E-Tender for Outsourcing BTS sites in Kannur BA - BSNL
-
Upload
khangminh22 -
Category
Documents
-
view
2 -
download
0
Transcript of E-Tender for Outsourcing BTS sites in Kannur BA - BSNL
E-Tender for Outsourcing BTS sites in Kannur BA
1
Signature & Seal of bidder
BHARAT SANCHAR NIGAM LIMITED
(A Govt. of India Enterprises)
TENDER DOCUMENT
E-Tender for Outsourcing of BTS sites in Kannur BA (Kannur & Kasaragod areas)
Tender No: PLG/MM/ E-Tender/ BSS/Out Sourcing/2021-22/3 Dated at Kannur the 15-11-2021
Cost of Tender Form: Rs.2360
E-Tender for Outsourcing BTS sites in Kannur BA
2
Signature & Seal of bidder
TABLE OF CONTENTS
Section No. Item Page No.
1 Notice Inviting E-Tender 3-9
2 Scope of work/ Technical Specifications/
Requirements/SoR 10-22
3 e-Tendering Instructions to bidders 23-24
4 General /Commercial Conditions of Contract (GCC) 25-29
5 Bidder‟s Profile 30
6 Undertaking and Declaration 31
7 No near relatives Certificate 32
8 Letter of Authorization 32
9 Undertaking regarding genuineness of the documents 33
10 Service Contract Agreement 34-39
11 Performance Bank Guarantee 40
12 Mutual NON-Disclosure Agreement 41-42
13 Part A Bid Form 43
13 Part B Financial Bid 44
List of Annexures
Annexures Description Page No.
Annexure 1 Contact Details of Deployed Personnel 45
Annexure 2 Log Book for diesel filling 46
Annexure 3 Log Book for Mobile access equipment maintenance
and Mobile infrastructure maintenance 46
Annexure 4 Log Book for Rigger activity 47
Annexure 5 Monthly Performance Certificates 47-49
Annexure 6 Payment details to Mobile access equipments and
Mobile infra maintenance and rigger personnel 50
Annexure 7 Monthly Diesel reconciliation Statement 51
Annexure 8 Diesel filling data 52
Annexure 9 Experience certificate 53
Annexure 10 List of BTS sites for Mobile access equipments and
Mobile infra maintenance 54-57
Annexure 11 List of BTS sites for Diesel filling 58-62
Annexure 12 Bid Security/EMD Undertaking & Declaration. 63
Annexure 13 Certificate to be submitted by Bidder & its technology
partner. 64
Annexure 14 Certificate regarding the firm is not black-listed. 65
E-Tender for Outsourcing BTS sites in Kannur BA
3
Signature & Seal of bidder
BHARAT SANCHAR NIGAM LIMITED
(A Government of India Enterprise)
Office of the General Manager, BSNL,
Bhavan, KANNUR – 670002
e-Tender for Outsourcing of BTS sites in Kannur BA (Kannur&Kasaragod areas)
NIT No: PLG/MM/ E-Tender/ BSS/Out Sourcing/2021-22/3 Dated at Kannur the 15-11-2021
SECTION I
NOTICE INVITING e-TENDER
e-Tenders are invited on behalf of Chairman and Managing Director, Bharat Sanchar Nigam
Limited (here in after referred to as BSNL) from Reputed and Experienced Registered/ Licensed
agencies or firms of contractors or Labour Co-operative societies for undertaking the Mobile access
equipment maintenance and Mobile infrastructure maintenance, Diesel filling, Bush cutting and
Rigger activity in Kannur BA (Kannur & Kasaragod areas).Those who are having EPF, ESI, GST
and PAN only are eligible for participating in this tender.
1.NAME OF WORK :Mobile access equipment maintenance and Mobile infrastructure
maintenance, Diesel filling, Bush cutting and Rigger activity in Kannur BA (Kannur &
Kasaragod areas).
2.ESTIMATED COST OF WORK:
Sl. Description of
Activity/Sites
Quantity under
the
contract
Estimated
Cost (Rs.)
EMD
(Rs)
Cost of
tender
form
(Rs)
01 Diesel Filling of DG sets(No of Sites) 342
1,19,31,240/-
In place
of EMD,
Please
submit
the BID
Security
Declarat
ion as
per
Annexur
e 12.
2360/-
02
Mobile
access
equipment
maintenance
and Mobile
infrastructure
maintenance(
No.of sites)
(A) General sites
falling under rural and
urban areas
204
(B) Sites falling under
hard station areas 40
03
Bush cutting, clearing of vegetation,
climbers etc in BTS site Compound
(no of instances in a year)
About 600
instances of
cleaning/year
04 Rigger
activity
Up to 50 M About 125
instances/month
Above 50 M About 30
instances/month
05 Replacement of XAHT/other Antennas
with dual band Antenna including
transportation of store to site
30 instances/Year
Note 1: The quantity /no / Sites stated above are estimated and BSNL reserves the right to vary the
quantity to the extent of -25 % to +25 % of specified quantity at the time of award of the
contract i.e. APO without any change in unit price or other terms & conditions.
E-Tender for Outsourcing BTS sites in Kannur BA
4
Signature & Seal of bidder
Note 2: The List of GSM BTS sites under Kannur BA where the Mobile access equipment
maintenance and Mobile infrastructure maintenance in Kannur BA (Kannur & Kasaragod
areas). in Annexure 10. BSNL is empowered to increase / decrease the number of
sites/manpower/instances at any point of time according to the requirement.
3. ELIGIBILITY OF BIDDERS
a) Intending bidders should be Well Reputed and experienced/Licensed agencies or firms of
contractors or Labour Co-operative Societies/ registered company under the Indian Companies
Act, 1956. (Proof should be attached)
b) The bidder should comply with the eligibility with respect to Preference to Make in India as
per GOI order no P-45021/2/2017- PP(BE-II), dated 16-09-2020.
c) Any bidder from a country which shares a land border with India will be eligible to bid in
this tender only if the bidder is registered with the competent authority as per OM
No.6/18/2019-PPD dated 23rd July, 2020 & 24th July, 2020 imposing restrictions under Rule
144(xi) of the General Financial rules (GFRs) 2017on the grounds of Defence of India and
National Security for Information and compliance. (Pl refer to the Government of India,
Ministry of Finance, Department of Expenditure, Office Memorandum F.No. 6/18/2019-PPD,
dated 23rd July,2020 &24th July ,2020 for more details) Bidders complying this order in all
respects will be considered for placing orders. Non-compliance of this order will result in
rejection of bid at evaluation stage itself.)
An undertaking is to be submitted by the bidder on the Bidder Company‟s letterhead (in
Original) as per the proforma available in ANNEXURE 13.
d) The total annual turnover (audited) of the bidder should be at least Rs.60 Lakhs or more
during any one of the preceding three financial years (ie 2018-19, 2019-2020 & 2020-2021).
Audited Annual Reports duly certified by CA for this is to be enclosed along with the bid.
e) Bidder should have successfully executed similar /related works with any of the Telecom
service provider/Telecom Infra Provider at least for two years during any of the previous five
years. The documentary proof in original for this shall be submitted by the bidder, signed by the
authorized signatory of the company, in the format attached in Annexure 9. In the case of
BSNL, the certificate shall be obtained from an officer not below the rank of DE/AGM.
d) The company should have been registered under Ministry of Labour and should have valid
PAN.
e) The Bidder should not have been black-listed by central/ state governments/ PSUs. A self-
declaration to this effect may be submitted along with the bid document as per Annexure 14.
3.1 The bidders shall submit necessary documentary proof showing that they meet the eligibility
criteria along with their tender bid. All documents submitted will also be self-attested by the
bidder.
4.TENDER DOCUMENTS:
The Tender document can be downloaded from the website: https://etenders.gov.in/eprocure/app or
www.kerala.bsnl.co.in and to be submitted in e-format. Cost of tender document is (Rs.2360/-)
which can be remitted either in cash at the cash counter of the Accounts Officer (Cash),O/o General
Manager, BSNL Kannur-670002 or as a crossed Demand Draft obtained from any Public
Sector/Scheduled Bank in favor of“ The Accounts Officer(Cash), BSNL Kannur” payable at
Kannur.
E-Tender for Outsourcing BTS sites in Kannur BA
5
Signature & Seal of bidder
The scanned copies of the Payment receipts /DD towards cost of bid document has to be uploaded
in the e-Tender Portal. The tender document is not transferable and its cost once paid shall not be
refunded under any circumstances.
Availability of Tender document for downloading 12.00 Hrs of 08/12/2021 onwards
Last date and time of online submission of
Eligibility documents and Bid documents
Up to 13.00 Hrs on 29/12/2021
Last date and time for submission of Tender
Document, Cost of bid document in original in
sealed envelope.
Up to 14.00 Hrs on 30/12/2021
Time and date of opening of Tender. At 15.00 Hrs on 30/12/2021
5. SUBMISSION OF TENDER
The bid contains two parts–
Part A: The First part relates to uploading of scanned documents required for Technical Bid in the
appropriate place of the e-Tender Portal.
Part B: The Second part relates to uploading of Financial Bid containing the Price schedule in
excel format filled carefully in the appropriate place of the e-Tender Portal.
a) All the clauses of the bids must be complied with and price bids must be quoted online by the
bidders before the locking/closing time of the bid as specified in NIT
b) Bids shall remain valid for 180 days from date of opening of the bid. A bid valid for a shorter
period shall be rejected by BSNL as substantially non-responsive bid; the concerned bid shall be
rejected at the opening stage itself.
c) The BSNL may, at its discretion, extend this deadline for the submission of the bids by amending
the bid document in accordance with NIT in which case all rights and obligations of the BSNL and
bidders previously referred to the deadline will thereafter be subject to the extended deadline.
5.1. The bidder shall submit the original tender form duly filled in and signed on all pages along
with the prescribed the cost of the tender documents (in the form of Demand Draft/ cash receipt as
prescribed) shall also be submitted as part of the Bid before the last date and time for submission of
Tender document as mentioned in NIT. Firms registered under MSME/NSIC are exempted from
remitting EMD/ Cost of tender document on production of valid certificate.
5.2 All over writing/erasures/corrections in the bids hall be attested with date by the person signing
the bid.
5.3.The tender in the enclosed proforma should be submitted in sealed cover and superscripted as
“Tender for Mobile access equipment maintenance and Mobile infrastructure maintenance, Diesel
filling, Bush cutting and Rigger activity in Kannur BA (Kannur & Kasaragod areas)”and addressed
to AGM(Plg), BSNL Bhavan, Kannur-670002. Tenders may be dropped in the Tender Box kept for
the purpose at Office of General Manager, III Floor, BSNL BHAVAN, Kannur 670002 or sent by
Registered Post with Acknowledgement Due .Address: AGM (Plg) BSNL Bhavan,Kannur-
670002).No separate acknowledgement will be given. The letter of authorization shall be indicated
by written power-of-attorney accompanying the bid.
E-Tender for Outsourcing BTS sites in Kannur BA
6
Signature & Seal of bidder
Power of Attorney
The power of Attorney should be submitted and executed in the non-judicial stamp paper of
appropriate value as prevailing in the BA and the same be attested by a Notary public or registered
before Sub-registrar of the state(s) concerned.
In case of the bidder being a firm, the said Power of Attorney should be executed by all the
partner(s) in favor of the said Attorney.
Attestation of the specimen signatures of authorized signatory by the Company‟s/ firm‟s
bankers shall be furnished. Name, designation, Phone number, mobile number, email address and
postal address of the authorized signatory shall be provided.
Price Bid should be submitted through e-tender portal only.
5.4 Bids shall be received only up to the closing date &time prescribed in the NIT. In case the
closing date prescribed happens to be an official holiday for the BSNL office, the closing date shall
stand extended to the next working day without any change in the closing time.
5.5 Bids received after the last date and time shall be rejected and returned to the bidder unopened.
BSNL shall not be responsible for any postal delays or other reason by which the delivery of the bid
is delayed and no demands for consideration of such bids shall be entertained by BSNL.
6. LIST OF DOCUMENTS TO BE SUBMITTED AS PART OF THE BID
The following documents should be submitted online by uploading in the-tender portal:
Slno Description
1 Scanned copy of all pages of Tender document signed by the bidder or Authorized Person on all pages along with seal
2 Self-Attested Scanned copy of EPF registration
3 Self-Attested Scanned copy of ESI registration
4 Self-Attested Scanned copy of GST registration
5 Self-Attested Scanned copy of PAN Card
6 Self-Attested Scanned copy Audited Annual report (s) duly certified by CA to support the
claims of financial qualification.
7 Scanned copy of payment details of Cost of Tenderdocument 8 Scanned copy of Bidder‟s profile duly filled-in ( Section 5)
9 Scanned copy of Undertaking and Declaration/Non tampering the tender Document /etc
(Section 6)
10 Scanned copy of No near relative certificate duly filled inand signed (Section 7)
11 Scanned copy of Letter of Authorization to Tender Opening Event(TOE) ,if any(Section 8)
12 Scanned copy of Undertaking regarding genuineness of the documents/information
submitted (Section 9)
13 Scanned copy of Duly filled Vendor Master Form(Annexure 10)
14 Self-Attested Scanned copy of Original" Power of Attorney" in case person signed the tender documents is other thanproprietor 15 Self-Attested Scanned copy of "Partnership Deed" duly registered if applicable
16 Self-Attested Scanned copy of Certificate of incorporation if applicable
17 Self-Attested Scanned copy of Article and Memorandum of Association or partnership
deed or proprietary deed as the case may be.
18 Self-Attested Scanned copy of Latest and valid MSME/NSIC Certificate (for the
tendered item) duly certified by MSME (if applicable)
19 Scanned copy of Experience certificate -2years
E-Tender for Outsourcing BTS sites in Kannur BA
7
Signature & Seal of bidder
20 An undertaking is to be submitted by the bidder on the Bidder Company‟s letterhead
(in Original) as per the proforma at Annexure 13
21 A self-declaration stating that the bidder is not black listed by GST Authorities (as per
the proforma at Annexure 14.
6.1 Tender documents in original, should be duly filled in and signed by the bidder on each page.
6.2 Bid Security should be in the form of Demand Draft/ cash receipt as prescribed.
6.3 Cost of Tender documents should be in form of crossed Demand Draft/Cash Receipt.
6.4 It is the sole responsibility of the bidder to confirm from the E-Tender Portal regarding
amendments ,if any ,or any other clarifications before uploading of the tender document.
6.5 . Firms registered under MSME/NSIC are exempted from remitting EMD/Cost of tender
document on production of valid certificate.
7. EARNEST MONEY DEPOSIT (EMD): (( This clause stands cancelled till 31-12-2021)
8. OPENING OF BIDS
The bids will be opened in single. The Tendering Authority will open both technical bid and
financial at time and date as mentioned in the NIT. The venue of opening will be the chamber of the
AGM( Plg) O / o General Manager, BSNL BHAVAN, Kannur–670002 or any other office
authorized for the purpose by the General Manager ,BSNL ,Kannur, in the presence of the bidders
or their authorized representative as may be present at the prescribed time and date of opening of the
tender. The bidders can view the opening details after the Tendering Authority opened them. The
date fixed for opening of bids, if subsequently declared as holiday by BSNL, the revised date of
schedule will be notified in the e-Tender Portal. However, in the absence of such notification, the
bids will be opened on the next working day, time remaining unaltered.
9. EVALUATION OF BIDS:
9.1 BSNL shall evaluate in detail and compare the substantially responsive bids. A substantially
responsive bid is one which confirms to all the terms and conditions of bid documents without
material deviation. A bid determined as substantially non responsive will be rejected by BSNL.
9.2 Evaluation will be made based on the total contract charges per annum (Sl.No.1,01 to 1.07) in the
financial bid. ie, on the basis of the total cost obtained by multiplying the quoted rate for each item of
work with quantity of work for one year and then summing up the amount quoted for carrying out
the whole work (Sl.No.1,01 to 1.07) ,but excluding GST.
The rate should be quoted both in figures and words in English in the quotation. However it shall not
be binding on BSNL to award the contract to the lowest bidder and the decision of the General
Manager, Kannur in this regard shall be final and binding on all.
9.3. It may be noted that the methodology given is applicable only for the purpose of evaluation of
bids and shall have no bearing on actual quantity of work/total payment to be made for the work to
be carried out.
10.SECURITY DEPOSIT:
All suppliers (including MSME/NSICs who are registered with the designated MSME/NSIC bodies,
like National Small Scale Industries Corporation etc.) shall furnish performance security to the
purchaser for an amount equal to 10% of the value of Advance purchase order within 14 days from
the date of issue of Advance Purchase Order by the Purchaser and valid for 30 months. In case
BSNL extends the CONTRACT beyond one year, PBG validity shall have to be extended
accordingly as per relevant tender clauses.
If the Security Deposit is in the form of PBG, the amount of PBG is 10% (ten percentage) of contract
value plus applicable GST).
The EMD and Security Deposit will not bear any interest.
E-Tender for Outsourcing BTS sites in Kannur BA
8
Signature & Seal of bidder
11. AGREEMENT (PERIOD OF CONTRACT)
The successful bidder will have to execute an agreement as per Section 10, after remitting the
security deposit, in a stamp paper of appropriate value at his own expenses. After executing the
agreement, the approved rate and contract shall be valid up to ONE year from the date of execution
of the agreement. The contract period can be extended on same terms and conditions for a period of
12 months, subject to satisfactory performance during the previous period by the contractor.
12. GENERAL
i) If the last date of receipt/opening of Tender happens to be a holiday, tenders will be received and
opened at the same time and venue as mentioned above on the next working day.
ii)All Tenders that are received after the last date and time prescribed above or are not accompanied
by EMD (Bid Security) or valid documentary proof establishing any exemptions in the matter of
EMD, besides the cost of the tender documents (if applicable) or are incomplete in any respect, or
are prepared or submitted without strictly following the terms and conditions and instructions carried
in the tender document, shall be summarily rejected.
iii)Amendments, if any, to the tender document will be notified in the website
https://etenders.gov.in/eprocure/app or www.kerala.bsnl.co.in as and when such amendments are
made. It is the sole responsibility of the bidders who have downloaded the tender document from the
website to keep themselves abreast of such amendments before submitting the tender document.
iv)Intending bidders are requested to register themselves with https://etenders.gov.in/eprocure/app or
www.kerala.bsnl.co.in for obtaining user-id and Password.
v)BSNL has decided to use the process of e-tendering for inviting this tender and thus the physical
copy of the tender would not be sold.
vi)Bidders may note that the tender document can be downloaded from the website
https://etenders.gov.in/eprocure/app or www.kerala.bsnl.co.in
vii)The bidders shall furnish a declaration that no addition /deletion /corrections have been made in
the downloaded tender document being submitted and it is identical to the tender document
appearing on Web-site https://etenders.gov.in/eprocure/app or www.kerala.bsnl.co.in as per Section
6.In case of any correction/addition/alteration/omission is found in the tender document ;the tender
bid shall be treated as non-responsive and shall be rejected.
viii)The total annual turnover (audited) of the bidder should be at least Rs.60 lakhs or more during
any one of the preceding three financial years (ie 2018-19, 2019-2020 & 2020-2021).
ix) The documents as listed out in clause 6 should be uploaded in the e-Tender Portal.
x) BSNL has adopted e-tendering process which offers a unique facility for, Public OnlineTender
Opening Event(TOE), BSNL‟s Tender Opening Officers as well as authorized representatives of
bidders can attend the Public Online Tender Opening Event(TOE) from the comfort of their offices.
However, if required, bidders or their authorized representatives can attend the Tender Opening
Event at the Office of General Manger, BSNL, BSNL BHAVAN, Kannur-670002 where BSNL‟s
Tender Opening Officers would be conducting Public Online Tender Opening Event(TOE).
xi) Incomplete, ambiguous, Conditional tender bids are liable to be rejected.
xii) All documents submitted in the bid offer should be preferably in English. In case the certificate
viz., experience, registration etc., is issued in any language other than English, the bidder shall
attach an English translation of the same duly attested by the bidder & the translator in addition to
the relevant certificate. All computer generated documents should be duly attested/signed by the
issuing organization.
xiii)All statutory taxes as applicable shall be deducted at source before payment.
E-Tender for Outsourcing BTS sites in Kannur BA
9
Signature & Seal of bidder
xiv) All computer generated documents should be duly signed/ attested by the bidder/ vendor
organization.
xv) The successful bidder should obtain registration from the Labour department within15 days
from the date of acceptance of the bid.
The General Manager, BSNL, Kannur reserves the right to cancel the tender at any stage of the
tendering processor accept or reject any or all the tenders received without assigning any reason and
is not bound to accept the lowest tender.
xvi) For any other queries please contact:
1. Mr. Jayalal S V, AGM (Planning), Kannur, Mob: +91 9495191616
2. Mr. Mahesh Kumar T, SDE (Planning), Kannur Mob: +91 9443100998
Asst. General Manager ( Plg )
BSNL Kannur, Kannur-670 002
E-Tender for Outsourcing BTS sites in Kannur BA
10
Signature & Seal of bidder
SECTION- 2Part A
SCOPE OF WORK
Mobile Access Equipment Maintenance (BSNL /N - BSNL/ IP)
All BTS related alarm need to be made functional and to be extended up to OMCR within
three month. (Penalty of Rs 50 per day per site for one month)
Prompt action (within 1 hour in city and 12 hours in Rural) on receipt of instructions (by call or
by SMS) from concerned officer regarding manual assistance in rectification of alarms/faults
in site. In case of no action in accepted time line Penalty per hour at the rate of Rs 10 per hour
per site)
Air filter cleaning in BTS/ Node B/ e-Node B, every month and entry in log book of site.
In case of BTS outages due to control card faults of BTSs / NODE-Bs fault, replace the fault
items with the spare module /cards as per instructions of BSNL Site In charge.
In case of Mini Link/ OFC failure, details of visual alarm noticed to be communicated to the
maintenance In-charge.
For prolonged failure of Electricity as intimated by BSNL officer, Coordination for
restoration of EB in consultation with BSNL Site/ IP In charge.
To check Earth Connectivity is available at BTS/ Node B.
The field staff being deployed should be provided with 2 SIMs one of BSNL & other from
private TSPs for communication when BTS site is down.
Any BSNL OFC breakdown en-route to be intimated to site in charge for prompt restoration
of OFC fault.
Site failure due to unsatisfactory support in Site upkeep activities which leads to prolonged
outage for more than 12 hrs in urban area and 48 Hours in Rural area will be treated as major
deviation and penalty @ Rs 50 per hour.
Up to 24 hrs of reporting of non-compliance related to above specific instance will be treated
as 1 minor deviation and further non completion of activity in every 3 days will be treated as
single instance.
Maintaining EMF related boards and help in providing data for Biennial submission of EMF
Radiation.
Antenna Orientation & Tilt as per requirement for optimization.
VSWR fault rectification per sector (includes reconnectorization, jumper cable change &
weather proofing)
Checking & correction of RF cable swap, L-1 antenna at RRH, removal of bird/honey
bee/wasp nest
Any other activity with minor modification in RF as per guidance of BSNL
Non-completion of ordered rigger activity within 3 days of intimation will be taken as minor
performance deviation. Every one week delay will be treated as one instance.
Each Minor performance deviation will result in penalty of Rs 50 except in case the deviation
is because of BSNL reasons.
Assistance in handling of minor store items.
Site wise capping of 12% is applicable in respect of minor performance deviations/ site upkeep
activities.
Penalties being charged for Major Performance Deviations attributable to the bidder will be
capped to 12% of the total contracted value for the services of the relevant invoice period.
E-Tender for Outsourcing BTS sites in Kannur BA
11
Signature & Seal of bidder
If the total penalties reaching the capping limit consecutively for three months, BSNL will
have the right to terminate the contract of the concerned SSA without any further notice.
If any fraudulent activity by the personnel deployed is detected by BSNL authorized
personnel/officer, then the bidder is liable to pay penalty as assessed by BSNL i.e. the cost of
consequential damages to installation(s)/DG set(s) would be deducted at actual, from the
service provider‟s bill. This will be over and above the other penalties and will not be subject
to capping if any.
Any tendered work not attended in time, BSNL will have the right to get it done from external
resources and payment made to them will be recovered from SP.
Mobile Infrastructure Maintenance (N-BSNL Sites )
Ensure working of Power plant alarms with OMC-R. (Penalty of Rs 8 per day per site for one month)
Prompt action (within 1 hour in city and 12 hours in Rural) on receipt of instructions (by call or
by SMS) from concerned officer regarding manual assistance in rectification of alarms/faults in
site. In case of no action in accepted time line (Penalty per hour at the rate of Rs 5 per hour per
site)
First line maintenance of power plants, battery and any problem reported. Any problem not
reported within 3 days for urban area and beyond 10 days will attract penalty of Rs 2 per day
per site for the days it has not reported.
Periodically check-up power plant modules working, load sharing and ensuring sufficient
Modules are available for Equipment in consultation with Site In charge and Charging of
Battery.
Tightening of all nuts /screws in interconnecting point of power cable from EB panel board to
each equipment, once in three months.
To ensure the control card is functioning properly so that battery do not go to deep discharge.
In case of any Power Plant outages due to fault in control card intimation to be given to Site In
charge for attending the same on priority.
Conducting Battery Backup test with Existing Load at least in quarterly & record the same in
Log Book.
Faulty Card/ Units need to be deposited at designated centre as per requirement & collect
repaired unit within 24 hours in urban and in 48 hours in rural areas and delay more than that
will be counted as one instance of minor deviation and penalty @ of Rs 50 per day will be
charged.
Replacement of the faulty modules with repaired Modules as per instructions of Site In charge
within 24 hours in urban and in 48 hours in rural areas is mandatory and any delay resulting in
downtime of equipment because of Non replacement of control card will be counted as major
deviation and will be charged @ Rs 20 per hour.
Bidder has to provide related testing equipments to discharge the functions listed.
Cleaning, security and up keeping of the site including all equipment, tower surroundings,
shelter/OD cabinet, DG etc. This includes bush cutting in the BTS sites in open areas. All tools
& Cleaning material to be provided by the bidder.
Routine check of free cooling systems available at site and DG set and other Equipments and
record the same in log book as per the periodicity defined for the visit as per tender. Reporting
of any alarms/faults/untoward incident to the concerned officer.
Running of DG sets as required.
E-Tender for Outsourcing BTS sites in Kannur BA
12
Signature & Seal of bidder
Assisting in Diesel filling in the DG Set available at the site.
Up to 24 hrs of reporting of non-compliance related to above specific instance will be treated
as 1 minor deviation and further non completion of activity in every 3 days will be treated as
single instance.
Site wise capping of 12% is applicable in respect of minor performance deviations / site
upkeep activities.
Penalties being charged for Major Performance Deviations attributable to the bidder will be
capped to 12% of the total contracted value for the services of the relevant invoice period.
If the total penalties reaching the capping limit consecutively for three months, BSNL will
have the right to terminate the contract of the concerned SSA without any further notice.
If any fraudulent activity by the personnel deployed is detected by BSNL authorized
personnel/officer, then the bidder is liable to pay penalty as assessed by BSNL i.e. the cost of
consequential damages to installation(s)/DG set(s) would be deducted at actual, from the
service provider‟s bill. This will be over and above the other penalties and will not be subject to
capping if any.
Any tendered work not attended in time, BSNL will have the right to get it done from external
resources and payment made to them will be recovered from SP.
Diesel filling
The activities to be carried out in the BTS sites are listed below.
Carrying Diesel from Pump and Diesel filling in the DG Set available at the sites.
Checking the level of diesel in the DG tank at the time of filling (opening level & closing) and
making entries in the Log book for diesel filling.
Collection of data directly from the site pertaining to monthly diesel reconciliation statement.
Checking the meter reading in the DG run hour meter (opening and closing) and Controller
logged hours (if available) and making entries of DG run hours in the Log book.
Ensuring availability of 50% tank capacity of diesel in the DG at any point of time.
Arranging test run in case, if any dispute arise between the Contractor and the BSNL official
concerned.
Bush cutting and clearing Vegetation from NBSNL sites:-
This includes bush/ grass/creepers/climbers cutting including small trees inside the tower base,
near the beds of OD BTS/OD Power plant/ O.D Node /DG/ OD battery bank etc. and removing
climbers from tower/shelter/DG/OD power plant etc. and clearing of weeds in the BTS site
compound
Rigger Activities:-
a. Climbing the tower (RTT/GBT) -up to 100m
b. Antenna re-orientation
c. Checking/Replacement of weather proof tapes to prevent water entry
d. Verification/replacement of connectors/fittings and Assistance in VSWR correction
e. Verification/correction of Lightning Arrestor and its fittings
f. Hoisting /De hoisting and associated installation work of AMF/Antenna
g. Any other related works in tower, as required by concerned BSS officer
Replacement of XAHT/other antennas
a. New dual antennas are to be collected from Mobile store at Thalasserry /Mattannur/
talipparamba/ Kanhangad and transportation to site.
b. Replacement of working XAHT and other type of antennas with dual antenna and making
the site functional.
E-Tender for Outsourcing BTS sites in Kannur BA
13
Signature & Seal of bidder
SECTION- 2 Part B
TECHNICAL SPECIFICATIONS/ REQUIREMENTS
A. Technical specifications:
The detailed scope of the works involved in the Tender are given below
1. Scope related to Diesel filling in DG Sets:
This is to carry out diesel filling in BSNL BTS sites on a periodic basis. On an average every
site needs diesel filling of one to two times per month. However in some of the sites, it can go up to
four times a month depending on the tank capacity and the frequency of EB supply interruption.
Other than the periodic refilling whenever there is emergency requirement, based on OMCR low
fuel alarm or message given by the concerned officer, refilling is to be arranged within three hours
on getting such intimation. Bidder has to ensure availability of 50 % tank capacity of diesel in
the DG at any point of time.
The diesel charges in respect of the usage of the diesel generator sets at the site shall be
reimbursed by BSNL in proportion to the actual diesel consumption, whenever diesel is procured by
vendor on payment basis. Depending on the log book data on Diesel filling and DG run hours in run
hour meter, the diesel charges in respect of each site will be paid by BSNL on monthly basis.
BSNL have an option to enter into direct MOU with oil companies for procurement of diesel
from their specified outlets through petro/ fleet cards. In such an event petro/ fleet card will be
issued to the contractor on proper acquaintance by the authorized person of the vendor & payment
will be made directly to the oil companies by BSNL. Any loss / misuse of the petro/ fleet cards
issued to the vendor will be the responsibility of the vendor. Any such losses will be recovered by
BSNL from the vendor by adjusting against the payment due to the vendor or will be recovered
from PBG. In the case of any misuse causing loss to BSNL, a penalty of 10% of the contract value
or forfeiture of the bank guarantee along with termination of contract, as decided by the competent
authority of BSNL will be imposed on the contractor. Any reduction in the diesel cost/ loyalty
benefits in view of the MOU will be availed by BSNL. It will be the responsibility of the contractor
to reconcile the diesel consumption as per actual usage in field with that in petrol/ fleet card
account. The payment of diesel cost from BSNL will be limited to actual consumption based on log
book after applying the ceiling limit based on the consumption computed with run Hr meter reading
and per hour consumption indicated in this tender document. The sites for which even one instance
of diesel filling per month is not recorded will not be considered for Diesel filling expenses for
the said month. The bills, will be verified, passed & forwarded by BSNL representative (Divisional
Engineer (BSS)) based on the consumption in litres/ Hr indicated in the tender document. Any extra
cost incurred will be the responsibility of the vendor. If the diesel cost through Petro/ fleet card is
found to be less than the diesel consumption based on mileage, the contractor will not have any
claim for the additional cost.
If the ceiling limit based on the Circle Average consumption/hour in a site is less than the
actual consumption based on log book entry continuously for two consecutive months, and the
contractor feels that Average consumption per liter in that site is to be reviewed due to aging of DG
or other factors then a test run can be requested by the vendor to calculate the Average
consumption/hour for that particular site. The test run will be conducted by a joint team
consisting of representatives of Contractor and BSNL. Test run will be conducted only on
quarterly basis. The test run report will be signed by the Contractor and the BSNL team (SDE BSS),
countersigned by DE(BSS) and to be submitted along with the performance report. If the test run
reports are not sent along with the performance report, the consumption will be taken as per the
circle average CPH and the HMR readings. The Average consumption/hour calculated will be
made applicable only in the subsequent Quarterly invoice period. The contractor can request for
only one test run in any site during the whole AMC period.
In the case of MOU with oil companies, BSNL will pay directly to the Oil companies. Any
excess usage of Diesel after tallying with log book entries/Run hour meter will be adjusted from the
vendor from their monthly bills.
E-Tender for Outsourcing BTS sites in Kannur BA
14
Signature & Seal of bidder
In about 45% of the sites, agreement with Building owner is available for house keeping
activities. Balance sites Mobile access equipment maintenance and Mobile infrastructure
maintenance activities are part of this tender.
The bidder has to maintain a log book in every site for Diesel filling, as per the format in
Annexure 2. It is the responsibility of the bidder to update the logbook promptly on Diesel filling.
Concerned BSNL officers will periodically verify the logbook entries and put their initials. The
bidder has to seal and lock the hour meter in the presence of BSNL representative. Every month the
hour meter reading is to be noted by bidder along with the BSNL representative and a consolidated
statement along with log book reports is to be submitted by the contractor. Under any
circumstances if any of the units like run hr meter is faulty then the diesel filling should be
done under the supervision of any of the BSNL officers/ persons authorized by BSNL. The
payment will be based on logbook entries, but will be limited to monthly consumption based on run
hour meter reading and BA Average consumption in litres/hour. The method for calculating the
same is as follows:
BA Average consumption in litres/hour for various makes of DG with Different
capacity
Capacity
Make
BA Avge consumption
in litres/hour *
7.5KVA
Eicher 1.6
Mahindra 1.8
Ph1 1.5
15KVA
FG Wilson / Innova 2.1/2.0
Eicher Ph IV/stanford 2.1/2.1
Eicher Ph V/ Diesel tec 1.8/2.0
APC/Automech 2.4/1.9
Mahindra/Indofrench 2.1/2.0
Kirloskar 2.1
Simpson 2.5
Jeevan 1.9
KEC 2.5
30KVA Kirloskar 3.0
Note:
* In case of addition of new make /type of DG in the BSNL network, the per hour diesel
consumption will be arrived by BSNL and will be intimated to the bidder. For some sites with high
load, CPH will be more than the circle average. Site wise CPH values are given in the Annexure.
Obtaining of special permit if any required, from Motor vehicle department for transporting Diesel
in bulk through motor vehicle, will be the responsibility of the contractor.
2. Mobile Access Equipment Maintenance and Mobile Infrastructure Maintenance
The BTS sites are classified into three categories : (i) Urban sites- sites in
Corporation/Municipal areas (ii) Rural sites – Sites in Panchayat areas (iii) Hard Stations – Sites
which are remote/geographically spread out (about 8km distance from nearby sites) or sites in hill
stations. The rate to be quoted are same for category (i) & (ii) sites where as separate rate is to be
quoted for category 3 sites. The maximum number sites which can be applied for these three
categories of sites are different.
The activities to be carried out in these three categories of sites are same as listed below.
E-Tender for Outsourcing BTS sites in Kannur BA
15
Signature & Seal of bidder
Mobile Access Equipment Maintenance
All BTS related alarm need to be made functional and to be extended up to OMCR within three
month. (Penalty of Rs 50 per day per site for one month)
Prompt action (within 1 hour in city and 12 hours in Rural) on receipt of instructions (by call or
by SMS) from concerned officer regarding manual assistance in rectification of alarms/faults in
site. In case of no action in accepted time line Penalty per hour at the rate of Rs 10 per hour per
site)
Air filter cleaning in BTS/ Node B/ e-Node B, every month and entry in log book of site.
In case of BTS outages due to control card faults of BTSs / NODE-Bs fault, replace the fault
items with the spare module /cards as per instructions of BSNL Site In charge.
In case of Mini Link/ OFC failure, details of visual alarm noticed to be communicated to the
maintenance In-charge.
For prolonged failure of Electricity as intimated by BSNL officer, Coordination for restoration
of EB in consultation with BSNL Site/ IP In charge.
To check Earth Connectivity is available at BTS/ Node B.
The field staff being deployed should be provided with 2 SIMs one of BSNL & other from private
TSPs for communication when BTS site is down.
Any BSNL OFC breakdown en-route to be intimated to site in charge for prompt restoration of
OFC fault.
Site failure due to unsatisfactory support in Site upkeep activities which leads to prolonged
outage for more than 12 hrs in urban area and 48 Hours in Rural area will be treated as major
deviation and penalty @ Rs 50 per hour.
Up to 24 hrs of reporting of non-compliance related to above specific instance will be treated as
1 minor deviation and further non completion of activity in every 3 days will be treated as
single instance.
Maintaining EMF related boards and help in providing data for Biennial submission of EMF
Radiation.
Antenna Orientation & Tilt as per requirement for optimization.
VSWR fault rectification per sector (includes reconnectorization, jumper cable change &
weather proofing)
Checking & correction of RF cable swap, L-1 antenna at RRH, removal of bird/honey bee/wasp
nest
Any other activity with minor modification in RF as per guidance of BSNL
Non-completion of ordered rigger activity within 3 days of intimation will be taken as minor
performance deviation. Every one week delay will be treated as one instance.
Each Minor performance deviation will result in penalty of Rs 50 except in case the deviation is
because of BSNL reasons.
Assistance in handling of minor store items.
Site wise capping of 12% is applicable in respect of minor performance deviations
/ site upkeep activities.
Penalties being charged for Major Performance Deviations attributable to the bidder will be
capped to 12% of the total contracted value for the services of the relevant invoice period.
If the total penalties reaching the capping limit consecutively for three months, BSNL will have
the right to terminate the contract of the concerned SSA without any further notice.
E-Tender for Outsourcing BTS sites in Kannur BA
16
Signature & Seal of bidder
If any fraudulent activity by the personnel deployed is detected by BSNL authorized
personnel/officer, then the bidder is liable to pay penalty as assessed by BSNL i.e. The cost of
consequential damages to installation(s)/DG set(s) would be deducted at actual, from the service
provider‟s bill. This will be over and above the other penalties and will not be subject to
capping if any.
Any tendered work not attended in time, BSNL will have the right to get it done from external
resources and payment made to them will be recovered from SP.
Mobile Infrastructure Maintenance (N-BSNL Sites )
Ensure working of Power plant alarms with OMC-R. (Penalty of Rs 8 per day per site for one
month)
Prompt action (within 1 hour in city and 12 hours in Rural) on receipt of instructions (by call or
by SMS) from concerned officer regarding manual assistance in rectification of alarms/faults in
site. In case of no action in accepted time line (Penalty per hour at the rate of Rs 5 per hour per
site)
First line maintenance of power plants, battery and any problem reported. Any problem not
reported within 3 days for urban area and beyond 10 days will attract penalty of Rs 2 per day
per site for the days it has not reported.
Periodically check-up power plant modules working, load sharing and ensuring sufficient
Modules are available for Equipment in consultation with Site In charge and Charging of
Battery.
Tightening of all nuts /screws in interconnecting point of power cable from EB panel board to
each equipment, once in three months.
To ensure the control card is functioning properly so that battery do not go to deep discharge.
In case of any Power Plant outages due to fault in control card intimation to be given to Site In
charge for attending the same on priority.
Conducting Battery Backup test with Existing Load at least in quarterly & record the same in
Log Book.
Faulty Card/ Units need to be deposited at designated centre as per requirement & collect
repaired unit within 24 hours in urban and in 48 hours in rural areas and delay more than that
will be counted as one instance of minor deviation and penalty @ of Rs 50 per day will be
charged.
Replacement of the faulty modules with repaired Modules as per instructions of Site In charge
within 24 hours in urban and in 48 hours in rural areas is mandatory and any delay resulting in
downtime of equipment because of Non replacement of control card will be counted as major
deviation and will be charged @ Rs 20 per hour.
Bidder has to provide related testing equipments to discharge the functions listed.
Cleaning, security and up keeping of the site including all equipment, tower surroundings,
shelter/OD cabinet, DG etc. This includes bush cutting in the BTS sites in open areas. All tools
& Cleaning material to be provided by the bidder.
Routine check of free cooling systems available at site and DG set and other Equipments and
record the same in log book as per the periodicity defined for the visit as per tender. Reporting
of any alarms/faults/untoward incident to the concerned officer.
Running of DG sets as required.
E-Tender for Outsourcing BTS sites in Kannur BA
17
Signature & Seal of bidder
Assisting in Diesel filling in the DG Set available at the site.
Up to 24 hrs of reporting of non-compliance related to above specific instance will be treated
as 1 minor deviation and further non completion of activity in every 3 days will be treated as
single instance.
Site wise capping of 12% is applicable in respect of minor performance deviations / site
upkeep activities.
Penalties being charged for Major Performance Deviations attributable to the bidder will be
capped to 12% of the total contracted value for the services of the relevant invoice period.
If the total penalties reaching the capping limit consecutively for three months, BSNL will
have the right to terminate the contract of the concerned SSA without any further notice.
If any fraudulent activity by the personnel deployed is detected by BSNL authorized
personnel/officer, then the bidder is liable to pay penalty as assessed by BSNL i.e. The cost of
consequential damages to installation(s)/DG set(s) would be deducted at actual, from the
service provider‟s bill. This will be over and above the other penalties and will not be subject to
capping if any.
Any tendered work not attended in time, BSNL will have the right to get it done from external
resources and payment made to them will be recovered from SP.
Any other miscellaneous work related to the BTS site maintenance, assigned by the concerned
Sub Divisional Engineer (BSS)/Junior Telecom Officer (BSS) or any other officer in charge of
BSS.
There are sites in which the owner is given the responsibility of keeping the tower premises
clean and tidy and to operate DG in power failure, in addition to ensuring general security .In such
cases; the remaining items in the scope of Mobile access equipment maintenance and Mobile
infrastructure maintenance mentioned above, will have to be carried out by the bidder and two such
sites (Partial sites) will be clubbed and taken as one full site.
2.1 Scope related with Rigger activities in BTS sites
2.1.1 Rigger Type 1
1. Climbing tower up to 100m for inspection/minor works as per the direction of concerned
BSNL officer in charge.
2. Redoing of IF connectors of micro wave systems on the top and bottom of different types
of towers.
3. Replacement of faulty jumper cable on the top of tower and bottom of tower in connection
with VSWR clearance.
4. Redoing of jumper cable connector on the top and bottom of tower in connection with
VSWR clearance.
5. Redoing of RF cable connector on the top and bottom of different types of towers in
connection with VSWR clearance.
6. VSWR clearance of repeater and home boosters. Fixing of EMF warning and danger boards
as per existing rule.
7. Tilt adjustment / Orientation change of antenna on the top of tower.
8. Hardware optimization of GSM BTS sites.
9. Verification/correction of Lightning Arrestor and its fittings/replacement of aviation lamp.
10. VSWR measurement analysis and corrections.
E-Tender for Outsourcing BTS sites in Kannur BA
18
Signature & Seal of bidder
11. Any other miscellaneous work related to the BTS site maintenance/BSS/NQM activities,
assigned by the concerned Sub Divisional Engineer(BSS/NQM)/Junior Telecom Officer
(BSS/NQM) or any other officer in charge of BSS/NQM. All the above activities is for
tower up to 80m.
2.1.2 Rigger Type 2
1. Replacement of faulty ODU of micro wave with good one on tower/Correcting MW LOS.
2. Installation of home booster/repeater.
3. Checking and replacement of faulty CPRI cable /RRU of Node Bs/any equipment on the top
of tower.
4. TMA mounting/ un-mounting related works on tower.
5. Tower maintenance related works like removing birds nests, bee hives etc.
6. Hoisting/De hoisting and associated installation work of AMF/Antenna
(SB/DB/TB/HW/any band antenna used by BSNL)/ any type and any size of Feeder
cable/Micro wave ODU/IF cable/CPRI cable/RRU/RRU power cable.
7. Any other miscellaneous work related to the BTS site maintenance/BSS/NQM activities,
assigned by the concerned Sub Divisional Engineer (BSS/NQM)/Junior Telecom Officer
(BSS/NQM) or any other officer in charge of BSS/NQM. All the above activities is for
tower up to 80m.
2.2 Scope related with Bush cutting/Clearing at BTS site
This includes bush/grass cutting including small trees inside the tower base and removing creepers
and climbers from tower/shelter/DG/OD power plants etc and clearing/cleaning of weeds in the
BTS site compound.DE (BSS) will issue work order for bush cutting as and when required and
work is to be completed within the time specified in the work order.
2.3 Replacement of XAHT/other antennas
a. New dual antennas are to be collected from Mobile store at Thalasserry /Mattannur/
Talipparamba/ Kanhangad and transportation to site.
b. Replacement of working XAHT and other type of antennas with dual antenna and making
the site functional.
3 OTHER CONDITIONS: 3.1 Bidder shall be responsible to have their own teams to perform the day-to-day works as per this
contract. The persons utilized by the contractor for Mobile access equipment maintenance and
Mobile infrastructure maintenance to subdivisions should be semi-skilled. The persons should
necessarily have a Two-wheeler and a mobile connection. They should visit the BTS Site, minimum
once in a day to carry out the activities listed in above clauses. They should also attend to the works
on call basis whenever there is such requirement, at any time. The persons utilized by the contractor
should preferably be a local resident with sufficient knowledge of operating DG and other
electronic switches fuse-carriers, fuse cut-outs and changeovers who shall reach the site within half
an hour of getting the calls. They should not be shared with other telecom service providers.
Minimum tools such as multi meter, screw driver etc. should be arranged by vendor. A
certificate to this effect shall be produced along with first invoice.
3.1.1Bidder shall be responsible to supply semi-skilled manual assistance on contract basis to
perform the BSS activities as per this contract. The persons utilized by the contractor for manual
assistance to subdivisions should be semi -skilled. The persons should necessarily have a Two-
wheeler and a mobile connection. The personnel supplied by the contractor shall be available to
BSNL for a minimum duration of 8 hours a day and the semi-skilled manual assistance must be
available on phone any time(6AM to 10 PM) to attend emergency works .Minimum tools such as
multi meter, screw driver etc. should be arranged by vendor. A certificate to this effect shall
be produced along with the first invoice.
E-Tender for Outsourcing BTS sites in Kannur BA
19
Signature & Seal of bidder
3.1.2Bidder shall be responsible to supply skilled Riggers to perform the rigger activities as per this
contract. The persons deployed by the contractor for Rigger activities at GSM BTS sites should be a
skilled worker. The person should know RF cable related tower works of any height. The
competency/workmanship of the workmen should be demonstrated before work in charge who
should be convinced of the capacity of the workmen to carry out tower related rigger activities. The
persons should necessarily have a Two-wheeler and a mobile connection. The workmen supplied by
the contractor should be available to BSNL on phone to attend rigger activities, break
down/emergency works on time between 6AM to 10 PM. All tools such as spanners, cutting plier
etc. and safety measures like helmet etc. required for rigger activities should be arranged by
vendor. A certificate to this effect shall be produced along with first invoice.
.2 This contract is valid for a period of one year. However BSNL reserves the right to extend the
duration of CONTRACT for further 12 months, at the same rate and terms & conditions.
3.3 BSNL also reserves the right to terminate this agreement at any time, by giving an advance
notice of one month.
3.4 The exact address details of all the BTS locations will be given as Annexure. The GSM BTS
locations are in the KANNUR BA area.
3.5 BSNL reserves the right to vary the quantity as per relevant tender clauses.
3.6 BSNL reserves the right to change the BTS locations under the contract, with 7 day‟s notice.
The bidder has to continue the support as per this contract in the changed locations.
3.7. Diesel filling should be from Public sector Oil companies or any other agencies approved by
BSNL. If there is an MOU by BSNL with Oil Companies for Petro/Fleet card, Diesel filling should
be with Petro/Fleet card as mentioned in Clause B.1 of Section III Part B.
3.8. As per this CONTRACT, the vendor has to ensure that there is no BTS outage due to delay in
Diesel filling or unsatisfactory Mobile access equipment maintenance and Mobile infrastructure
maintenance support, unsatisfactory manual assistance/Rigger.
3.9 Bidder shall station sufficient number of Persons to support the services as per this contract.
Persons should be placed in such a way that they are able to carry out the day to day activities as
mentioned in relevant clauses of this section and also to ensure compliance to performance
indicators given below.
Sl.No
Description of Nature of Cluster
Max Sites (Cluster size) that
can be allotted per Personnel
01
BTS Sites Classified as Hard stations where Sites are
Geographically spread apart (more than 8 km from
nearby site) or hill stations.
Four
02 BTS sites in Rural Sites other than the classified
Hard stations
Eight
03 BTS sites in Urban (Municipal/Corporation) areas Twelve
3.10 During the agreement period bidder shall assign a work supervisor who shall act as a single
point of contact in the BA for BSNL for handling any service related issues under the agreement.
The details of supervisor and personnel deployed may be furnished at the time of signing the service
contract with BSNL as per the Proforma at Annexure 2. The Petrocard/Fleet cards will be handed
over to the Work supervisor under acquaintance. The safe custody of Petrocard/Fleet card and
ensuring its proper handling is solely the responsibility of the Contractor. On the termination of the
Agreement/contract period, the Petrocard/Fleet cards are to be handed over to BSNL
3.11 Bidder shall ensure that the persons utilized are competent, responsible, reliable and capable of
meeting the service obligations as per the contract. If the performance of any person is found to be
unsatisfactory, such persons should be replaced within 7 days of notice. If the total numbers of
notices necessitated on unsatisfactory performance during the contract period are more than
25% of the total number of sites under Mobile access equipment maintenance and Mobile
infrastructure maintenance contract, then the competent authority of BSNL may consider
termination of the contract.
E-Tender for Outsourcing BTS sites in Kannur BA
20
Signature & Seal of bidder
3.12 The bidder shall provide proper identity card to the persons utilized/ subcontractors.
3.13 The bidder shall support/co-ordinate with other agencies working at the BTS sites, (which)
who are authorized by the BSNL.
3.14 No staff deployed directly or indirectly by the contractor for the CONTRACT service would
have any claim in any way for getting future employment in BSNL.
3.15 PAYMENT TO THE SERVICE PERSONNEL: The persons employed by the bidder are to
be paid by the bidder with fair wages as per Labour Laws of Central/State Government. Other
benefits to the persons like Bonus, ESI, Gratuity, EPF etc., are falling under the complete
responsibility of the bidder. All safety precautions are to be carried out by the house keeping
personnel, semi-skilled manual assistance, Rigger while performing their routine Mobile access
equipment maintenance and Mobile infrastructure maintenance /BSS activities. Any
injury/mishap caused to the worker during the course of work due to negligence or non-adherence
to standard safety measures shall be the responsibility of the bidder.
3.16 The bidder is governed by the Workmen‟s Compensation Act 1923 in case of any claim by the
persons employed by him/her/firm. The Service Contractor shall indemnify the Department (BSNL)
of all claims made by the employees of the service contractor.
3.17 Bidder shall have insurance / Group insurance scheme for the employees deployed for
CONTRACT.
3.18 The Bidder would set up an office and help desk with sufficient number of staff in designated
place in KANNUR to accept telephone calls/SMS/email from TSEs/BSNL officers.
3.19 The bidder should coordinate with OMCR and field level BSNL officers (BSS) to schedule
and monitor the Diesel filling and Mobile access equipment maintenance and Mobile
infrastructure maintenance activity. Arrangement to collect „Low fuel Alarms‟ from OMCR is to
be done by the bidder. Responsibility to communicate the centrally collected information from
OMCR alarms or by SMS/calls/email, to the concerned field persons is with the vendor.
3.20 The bidder should provide the contact details of all the persons/agencies marked for Diesel
filling activity, Bush cutting/removing of vegetation etc from BTS sites, manual assistance, rigger
and Mobile access equipment maintenance and Mobile infrastructure maintenance works to
the concerned BSS officers. In case of any change of persons, it should be with advance intimation
to the concerned BSNL officers with the changes in contact details, if any.
3.21 The Bidder will also maintain the logbook at each site (to be kept with BSNL) where in the
Daily routine visits/ checks, activities done as part of Mobile access equipment maintenance and
Mobile infrastructure maintenance, Diesel filling and DG run details are to be entered on a daily
basis. The same shall be countersigned by the concerned BSNL in-charge for reference. The format
of the logbook that will be kept at BTS site for recording the events is attached as Annexure -3 &4.
3.22 Officer in charge/duty officer of the BSNL site shall carefully monitor the entries and
countersign the logbook periodically.
3.23. The Bidder shall also maintain a consolidated record of the activities carried out as per this
contract, a copy of which along with performance reports from field unit is to be submitted along
with the invoice for payment on a quarterly basis.
3.24. In order to ensure the security of the network, bidder will be required to submit the signed
Non-Disclosure Agreement as per Section 12 within 15 days of Work order.
3.25. Bidder shall ensure that the agencies or any other representative concerned for support strictly
adheres to BSNL‟s Third Party Connection Acceptable Use Policy which is as follows:
a. Any change on equipment shall only be performed by the bidder after notification and
Approval by BSNL.
b. Passwords/locking system on any equipment will be set by BSNL representatives and should
not be changed by bidder‟s representative without the approval from concerned BSNL officer.
c. Bidder shall notify BSNL, when its employee who has access to BSNL
Equipment/configuration leaves the company or is transferred to another position which no
longer requires access. Also the bidder should surrender the Temporary ID cards of the
employees issued by any agency related to BSNL during the course of Mobile access
E-Tender for Outsourcing BTS sites in Kannur BA
21
Signature & Seal of bidder
equipment maintenance and Mobile infrastructure maintenance of specific sites at the time of
cessation of service of a Mobile access equipment maintenance and Mobile infrastructure
maintenance personnel from bidder‟s company or from the company to which bidder has
entered in to an agreement for service.
d. Bidder or its representatives shall not make a change on any system that is not directly related
to his job/duty.
e. The contractor shall comply with the statutory provisions/obligations under all laws in force.
f. The Contractor shall keep a comprehensive record of the workers being engaged on the work
with their full postal address and specimen signatures.
g. Record of attendance of the workmen shall be maintained by the contractor and the officer in
charge of the work.
h. The contractor shall observe the provisions of all the relevant laws of the land pertaining to
employment of workers/ labourers and their working conditions, payment of compensation etc.
Any cost/damages/penalties arising out of the violation of any of law /rules/regulations/orders
in relation to the activities undertaken by the contractor under this tender shall be fully borne
by the contractor and it shall be open for BSNL to recover any sums related to this from the
amount payable/refundable to the contractor
i. The contractor is responsible to supply all safety tools to the work men to carry out the work
and its compliance to be ensured.
4. JURISDICTION OF CONTRACT:
Jurisdiction of Contract will be areas under BSS Division Kannur with mobile sites in
Kannur and Kasargod areas with following details:
SL.NO Division Custodian of UG OF cable
Divisional Engineer(s) in
charge responsible for
execution of work.
1 Kannur
DE BSS Kannur DE BSS Kannur
E-Tender for Outsourcing BTS sites in Kannur BA
22
Signature & Seal of bidder
SECTION-2 Part C
SCHEDULE OF REQUIREMENTS (SOR)
Approved rate per
site/month in Rs.
Sl.No Description of
Quantity under
the
Activity/Sites Unit contract
Diesel Filling of DG sets(No of sites) Sites 342 685
1
2
Mobile access
equipment
maintenance and
Mobile
infrastructure
maintenance (No
of sites)
(A). General Sites
falling under Rural
& Urban areas
Sites 204 2075
(B). Sites falling
under Hard Station
Areas
Sites 40 2300
Description of Activity Unit Quantity under
the contract
Approved rate per instance in
Rs.
Bush cutting clearing of vegetation in
BTS Compound/tower Instances
600 instances of
cleaning/year 700
3
4 Rigger activity
Up to
50M instances
About 125
instances/month 1250
Above
50M
About 30
instances/month 1590
5
Replacement of XAHT/other Antennas
with dual band Antenna including
transportation of store to site
Instances 30 instances /year 2300
1 The quantity /no. /sites stated in SoR are estimated and BSNL reserves the right to vary the
quantity to the extent of -25 % to +25 % of specified quantity at the time of award of the
contract i.e. APO without any change in unit price or other terms & conditions.
2 BSNL Reserves the right for placement of additional order or up to 25% of the additional
quantities of goods and services contained in the running tender / contract within a period of
twelve months from the date of acceptance of APO in the tender at the same rate or a rate
negotiated (downwardly) with the existing vender considering the reasonability of rates based
on prevailing market conditions and the impact of reduction in duties and taxes etc. and
supplies to be obtained within delivery period scheduled afresh.
3 No. of instances per month for rigger and no. of instances per year for bush cutting is given
only for calculating contract value. The quantity may vary according to the actual requirement
in sites.
E-Tender for Outsourcing BTS sites in Kannur BA
23
Signature & Seal of bidder
SECTION-3
E-tendering Instructions to Bidders
Note : The instructions given below is an indicative one which is applicable for a specific e-tender
platform. However, there can be variations according to the platform being used. In case of any help
or clarification, contact MM cell, Phone no: 0120-4001002/ 4001005/6277787on working days.
General
These Special Instructions (for e-Tendering) supplement „Instruction to Bidders‟, as enclosed in Sec
4 Part A of the Tender Documents. Submission of Bids only through online process is mandatory
for this Tender.
For conducting electronic tendering, BSNL HQ is using the portal (URL of e-tender portal).
1. Broad outline of activities on e-tender portal from Bidders prospective
…………………………..
…………………………….
……………………………..
………………………………….
For participating in this tender online, the following instructions need to be read carefully. These
instructions are supplemented with more detailed guidelines on the relevant screens of the ETS.
2. Digital Certificates
For integrity of data and its authenticity/ non-repudiation of electronic records, and be
compliant IT Act 2000, it is necessary for each user to have a Digital Certificate (DC). also
referred to as Digital Signature Certificate (DSC), of Class 2 or above, issued by a Certifying
Authority (CA) licensed by Controller of Certifying Authorities (CCA) [refer
http://www.cca.gov.in].
3. Registration
To use the Electronic Tender® portal (https://etenders.gov.in/eprocure/app), vendor needs to
register on the portal (if not already registered). Registration of each organization is to be done by
one of its senior persons who will be the main person coordinating for the e-tendering activities.
Pay Annual Registration Fee if applicable.
Note: After successful submission of Registration details and Annual Registration Fee (as
applicable). Please contact Helpdesk (as given below), to get your registration accepted/activated.
4. Bid related Information for this Tender (Sealed Bid)
Bidders should refer to User Manual for SO (Supplier Organization) in USER GUIDANCE on
https://etenders.gov.in/eprocure/app (URL of e-tender portal).
Bidders must ensure that all documents uploaded on e-tender portal as files or zipped folders,
contain valid files and are not corrupt or damaged due to any processing at bidder PC system like
zipping etc. It shall be the responsibility of bidder himself for proper extractability of uploaded
zipped files. Any error/ virus creeping into files/folder from client end PC system cannot be
monitored by e-tender software/ server and will be bidder‟s responsibility only.
In case the files are non-extractable or illegible otherwise, then the bidder‟s authorized
representative shall be given one chance by Tender Opening Committee to open and demonstrate
the contents of bid data downloaded from the e-tender portal in his presence. If, even after above
chance, the bidder is unable to open and demonstrate the contents of bid data downloaded from the
e-tender portal in his presence then no fresh bid in any form, soft or hard copies, shall be accepted
by tendering authority and his bid shall be summarily rejected and treated as non-responsive.
E-Tender for Outsourcing BTS sites in Kannur BA
24
Signature & Seal of bidder
NOTE 2: In case any discrepancy between information entered by bidder in the electronic
form/template and that as per the supporting document uploaded, then information as per uploaded
supporting documents shall prevail over the information in the electronic form/template.
5. Offline Submissions:
The bidder is requested to submit the following documents offline to AGM (planning), O/o
GMTD, BSNL, Kannur on or before the date and time of submission of bids specified in covering
letter of this tender document, in a Sealed Envelope. The envelope shall bear (name of the work),
the tender number and the words „DO NOT OPEN BEFORE‟ (due date and time).
i. EMD-Bid Security declaration in Original. ( This clause stands cancelled till 31-12-
2021)
ii. DD/ Bankers cheque against payment of tender fee if applicable.
iii. Power of attorney in accordance with Clause 14.3 of Section-4 Part A.
iv. Sealed pass-phrases
6. Other Instructions For further instructions, the vendor should visit the home-page of the portal
(https://etenders.gov.in/eprocure/app URL of e-tender portal), and go to the User-Guidance
Center
Note: It is strongly recommended that all authorized users of Supplier organizations should
thoroughly peruse the information provided under the relevant links, and take appropriate action.
This will prevent hiccups, and minimize teething problems during the use of e-tender portal.
E-Tender for Outsourcing BTS sites in Kannur BA
25
Signature & Seal of bidder
SECTION-4
GENERAL (COMMERCIAL) CONDITIONS OF CONTRACT
1. APPLICATION
The general condition shall apply in contracts made by the purchaser for the procurement of
goods.
2. STANDARDS
The goods supplied under this contract shall conform to the standards prescribed in the Technical
Specifications mentioned in section -2.
3. PATENT RIGHTS
The supplier shall indemnify the purchaser against all third-party claims of infringement of
patent, trademark or industrial design rights arising from use of the goods or any part thereof in
Indian Telecom Network.
4. PERFORMANCE SECURITY
4.1 All suppliers (including MSMEs who are registered with the designated MSME bodies, like
National Small Scale Industries Corporation etc. shall furnish performance security to the purchaser
for an amount equal to 10% of the value of Advance purchase order within 14 days from the date of
issue of Advance Purchase Order by the Purchaser and valid for 30 months. In case BSNL extends
the CONTRACT beyond one year, PBG validity shall have to be extended accordingly as per
relevant tender clauses.
4.2 If the Security Deposit is in the form of PBG, the amount of PBG is 10% (ten percentage) of
contract value plus applicable GST).
4.3 The proceeds of the performance security shall be payable to the Purchaser as compensation for
any loss resulting from the supplier's failure to complete its obligations under the contract.
4.4 The performance security Bond shall be in the form of Bank Guarantee issued by a scheduled
Bank and in the proforma provided in Section 11.
4.5 The performance security Bond will be discharged by the Purchaser after completion of the
supplier's performance obligations including any warranty obligations under the contract. If BSNL
is not satisfied with the performance of bidder during CONTRACT, it reserves the right to en cash
the Performance Bank Guarantee and/or without prejudice to any other remedy for breach of
contract, by termination notice of default, giving a time of 30 days to bidder, terminate the Contract
in whole or in part.
5.PAYMENT TERMS(Contract charges and payments):-
5.1. The CONTRACT charges shall be processed by BSNL on monthly basis at the end of each
month from the beginning of CONTRACT. The monthly payments will be made after deducting
penalties (mentioned in clause 4 of Section 2), based on the performance reports from field units
5.2 This price is total composite inclusive of all levies and taxes, insurance and incidental
charges,TDS, the building and other construction workers welfare cess (Rules 1998) and all other
applicable taxes on time to time will be recovered from the bill.
5.3 Reimbursement of Diesel cost will be done on a monthly basis, based on the invoice raised by
the contractor. The Diesel invoices are to be prepared by the bidder based on the logbook entries
after applying the capping based on run hour meter as specified in relevant clauses. The invoices are
to be prepared subdivision wise, duly got signed by Sub Divisional Engineer(BSS), counter signed
by DE(BSS) and to be forwarded to AGM(MM), O/o General Manager, BSNL, BSNL BHAVAN,
KANNUR-11 at the end of every month. In the case of direct payment of Diesel cost to Oil
companies as specified in Section 2, any excess Diesel cost incurred after applying the capping will
be recovered from the vendor from the Monthly bills submitted.
5.4 The contractor shall submit monthly invoice to AGM (MM) before 10th
of every month along
with following documents
E-Tender for Outsourcing BTS sites in Kannur BA
26
Signature & Seal of bidder
(i) Monthly performance report for DF& Mobile access equipment maintenance and Mobile
infrastructure maintenance, rigger and manual assistance and bush cutting along with
quantity and site list signed by SDE BSS/NQM and countersigned by DE BSS.
(ii) Monthly Diesel reconciliation statement as per annexure 7 signed by the bidder (soft copy
of the statement must be forwarded to SDE(BSS) for verification before 5th
of every month)
and site wise diesel filing data in Excel as per Annexure 8 (to be mailed to SDE (BSS)
concerned after the utilization of each transaction of petro card for uploading in ERP)
(iii) Copy of logbook for rigger activities in a month,
(iv) Certificate for provision of tools and safety measures as per clause 3 in Section 2 Part B.
(v) Test run report if CPH is higher than the site wise CPH mentioned in tender.
(vi) List showing the details of supervisor, Mobile access equipment maintenance and Mobile
infrastructure maintenance /rigger/manual assistance as per Annexure 1.
(vii) The amount of wages paid to such personnel for the duration in question as per Annexure 6.
(viii) Copies of authenticated documents of payments of such contribution of EPF
Authorities (ECR etc.) and ESI.
5.5 Incomplete bills and bills without any one of the document will be rejected. The payment of the
employees should be made through bank and a copy of payment should be submitted in the next bill.
5.6The compensation for interruption of service rendered by the Contractor, or cost of materials or
stores lost or damaged while carrying out the work or cost of defective components, spares or tools
towards damage of other utility services while carrying out the work will be deducted from the bills
submitted for payment. The Security Deposit shall be considered for adjustment against
compensation/other sum due, only at the time of financial settlement of bills.
5.7 BSNL‟s decision will be final on all matters relating to the work and will be binding on the
contractor.
5.8 Paying authority shall be The Accounts Officer (Cash), O/o General Manager, BSNL
KANNUR .
5.9 The bidder has to give the mandate for receiving payment electronically and the charges, if
any, levied by bank has to be borne by the bidder/ contractor/supplier. The bidder company is
required to give the following information for this purpose:-
(a) Beneficiary Bank Name:
(b) Beneficiary branch Name:
(c) IFSC code of beneficiary Branch
(d) Beneficiary account No.:
(e) Branch Serial No. (MICR No.):
6.PRICES
6.1 Prices charged by the supplier for goods delivered and services performed under the contract
shall not be higher than the prices quoted by the Supplier in its Bid except for variation caused by
change in taxes/ duties as specified in Clause-10.2 mentioned below.
6.2 For changes in taxes/ duties during the scheduled delivery/execution period, the unit price shall
be regulated as under:
a. Prices will be fixed at the time of issue of purchase order as per taxes and statutory duties
applicable at that time
b. In case of reduction of taxes and other statutory duties during the scheduled delivery period,
purchaser shall take the benefit of decrease in these taxes/ duties for the supplies made from the
date of enactment of revised duties/taxes.
c. In case of increase in duties/taxes during the scheduled delivery period, the purchaser shall
revise the prices as per new duties/ taxes for the supplies, to be made during the remaining
delivery period as per terms and conditions of the purchase order.
E-Tender for Outsourcing BTS sites in Kannur BA
27
Signature & Seal of bidder
6.3 Any increase in taxes and other statutory duties/ levies, after the expiry of the delivery date shall
be to the supplier's account. However, benefit of any decrease in these taxes/duties shall be passed
on to the Purchaser by the supplier. The total price is to be adjusted (by reducing the basic price)
with increased duties and taxes as per price mentioned in PO.
7. CHANGES IN PURCHASE ORDERS
7.1 The purchaser may, at any time, by a written order given to a supplier, make changes within the
general scope of the contract in any one or more of the following:
(a) drawings, designs or specifications, where Goods to be supplied under the contract are to be
specifically manufactured for the Purchaser;
(b) the method of transportation or packing;
(c) the place of delivery; or
(d) the services to be provided by the supplier.
7.2 If any such change causes an increase or decrease in the cost of, or the time required for the
execution of the contract an equitable adjustment shall be made in the contract price or delivery
schedule, or both, and the contract shall accordingly be amended. Any proposal by the supplier
for adjustment under this clause must be made within thirty days from the date of the receipt of
the change in order.
8. FORCE MAJEURE
8.1 If, at any time, during the continuance of this contract, the performance in whole or in part by
either party of any obligation under this contract is prevented or delayed by reasons of any war or
hostility, acts of the public enemy, civil commotion, sabotage, fires, floods, explosions, epidemics,
quarantine restrictions, strikes, lockouts or act of God (hereinafter referred to as events) provided
notice of happenings of any such eventuality is given by either party to the other within 21 days
from the date of occurrence thereof, neither party shall by reason of such event be entitled to
terminate this contract nor shall either party have any claim for damages against other in respect of
such non-performance or delay in performance, and deliveries under the contract shall be resumed
as soon as practicable after such an event come to an end or cease to exist, and the decision of the
Purchaser as to whether the deliveries have been so resumed or not shall be final and conclusive.
Further that if the performance in whole or part of any obligation under this contract is prevented or
delayed by reasons of any such event for a period exceeding 60 days, either party may, at its option,
terminate the contract.
8.2 Provided, also that if the contract is terminated under this clause, the Purchaser shall be at
liberty to take over from the Supplier at a price to be fixed by the purchaser, which shall be final, all
unused, undamaged and acceptable materials, bought out components and stores in course of
manufacture which may be in possession of the Supplier at the time of such termination or such
portion thereof as the purchaser may deem fit, except such materials, bought out components and
stores as the Supplier may with the concurrence of the purchaser elect to retain.
9. ACTION BY PURCHASER AGAINST BIDDER(S)/ VENDOR(S) IN CASE OF
DEFAULT.
In case of default by Bidder(s)/ Vendor(s) such as
(a) Failure to perform any other obligation(s) under the Contract; and
(b) Or any other default as per clause 4.1 of section IVPurchaser will take action as specified
in clause 4.2 of section IV
E-Tender for Outsourcing BTS sites in Kannur BA
28
Signature & Seal of bidder
10. ARBITRATION:
Except as otherwise provided elsewhere in the contract, if any dispute, difference, question
or disagreement arises between the parties hereto or their respective representatives or assignees,
in connection with construction, meaning, operation, effect, interpretation of the contract or
breach thereof which parties unable to settle mutually, the same shall be referred to Arbitration as
provided hereunder.
(1) A party wishing to commence arbitration proceedings shall revoke Arbitration Clause by
giving 60 days‟ notice to the designated officer of the other party. The notice invoking
arbitration shall specify all the points of disputes with details of the amount claimed to be
referred to arbitration at the time of invocation of arbitration and not thereafter. If the
claim is in foreign currency, the claimant shall indicate its value in Indian Rupee for the
purpose of constitution of the arbitral tribunal.
(2) The number of arbitrators and the appointing authority will be as under.
Claim amount (excluding claim
for counter claim, if any) Number of arbitrator Appointing authority
Above Rs.5 lakhs to Rs. 5 Sole Arbitrator to be BSNL ( Note: BSNL will forward a
crores appointed from a panel of list containing names of three
arbitrators of BSNL empanelled arbitrators to the other
party for selecting one from the list
who will be appointed as sole
arbitrator by BSNL)
Above Rs. 5 crores 3 Arbitrators One arbitrator by each party and the
3rd
arbitrator, who shall be presiding
arbitrator, by the two arbitrators.
BSNL will appoint its arbitrator for its
panel.
(3) Neither party shall appoint its serving employee as arbitrator.
(4) If any of the Arbitrators so appointed dies, resigns, becomes incapacitated or withdraws
for any reason from the proceedings, it shall be lawful for the concerned party/arbitrators
to appoint another person in his place in the same manner as aforesaid. Such person shall
proceed with the reference for the stage where his predecessor had left it both parties
consent for the same; otherwise, he shall proceed de novo.
(5) Parties agree that neither party shall be entitled for any pre-reference or pendent elite
interest on its claims. Parties agree that any claim for such interest made by any party shall
be void.
(6) In case of sole arbitrator, BSNL shall make all necessary arrangements for the travel/stay
and the expenses incurred shall be shared equally by the parties.
(7) The arbitration proceedings shall be held at New Delhi or Circle or SSA Headquarter ( as
the case may be)
19. SET OFF:
19.1 Any sum of money due and payable to the contractor (including security deposit
refundable to him) under this contract may be appropriated by the Company or any other person
or persons contracting through the CMD, BSNL and set off the same against any claim of the
Company or such other person or persons for payment of a sum of money arising out of this
E-Tender for Outsourcing BTS sites in Kannur BA
29
Signature & Seal of bidder
contract made by the Contractor with the company or such other person or persons contracting
through CMD, BSNL.
19.2 In case of set off of the security deposit against any claim as in 19.1 above, the GST
on such set off will be borne by the supplier.
19.3 GST would not be liable on Security Deposit. But if supplier set off the security
deposit against any claim as in 19.1 and 19.2 above, then GST would be levied.
15. COURT JURISDICTION
15.1 Any dispute arising out of the tender/ bid document/ evaluation of bids/ issue of APO shall be
subject to the jurisdiction of the competent court at the place from where the NIT/ tender has been
issued.
15.2 Where a contractor has not agreed to arbitration, the dispute/ claims arising out of the
Contract/ PO entered with him shall be subject to the jurisdiction of the competent Court at the
place from where Contract/ PO has been issued. Accordingly, a stipulation shall be made in the
contract as under.
“This Contract/ PO is subject to jurisdiction of Court at KANNUR only”.
E-Tender for Outsourcing BTS sites in Kannur BA
30
Signature & Seal of bidder
SECTION 5
BIDDER'SPROFILE
Passport size Photograph (To
be pasted) of the
Bidder/authorized Signatory
holding Power of Attorney
with signature on the
Front side of Photograph
overlapping the form
1 Name of the bidder
2 Name of the person submitting the tender
(In case of Proprietary / Partnership firms,
the tender has to be signed by Proprietor /
Partner)
3 Address of the firm
4.a Telephone No. (with STD code)
4.b Mobile No.
4.c Fax No.
4.d E-Mail Address
5 Registration & incorporation particulars of
the firm (Please attach attested copies of
documents of registration / incorporation
of your firm with the competent authority
as required by business law)
5.a Proprietorship
5.b Partnership
5.c Private limited
5.d Public limited
6 Name of Proprietor/Partner/Directors
7 PAN No
8 GST Registration No
Has the firm been blacklisted by any Organization? If so, attach details thereof. *
Is the Bidder aware of all the Rules and
Guidelines of Government on the subject of tender? (Write YES or NO)
I/We hereby declare that the information furnished above is true and correct.
Place: Signature of bidder /authorised
signatory
Date:
Name & Seal of the bidder
E-Tender for Outsourcing BTS sites in Kannur BA
31
Signature & Seal of bidder
SECTION 6
UNDERTAKING &DECLARATION For understanding the terms &conditions of Tender & Specification of work.)
Certified that
1. I/We ……………………………………. Have read, understood and agree with
all the terms and conditions , specifications included in the tender documents &
offer to execute the work at the rates quoted by us in the tender form.
2. IfI/We fail to enter into the agreement &commence the work in time, the EMD/SD
Deposited by us will stand forfeited to the
BSNL. b) The bidder here by covenants and
declares that:
1. All the information, Documents, Photocopies of the Documents/Certificates enclosed along with the Tender offer are correct.
2. If anything is found false and/or incorrect and/or reveals any suppression of fact at
any time, BSNL reserves the right to debar our tender offer/cancel the LOA/Purchase/
work order If issued and forfeit the EMD/SD/Bill amount pending with BSNL. In
Addition, BSNL may debar the contractor from participation in its future tenders.
3.No addition/deletion/corrections have been made in the downloaded tender document
being submitted and it is identical to the tender document appearing on the website.
In case of any correction/addition/alteration/omission in the tender document, the
tender bid shall be treated as non-responsive and shall be rejected summarily. Date:---------------------------------- Signature Of Bidder.
Place---------------------------------- Name of bidder Along with date &seal.
E-Tender for Outsourcing BTS sites in Kannur BA
32
Signature & Seal of bidder
SECTION 7
No Near relative certificate I/ We………………………………………..……S/o……………………………………………………… here by certify that none of my relative(s),as defined in the tender document is /are employed in BSNL units as per definitions given in tender document. In case, at any stage, it is found that the information given by me/us is false/ incorrect, BSNL shall have the absolute right to take any action as deemed fit/ without any prior intimation to me/us.
Signature of the Bidder Note: The near relatives for this purpose are defined as:
A. Members of a Hindu Undivided family. B. They are husband and wife.
C. The one is related to the other in the manner as father, mother, son(s) and son‟s Wife (Daughter-in-law) , Daughter(s) and daughter‟s husband (Son-in-law), Brother(s) and brother‟s wife, sister(s) and sister‟s husband (Brother-in-law) Note: In case of proprietorship firm, certificate will be given by the proprietor, for partnership
firm, certificate will be given by all the partners and incase of Private Ltd. Company, by all
the directors of the company.
SECTION 8
Letter of Authorisation for attending Bid opening (To be submitted before T\ender Opening)
Subject: Authorization for attending bid opening on Tender of
(date) for the
Following person is/are hereby authorized to attend the bid opening for the tender mentionedabove on behalf of given below.
(Bidder) in order of preference
Order of Preference Name Specimen Signatures
I
2.
__ _ _ _
_ __
Signature of bidder Or Officer authorized to
sign the bid Documents on behalf of the
bidder Note: 1.A maximum of two representatives will be permitted per bid to attend bid opening.
Permission for entry to the hall where bids are opened may be refused in case authorization as
prescribed above is not received.
E-Tender for Outsourcing BTS sites in Kannur BA
33
Signature & Seal of bidder
SECTION 9
UNDERTAKING REGARDING GENUINENESS OF THE DOCUMENTS /INFORMATION SUBMITTED
I,Shri/Smt...................................................................................Son/Daughter of
Shri............................................................... do hereby undertake that all the documents / certificates
submitted by me with this tender (E Tender for Diesel Filling, Mobile access equipment
maintenance and Mobile infrastructure maintenance, bush cutting & Rigger activities @ BTS
sites in KANNURBA)are true and are exact copies of the original documents/ certificates are
available with me.
I further undertake that if at any time any information furnished in the documents / certificates submitted by me are found to be false, BSNL will have every right to take suitable action against me including forfeiture of my EMD/Performance Security Deposit, termination of my contact agreement and/or black-listing of my contract as deemed fit.
Place: Signature of bidder/ Authorised signatory
Date: Name &Seal of the bidder
E-Tender for Outsourcing BTS sites in Kannur BA
34
Signature & Seal of bidder
SECTION 10 SERVICE CONTRACT AGREEMENT FOR DIESEL FILLING, Mobile access equipment
maintenance and Mobile infrastructure maintenance, BUSH CUTTING AND RIGGER IN
GSM BTS SITES IN KANNUR BA
Ref: Tender No: PLG/MM/ E-Tender/ BSS/Out Sourcing/2021-22/3 Dated at Kannur the 15-11-
2021
This agreement is made ………………. between ………………….a unit of M/s Bharat Sanchar
Nigam Limited, a company registered under the Companies Act 1956 having license to provide all
types of telecom services and having its registered office at Bharath BSNL BHAVAN,HC Mathur
Lane, Janpath Road, New Delhi – 110 001 (hereinafter called the BSNL) of the ONE PART
The term “BSNL” unless repugnant to the context, shall include its successor and persons
nominated or appointed by BSNL and interlaid, deal with supervision of the execution of the
agreement.
AND
................................... having its registered office at.............hereinafter called CONTRACTOR
which expression shall unless repugnant to the context, include its successors in business, legal
representatives and administrators or permitted assigns) of the OTHER PART for Diesel filling,
Mobile access equipment maintenance and Mobile infrastructure maintenance, bush cutting and
rigger activities in GSM BTS sites Kannur BA.
The term/expression “Contractor” shall, unless repugnant to the context, include its
successor/assignees in business, administrators, liquidator or legal representative of the company
(the second Party to the agreement)
BSNL and the Contractor which are parties to this agreement shall be collectively be referred to
as “the Parties” and individually as “Party” WHEREAS the Contractor has made the offer to duly
comply with all the provisions, terms and conditions of the aforesaid tender and its clarifications
pertaining to Service contract for Diesel filling, Mobile access equipment maintenance and
Mobile infrastructure maintenance, bush cutting and rigger activities in the GSM BTS sites in
KANNUR BA after making himself fully aware and understanding fully the implications of the
terms and conditions mentioned thereof and submitted the acceptance of the APO issued vide No.
…………….. vide their letter …………. submitting also the required performance security and
acceptance for APOs.
AND WHEREAS pursuant to the understanding of the Parties the Contractor has agreed for
Diesel filling, Mobile access equipment maintenance and Mobile infrastructure maintenance,
bush cutting and rigger activities in GSM BTS sites as listed in Annexure ……… and as per the
scope of the work, supporting BSNL for Diesel filling and Mobile access equipment maintenance
and Mobile infrastructure maintenance, bush cutting and rigger activities in GSM BTS sites.
NOW the AGREEMENT WITNESSETH as follows:
1. EFFECITVE DATE OF CONTRACT:
This Agreement will be effective from …
2. PERIOD OF CONTRACT
This Agreement shall remain in force for a period of One Year from the date of start of SERVICE
CONTRACT i.e. with effect from …. (“SERVICE CONTRACT Period”) for Diesel filling
Mobile access equipment maintenance and Mobile infrastructure maintenance, bush cutting
and rigger activities in the GSM network of Kannur BA and as listed in Annexure …. and as per
the scope of work .
3. EXTENSION OF THE CONTRACT
The BSNL reserves the right to extend the SERVICE CONTRACT period further for a period
maximum of 12 months duration with the same contractor after the expiry of the SERVICE
CONTRACT period. The payment of the same will be made on the same rates with the
applicability of all terms and conditions as mentioned in this agreement and the bid document. The
E-Tender for Outsourcing BTS sites in Kannur BA
35
Signature & Seal of bidder
contractor(s) shall submit the requisite Performance Bank Guarantee equal to the 10% amount of
SERVICE CONTRACT charges of one year and having validity of 30 months.
4. SCOPE OF THE CONTRACT
4.1 Mobile Access Equipment Maintenance (BSNL /N - BSNL/ IP)
All BTS related alarm need to be made functional and to be extended up to OMCR within
three month. (Penalty of Rs 50 per day per site for one month)
Prompt action (within 1 hour in city and 12 hours in Rural) on receipt of instructions (by
call or by SMS) from concerned officer regarding manual assistance in rectification of
alarms/faults in site. In case of no action in accepted time line Penalty per hour at the rate
of Rs 10 per hour per site)
Air filter cleaning in BTS/ Node B/ e-Node B, every month and entry in log book of site.
In case of BTS outages due to control card faults of BTSs / NODE-Bs fault, replace the
fault items with the spare module /cards as per instructions of BSNL Site In charge.
In case of Mini Link/ OFC failure, details of visual alarm noticed to be communicated to
the maintenance In-charge.
For prolonged failure of Electricity as intimated by BSNL officer, Coordination for
restoration of EB in consultation with BSNL Site/ IP In charge.
To check Earth Connectivity is available at BTS/ Node B.
The field staff being deployed should be provided with 2 SIMs one of BSNL & other from
private TSPs for communication when BTS site is down.
Any BSNL OFC breakdown en-route to be intimated to site in charge for prompt
restoration of OFC fault.
Site failure due to unsatisfactory support in Site upkeep activities which leads to
prolonged outage for more than 12 hrs in urban area and 48 Hours in Rural area will be
treated as major deviation and penalty @ Rs 50 per hour.
Up to 24 hrs of reporting of non-compliance related to above specific instance will be
treated as 1 minor deviation and further non completion of activity in every 3 days will
be treated as single instance.
Maintaining EMF related boards and help in providing data for Biennial submission of
EMF Radiation.
Antenna Orientation & Tilt as per requirement for optimization.
VSWR fault rectification per sector (includes reconnectorization, jumper cable change &
weather proofing).
Checking & correction of RF cable swap, L-1 antenna at RRH, removal of bird/honey
bee/wasp nest.
Any other activity with minor modification in RF as per guidance of BSNL.
Non-completion of ordered rigger activity within 3 days of intimation will be taken as
minor performance deviation. Every one week delay will be treated as one instance.
Each Minor performance deviation will result in penalty of Rs 50 except in case the
deviation is because of BSNL reasons.
Assistance in handling of minor store items.
Site wise capping of 12% is applicable in respect of minor performance deviations
/ site upkeep activities.
E-Tender for Outsourcing BTS sites in Kannur BA
36
Signature & Seal of bidder
Penalties being charged for Major Performance Deviations attributable to the bidder will
be capped to 12% of the total contracted value for the services of the relevant invoice
period.
If the total penalties reaching the capping limit consecutively for three months, BSNL
will have the right to terminate the contract of the concerned SSA without any further
notice.
If any fraudulent activity by the personnel deployed is detected by BSNL authorized
personnel/officer, then the bidder is liable to pay penalty as assessed by BSNL i.e. The
cost of consequential damages to installation(s)/DG set(s) would be deducted at actual,
from the service provider‟s bill. This will be over and above the other penalties and will
not be subject to capping if any.
Any tendered work not attended in time, BSNL will have the right to get it done from
external resources and payment made to them will be recovered from SP.
Mobile Infrastructure Maintenance (N-BSNL Sites )
Ensure working of Power plant alarms with OMC-R. (Penalty of Rs 8 per day per site for one
month).
Prompt action (within 1 hour in city and 12 hours in Rural) on receipt of instructions (by call
or by SMS) from concerned officer regarding manual assistance in rectification of alarms/faults.
in site. In case of no action in accepted time line (Penalty per hour at the rate of Rs 5 per hour
per site).
First line maintenance of power plants, battery and any problem reported. Any problem not
reported within 3 days for urban area and beyond 10 days will attract penalty of Rs 2 per day
per site for the days it has not reported.
Periodically check-up power plant modules working, load sharing and ensuring sufficient
Modules are available for Equipment in consultation with Site In charge and Charging of
Battery.
Tightening of all nuts /screws in interconnecting point of power cable from EB panel board to
each equipment, once in three months.
To ensure the control card is functioning properly so that battery do not go to deep discharge.
In case of any Power Plant outages due to fault in control card intimation to be given to Site
In charge for attending the same on priority.
Conducting Battery Backup test with Existing Load at least in quarterly & record the same in
Log Book.
Faulty Card/ Units need to be deposited at designated centre as per requirement & collect
repaired unit within 24 hours in urban and in 48 hours in rural areas and delay more than that
will be counted as one instance of minor deviation and penality @ of Rs 50 per day will be
charged.
Replacement of the faulty modules with repaired Modules as per instructions of Site In charge
within 24 hours in urban and in 48 hours in rural areas is mandatory and any delay resulting in
downtime of equipment because of Non replacement of control card will be counted as major
deviation and will be charged @ Rs 20 per hour.
Bidder has to provide related testing equipments to discharge the functions listed.
Cleaning, security and up keeping of the site including all equipment, tower surroundings,
shelter/OD cabinet, DG etc. This includes bush cutting in the BTS sites in open areas. All tools
& Cleaning material to be provided by the bidder.
E-Tender for Outsourcing BTS sites in Kannur BA
37
Signature & Seal of bidder
Routine check of free cooling systems available at site and DG set and other Equipments and
record the same in log book as per the periodicity defined for the visit as per tender. Reporting
of any alarms/faults/untoward incident to the concerned officer.
Running of DG sets as required.
Assisting in Diesel filling in the DG Set available at the site.
Up to 24 hrs of reporting of non-compliance related to above specific instance will be treated
as 1 minor deviation and further non completion of activity in every 3 days will be treated as
single instance.
Site wise capping of 12% is applicable in respect of minor performance deviations / site
upkeep activities.
Penalties being charged for Major Performance Deviations attributable to the bidder will be
capped to 12% of the total contracted value for the services of the relevant invoice period.
If the total penalties reaching the capping limit consecutively for three months, BSNL will
have the right to terminate the contract of the concerned SSA without any further notice.
If any fraudulent activity by the personnel deployed is detected by BSNL authorized
personnel/officer, then the bidder is liable to pay penalty as assessed by BSNL i.e. the cost of
consequential damages to installation(s)/DG set(s) would be deducted at actual, from the
service provider‟s bill. This will be over and above the other penalties and will not be subject
to capping if any.
Any tendered work not attended in time, BSNL will have the right to get it done from external
resources and payment made to them will be recovered from SP
Diesel filling
The activities to be carried out in the BTS sites are listed below.
Carrying Diesel from Pump and Diesel filling in the DG Set available at the sites.
Checking the level of diesel in the DG tank at the time of filling (opening level & closing) and
making entries in the Log book for diesel filling.
Collection of data directly from the site pertaining to monthly diesel reconciliation statement.
Checking the meter reading in the DG run hour meter (opening and closing) and Controller
logged hours (if available) and making entries of DG run hours in the Log book.
Ensuring availability of 50% tank capacity of diesel in the DG at any point of time.
Arranging test run in case, if any dispute arise between the Contractor and the BSNL official
concerned.
Bush cutting and clearing Vegetation from NBSNL sites:-
This includes bush/ grass/creepers/climbers cutting including small trees inside the tower base,
near the beds of OD BTS/OD Power plant/ O.D Node /DG/ OD battery bank etc. and removing
climbers from tower/shelter/DG/OD power plant etc. and clearing of weeds in the BTS site
compound.
Rigger Activities:-
a. Climbing the tower (RTT/GBT) -up to 80m.
b. Antenna re-orientation.
c. Checking/Replacement of weather proof tapes to prevent water entry.
d. Verification/replacement of connectors/fittings and Assistance in VSWR correction.
e. Verification/correction of Lightning Arrestor and its fittings.
f. Hoisting /De hoisting and associated installation work of AMF/Antenna.
g. Any other related works in tower, as required by concerned BSS officer.
E-Tender for Outsourcing BTS sites in Kannur BA
38
Signature & Seal of bidder
Replacement of XAHT/other antennas
a. New dual antennas are to be collected from Mobile store at Thalasserry /Mattannur/
talipparamba/ Kanhangad and transportation to site.
b. Replacement of working XAHT and other type of antennas with dual antenna and making
the site functional.
4.2 RIGHT TO VARY QUANTUM OF WORK: BSNL shall have the right to increase or decrease
the QUANTUM OF WORK up to 50% of the total requirement as specified in the schedule of
requirement specified in the tender without any change in the unit price or other terms and
conditions during the operation of contract.
4.3 BSNL also reserves the right to terminate this agreement at any time, by giving an advance
notice of one month.
4.4 Diesel filling shall be from Public sector Oil companies or any other agencies approved by
BSNL. Based on the MOU by BSNL with Oil Companies like IOC/BPCL Petro/Fleet cards are
arranged by BSNL. , Diesel filling shall be with Petro/Fleet card as mentioned in Section 3 Part B
of tender.
4.5. As per this CONTRACT, the contractor has to ensure that there is no BTS outage due to
delay in Diesel filling or unsatisfactory Mobile access equipment maintenance and Mobile
infrastructure maintenance/rigger support.
4.6. No staff deployed directly or indirectly by the contractor for the CONTRACT service would
have any claim in any way for getting future employment in BSNL.
5. SERVICE CONTRACT CHARGES
5.1 The SERVICE CONTRACT charges inclusive of all the taxes levies excluding GST and duties
payable under this agreement shall be as herein under:
.................................................
5.2 The contract values given in the table above are based on the SoR listed in Annexure. Subject
to the variation of quantity of items in the list under Annexure, the contract value will be changed.
5.3 All inclusive SERVICE CONTRACT rate per unit per annum for the SERVICE CONTRACT
items is given below:
TENDER APROVED RATES FOR SERVICE CONTRACT ITEMS:
……………………………..
5.4 Whenever there is a requirement of Diesel purchase directly by the Contractor , reimbursement
of such Diesel cost will be done on a monthly basis, based on the invoice raised by the contractor .
When the Petrocard is in use, any such direct purchase contractor shall be on formal request from
BSNL. In such cases, the Diesel invoices are to be prepared and submitted by the contractor on a
monthly basis along with Diesel reconciliation statement in the specified format. Payment will be
based on logbook entry after applying the ceiling limits as mentioned in 8.4. The bills ,will be
verified, passed & forwarded by BSNL representative based on the consumption in litres/ Hr
indicated in the tender document.
6. PAYMENT TO THE SERVICE PERSONNEL BY THE CONTRACTOR:
6.1 The persons employed by the contractor are to be paid by the contractor with fair wages as per
Labour Laws of Central/State Government. Other benefits to the persons like Bonus, ESI, Gratuity,
PF etc., are complete responsibility of the contractor. Any injury/mishap caused to the worker
during the course of work shall be the responsibility of the contractor.
6.2. The contractor is governed by the Workman‟s Compensation Act in case of any claim by the
persons employed by him/her/firm. The Service Contractor shall indemnify BSNL of all claims
made by the employees of the service contractor.
6.3. Contractor shall have insurance / Group insurance scheme for the employs deployed for the
CONTRACT.
7. FAULT BOOKING AND ESCALATION PROCEDURE:
E-Tender for Outsourcing BTS sites in Kannur BA
39
Signature & Seal of bidder
7.1 The Contractor would set up an office and help desk with sufficient number of staff in
designated place in Kerala to accept telephone calls/SMS/email from TSEs/BSNL officers.
8 .MAINTENANCE OF CALL DOCKETS, LOG BOOKS
8.1 The Contractor will also maintain the logbook at each site (to be kept with BSNL) where in the
Daily routine visits/ checks, activities done as part of Mobile access equipment maintenance and
Mobile infrastructure maintenance, Diesel filling and DG run details are to be entered on a daily
basis. The same shall be countersigned by the concerned BSNL in-charge for reference. The format
of the logbook that will be kept at BTS site for recording the events is attached as
8.2. In order to ensure the security of the network, contractor has submitted the signed Non-
Disclosure Agreement as per the tender conditions.
8.3. Contractor shall ensure that the agencies or any other representative concerned for support
strictly adheres to BSNL‟s Third Party Connection Acceptable Use Policy which is as follows:
a.Any change on equipment shall not be permitted unless instructed from BSNL side.
b. Passwords/locking system on any equipment will be set by BSNL representatives and shall not
be changed by contractor‟s representative without the approval from concerned BSNL officer.
c. Contractor shall notify BSNL, when its employee who has access to BSNL
Equipment/configuration leaves the company or is transferred to another position which no longer
requires access. Also the contractor shall surrender/cancel the ID cards of the employees who
leave the company.
d. Contractor or its representatives shall not make a change on any system that is not directly
related to his job/duty.
9. COURT JURISDICTION
9.1 Any dispute arising out of the tender/ bid document/ evaluation of bids/ issue of APO shall be
subject to the jurisdiction of the competent court at the place from where the NIT/ tender has been
issued.
9.2 Where a contractor has not agreed to arbitration, the dispute/ claims arising out of the
Contract/ PO entered with him shall be subject to the jurisdiction of the competent Court at the
place from where Contract/ PO has been issued. Accordingly, a stipulation shall be made in the
contract as under.
“This Contract/ PO is subject to jurisdiction of Court at KANNUR only”.
10. The NIT( Notice Inviting Tender ), Bid documents (Qualifying and Financial), letter of intent,
approved rates, annexed hereto and such other additional particulars, addendums, corrigendums,
instructions, work orders as may be found requisite to be given during execution of the work shall
be deemed and taken to be an integral part of the contract and shall also be deemed to be included
in the expression “The Agreement” or “The Contract” wherever herein used.
IN WITNESS WHEREOF the Parties hereto have caused this agreement to be executed through
their respective authorized representatives on the day and year first above written.
Signed and delivered for and on behalf of BHARAT SANCHAR NIGAM LIMITED
By Shri._________________________________________
Signature (with seal)
Signed on behalf of Contractor.
By Shri. ………………………………………………………………….
Signature (with seal)
In presence of:
Witness: 1._____________________________________________Signature
2._____________________________________________Signature
E-Tender for Outsourcing BTS sites in Kannur BA
40
Signature & Seal of bidder
SECTION 11
PERFORMANCE SECURITY GUARANTEE BOND
1.In consideration of the General Manager BSNL,BSNL,KANNUR(hereinafter called„ BSNL‟)Having agreed to exempt (hereinafter called „the said supplier(s)‟) from thedemand under the terms and conditions of an agreement/ Final Acceptance letter No…………………………………………………………………………………………………………………….
dated and
made between for the supply of
(hereinafter called “the said agreement ”), of security deposit for the due fulfillment by the said
supplier(s) of the terms and conditions contained in the said Agreement, on production of the bank
guarantee for we,(name of the bank)(Hereinafter refer to as “the bank”)at the request of
(supplier(s)) do here by undertake to pay to the BSNL an amount not exceeding
against any loss or damage caused to or suffered or would be caused to or suffered by BSNL by reason
of any breach by the said Supplier(s) of any of the terms or conditions contained in the said Agreement.
2.We…..(name of the bank) do hereby undertake to pay the amounts due and payable under this
guarantee without any demure, merely on a demand from the BSNL by reason of breach by the
saidsupplier(s)‟ofanyofthetermsorconditionscontainedinthesaidAgreementor by reason of the
suppliers(s)‟ failure to perform the said Agreement. Any such demand made on the bank shall be
conclusive as regards the amount due and payable by the Bank under this guarantee where the decision
of BSNL in these counts shall be final and binding on the bank. However, our liability under this
guarantee shall be restricted to an amount not exceeding
3.We undertake to pay to the BSNL any money so demanded not withstanding any dispute or disputes
raised by the supplier(s)/supplier(s) in any suit or proceeding pending before any court or tribunal
relating there to our liability under this present being absolute and unequivocal. The payment so made
by us under this bond shall be valid discharge of our liability for payment there under and the supplier(s)
shall have no claim against us for making such payment.
4. We (name of the bank)_further agree that the guarantee herein contained shall remain in full force
and effect during the period that would be taken for the performance of the said agreement and that it
shall continue to be enforceable till all the dues of the BSNL under or by virtue of the said Agreement
have been fully paid and its claims satisfied or discharged or till (office/Department) BSNL
certifies that the terms and conditions of the said Agreement have been fully or properly carried out by
the said supplier (s) and accordingly discharges this guarantee. Unless a demand or claim under this
guarantee is made on us in writing on or before the expiry of 30 MONTHS (as specified in P.O) from
the date here of, we shall be discharged from all liabilities under this guarantee thereafter.
5.We (name of the bank) further agree with the BSNL that the BSNL
shall have the fullest liberty with out our consent and without affecting in any manner our obligations
here under to vary any of the terms and conditions of the said Agreement or to extend time of
performance by the said supplier(s) from time to time or to postpone for any time or from time to time
any of the powers exercisable by the BSNL against the said Supplier(s) and to forbear or enforce any of
the terms and conditions relating to the said agreement and we shall not be relieved from our liability by
reason of any such variation,or extension being granted to thes aid Supplier(s) or for any forbearance,act
or omission on the part of the BSNL or any indulgence by the BSNL to the said Supplier(s) or by any
such matter or thing what so ever which under the law relating to sureties would,but for this
provision,have effect of so relieving us.
6.This guarantee will not be discharged due to the change in the constitution of the Bank or
the supplier(s).7. We (name of the bank) lastly undertake not to revoke thisguarantee during its currency except with the previous consent of the BSNL in writing.Dated the
(Indicate the name of
bank)
Day of For
E-Tender for Outsourcing BTS sites in Kannur BA
Signature & Seal of bidder
41
SECTION 12
MUTUAL NON-DISCLOSURE AGREEMENT
This Agreement is made as of the ___________ between Bharat Sanchar Nigam Limited (A
Government of India Enterprise), O/o General Manager BSNL,BSNL BHAVAN,,KANNUR-11
having its registered office at 10th Floor, Statesman House, B-148, Barakhamba Road, New Delhi-
110001 herein after called “BSNL” which expression shall unless repugnant to the subject or the
context mean and included its successors, nominees or assign and M/s …….. (Bidder),
………………..herein after referred to as the “Bidder” which expression shall unless repugnant to
the subject or the context mean and include its successors, nominees or assigns.
In order to pursue the mutual business purpose specified in Exhibit A (the "Business Purpose"),
BSNL and Bidder recognize that there is a need to disclose to one another certain confidential
information of each party to be used only for the Business Purpose and to protect such confidential
information from unauthorized use and disclosure.
In consideration of the other party's disclosure of such information, each party agrees as follows:
1. This Agreement will apply to all confidential and proprietary information disclosed by one party
to the other party, including information listed in Exhibit A and other information which the
disclosing party identifies in writing as confidential before or within thirty days after disclosure to
the receiving party ("Confidential Information").
2. Each party agrees (i) to hold the other party's Confidential Information in strict confidence, (ii)
not to disclose such Confidential Information to any third parties, and (iii) not to use any
Confidential Information for any purpose except for the Business Purpose. Each party may
disclose the other party's Confidential Information to its responsible employees with a bona fide
need to know, but only to the extent necessary to carry out the Business Purpose. Each party
agrees to instruct all such employees not to disclose such Confidential Information to third parties,
including consultants, without the prior written permission of the disclosing party.
3. Confidential information will not include information which:
(i) is now, or hereafter becomes, through no act or failure to act on the part of the receiving party,
generally known or available to the public:
(ii) Was acquired by the receiving party before receiving such information from the disclosing
party and without restriction as to use or disclosure;
(iii) Is hereafter rightfully furnished to the receiving party by a third party,
without restriction as to use or disclosure:
(IV) is information which the receiving party can document was independently developed by the
receiving party;
(v) is required to be disclosed pursuant to law, provided the receiving party uses reasonable efforts
to give the disclosing party reasonable notice of such required disclosure; or
(vi) Is disclosed with the prior written consent of the disclosing party.
4. Each party agrees not to remove any of the other party's Confidential Information from the
premises of the disclosing party without the disclosing party's prior written approval. Each party
agrees to exercise extreme care in protecting the confidentiality of any Confidential Information
which is removed, only with the disclosing party's prior written approval, from the disclosing
party's premises. Each party agrees to comply with any and all terms and conditions the
disclosing party may impose upon any such approved removal, such as conditions that the
removed Confidential Information and all copies must be returned by a certain date, and that no
copies are to be making off of the premises.
5. Upon the disclosing party's request, the receiving party will promptly return to the disclosing
party all tangible items containing or consisting of the disclosing party's Confidential
Information all copies thereof.
E-Tender for Outsourcing BTS sites in Kannur BA
Signature & Seal of bidder
42
6.Each party recognizes and agrees that nothing contained in this Agreement will be construed as
granting any rights to the receiving party, by license or otherwise, to any of the disclosing party's
Confidential Information except as specified in this Agreement.
7. Each party acknowledges that all of the disclosing party's Confidential Information is owned
solely by the disclosing party (or its licensors) and that the unauthorized disclosure or use of
such Confidential Information would cause irreparable harm and significant injury, the degree of
which may be difficult to ascertain. Accordingly, each party agrees that the disclosing party will
have the right to obtain an immediate injunction enjoining any breach of this Agreement, as well
as the right to pursue any and all other rights and remedies available at law or in equity for such
a breach.
8. This Agreement will be construed, interpreted, and applied in accordance with the laws of India.
Subject to terms and conditions regarding the removal of Confidential Information as set forth
under relevant Sections, this Agreement and Exhibit A attached hereto are the complete and
exclusive statement regarding the subject matter of this Agreement and supersede all prior
agreements, understandings and communications, oral or written, between the parties regarding
the subject matter of this Agreement.
9. This Agreement will remain in effect for five years from the date of the last disclosure of
Confidential Information, at which time it will terminate.
IN WITNESS WHEREOF, the parties hereto have executed this Agreement by their duly
authorized officers or representatives.
Bidder Company Name Bharat Sanchar Nigam Limited
Signature Signature
Printed Name Printed Name
Title
Title
Seal Seal
Exhibit A
1. Business Purpose:
To carry out Annual Maintenance of Infrastructure Equipments
(Reference: Tender No :…………………….)
2. Confidential Information of Bidder
3. Confidential Information of Bharat Sanchar Nigam Limited (BSNL):
The equipment details including the configurations.
All information shared in oral or in written form by BSNL with Bidder
Bidder Company Name Bharat Sanchar Nigam Limited
Signature Signature
Printed Name Printed Name
Title Title
Seal Seal
E-Tender for Outsourcing BTS sites in Kannur BA
Signature & Seal of bidder
43
SECTION 13 PART A
BIDFORM Ref: Tender No: PLG/MM/ E-Tender/ BSS/Out Sourcing/2021-22/3 Dated at Kannur the 15-11-
2021
To
DE (BSS),
BSNL, Telephone Bhavan, KANNUR - 670002
Dear Sir,
1.Having examined the conditions of contract and specifications including addenda
Nos......................the receipt of which is hereby duly acknowledged, we, undersigned, offer to supply and deliver.............................................. in conformity with the said contract and specifications for the sum shown the schedule of prices attached herewith and made part of this Bid.
2. We undertake, if our Bid is accepted, to commence deliveries within (…….) days from the
Date of issue of your purchase order. 3. If our Bid is accepted, we will obtain the performance guarantees of a Scheduled Bank for a
sum@10%of the contract value for the due performance of the contract. 4. We agree to abide by this Bid for a period of 180 days from the date fixed for Bid opening and
it shall remain binding upon us and may be accepted at any time before the expiration of that period.
5. Until a formal Purchase Order of Contract is prepared and executed, this Bid together with
your written acceptance thereof in your notification of award shall constitute a binding contract between us.
6. Bid submitted by us is properly sealed and prepared so as to prevent any subsequent alteration
and replacement. 7. We understand that you are not bound to accept the lowest or any bid, you may receive.
Dated this..............................day of ........................2021
Name and Signature…………………………………………… In the capacity of ………………………………………………… Duly authorized to sign the bid for and on behalf of.............................................. Witness......................................... Address......................................... Signature…………………………………
E-Tender for Outsourcing BTS sites in Kannur BA
44
Signature & Seal of bidder
+ PART B
FINANCIAL BID (ONLINE SUBMISSION ONLY)
To
The General Manager,
Bsnl, KANNUR.
Sub: Our Financial bid for Diesel Filling, Mobile access equipment maintenance and Mobile
infrastructure maintenance, rigger and bush cutting at BTS sites in KANNUR BA
Ref: Tender No: PLG/MM/ E-Tender/ BSS/Out Sourcing/2021-22/3 Dated at Kannur the 15-11-2021
Dear Sir,
With reference to your Tender cited above,, we the under signed offer to undertake “Diesel filling,
Mobile access equipment maintenance and Mobile infrastructure maintenance, rigger and bush cutting
in GSM BTS sites in conformity with the said specifications and conditions of contract at the rate quoted
below: 1 Diesel filling, Mobile access equipment maintenance
and Mobile infrastructure maintenance, rigger and bush cutting in GSM BTS sites in Kannur BA 2021-22
Quantity Units Estimated Rate in
Rs. P
1.01 Diesel filling in DG sets at GSM BTS sites 342 No of Sites/ month
685.00
1.02 Mobile access equipment maintenance and Mobile infrastructure maintenance in BTS sites (In Rural & Urban)
204 No of Sites/ month
2075.00
1.03 Mobile access equipment maintenance and Mobile infrastructure maintenance in BTS sites ( In remote area Hard stations)
40 No of Sites/ month
2300.00
1.04 Rigger activities up to 50 m (Instances per month) 125 No of Instances/ month
1250.00
1.05 Rigger activities above 50 m (Instances per month) 30 No of Instances/ month
1590.00
1.06 Bush cutting, clearing of vegetation, climbers etc in BTS site Compound ( Instances per year)
600 No of Instances/ Year
700.00
1.07 Replacement of XAHT/other Antennas with dual band Antenna including transportation of store to site (Instances per year)
30 No of Instances/ Year
2300.00
E-Tender for Outsourcing BTS sites in Kannur BA
45
Signature & Seal of bidder
ANNEXURE –1
Contact Details of Deployed Personnel and supervisor
(a) Contact details work supervisor
Sl No Cluster Name Address Phone Mobile E-mail
(b) Contact details of personnel for Mobile access equipment maintenance and Mobile
infrastructure maintenance with site details
Sl No Site Details Sub div Div Name of
Personnel
Mobile
Number
Residential
Phone
(c) Contact details of personnel deployed for Rigger activities
No Division Name of
Personnel
Mobile Residential
Phone
E-Tender for Outsourcing BTS sites in Kannur BA
46
Signature & Seal of bidder
ANNEXURE – 2
SITE WISE LOG BOOK FOR DIESEL FILLING:-
Site Name: Rp ID: Diesel Fill Log register
Sl
N
o
Dat
e
Tim
e
Name &
Cotact no
of
Person
filling
diesel
Sig
nat
ure
of
Per
son
fill
ing
die
sel
Die
sel
Av
aila
ble
in
tan
k b
efo
re f
illi
ng
(L
)
Die
sel
Fil
led
(L
)
To
tal
Die
sel
avai
lab
le
afte
r fi
llin
g m
esu
red
usi
ng
dip
sti
ck(L
)
Die
sel
con
sum
ed
DG
HM
R R
ead
ing
Ho
urs
ru
n B
/w
con
secu
tiv
e d
iese
l fi
ll
DG
kW
h r
ead
ing
at
tim
e o
f d
iese
l fi
llin
g
DG
kW
h r
ead
ing
dif
fere
nce
Dis
el c
on
sup
tio
n/
hr
Pet
ro C
ard
, P
um
p,
rece
ipt
NO
, d
ate,
Qty
of
die
sel
sale
,
Am
t o
f d
iese
l sa
le,
Bal
ance
am
t d
etai
ls
Rem
ark
s if
an
y
/Sig
nat
ure
of
MO
BIL
E A
CC
ES
S
EQ
UIP
ME
NT
MA
INT
EN
AN
CE
AN
D M
OB
ILE
INF
RA
ST
RU
CT
U
RE
MA
INT
EN
AN
CE
per
son
A D G
B
C=
A-B
E
F=
E-D
H
I=H
-G
J=C
/F
ANNEXURE – 3
Site Wise LOG BOOK FOR Mobile access equipment maintenance and Mobile infrastructure
maintenance(MAM&MIM) Name of Site:
Site Name: Rp ID: Month: MAM&MIM
activity register
Sl
No
D
at
e
Name of
personal
Tim
e IN
DG
HM
R
read
ing
Die
sel
avai
lab
le i
n
DG
DG
KW
h
read
ing
EB
KW
h
met
er r
dng
Diesel Fill/Observations/ Work done/
material,bill movement details
Tim
e O
UT
Sig
nat
ure
of
MA
M&
MI
M
Sig
nat
ure
of
site
in
char
ge
1
31
DG
K
W
H
OMR first of
month:
Diffe
rence DG
HM
R OMR first of month: Total diesel filled (L)
CMR END
of month:
HM
R CMR End of month:
EB
K
W
H
OMR first of
month:
Diffe
rence Total hours run this month:
Total diesel consumed
(L)
CMR END
of month: Total KWH (EB+DG) this month:
E-Tender for Outsourcing BTS sites in Kannur BA
47
Signature & Seal of bidder
ANNEXURE – 4
LOG Book for Rigger Activities Tower Height: upto 50m/Above 50 m
Month:
SlNo Date Name of
Person
Name of
site
Work
instance
Observation/Work
done
Signature
Annexure 5
Monthly Performance Report
Name of Subdivision: Period:
Total no. of sites under Mobile access equipment maintenance and Mobile infrastructure maintenance:
Total no. of sites under Partial Mobile access equipment maintenance and Mobile infrastructure
maintenance:
Total no. of sites under diesel filling:
Type of Work : Diesel Filling/ Mobile access equipment maintenance and Mobile infrastructure
maintenance
Date Name of Site where
deviation exist
Type of Deviation
(Major/Minor)
Duration in case
of Major
*Remarks
Total Duration of Major Deviation (in hours): Total Instances of Minor Deviation :
1. It is certified that the performance in ……………………………..…activity in
…………….subdivision of the Monthly period …………..was satisfactory for the
vendor………………..except for the deviations listed above.
2. It is certified that cleaning of equipments and surrounding area in all sites under Mobile access
equipment maintenance and Mobile infrastructure maintenance were done by Mobile access
equipment maintenance and Mobile infrastructure maintenance personnel.
3. It is certified that site wise filling details as per Annexure 8 was receiving on daily basis.
Signed by : Sub divisional Engineer (BSS)
Countersigned by : Divisional Engineer (BSS).
Note :Deviation in Diesel Filling or Mobile access equipment maintenance and Mobile infrastructure
maintenance Activities are to be clearly distinguished in the Performance report
E-Tender for Outsourcing BTS sites in Kannur BA
48
Signature & Seal of bidder
ANNEXURE 5A
Performance Report(Bush cutting/Vegetation clearing)
Name of Subdivision: Period:
Type of Work : Bush/Grass cutting and removing vegetation activity
No. of sites :
(List of sites to be attached)
Sl No Name of Deviated Site Phase of clearing
vegetation
*Remarks
It is certified that the performance in Bush cutting/vegetation activity in …………….subdivision
during …….. Phase(2 times in a year)was satisfactory for the vendor………………..except for the
deviations listed above
Signed by : Sub divisional Engineer (BSS)
Countersigned by : Divisional Engineer (BSS)
.
E-Tender for Outsourcing BTS sites in Kannur BA
49
Signature & Seal of bidder
ANNEXURE 5B
Monthly Performance Report , Rigger)
Name of Subdivision: Period:
Type of Work : Rigger activities.
:
No. of instances for Rigger type 1
No. of instances for Rigger type 2
(Copy of rigger logbook to be attached)
Sl No Name of Sub division Deviation details *Remarks
It is certified that the performance in rigger in …………….subdivision of the monthly period
…….. was satisfactory for the vendor………………..except for the deviations listed above
Signed by : Sub divisional Engineer (BSS/NQM)
Countersigned by : Divisional Engineer (BSS)
.
E-Tender for Outsourcing BTS sites in Kannur BA
50
Signature & Seal of bidder
ANNEXURE 6
Payment details to Mobile access equipment maintenance and Mobile infrastructure maintenance
and rigger
Sl
.
N
o:
MA
M&
MI
M
Site
Na
me
Sub
Divisi
on
Nam
e of
MA
M&
MI
M
pers
onne
l
Addres
s
Wages
(Salary
+DA)
EPF
A/C
No:
ESI
A/c
No:
EPF
Contri
bution
(Empl
oyer's
share)
EPF
Contri
bution
(Empl
oyee's
share)
ESIC
Contri
bution
(Empl
oyer's
share)
ESIC
Contribu
tion
(Employ
ee's
share=1.
75% of
Wages)
Net
Wages
after
deductin
g
Employe
e's
contribut
ion of
EPF,
ESIC
E-Tender for Outsourcing BTS sites in Kannur BA
51
Signature & Seal of bidder
ANNEXURE 7
PROFORMA FOR RECONCILIATION OF DIESEL
COST
PERIOD -
DATA AS PER LOG BOOK ENTRY
S/n
RP
ID
SIT
E N
AM
E
DG
MA
KE
DG
Ca
pacit
y
Die
sel-
Op
en
ing
Bala
nce
as
on
1
ast
da
y o
f th
e
previo
us
mo
nth
Die
sel-
Clo
sin
g M
ete
r R
ea
din
g a
s on
1a
st d
ay
of
the c
urr
en
t m
on
th
Die
sel
fill
ed
du
rin
g t
he m
on
th
To
tal
Die
sel
Co
nsu
med
(A
)
MU
LT
IPL
ICA
TIO
N F
AC
TO
R-C
PH
(a
s p
er
agree
men
t)/a
pp
rov
ed
test
ru
n (
B)
DG
ru
n h
ou
r-O
PE
N M
ET
ER
RE
AD
ING
(OM
R)
as
on
la
st d
ay
of
the p
rev
iou
s m
on
th
DG
ru
n h
ou
r-C
LO
SE
ME
TE
R R
EA
DIN
G
(CM
R)
as
on
la
st d
ay o
f th
e cu
rren
t m
on
th
Logg
ed
Ho
urs
in c
on
trol
pa
nel
(Ph
V s
ites)
-
OP
EN
ME
TE
R R
EA
DIN
G (
OM
R)
as
on
la
st
da
y o
f th
e p
revio
us
mo
nth
Logg
ed
Ho
urs
in c
on
troll
pa
nel
(Ph
V s
ites)
-
CL
OS
E M
ET
ER
RE
AD
ING
(C
MR
) a
s o
n l
ast
da
y o
f th
e c
urren
t m
on
th
To
tal
DG
RU
N T
IME
du
rin
g t
he m
on
th ©
To
tal
Die
sel
con
sum
ed
as
per
CP
H(D
=B
xC
)
Die
sel
Qu
an
tity
Reco
mm
en
ded
A o
r D
wh
ich
ev
er i
s le
sser
(E
)
Co
st o
f D
iese
l =
E*
Die
sel
pri
ce p
er l
iter
Co
st o
f th
e D
iese
l =
((C
B-O
B)+
Rec
mn
d
qty
)*D
.P
Certification : The details above are verified with Logbook maintained in site, run hour meter
readings and further cross checked
with other available data like DG ON alarm data from OMCR, Logged hours in DG Controller
(in the case of Phase V DG),
Counter Signature of DE(BSS)
with seal
Signature of SDE(BSS) with date &
Seal
Signature of the
representative of
Contractor & Seal
E-Tender for Outsourcing BTS sites in Kannur BA
52
Signature & Seal of bidder
ANNEXURE 8
Diesel filling data to be e mailed to SDE (BSS)s after each transaction using petro card/fleet
card
Sl
N
o.
Bill no
of
petrocar
d
transacti
on
Date of
petro
card
transact
ion
Quant
ity
(lrs)
Amou
nt
(Rs.)
RPI
D
SIT
E
NA
ME
CAR
D
NO
Sub
Divisi
on
DIES
EL
AVAI
LABL
E
DIES
EL
FILL
ED
TOT
AL
DIES
EL
HMR
Readin
g
E-Tender for Outsourcing BTS sites in Kannur BA
53
Signature & Seal of bidder
ANNEXURE 9
Experience Certificate
It is hereby certified that M/s ………………….. has got experience in ,diesel filling &
Mobile access equipment maintenance and Mobile infrastructure maintenance and rigger activity in
BTS sites as per the details given below.
(1) Name of the Telecom Provider :
(2) Name of Telecom Circle :
(3) Details of contract:
Items
Carried
out
Yes/
No
If Yes: Period of
contract
Remarks
Diesel filling
Mobile access
equipment
maintenance and
Mobile infrastructure
maintenance
Rigger activities
(4) Overall performance assessment: Satisfactory / Not satisfactory
Signature
(To be signed by Authorized Signatory of the company with seal & date)
……………………..
E-Tender for Outsourcing BTS sites in Kannur BA
54
Signature & Seal of bidder
ANNEXURE 10
List of BTS sites for Mobile Access equipment & infrastructure maintenance required. KANNUR BA
Sl No RP Site Name
Sub Div
Sl No RP Site Name Sub Div
1 RP-04036 RP-04036-Mamakunnu KNR1
39 RP-02876 RP-02876-Supdtgate KNR 2
2 RP-02215 RP-02215-Varamstaffqtrs KNR1
40 RP-02877 RP-02877-Pannenpara KNR 2
3 RP-03322 RP-03322-Mannikakavu KNR1
41 RP-03356 PallipuramKNR KNR 2
4 RP-04960 RP-04960-Niramthode KNR1
42 RP-04027 RP-04027-ChaladEast KNR 2
5 RP-07935 RP-07935-Kalluvayal KNR1
43 RP-04032 RP-04032-Manal KNR 2
6 RP-02881 RP-02881-Chalakunnu KNR1
44 RP-04045 RP-04045-Bakkalam KNR 2
7 RP-04952 RP-04952-Pannerichal KNR1
45 RP-08986 PaliyathValapu KNR 2
8 RP-07938 RP-07938-Puravayal KNR1
46 RP-01271 RP-01271-Azhikode KNR 2
9 RP-04025 Edachowa KNR1
47 RP-04034 RP-04034-Edacherry KNR 2
10 RP-03096 Mannikadavu(hard) KNR1
48 RP-07261 RP-07261-Panthottam KNR 2
11 RP-01300 RP-01300-KOODALI KNR1
49 RP-02231 RP-02231-Puthiyangadi KNR 2
12 RP-00536 RP-00536-Peralasseri KNR1
50 RP-03262 Payangaditown KNR 2
13 RP-01266 AnjarakandyTown KNR1
51 RP-03513 RP-03513-Chembanal KNR 2
14 RP-03355 RP-03355-Thilanur KNR1
52 RP-03774 PariyaramWest KNR 2
15 RP-02202 RP-02202-Malikaparamba KNR1
53 RP-08885 CoOpClgPilatara KNR 2
16 RP-02201 RP-02201-Koyyode KNR1
54 RP-01721 RP-01721-Ezhome KNR 2
17 RP-02878 RP-02878-Ottamavu KNR1
55 RP-03103 RP-03103-Aduthila KNR 2
18 RP-07296 RP-07296-Mathukoth KNR1
56 RP-02241 RP-02241-EMBETTIL KNR 2
19 RP-03088 RP-03088-Kolappa KNR1
57 RP-03514 RP-03514 Yogasala KNR 2
20 RP-04953 Kannadivelicham KNR1
58 RP-08211 RP-08211 EzhimalaRS KNR 2
21 RP-04957 RP-04957-Maniyoor KNR1
59 RP-04964 RP-04964 PuthiyatheruE KNR 2
22 RP-07264 RP-07264-Perumannu KNR1
60 RP-0311 RP-00311-SIVAPURAM MTR
23 RP-08015 KALANKI KNR1
61 RP-01708 PeravoorTown MTR
24 RP-07269 NELLIKAMPOYIL KNR1
62 RP-02226 RP-02226-KEEZHOOR MTR
25 RP-07283 PARIKKALAM KNR1
63 RP-04057 RP-04057-Kololamnorth MTR
26 RP-05644 Chelora KNR1
64 RP-04725 RP-04725-MTRStaffQtrs MTR
27 RP-03515 Edakkadtown KNR1
65 RP-04966 RP-04966-Palottupally MTR
28 RP-04024 Elayavurtemple KNR1
66 RP-04973 RP-04973-Kunnoth MTR
29 RP-00533 RP-00533-Skcomplex KNR 2
67 RP-07004 RP-07004-Aiyapanthodu MTR
30 RP-02210 RP-02210-Kazanakotta KNR 2
68 RP-07335 RP-07335-Vellarvally MTR
31 RP-02216 RP-02216-Vkcomplex KNR 2
69 RP-07339 Mannalampuram MTR
32 RP-02874 RP-02874-Caltex KNR 2
70 RP-08874 ManathanaTown MTR
33 RP-02882 RP-02882-Thanadlc KNR 2
71 RP-04975 RP-04975-Nedumpoyil MTR
34 RP-07733 Payyambalam KNR 2
72 RP-07272 RP-07272-Pazhassidam MTR
35 RP-01324 Vankulathuvayal KNR 2
73 RP-07333 RP-07333-Kayani MTR
36 RP-02211 RP-02211-Kunhipalli KNR 2
74 RP-07905 RP-07905-Odanthod MTR
37 RP-02212 RP-02212-Puthiyatheru KNR 2
75 RP-08385 RP-08385-Kaayapanachi MTR
38 RP-02875 RP-02875-Chalad KNR 2
76 RP-08386 RP-08386-Vattiyora MTR
E-Tender for Outsourcing BTS sites in Kannur BA
55
Signature & Seal of bidder
Sl No RP Site Name
Sub Div
Sl No RP Site Name Sub Div
77 RP-08475 RP-08475-Ambayathod MTR
117 RP-07267 Poomangalam TMB
78 RP-08624 RP-08624-Barapole MTR
118 RP-01278 CHAPPARAPPADAVU TMB
79 RP-08798 Mudavangode MTR
119 RP-04954 RP-04954-Paissakari TMB
80 RP-07338 Chunkakunnu MTR
120 RP-08172 RP-08172-Pooparamba TMB
81 RP-08902 PeriyaramMTR MTR
121 RP-03676 RP-03676-Eryam TMB
82 RP-00552 Mahehospital TLY
122 RP-07947 RP-07947-Kannapilavu TMB
83 RP-01297 RP-01297-Kinnavakal TLY
123 RP-04059 RP-04059-Chuzhali TMB
84 RP-01301 RP-01301-KottayamPoil TLY
124 RP-07063 RP-07063-Nellippara TMB
85 RP-01306 RP-01306-Mambram TLY
125 RP-03507 Thrikkanad KSGD
86 RP-01323 RP-01323-Pinarayi TLY
126 RP-07020 Manadukkam KSGD
87 RP-02219 RP-02219-NIRMALAGIRI TLY
127 RP-07722 Manimoola KSGD
88 RP-02236 RP-02236-Chonadam TLY
128 RP-07040 Kannadipara KSGD
89 RP-02237 RP-02237-Kundoormala TLY
129 RP-07155 Maniyanpara KSGD
90 RP-02238 RP-02238-Punnol2 TLY
130 RP-08520 Songal KSGD
91 RP-03089 RP-03089-Kannavam TLY
131 RP-08612 Nalka KSGD
92 RP-03092 RP-03092-Kaithery TLY
132 RP-08133 Poiyathubail KSGD
93 RP-03670 RP-03670-Pottanpara TLY
133 RP-01279 Poinachi KSGD
94 RP-03673 RP-03673-Champad TLY
134 RP-02198 THEKKIL KSGD
95 RP-04720 RP-04720-Pookkom TLY
135 RP-03506 Southkalanad KSGD
96 RP-04967 RP-04967-Chendayad TLY
136 RP-04049 Chemanad KSGD
97 RP-04968 RP-04968-Pathiriyad TLY
137 RP-04050 Vidyanagarqtrs KSGD
98 RP-07978 RP-07978-Swamikunnu TLY
138 RP-04992 Koliyadukkam KSGD
99 RP-08881 RP-08881-Kottiyodi TLY
139 RP-07048 Mangad KSGD
100 RP-08602 KuthuparambaQtr TLY
140 RP-07579 Chattamchal KSGD
101 RP-07109 RP-07109-Padenthazhe TLY
141 RP-07914 UdumaNorth KSGD
102 RP-07345 Karyattupuram TLY
142 RP-00559 PAIVALIKA KSGD
103 RP-08883 RP-08883-Kaithachal TLY
143 RP-01304 KUNJATHUR KSGD
104 RP-02220 Valiyavelicham TLY
144 RP-02221 BANDIYODU KSGD
105 RP-01267 RP-01267-Andallur TLY
145 RP-02225 MIAPADAVU KSGD
106 RP-07301 Vayattuparamba TMB
146 RP-03502 Hosangadi KSGD
107 RP-07325 RP-07325-Kadukkaram TMB
147 RP-03503 UppalaGate KSGD
108 RP-04955 RP-04955-Chengalayi TMB
148 RP-04982 Madathadukka KSGD
109 RP-03778 RP-03778-Kuppam TMB
149 RP-07582 Kurudapadavu KSGD
110 RP-02502 RP-02502-MANNA TMB
150 RP-08382 Kaikamba KSGD
111 RP-07291 PushpagiriKnr TMB
151 RP-08481 Kadamana KSGD
112 RP-08209 RP-08209-Karimbam TMB
152 RP-10923 GPMGovtCollege KSGD
113 RP-08173 TMBSirSyedCLG TMB
153 RP-00306 Thalangara KSGD
114 RP-07268 RP-07268-Thimiri TMB
154 RP-02196 Nullippadi KSGD
115 RP-04958 Peruvalthparamb TMB
155 RP-02197 NEKRAJE KSGD
116 RP-04956 Oduvallithattu TMB
156 RP-03505 Mogralputhur KSGD
E-Tender for Outsourcing BTS sites in Kannur BA
56
Signature & Seal of bidder
Sl No RP ID Site Name
Sub Div
Sl No RP ID Site Name Sub Div
157 RP-04053 KblSouthMarr KSGD
197 RP-01299 KONNAKKAD TE KNHD
158 RP-04054 Seethangoli KSGD
198 TE PERUMBATTA TE KNHD
159 RP-07044 KsgdNewBusStand KSGD
199 RP-05219 ChullyKNGD KNHD
160 RP-07773 Karmanthodi KSGD
200 RP-07091 Ranipuram KNHD
161 RP-08557 EDANEER KSGD
201 RP-07072 Edathodu KNHD
162 RP-08846 Pallamkode KSGD
202 RP-08374 iyrote KNHD
163 RP-05646 Kuttiyanam KSGD
203 RP-07083 Pollakada KNHD
164 RP-04984 Parakalai KNHD
204 RP-02229 NLS_GOVT_HOSPITAL KNHD
165 RP-01284 CHITTARIKAL KNHD
205 RP-02243 CHANDERA PAY
166 RP-08512 PanangadKNR KNHD
206 RP-04048 Cheruvathurtown PAY
167 RP-07693 Kothottupara KNHD
207 RP-01719 EZHIMALA PAY
168 RP-01333 VELLARIKUNDU KNHD
208 RP-05771 KoromKnr PAY
169 RP-07690 Ettithattu KNHD
209 RP-08891 KoromNorth PAY
170 RP-08285 KaraChittarikal KNHD
210 RP-08863 PAY BUS STAND PAY
171 RP-07977 Karat KNHD
211 RP-01305 PAYYANNUR CXL PAY
172 RP-07499 Pullumala KNHD
212 RP-01320 PEELIKODE PAY
173 RP-02206 MAVUNGAL_DLC KNHD
213 RP-03899 Perumba PAY
174 RP-08053 KanhangadBusStand KNHD
214 RP-07092 Ponnampara PAY
175 RP-03768 Avikkara KNHD
215 RP-08928 Pranthanchal PAY
176 RP-07815 Chathamath KNHD
216 RP-07639 Thabore PAY
177 RP-07595 Kottodi KNHD
217 RP-00542 PADAYOTCHAL PAY
178 RP-03777 Pakkom KNHD
218 RP-04981 CHANADUKKAM PAY
179 RP-07075 Kolichal KNHD
219 RP-07008 KAKKARA NEW TE PAY
180 RP-07694 Choyyomkod KNHD
220 RP-07980 Alanthatta PAY
181 RP-08357 MaukodeBSNL KNHD
221 RP-03101 Chandapura PAY
182 RP-07018 Nallompuzha KNHD
222 RP-08293 Edachakai PAY
183 RP-07705 Nelliyadukkam KNHD
223 RP-07709 Eyyakkad PAY
184 RP-04996 Kottapara Adukkam KNHD
224 RP-07697 JOSEGIRIW PAY
185 RP-07512 Madikai KNHD
225 RP-03669 KADANKOD PAY
186 RP-08924 NileshwarHW KNHD
226 RP-03512 Kandankali PAY
187 RP-08848 Poochakkad KNHD
227 RP-04047 KANKOL PAY
188 RP-07689 Madiyan KNHD
228 RP-07703 KARAMMEL PAY
189 RP-02244 KANHANGAD_NEW_EXG KNHD
229 RP-04993 Klayikode PAY
190 RP-03510 Padanakkad KNHD
230 RP-07005 KODAKKAD PAY
191 RP-03674 Pullur KNHD
231 RP-03814 Kothaimukku PAY
192 RP-00528 ATHINHAL KNHD
232 RP-08706 KOYIPRA PAY
193 RP-03508 Chittari KNHD
233 RP-02504 KUNHIPPARA PAY
194 RP-06372 Bengalam KNHD
234 RP-07292 KUTTOR KNR PAY
195 RP-08291 KanhangadNewBusStand KNHD
235 RP-08664 MENONKUNNU PAY
196 RP-02205 HOSDURG KNHD
236 RP-08684 NHEKLI PAY
E-Tender for Outsourcing BTS sites in Kannur BA
57
Signature & Seal of bidder
Sl No RP ID Site Name
Sub Div
237 RP-07945 PALAKKUNNU PAY
238 RP-07982 PALLIPPARA PAY
239 RP-08723 PERINGOME TOWN PAY
240 RP-07650 PODAVUR NEW PAY
241 RP-07707 POTHAMKANDAM PAY
242 RP-08294 ThayineriPyr PAY
243 RP-08894 THATTUMMAL PAY
244 RP-03511 Udinoor PAY
E-Tender for Outsourcing BTS sites in Kannur BA
58
Signature & Seal of bidder
ANNEXURE 11
List of diesel filling required sites- KANNUR BA SL No RP-ID Site name
SL No RP-ID Site name
1 RP-00536 Peralasseri
41 RP-07082 Kovvappuram
2 RP-01266 AnjarakandyTown
42 RP-02211 Kunhipalli
3 RP-01300 Koodali
43 RP-02241 Embettel
4 RP-02201 Koyyode
44 RP-00532 Kakkad
5 RP-02202 Malikaparamba
45 RP-00533 SK Complex
6 RP-02207 Adikadalayi
46 RP-01324 Vankulathuvayal
7 RP-02209 EachurDLC
47 RP-03774 Pariyaram_West
8 RP-02214 Thazhechovva
48 RP-02876 Supt gate
9 RP-02215 Varamstaffqtrs
49 RP-03356 PallipuramKNR
10 RP-02878 Ottamavu
50 RP-02882 Thanadlc
11 RP-02879 Kannurpadanna
51 RP-08986 Palayathuvalappu
12 RP-02881 Chalakunnu
52 RP-02199 Anjampeedika
13 RP-03088 Kolappa
53 RP-08213 Vellikeel
14 RP-03322 Mannikakavu
54 RP-01271 Azhikode
15 RP-03353 Chapa
55 RP-08885 Co-Op College Pilathara
16 RP-03355 Thilanur
56 RP-02212 Puthiyatheru
17 RP-03515 Edakkadtown
57 RP-02210 Kazanakotta
18 RP-04024 Elayavurtemple
58 RP-04033 Chirakkal South
19 RP-04025 Edachowa
59 RP-03514 Yogasala
20 RP-04036 Mamakunnu
60 RP-08211 Ezhimala Railway Stn.
21 RP-04952 Pannerichal
61 RP-03513 Chembanal
22 RP-04953 Kannadivelicham
62 RP-01721 Ezhome
23 RP-04957 Maniyoor
63 RP-04045 Bakkalam
24 RP-04960 Niramthode
64 RP-02874 Caltex
25 RP-07264 Perumannu
65 RP-04034 Edacherry
26 RP-07269 Nellikkampoyil
66 RP-04962 Hanumarambalam
27 RP-07283 Parikkalam
67 RP-02231 Puthiyangadi
28 RP-07284 Palliparambu
68 RP-04027 ChaladEast
29 RP-07285 Vellachal
69 RP-07261 Panthottam
30 RP-07296 Mathukoth
70 RP-03103 Aduthila
31 RP-07330 Chakkarakaltown
71 RP-00311 SIVAPURAM
32 RP-07935 Kalluvayal
72 RP-01708 PeravoorTown
33 RP-07938 Puravayal
73 RP-01723 THERUR
34 RP-08015 Kaalanki
74 RP-02226 KEEZHOOR
35 RP-08715 Muzhappala
75 RP-03086 Chavassery
36 RP-02877 Pannenpara
76 RP-03662 Maruthai
37 RP-04032 Manal
77 RP-03667 Sivapurameast
38 RP-02875 Chalad
78 RP-04057 Kololamnorth
39 RP-04964 Puthiyatheru East
79 RP-04725 MTRStaffQtrs
40 RP-07106 Neruvambram
80 RP-04966 Palottupally
E-Tender for Outsourcing BTS sites in Kannur BA
59
Signature & Seal of bidder
SL No RP-ID Site name
SL No RP-ID Site name
81 RP-04973 Kunnoth
122 RP-07067 Rayarome
82 RP-04974 Manathanna
123 RP-07265 Cheriyoor
83 RP-04975 Nedumpoyil
124 RP-07291 PushpagiriKnr
84 RP-04976 Keezhpally
125 RP-07301 Vayattuparamba
85 RP-05764 AralamTown
126 RP-07326 Manjankari
86 RP-07004 Aiyapanthodu
127 RP-07327 Pokkundu
87 RP-07272 Pazhassidam
128 RP-07744 Therandi
88 RP-07331 Poolakutty
129 RP-07937 Vathilmada
89 RP-07332 Nelloonni
130 RP-07946 Kanjirakolli
90 RP-07333 Kayani
131 RP-07947 Kannapilavu
91 RP-07335 Vellarvally
132 RP-08172 Pooparamba
92 RP-07338 Chunkakunnu
133 RP-08209 Karimbam
93 RP-07339 Mannalampuram
134 RP-08219 Urathoor
94 RP-07905 Odanthod
135 RP-06679 Vanchiyam
95 RP-07979 Karaperavoor
136 RP-07267 Poomangalam
96 RP-08161 Karetta
137 RP-07268 Thimiri
97 RP-08385 Kaayapanachi
138 RP-07325 Kadukkaram
98 RP-08386 Vattiyora
139 RP-08173 TMBSirSyedCLG
99 RP-08388 Ayyallur
140 RP-08560 ValiaAreekamala
100 RP-08475 Ambayathod
141 RP-08667 Mampoyil
101 RP-08624 Barapole
142 RP-00550 TLSYMW
102 RP-08716 Edayannur
143 RP-00552 Mahehospital
103 RP-08721 Vaduvankulam
144 RP-01267 Andallur
104 RP-08730 Thrikadaripoyil
145 RP-01297 Kinnavakal
105 RP-08798 Mudavangode
146 RP-01301 KottayamPoil
106 RP-08874 ManathanaTown
147 RP-01306 Mambram
107 RP-08887 Eelapeedika
148 RP-01323 Pinarayi
108 RP-08890 Kallumutirakunu
149 RP-02219 NIRMALAGIRI
109 RP-08902 PeriyaramMTR
150 RP-02220 Valiyavelicham
110 RP-08904 Veerpad
151 RP-02224 Pandakkal
111 RP-01278 CHAPPARAPPADAVU
152 RP-02236 Chonadam
112 RP-02502 MANNA
153 RP-02237 Kundoormala
113 RP-03105 Tmb7ThMile
154 RP-02238 Punnol2
114 RP-03778 Kuppam
155 RP-02239 Tlybusstand
115 RP-04059 Chuzhali
156 RP-02240 Saidarpalli
116 RP-04722 Mandalam
157 RP-03089 Kannavam
117 RP-04954 Paissakari
158 RP-03092 Kaithery
118 RP-04955 Chengalayi
159 RP-03670 Pottanpara
119 RP-04956 Oduvallithattu
160 RP-03673 Champad
120 RP-04958 Peruvalthparamb
161 RP-04042 Maheeast
121 RP-07063 Nellippara
162 RP-04060 Tlsy North
E-Tender for Outsourcing BTS sites in Kannur BA
60
Signature & Seal of bidder
SL No
RP-ID Site name
SL No
RP-ID Site name
163 RP-04720 Pookkom
204 RP-02221 BANDIYODU
164 RP-04967 Chendayad
205 RP-02225 MIAPADAVU
165 RP-04968 Pathiriyad
206 RP-03501 ManjeswarNorth
166 RP-04969 CentralPoilur
207 RP-03502 Hosangadi
167 RP-04970 Kariad
208 RP-03503 UppalaGate
168 RP-04978 Kanhileri
209 RP-04982 Madathadukka
169 RP-06676 Kidanji
210 RP-07040 Kannadipara
170 RP-07097 Venduttayi
211 RP-07068 Guvathapadapu
171 RP-07109 Padenthazhe
212 RP-07117 Kumbla
172 RP-07281 Olavilam
213 RP-07151 Santhadukka
173 RP-07299 Menapram
214 RP-07155 Maniyanpara
174 RP-07345 Karyattupuram
215 RP-07582 Kurudapadavu
175 RP-07978 Swamikunnu
216 RP-07887 Anantapuratmple
176 RP-08390 Vaayannur
217 RP-07985 Vidhyagiri
177 RP-08601 ThalasseryFort
218 RP-08133 Poiyathubail
178 RP-08883 Kaithachal
219 RP-08134 Morathane
179 RP-02198 THEKKIL
220 RP-08378 Neerchal
180 RP-03506 Southkalanad
221 RP-08382 Kaikamba
181 RP-03507 Thrikkanad
222 RP-08481 Kadamana
182 RP-03671 ChengalaEknHosp
223 RP-08520 Songal
183 RP-04049 Chemanad
224 RP-08611 Belinja
184 RP-04050 Vidyanagarqtrs
225 RP-08612 Nalka
185 RP-04055 Munnad
226 RP-08621 Muligadde
186 RP-04991 Perladukka
227 RP-10923 GPMGovtCollege
187 RP-04992 Koliyadukkam
228 RP-00306 Thalangara
188 RP-07020 Manadukkam
229 RP-02196 Nullippadi
189 RP-07048 Mangad
230 RP-03505 Mogralputhur
190 RP-07055 Thachangad
231 RP-04051 Nellikkatte
191 RP-07049 Paramba
232 RP-04052 Kasaragodfort
192 RP-07579 Chattamchal
233 RP-04053 KblSouthMarr
193 RP-07692 Nalleacre
234 RP-04054 Seethangoli
194 RP-07719 Thorothu
235 RP-04058 KsdCpcriEast
195 RP-07722 Manimoola
236 RP-04987 Padiyathadukka
196 RP-07742 MullasseryNew
237 RP-07030 ThairaTemple
197 RP-07746 Chembarika
238 RP-07044 KsgdNewBusStand
198 RP-07914 UdumaNorth
239 RP-07114 Chowky
199 RP-08358 BALANADUKAM
240 RP-07153 Bellur
200 RP-08845 Shankarampadi
241 RP-07716 KelKasaragod
201 RP-08849 Kollampana
242 RP-07773 Karmanthodi
202 RP-08898 Kanhiradukkam
243 RP-08034 Maniyoor
203 RP-01304 KUNJATHUR
244 RP-08035 Mallam
E-Tender for Outsourcing BTS sites in Kannur BA
61
Signature & Seal of bidder
SL No RP-ID Site name
SL No RP-ID Site name
245 RP-08557 EDANEER
286 RP-04984 Parakalai
246 RP-08846 Pallamkode
287 RP-07083 Pollakada
247 RP-05646 Kuttiyanam
288 RP-08848 Poochakkad
248 RP-08374 Aiyrote
289 RP-07499 Pullumala
249 RP-08897 Alakkodperiya
290 RP-03674 Pullur
250 RP-08671 Ambalathukara
291 RP-07091 Ranipuram
251 RP-00528 ATHINHAL
292 RP-01333 VELLARIKUNDU
252 RP-03672 Bengalam
293 RP-08369 Chamundikunnu
253 RP-07815 Chathamath
294 RP-03768 Avikkara
254 RP-03508 Chittari
295 RP-03777 Pakkom
255 RP-01284 CHITTARIKAL
296 RP-07980 Alanthatta
256 RP-08285 RP-08285-KaraChittarikal
297 RP-03101 Chandapura
257 RP-07694 Choyyomkod
298 RP-02243 CHANDERA
258 RP-05219 ChullyKNGD
299 RP-04048 Cheruvathurtown
259 RP-07072 Edathodu
300 RP-03785 CheruvaturKolam
260 RP-04743 Elarithattu
301 RP-08293 Edachakai
261 RP-07690 Ettithattu
302 RP-07043 Edayiiliyakad
262 RP-02205 HOSDURG
303 RP-07709 Eyyakkad
263 RP-08376 KallarKngd
304 RP-01719 EZHIMALA
264 RP-02244 KANHANGAD_NEW_EXG
305 RP-07697 Josegiriw
265 RP-08053 KanhangadBusStand
306 RP-03669 Kadankod
266 RP-08291 KanhangadNewBusStand
307 RP-03512 Kandankali
267 RP-07977 Karat
308 RP-04047 Kankol
268 RP-07075 Kolichal
309 RP-07703 Karammel
269 RP-07693 Kothottupara
310 RP-07069 Karayil
270 RP-04996 Kottapara Adukkam
311 RP-04993 Klayikode
271 RP-07595 Kottodi
312 RP-07005 Kodakkad
272 RP-07976 KunnuparaJunction
313 RP-07026 Koluvally
273 RP-07512 Madikai
314 RP-05771 KoromKnr
274 RP-07689 Madiyan
315 RP-08891 KoromNorth
275 RP-04985 Malakkal
316 RP-03814 Kothaimukku
276 RP-07696 Mandapam
317 RP-08706 Koyipra
277 RP-08357 MaukodeBSNL
318 RP-02504 KUNHIPPARA
278 RP-02206 MAVUNGAL_DLC
319 RP-07101 Kunnaru
279 RP-07018 Nallompuzha
320 RP-07292 KuttoorKnr
280 RP-07705 Nelliyadukkam
321 RP-08664 Menonkunnu
281 RP-05446 Kallapally
322 RP-08684 Nhekli
282 RP-08924 NileshwarHW
323 RP-04505 Olavara
283 RP-02229 NLS_GOVT_HOSPITAL
324 RP-08623 Olayambadi
284 RP-03510 Padanakkad
325 RP-07945 Palakkunnu
285 RP-08512 PanangadKNR
326 RP-07982 Pallippara
E-Tender for Outsourcing BTS sites in Kannur BA
62
Signature & Seal of bidder
SL No
RP-ID Site name
327 RP-08863 PayBusStand
328 RP-01305 PayyannurCXL
329 RP-01320 PEELIKODE
330 RP-08723 PeringomeTown
331 RP-03899 Perumba
332 RP-07650 Podavurnew
333 RP-07092 Ponnampara
334 RP-07707 Pothamkandam
335 RP-08928 Pranthanchal
336 RP-04989 Swamimukku
337 RP-07639 Thabore
338 RP-08894 Thattummal
339 RP-08294 ThayineriPyr
340 RP-06293 Thuruthy
341 RP-03511 Udinoor
342 RP-07717 Vadukkumbadu
E-Tender for Outsourcing BTS sites in Kannur BA
63
Signature & Seal of bidder
ANNEXURE 12 Bid Security/EMD DECLARATION (As per the BSNL CO Ltr No. BSNLCO-MMT/12(15)/1/2020-MMT dtd 05-12-20)
BID SECURITY/EMD UNDERTAKING & DECLARATION
I/ We ……………………………………. R/o ……………… ………… and authorized signatory of the firm
M/s……………………………….(Hereafter referred to as Bidder) have read, understood and agree with all the terms and
conditions included in the tender documents for participation in the tender of work/supply of …………………………………………….. Vide tender no. …………………………………. do hereby undertake and
declare that:
1. If I/ We fail to enter into the agreement & commence the work in time as per BSNL order
2. If any loss or damage caused to or would be caused to or suffered by the BSNL by reason of breach by the bidder(s) of
any of terms or conditions contained in the said tender document or by reason of the bidder (s) failure to perform the said
Agreement.
3. If anything is found false and/or incorrect and/or reveals any suppression of fact at any time,
4. If the bidder either registered with body specified by Ministry of Micro, Small & Medium Enterprise or Non MSE
bidder claiming any concessional benefits is awarded work by BSNL and subsequently fails to obey any of the
contractual obligations,
I hereby undertake that under any/all the above conditions, BSNL reserves the right to debar our tender offer/ cancel
the LOA/ Purchase/ work order if issued, and to suspend/Debar/Ban for a period of one year from the date of such
order/instance. BSNL can debar my/our firm from any further work/ contract by BSNL for one year from the date of issue of
such order.
In lieu of EMD/Bid security, this declaration is submitting.
Date: …………… Signature of Tenderer………………………………
Place: …………… Name of Tenderer ………………………………. Along with date & Seal
E-Tender for Outsourcing BTS sites in Kannur BA
65
Signature & Seal of bidder
ANNEXURE 14
A. CERTIFICATE REGARDING FIRM HAS NOT BEEN BLACK LISTED BY
BSNL/MTNL
I, ……………………………………………………….… S/o ……………………………………… r/o
……………………………………………… hereby certify that we or our firm
…………………………………………………………………………………………. has not been
BLACK LISTED for Telecom business by any Central/State Governments/PSUs in India. In case at any
stage, it is found that the information given by me is false/incorrect, BSNL shall have the absolute right
to take any action as deemed fit/without any prior intimation to me.
Date: …………… …… ………………………
Place: ……………
Name of Tenderer
Signature of Tenderer Along with date & Seal
B. CERTIFICATE REGARDING FIRM HAS NOT BEEN BLACK LISTED BY
GST Authorities
I, ……………………………………………………….… S/o ……………………………………… r/o
……………………………………………… hereby certify that we or our firm
…………………………………………………………………………………………. has not been
BLACK LISTED for Telecom business by GST Authorities. In case at any stage, it is found that the
information given by me is false/incorrect, BSNL shall have the absolute right to take any action as
deemed fit/without any prior intimation to me.
Date: …………… …… ………………………
Place: ……………
Name of Tenderer
Signature of Tenderer Along with date & Seal