.18 208.27 22,356.48
11. Deferred tax assets (net)
As at
31st December 2014
As at
31st December 2013
Deferred tax asset arising on account of (A)
Provision for doubtful debts 975.54 696.39
Provision for employee benefits 496.43 339.06
Disallowance u/s 43B as per Income Tax Act, 1961 318.33 305.65
Timing difference between book depreciation and depreciation as per Income Tax Act, 1961 - 728.95
Provision for doubtful advances 16.09 19.64
Unabsorbed depreciation 1,065.19 -
Unabsorbed loss 984.04 -
Others 368.78 32.19
4,224.40 2,121.88
Deferred tax liability arising on account of (B)
Timing difference between book depreciation and depreciation as per Income Tax Act, 1961 2,739.27 -
Deferred tax assets (A-B) 1,485.13 2,121.88
Summary of significant accounting policies and other explanatory information to the consolidated
financial statements for the year ended 31 December 2014 (Currency : Indian Rupee in lakhs)
274
Annual Report 2014
12. Loans and advances
As at 31st December 2014 As at 31st December 2013
Long term Short term Long term Short term
(Unsecured, considered good unless otherwise stated)
Capital advances 1,012.39 - 1,763.89 -
Security and other deposits - -
- considered good 253.46 1,975.47 284.30 1,697.54
- considered doubtful - 47.33 49.56
Receivable from Holding Company (Refer note 34) - 1,157.68 1,651.46
Other loans and advances - -
Advance recoverable in cash or kind - -
- considered good - 2,820.91 - 1,373.60
- considered doubtful - - - 60.52
Prepaid expenses - 1,526.53 - 1,439.56
Loans and advances to employees - 16.95 - 18.80
Balances with statutory / government authorities 12,574.43 - 9,855.59 -
Advance income tax [including MAT tax credit] (net of
provisions)
2,755.49 - 3,716.33 -
16,595.77 7,544.87 15,620.11 6,291.04
Less : Provision for doubtful advances / deposits - (47.33) - (110.08)
16,595.77 7,497.54 15,620.11 6,180.96
13. Other non current assets
As at
31st December 2014
As at
31st December 2013
Non-current bank balances (refer note 17) 22.00 22.00
Interest accrued but not due 5.54 -
27.54 22.00
Summary of significant accounting policies and other explanatory information to the consolidated
financial statements for the year ended 31 December 2014 (Currency : Indian Rupee in lakhs)
14. Current investments
As at 31st December 2014 As at 31st December 2013
No. of Shares Book Value No. of Shares Book Value
(Non-trade, unquoted at lower of cost and fair value)
Investments in equity shares
AVR Infra Private Limited (Face value of H10 each) 2600 0.26 2600 0.26
0.26 0.26
15. Inventories
As at
31st December 2014
As at
31st December 2013
Construction materials 15,920.72 13,574.02
Tools and equipment 5,152.54 5,308.45
Machinery spares 1,817.74 1,474.04
Unbilled work in progress 90,234.22 75,326.08
113,125.22 95,682.59
275
ITD Cementation India Limited
16. Trade receivable
As at 31st December 2014 As at 31st December 2013
Long term Short term Long term Short term
(unsecured, considered good unless otherwise stated)
Trade receivables outstanding for more than six months
- Considered good * 2,863.37 24,565.38 - 27,552.77
- Considered doubtful - 2,870.08 - 2,213.75
2,863.37 27,435.46 - 29,766.52
Less: Provision for doubtful debts - (2,870.08) - (2,213.75)
2,863.37 24,565.38 - 27,552.77
Other debts ** - 16,720.43 - 12,605.68
2,863.37 41,285.81 - 40,158.45
Notes :
* Includes retention money - 8,667.24 - 7,986.31
** Includes retention money - 3,410.04 - 2,347.52
17. Cash and bank balances
As at 31st December 2014 As at 31st December 2013
Non-current Current Non-current Current
Cash and cash equivalents
Cash in hand - 194.75 - 164.56
Balance with scheduled banks -
- current accounts - 1,924.98 - 1,930.43
- dividend bank accounts - 7.44 - 6.94
Bank deposits with maturity not more than 3 months 368.16 294.00
- 2,495.33 - 2,395.93
Other bank balances
Deposit with maturity of more than 3 months and less than 12
months *
- 222.87 - 795.89
Bank deposits with maturity of more than 12 months ** 22.00 - 22.00 -
22.00 2,718.20 22.00 3,191.82
Less: Amounts disclosed as Other non-current assets
(Refer note 13)
(22.00) - (22.00) -
- 2,718.20 - 3,191.82
* Earmarked against bank guarantees taken by the Company
** Placed as earnest money deposit
18. Other current assets
As at
31st December 2014
As at
31st December 2013
Interest accrued but not due 15.75 33.28
15.75 33.28
19. Other operating income
Year ended
31st December 2014
Year ended
31st December 2013
Service income from unincorporated joint ventures 652.29 570.69
652.29 570.69
Summary of significant accounting policies and other explanatory information to the consolidated
financial statements for the year ended 31 December 2014 (Currency : Indian Rupee in lakhs)
276
Annual Report 2014
20. Other Income
Year ended
31st December 2014
Year ended
31st December 2013
Interest income
- on bank deposits 131.40 221.10
- on income tax refund 320.88 304.46
- on sales tax refund - 6.16
- from customer on settlement 222.89 614.26
- others 18.30 2.77
Other non operating income:
- Profit on sale of fixed assets (net) - 52.77
- Sundry balances written back 132.13 819.47
- Bad debts recovered 7.00 174.38
- Excess provisions of prior year written back 176.95 883.56
- Insurance claim - 157.95
- Miscellaneous income 839.92 159.24
1,849.47 3,396.12
21. Employee benefits expense
Year ended
31st December 2014
Year ended
31st December 2013
Salaries and wages 17,338.61 17,505.79
Contribution to gratuity (Refer note 30) 359.44 111.91
Contribution to provident and other funds (Refer note 30) 1,344.55 1,270.48
Staff welfare expenses 321.29 341.22
19,363.89 19,229.40
22. Finance costs
Year ended
31st December 2014
Year ended
31st December 2013
Interest expenses
- Working capital loans 9,069.73 8,332.48
- Long term loan 1,149.08 1,385.12
- Advances from customers 940.89 510.15
- External commercial borrowings 17.84 72.24
- Others 273.20 114.96
Exchange loss (attributable to finance costs) 204.93 522.40
Bank charges and guarantee commission 1,894.70 1,894.61
13,550.37 12,831.96
Summary of significant accounting policies and other explanatory information to the consolidated
financial statements for the year ended 31 December 2014 (Currency : Indian Rupee in lakhs)
277
ITD Cementation India Limited
23. Other expense
Year ended
31st December 2014
Year ended
31st December 2013
Plant hire expenses 4,848.76 6,069.05
Power and fuel 7,057.98 7,002.25
Sales tax on works contracts 5,396.99 4,402.06
Travelling expenses 890.64 854.67
Tools and equipment 1,025.41 1,416.43
Foreseeable loss 1,329.73 308.58
Site transport and conveyance 2,856.71 2,591.28
Repairs and maintenance:
- Plant & machinery 528.07 478.28
- Others 196.91 182.78
Insurance 849.59 989.74
Professional fees 2,356.09 1,940.75
Rent (Refer note 40) 2,709.79 2,194.51
Spares consumed 1,287.58 1,630.21
Security charges 990.34 751.39
Temporary site installations 449.19 1,820.70
Postage, telephone and telegram 200.27 204.55
Auditor remuneration (Refer note 25) 75.46 70.40
Provision for doubtful debts (Refer note 26) 673.69 678.17
Provision for doubtful advance / deposits 47.33 49.56
Rates & taxes 135.76 246.72
Water charges 370.22 538.36
Printing and stationery 137.01 137.69
Fees and subscription 45.90 149.52
Infotech expenses 200.66 233.35
Service tax 1,300.51 1,570.41
Labour cess 876.66 845.38
Royalty expense - 610.84
Exchange loss (net) 114.74 52.22
Directors’ sitting fees 2.75 1.65
CSR expenses 12.87 -
Loss on sale of fixed assets (net) 20.03 -
Miscellaneous expenses 1,783.28 1,451.38
38,770.92 39,472.88
24. Earnings per share
Year ended
31st December 2014
Year ended
31st December 2013
Weighted average number of equity shares outstanding during the year 12,819,900 11,515,790
Add:- Dilutive effect - -
Weighted average number of equity shares used to compute diluted EPS 12,819,900 11,515,790
Before exceptional item:
Net (loss)/profit after tax before exceptional item (7,611.82) 930.91
Earning per share :
Basic and diluted (59.38) 8.08
After exceptional item:
Net Profit after tax attributable to equity shareholders 1,941.43 930.91
Earning per share :
Basic and diluted 15.14 8.08
Summary of significant accounting policies and other explanatory information to the consolidated
financial statements for the year ended 31 December 2014 (Currency : Indian Rupee in lakhs)
278
Annual Report 2014
25. Auditor remuneration (including service tax)
Year ended
31st December 2014
Year ended
31st December 2013
Audit fee 28.93 26.63
Tax audit fee 14.71 15.75
Limited review 24.73 22.45
Certification 5.96 4.26
Out-of-pocket expenses 1.13 1.31
75.46 70.40
26. Provision for doubtful debts
Year ended
31st December 2014
Year ended
31st December 2013
Bad debts written off during the year 17.36 -
Add: Provision for doubtful debts, end of year 2,870.08 2,213.75
Less: Provision for doubtful debts, beginning of year 2,213.75 1,535.58
673.69 678.17
28. Contingent Liabilities
Year ended
31st December 2014
Year ended
31st December 2013
a) Guarantees/Letter of credits given by banks in respect of contracting commitments in
the normal course of business
24,381.82 30,331.96
b) The Company has a number of claims on customers for price escalation and / or
variation in contract work. In certain cases which are currently under arbitration, the
customers have raised counter-claims. The Company has received legal advice that
none of the counter-claims are legally tenable. Accordingly no provision is considered
necessary in respect of these counter claims.
12,016.77 12,244.58
c) Corporate Guarantee given to bank on behalf of Joint Ventures 51,000.00 51,000.00
d) Sales Tax matters pending in appeals 3,738.36 3,469.69
e) Income Tax matters pending in appeal 1,454.27 1,188.44
f) Excise matter pending in appeal 52.00 52.00
g) Entry tax matter pending in appeal 335.15 335.15
27. Commitment
Year ended
31st December 2014
Year ended
31st December 2013
Estimated amount of contracts remaining to be executed on capital accounts
and not provided for (net of advances)
1,977.92 897.22
Future cash outflows in respect of above matters are determinable only on receipt of judgments/decisions pending at various forums/authorities.
The management does not expect these claims to succeed and accordingly, no provision for the contingent liability has been recognized in the
financial statements.
Summary of significant accounting policies and other explanatory information to the consolidated
financial statements for the year ended 31 December 2014 (Currency : Indian Rupee in lakhs)
279
ITD Cementation India Limited
29 Particulars of derivative instruments and unhedged foreign currency exposures at the balance sheet date
a) Derivative outstanding at the reporting date
Buyers credit, Trade payables
and Acceptances
As at 31st December 2014 As at 31st December 2013
Foreign
Currency
Exchange
RateINR in lakhs
Foreign
Currency
Exchange
RateINR in lakhs
US Dollar Exposure 945,307 63.80 603.11 1,174,215 62.26 731.07
EURO Exposure 283,381 77.84 220.58 4,214,095 86.23 3,633.81
GBP Exposure - - - 725,000 102.88 745.88
Total 823.69 5,110.76
b) Particulars of unhedged foreign currency exposures at the reporting date
Buyers credit, Trade payables
and Acceptances
As at 31st December 2014 As at 31st December 2013
Foreign
Currency
Exchange
RateINR in lakhs
Foreign
Currency
Exchange
RateINR in lakhs
US Dollar Exposure - - - 1,516 62.26 0.94
EURO Exposure - - - 8,922 86.23 7.69
Total - 8.63
30 Employee benefits
The following tables summarise the components of net benefit expense recognised in the statement of profit and loss and the funded
status and amounts recognised in the balance sheet for the respective plans.
Gratuity
31st December 2014 31st December 2013
The amount recognised in the statement of profit & loss :
Current service cost 214.41 189.38
Interest cost 157.43 138.31
Expected return on plan assets (109.59) (108.71)
Net actuarial (gain) / loss for the period 97.19 (107.07)
Net benefit expense 359.44 111.91
The amount recognised in the balance sheet is as follows :
Defined benefit obligation 2,160.83 1,759.84
Fair value of plan assets 1,367.21 1,225.67
Plan liability / (asset) 793.62 534.17
Changes in the present value of the defined benefit obligations :
Defined benefit obligation at beginning of the period 1,759.84 1,714.10
Current service cost 214.41 189.38
Interest cost 157.43 138.31
Actuarial loss/(gain) 145.25 (189.33)
Benefit paid (116.10) (92.62)
Present value of defined benefit obligation at end of period 2,160.83 1,759.84
Changes in the fair value of the plan assets of the gratuity plan :
Plan assets at beginning of the period 1,225.67 1,216.84
Expected return on plan assets 109.59 108.72
Contributions by employer 100.00 74.99
Benefit paid (116.10) (92.62)
Actuarial (loss)/gain on plan assets 48.05 (82.26)
Fair value of plan assets at end of the period 1,367.21 1,225.67
Summary of significant accounting policies and other explanatory information to the consolidated
financial statements for the year ended 31 December 2014 (Currency : Indian Rupee in lakhs)
280
Annual Report 2014
31st December 2014 31st December 2013
The principal assumptions used in determining the gratuity obligations :
Discount rate 8.00% 9.25%
Expected rate of return on plan assets 9.00% 9.00%
Salary escalation rate 4.50% 4.50%
Withdrawal rates Upto age 44 - 2%
45 years & above - 1%
Upto age 44 - 2%
45 years & above - 1%
The amount of defined benefit obligation, plan assets, the deficit thereof and the experience adjustments on plan assets and plan liabilities
for the current and previous four years are as follows:
2014 2013 2012 2011 2010
Defined benefit obligation 2,160.83 1,759.84 1,714.10 1,473.32 1,266.02
Plan assets 1,367.21 1,225.67 1,216.84 1,081.14 1,085.40
Deficit (793.62) (534.17) (497.26) (392.18) (180.62)
Experience adjustments on plan assets 48.05 (82.26) 71.78 (108.93) 13.71
Experience adjustment on plan liabilities (145.24) 189.33 (118.31) (27.20) (104.50)
30 Employee benefits (contd.)
The gratuity fund is invested in a Group Gratuity policy invested with the Life Insurance Corporation of India and Birla Sunlife Insurance.
The fair value of plan assets with Life Insurance Corporation of India and Birla Sunlife Insurance as at 31 December 2014 are H0.15
lakhs (31 December 2013 - H0.13 lakhs) and H1,367.06 lakhs (31 December 2013 - H1,225.54 lakhs) respectively. The management
understands that the assets in these portfolios are well diversified and as such the long term return thereon is expected to be higher than
the rate of return on Government Bonds.
The overall expected rate of return on assets is determined based on the market prices prevailing on that date, applicable to the period
over which the obligation is to be settled.
The estimates of future salary increases, considered in actuarial valuation take account of inflation, seniority, promotion and other relevant
factors such as supply and demand in the employment market.
The Guidance Note on implementing AS 15,“Employee Benefits”, issued by the Accounting Standards Board (ASB) of the Institute of
Chartered Accountants of India states that Provident Fund set up by employers that guarantee a specified rate of return and which require
interest shortfall to be met by the employer would be Defined Benefit Plan in accordance with the requirements of paragraph 26(b) of
AS 15. Pursuant to the Guidance Note, the liability in respect of the shortfall of interest earnings of the fund is Nil as determined on the
basis of an actuarial valuation carried out as at 31 December 2014. As per the actuarial valuation report, the interest shortfall liability being
“Other Long-term Employee Benefit”, detailed disclosures are not required.
The Company’s expense for the superannuation and provident fund aggregates H1,344.55 lakhs during the year (31 December 2013 -
H1,270.48 lakhs)
The liability for leave entitlement and compensated absences as at year end is H676.43 lakhs (31 December 2013 : H515.49 lakhs).
Summary of significant accounting policies and other explanatory information to the consolidated
financial statements for the year ended 31 December 2014 (Currency : Indian Rupee in lakhs)
31 Segment reporting
The activities of the Company comprises of only one business segment viz Construction. The Company operates in only one geographical
segment viz India. Hence the Company’s financial statements also represents the segmental information.
32 Subsidiaries
The following Subsidiary Company (incorporated in India) has been consolidated in the consolidated financial statement applying
Accounting Standard (AS) - 21:
Name of the Subsidiary 31st December 2014 31st December 2014
Proportion of
Ownership
Interest
Voting Power
Proportion of
Ownership
Interest
Voting Power
ITD Cementation Projects India Limited 100% 100% 100% 100%
281
ITD Cementation India Limited
Summary of significant accounting policies and other explanatory information to the consolidated
financial statements for the year ended 31 December 2014 (Currency : Indian Rupee in lakhs)
33 Jointly Controlled Entities
The following Jointly Controlled Entities have been consolidated applying Accounting Standard (AS) - 27 (“Financial Reporting of Interests
in Joint Ventures”).
Name of the Joint Venture 31st December 2014 31st December 2014
ITD Cemindia JV 80% 80%
ITD - ITD Cem JV 49% 49%
ITD - ITDCem JV (Consortium of ITD - ITD Cementation) 40% 40%
ITD-Cem Maytas Consortium 95% 95%
All the above are unincorporated jointly controlled entities in India
The proportionate share of assets, liabilities, income and expenditure of the Joint Ventures, consolidated in the accounts is tabulated
hereunder:
Balance Sheet Items As at 31st December 2014 As at 31st December 2013
Assets
Net block 5,395.62 3,186.62
Capital work-in-progress - -
Deferred tax assets 820.93 699.68
Current Assets :
Inventories 17,181.30 18,510.23
Trade receivables 7,828.00 6,681.37
Cash and bank balances 1,037.61 2,075.98
Loans and advances 3,460.84 3,629.90
Total Current Assets (A) 29,507.75 30,897.48
Current Liabilities (B) 15,028.02 15,172.89
Net Current Assets (A-B) 14,479.73 15,724.59
Total Assets 20,696.28 19,610.89
Liabilities
Loan funds :
Secured loans 9,455.07 7,451.20
Reserves & Surplus
Opening balance of retained earnings 5,398.58 3,562.42
Add : Profit for the period 510.53 2,429.71
5,909.11 5,992.13
Total Liabilities 15,364.18 13,443.33
Revenue
Turnover 36,001.47 35,360.86
Other income 1,160.01 1,525.53
Total revenue 37,161.48 36,886.39
Less : Expenses
Site and administration expenses 33,874.09 30,650.96
Interest and finance expenses 1,554.81 1,275.80
Depreciation 1,328.18 1,073.92
Total expenses 36,757.08 33,000.68
Profit before tax 404.40 3,885.71
Provision for tax 15.94 1,485.62
Deferred tax credit (122.07) (29.62)
Profit after tax 510.53 2,429.71
Contingent liabilities 2,519.28 3,767.09
282
Annual Report 2014
34 Related Party Disclosures :
a) Names of related parties and description of relationship
A Enterprise where control exists
i) Holding Company
Italian-Thai Development Public Company Limited
B Other related parties with whom the Company had transactions, etc.
Fellow subsidiary
Aquathai Co., Ltd.
Key management personnel (KMP)
Mr. Adun Saraban – Managing Director
Mr. S. Ramnath – Chief Financial Officer
Mr. R. C. Daga - Company Secretary
b) Transactions with related parties for the year are as follows:
Transaction during the year Holding Company KMP Fellow Subsidiary
Contract revenue
Italian-Thai Development Public Company Limited 13.95 - -
(107.95) (-) (-)
Royalty expense
Italian-Thai Development Public Company Limited - - -
(610.84) (-) (-)
Dividend paid
Italian-Thai Development Public Company Limited 80.11 - -
(160.23) (-) (-)
Engineering services
Aquathai Co., Ltd. - - -
(-) (-) (114.00)
Remuneration
Mr. Adun Saraban - 81.80 -
(-) (81.71) (-)
Mr. S. Ramnath - 48.36 -
(-) (48.91) (-)
Mr. R. C. Daga - 42.07 -
(-) (42.25) (-)
c) Balances at the year end:
Particulars Holding Company
Trade receivables
Italian-Thai Development Public Company Limited -
(59.70)
Loans and advances
Italian-Thai Development Public Company Limited 1,157.68
(1,651.46)
Summary of significant accounting policies and other explanatory information to the consolidated
financial statements for the year ended 31 December 2014 (Currency : Indian Rupee in lakhs)
(Figures in bracket represents previous year numbers)
(Figures in bracket represents previous year numbers)
35 Trade receivables and Unbilled Work-in-progress as at December 31, 2014 include amounts aggregating H2,655 Lakhs and H1,584 Lakhs
respectively, which have been outstanding for a substantial period of time. The Company has been actively negotiating for speedy recovery
of the balance receivables. In view thereof, management is reasonably confident of their recovery.
283
ITD Cementation India Limited
37 Trade receivables and unbilled work-in-progress as at 31 December 2014 include Company’s share of H2,076 lakhs and H2,394 lakhs
respectively, in respect of a joint venture, representing escalation and variation claims recognized by the joint venture. These claims are
presently under various stages of litigation. Considering favorable arbitration awards, claims under consideration at various forums and
based on the legal opinion received, the management is reasonably confident of recovery of these amounts and are expected to be
realised within next twelve months.
38 Micro, Small and Medium Enterprises
There are no Micro, Small and Medium Enterprises, to whom the Company owes dues, which are outstanding for more than 45 days as at
31 December 2014. This information as required to be disclosed under the Micro, Small and Medium Enterprises Development Act, 2006,
has been determined to the extent such parties have been identified on the basis of information available with the Company. There is no
interest paid or payable during the year.
36 (a) Trade receivables as at 31 December 2014 representing variation claims and interim work bills recognized by the Company aggregating
H6,842 lakhs (31 December 2013 : H6,849 lakhs). These claims are presently under various stage of litigations. Considering favorable
arbitration awards, claims under consideration at various forums, past experience of the Company and based on the legal opinion
received, the management is reasonably confident of recovery of these amounts and are expected to be realised within next twelve
months.
(b) Trade receivables as at 31 December 2014 include H696 lakhs (31 December 2013 : H1,140 lakhs) relating to price escalation claims
which are disputed by the customer. The Company has received an arbitration award in its favour which has subsequently been upheld
by the High Court. The customer has challenged this High Court order. However, based on the above arbitration award, High Court
order and legal opinion, management is reasonably confident of recovery of these amounts and are expected to be realised within
next twelve months.
(c) Long term trade receivables as at 31 December 2014 include variation claims of H309 lakhs (Trade receivables as at 31 December
2013 : H309 lakhs) for which the Company had received an arbitration award in its favour which has subsequently been upheld by
the District Court. The customer has challenged this Court Order. However, based on the above arbitration award, Court Order and
legal opinion, management is reasonably confident of recovery of these amounts.
(d) Long term trade receivables and unbilled work-in-progress as at 31 December 2014 include H1,140 lakhs (Trade receivables as at 31
December 2013 - H1,140 lakhs ) and H2,756 lakhs (31 December 2013 - H2,756 lakhs) respectively, in respect of a contract which
has been rescinded by the Company and long term trade receivable and unbilled work-in-progress as at 31 December 2014 include
H1,414 lakhs (Trade receivables as at 31 December 2013 : H689 lakhs) and H5,922 lakhs (31 December 2013 - H5,922 lakhs) respectively,
in respect of another contract where the Company has received a notice from the customer withdrawing from the Company the
balance works to be executed under the contract; for which the Company has also issued guarantees aggregating H1,497 lakhs
(31 December 2013 - H2,227 lakhs). The Company has made claims against the customer to recover these amounts and has initiated
legal action. Based upon legal opinion received, management is reasonably confident of recovery of these amounts of long term trade
receivable and unbilled work-in-progress and consequently no changes have been made to the values and classification of these
amounts in the financial statements.
(e) Trade receivables and unbilled work in progress as at 31 December 2014 includes H983 lakhs (31 December 2013 - H972 lakhs)
and H16,789 lakhs (31 December 2013 - H16,829 lakhs) respectively in respect of certain road contracts which are executed by the
Company. The Company has made claims on the customer for recovery of these amounts. Based on the contract terms and legal
opinion obtained, the management is reasonably confident of recovery of these amounts and are expected to be realised within next
twelve months.
39. The disclosures as per provisions of Clauses 38, 39 and 41 of Accounting Standard 7 ‘Construction Contracts’ issued
by Institute of Chartered Accountants of India are as under:
Year ended
31st December 2014
Year ended
31st December 2013
a) Contract revenue recognised as revenue in the period Clause 38 (a) 171,242.31 157,836.53
b) Aggregate amount of costs incurred and recognised profits up to the reporting date
on Contract under progress Clause 39 (a)
600,087.93 655,366.94
c) Advance received on Contract under progress Clause 39 (b) 35,514.07 29,283.28
d) Retention amounts on Contract under progress Clause 39 ( c) 9,282.57 10,333.83
e) Gross amount due from customers for contract work as an asset Clause 41 (a) 90,234.22 75,326.08
f) Gross amount due to customers for contract work as an asset Clause 41 (b) 951.30 2,177.52
Summary of significant accounting policies and other explanatory information to the consolidated
financial statements for the year ended 31 December 2014 (Currency : Indian Rupee in lakhs)
284
Annual Report 2014
40 Operating lease
a) The Company has taken various residential/commercial premises and construction equipments on cancellable operating lease.
These lease agreements are normally renewed on expiry. Rental expenses in the statement of profit and loss for the year includes
lease payments towards premises H2,068.90 lakhs (31 December 2013 - H1,566.61 lakhs).
b) The Company, in addition to above, has taken commercial premises on leases (non-cancellable operating leases). The future
minimum lease payments in respect of which as at 31 December 2014 are as follows:
As at
31st December 2014
As at
31st December 2013
Minimum Lease Payments
Payable not later than 1 year 511.50 470.40
Payable later than 1 year and not later than 5 years 826.50 1,338.00
Payable later than 5 years - -
Total 1,338.00 1,808.40
These leases have no escalation clauses.
Rental expenses in the statement of profit and loss for the year includes H640.89 lakhs (31 December 2013 - H627.90 lakhs) towards
such non-cancellable leases.
c) General descriptions of non-cancellable lease terms :
- Lease rentals are charged on the basis of agreed terms.
- Assets are taken on lease over a period of 3-5 years.
- The Company did not sublease any of its assets and hence did not receive any sub lease payments during the current or previous
year.
Summary of significant accounting policies and other explanatory information to the consolidated
financial statements for the year ended 31 December 2014 (Currency : Indian Rupee in lakhs)
41 Company has unabsorbed depreciation and business loss during the year which is available for set off against future taxable income under
the Income Tax Act. The Company has recognized deferred tax asset on such unabsorbed depreciation and business loss amounting
H6,029 lakhs on the basis of profitable non-cancellable binding contracts in hand. Management believes that the profitable non-cancellable
binding contracts in hand satisfies the test of virtual certainty with convincing evidence as required by Accounting Standard (AS) - 22 on
Accounting for taxes on income.
42 The tax year for the Group being the year ending 31 March, the provision for taxation for the year is the aggregate of the provision made
for the three months ended 31 March 2014 and the provision based on the figures for the remaining nine months up to 31 December
2014, the ultimate tax liability of which will be determined on the basis of the figures for the period 1 April 2014 to 31 March 2015.
43 Previous year figures have been regrouped or reclassified, to conform to the current year’s presentation wherever considered necessary.
For Walker Chandiok & Co LLP For and on behalf of the Board of Directors
(formerly Walker, Chandiok & Co.)
Chartered Accountants
Firm Registration No. 001076N/N500013
Amyn Jassani Adun Saraban P. Chakornbundit
Partner Managing Director Director
Membership No: 46447
S. Ramnath R. C. Daga
Chief Financial Officer Company Secretary
Mumbai Mumbai
24 February 2015 24 February 2015
285
301
DECLARATION
Our Company certifies that all relevant provisions of Chapter VIII read with Schedule XVIII of the SEBI ICDR
Regulations have been complied with and no statement made in this Preliminary Placement Document is contrary
to the provisions of Chapter VIII and Schedule XVIII of the SEBI ICDR Regulations and that all approvals and
permissions required to carry on our business have been obtained, are currently valid and have been complied
with. Our Company further certifies that all the statements in this Preliminary Placement Document are true and
correct.
Signed by
______________________
Mr. Adun Saraban
Managing Director
Date: January 24, 2018
Place: Mumbai
302
DECLARATION IN ACCORDANCE WITH FORM PAS - 4
We the Board of Directors of our Company certify that:
(a) our Company has complied with the applicable provisions of the Companies Act, 2013 and the rules made
thereunder;
(b) the compliance with the Companies Act, 2013 and the rules does not imply that payment of dividend or
interest or repayment of debentures, if applicable, is guaranteed by the Central Government; and
(c) the monies received under the offer shall be used only for the purposes and objects indicated in the Placement
Document (which includes disclosures prescribed under Form PAS-4).
Signed by
Sd/-
________________
Mr. Adun Saraban
Managing Director
I am authorized by the QIP Committee, a committee of the Board of Directors of our Company, vide resolution
number 7 dated January 24, 2018 to sign this form and declare that all the requirements of Companies Act, 2013
and the rules made thereunder in respect of the subject matter of this applicable form and matters incidental thereto
have been complied with. Whatever is stated in this form and in the attachments thereto is true, correct and
complete and no information which is material to the subject matter of this form has been suppressed or concealed
and is as per the original records maintained by the Promoter subscribing to the Memorandum of Association and
Articles of Association.
It is further declared and verified that all the required attachments have been completely, correctly and legibly
attached to this form.
Signed by
Sd/-
_______________________
Mr. Adun Saraban
Managing Director
Date: January 24, 2018
Place: Mumbai
ITD CEMENTATION INDIA LIMITED
Registered Office of the Issuer
National Plastic Building, A-Subhash Road, Paranjape B Scheme, Vile Parle (East), Mumbai 400057.
Tel: +91-22-6693 1600; Fax: +91– 22 6693 1628
Website: www.itdcem.co.in CIN: L61000MH1978PLC020435
Contact Person: Mr. Rahul Neogi
Address of the Compliance Officer
Mr. Rahul Neogi
National Plastic Building, A-Subhash Road, Paranjape B Scheme, Vile Parle (East),Mumbai 400057
Tel: +91-22-6693 1600; Fax: +91– 22 6693 1628
Email id: [email protected]
BOOK RUNNING LEAD MANAGER
ICICI Securities Limited
ICICI Center, H.T. Parekh Marg Churchgate, Mumbai – 400 020, Maharashtra, India Tel: +91 22 2288 2460
Fax: +91 22 2282 6580
Investor Grievance e-mail: [email protected]
Website: www.icicisecurities.com
Contact Person: Rishi Tiwari / Vishal Kanjani
SEBI Registration Number: INM000011179
DOMESTIC LEGAL ADVISORS TO THE ISSUE
M/s. Crawford Bayley & Co.
State Bank Buildings, 4th Floor
N.G.N. Vaidya Marg, Fort
Mumbai 400 023
Maharashtra, India
LEGAL COUNSEL TO THE COMPANY
Udwadia & Co.
Elphinstone House, 1stFloor,
17 Murzban Road,
Mumbai 400 001
Maharashtra, India
INTERNATIONAL LEGAL ADVISOR FOR SELLING RESTRICTIONS
(with respect to International Selling and Transfer Restrictions)
Squire Patton Boggs Singapore LLP
10 Collyer Quay, #03-01/03
Ocean Financial Centre
Singapore 049315
STATUTORY AUDITORS
Walker Chandiok & Co LLP
16th Floor, Tower II,
Indiabulls Finance Center, S. B. Marg, Elphinstone (W)
Mumbai 400 013,
Maharashtra, India